Office of the City Clerk - Record #: O2013-9161

This record contains private information, which has been redacted from public viewing.

Record #:

O2013-9161

Type:

Ordinance

Status:

Passed

Intro date:

11/26/2013

Current Controlling Legislative Body:

Committee on Finance

Final action:

12/11/2013

Title:

Redevelopment agreement with Children's Place Association, LLC and Children's Place Community Living LLC for property at 3533-3545 W Chicago Ave

Sponsors:

Emanuel, Rahm

Topic:

AGREEMENTS - Redevelopment

Attachments:

1. O2013-9161.pdf

Date	Journal Page Number	Action By	Action	Result	Action Details	Meeting Details	Captions
1/22/2014		Office of the Mayor	Signed by Mayor		Action details	Meeting details	Not available
12/11/2013	69120	City Council	Passed	Pass	Action details	Meeting details	Not available
12/9/2013		Committee on Finance	Recommended to Pass	Pass	Action details	Meeting details	Not available
11/26/2013	66862	City Council	Referred		Action details	Meeting details	Not available

OFFICE OF THE MAYOR

CITY OF CHICAGO

RAHM EMANUEL

MAYOR

November 26, 2013

TO THE HONORABLE, THE CITY COUNCIL OF THE CITY OF CHICAGO

Ladies and Gentlemen:

At the request of the Commissioner of Housing and Economic Development, I transmit herewith an ordinance authorizing the execution of a redevelopment agreement for Children's Place Association.

Your favorable consideration of this ordinance will be appreciated.

Mayor

Very truly yours,

S.\SHARED\Finance\West Humboldt Place\Ordinance\ord v2.doc

ORDINANCE

WHEREAS, the City of Chicago (the "City") is a home rule unit of government under Section 6(a), Article Vll of the 1970 Constitution of the State of Illinois; and

WHEREAS, pursuant to an ordinance adopted by the City Council (the "City Council") of the City of Chicago (the "City") on February 27, 2002 and published at pages 79794 to 80002 of the Journal of the Proceedings of the City Council (the "Journal") of such date, a certain redevelopment plan and project (the "Plan") for the Chicago/Central Park redevelopment project area (the "Area") was approved pursuant to the Illinois Tax Increment Allocation Redevelopment Act, as amended (65 ILCS 5/11-74.4-1 et seg.) (the "Act"); and

WHEREAS, pursuant to an ordinance adopted by the City Council on February 27, 2002 and published at pages 80003 to 80014 of the Journal of such date, the Area was designated as a redevelopment project area pursuant to the Act; and

WHEREAS, pursuant to an ordinance (the "TIF Ordinance") adopted by the City Council on February 27, 2002 and published at pages 80015 to 80025 of the Journal of such date, tax increment allocation financing was adopted pursuant to the Act as a means of financing certain Area redevelopment project costs (as defined in the Act) incurred pursuant to the Plan; and

WHEREAS, pursuant to Section 5/11-74.4-8(b) of the Act and the TIF Ordinance, incremental taxes ("Incremental Taxes") are deposited from time to time in the "Chicago/Central Park Redevelopment Project Area Special Tax Allocation Fund" (the "TIF Fund") established pursuant to the TIF Ordinance; and

WHEREAS, The Children's Place Association, an Illinois not-for-profit corporation ("CPA") and Children's Place Community Living LLC, an Illinois limited liability company ("Owner" and together with CPA, the "Developer") have proposed to undertake redevelopment of the Property in accordance with the Redevelopment Plan and pursuant to the terms and conditions of a proposed redevelopment agreement to be executed by Developer and the City to be financed in part by a portion of Incremental Taxes, if any, deposited in the TIF Fund pursuant to Section 5/11-74.4-8(b) of the Act; and

WHEREAS, pursuant to Resolution 13-CDC-34 adopted by the Community Development Commission of the City (the "Commission") on September 10, 2013, the Commission has recommended that Developer be designated as the developer for the Project (as defined in such Resolution) and that DHED be authorized to negotiate, execute and deliver on behalf of the City a redevelopment agreement with the Developer for the Project; now, therefore,

BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO:

SECTION 1. The above recitals are expressly incorporated in and made a part of this ordinance as though fully set forth herein.

SECTION 2. Developer is hereby designated as the developer for the Project pursuant to Section 5/11-74.4-4 of the Act.

SECTION 3. The Commissioner of the City's Department of Housing and Economic Development ("DHED") or a designee of the Commissioner are each hereby authorized, with the

approval of the City's Corporation Counsel as to form and legality, to negotiate, execute and deliver a redevelopment agreement between the Developer and the City substantially in the form attached hereto as Exhibit A and made a part hereof (the "Redevelopment Agreement"), and such other supporting documents as may be necessary to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement.

SECTION 4. The City Council of the City hereby finds that the City is authorized to pay $1,000,000 ("City Funds") from Incremental Taxes deposited in the general account of the TIF Fund to Developer to finance a portion of the eligible costs included within the Project. The proceeds of the City Funds are hereby appropriated for the purposes set forth in this Section 4.

SECTION 5. Pursuant to the TIF Ordinance, the City has created the TIF Fund. The Chief Financial Officer (or his or her designee) of the City is hereby directed to maintain the TIF Fund as a segregated interest-bearing account, separate and apart from the City's Corporate Fund or any other fund of the City. Pursuant to the TIF Ordinance, all Incremental Taxes received by the City for the Area shall be deposited into the TIF Fund. The City shall use the funds in the TIF Fund to make payments pursuant to the terms of the Redevelopment Agreement.

SECTION 6. The Mayor, the Chief Financial Officer, the Comptroller, the City Clerk and the other officers of the City are authorized to execute and deliver on behalf of the City such other documents, agreements and certificates and to do such other things consistent with the terms of this ordinance as such officers and employees shall deem necessary or appropriate in order to effectuate the intent and purposes of this ordinance.

SECTION 7. To the extent that any ordinance, resolution, rule, order or provision of the Municipal Code of Chicago, or part thereof, is in conflict with the provisions of this ordinance, the provisions of this ordinance shall control. If any section, paragraph, clause or provision of this ordinance shall be held invalid, the invalidity of such section, paragraph, clause or provision shall not affect any of the other provisions of this ordinance.

SECTION 8. This ordinance shall be effective as of the date of its passage and approval.

EXHIBIT A

FORM OF REDEVELOPMENT AGREEMENT See attached.

THE CHILDREN'S PLACE ASSOCIATION

REDEVELOPMENT AGREEMENT

BY AND AMONG

THE CITY OF CHICAGO AND

THE CHILDREN'S PLACE ASSOCIATION AND

CHILDREN'S PLACE COMMUNITY LIVING LLC

This agreement was prepared by and after recording return to: Ann R. Kaplan-Perkins, Esq. City of Chicago Law Department 121 North LaSalle Street, Room 600 Chicago, IL 60602

4844-0160-8726.2

TABLE OF CONTENTS

PAGE

SECTION 1. RECITALS 3

SECTION 2. DEFINITIONS 3

SECTION 3. THE PROJECT ' 10

The Project 10
Scope Drawings and Plans and Specifications 10
Project Budget 10
Change Orders 11
DHED Approval 11
Other Approvals 12
Progress Reports and Survey Updates 12
Inspecting Agent or Architect 12
Barricades 12
Signs and Public Relations 12
Utility Connections 12
Permit Fees 12

SECTION 4. FINANCING 13

Total Project Cost and Sources of Funds 13
Developer Funds 13
Citv Funds 13
Reguisition Form 15
Treatment of Prior Expenditures and Subseguent Disbursements 16
Cost Overruns 17
Preconditions of Disbursement 18
Conditional Grant 19
Cost of Issuance 19

SECTION 5. CONDITIONS PRECEDENT 19

Project Budget 19
Scope Drawings and Plans and Specifications 19
Other Governmental Approvals 19
Financing 20
Acguisition and Title 20
Evidence of Clean Title 20
Surveys 21
Insurance 21
Opinion of the Developer's Counsel 21
Evidence of Prior Expenditures 21
Financial Statements 21
Documentation 21
Environmental 21
Corporate Documents; Economic Disclosure Statement 21
Litigation 22

SECTION 6. AGREEMENTS WITH CONTRACTORS 22

4844-0160-8726.2

Bid Requirement for General Contractor and Subcontractors 22
Construction Contract 23
Performance and Payment Bonds 23
Employment Opportunity 23
Other Provisions 23

SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION 23

Certificate of Completion of Construction or Rehabilitation 23
Effect of Issuance of Certificate; Continuing Obligations 24
Failure to Complete 24
Notice of Expiration of Term of Agreement 25

SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF THE DEVELOPER 25

General 25
Covenant to Redevelop 27
Redevelopment Plan 27
Use of Citv Funds 27
Other Bonds 27
Job Creation and Retention; Covenant to Remain in the City 28
Employment Opportunity!; Progress Reports] 28
Employment Profile 28
Prevailing Wage 28
Arms-Length Transactions 29
Conflict of Interest 29
Disclosure of Interest 29
Financial Statements 29
Insurance 29
Non-Governmental Charges 29
Developer's Liabilities 30
Compliance with Laws 30
Recording and Filing 30
Real Estate Provisions 31
Survival of Covenants 35
Annual Compliance Report 35

SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF CITY 35

General Covenants 35
Survival of Covenants 35

SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS 35

Employment Opportunity 35
Citv Resident Construction Worker Employment Reguirement 36

SECTION 11. ENVIRONMENTAL MATTERS 40

SECTION 12. INSURANCE 41

SECTION 13. INDEMNIFICATION 45

13.01 General Indemnity 45

SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT 46

4844-0160-8726 2

Books and Records 46
Inspection Rights 46

SECTION 15. DEFAULT AND REMEDIES 46

Events of Default 46
Remedies 48
Curative Period 48

SECTION 16. MORTGAGING OF THE PROJECT 48

SECTION 17. NOTICE 49

SECTION 18. MISCELLANEOUS 50

Amendment 50
Entire Agreement 51
Limitation of Liability 51
Further Assurances 51
Waiver 51
Remedies Cumulative 51
Disclaimer 51
Headings 51
Counterparts 51
Severability 51
Conflict 52
Governing Law 52
Form of Documents 52
Approval 52
Assignment 52
Binding Effect 52
Force Majeure 52
Exhibits 53
Business Economic Support Act 53
Venue and Consent to Jurisdiction 53
Costs and Expenses 53
Business Relationships 53

4844-0160-8726.2

LIST OF EXHIBITS

Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib Exhib

it A tB

it D

t J

*Redevelopment Area *Property

*TIF-Funded Improvements Redevelopment Plan Construction Contract Escrow Agreement *Permitted Liens *Project Budget Approved Prior Expenditures Opinion of Developer's Counsel *Prior Obligations Requisition Form

Form of Subordination Agreement

(An asterisk (*) indicates which exhibits are to be recorded.)

4844-0160-8726.2

[leave blank 3" x 5" space for recorder's office]

This agreement was prepared by and after recording return to: Ann R. Kaplan-Perkins, Esq. City of Chicago Law Department 121 North LaSalle Street, Room 600 Chicago, IL 60602

THE CHILDREN'S PLACE ASSOCIATION REDEVELOPMENT AGREEMENT

This The Children's Place Association Redevelopment Agreement (this "Agreement") is

made as of this day of , 20 , by and among the City of Chicago, an Illinois

municipal corporation (the "City"), through its Department of Housing and Economic Development ("DHED"), and The Children's Place Association, an Illinois not-for-profit corporation ("CPA"), and Children's Place Community Living LLC, an Illinois limited liability company ("Owner" and together with CPA, the "Developer").

RECITALS

Constitutional Authority: As a home rule unit of government under Section 6(a), Article Vll of the 1970 Constitution of the State of Illinois (the "State"), the City has the power to regulate for the protection of the public health, safety, morals and welfare of its inhabitants, and pursuant thereto, has the power to encourage private development in order to enhance the local tax base, create employment opportunities and to enter into contractual agreements with private parties in order to achieve these goals.
Statutory Authority: The City is authorized under the provisions of the Tax Increment Allocation Redevelopment Act. 65 ILCS 5/11-74.4-1 et seq as amended from time to time (the "Act"), to finance projects that eradicate blighted conditions and conservation area factors through the use of tax increment allocation financing for redevelopment projects.
Citv Council Authority: To induce redevelopment pursuant to the Act, the City Council of the City (the "City Council") adopted the following ordinances on February 27, 2002: (1) "An Ordinance of the City of Chicago, Illinois Approving a Redevelopment Plan for the Chicago/Central Park Redevelopment Project Area"; (2) "An Ordinance of the City of Chicago, Illinois Designating the Chicago/Central Park Redevelopment Project Area as a Redevelopment Project Area Pursuant to

4844-0160-8726.2

the Tax Increment Allocation Redevelopment Act"; and (3) "An Ordinance of the City of Chicago, Illinois Adopting Tax Increment Allocation Financing for the Chicago/Central Park Redevelopment Project Area" (the "TIF Adoption Ordinance") (items(1 )-(3) collectively referred to herein as the "TIF Ordinances"). The redevelopment project area referred to above (the "Redevelopment Area") is legally described in Exhibit A hereto.

The Project: The Owner has purchased (the "Acquisition") certain property located within the Redevelopment Area at 3533-45 West Chicago Avenue, Chicago, Illinois 60651 and legally described on Exhibit B hereto (the "Property"), and, within the time frames set forth in Section 3.01 hereof, the Developer shall commence and complete construction of "West Humboldt Place", a 3-story building with thirteen rental units for low-income families in which at least one member has a disability (the "Facility") thereon. The Facility and related improvements (including but not limited to those TIF-Funded Improvements as defined below and set forth on Exhibit C) are collectively referred to herein as the "Project." The completion of the Project would not reasonably be anticipated without the financing contemplated in this Agreement.
Redevelopment Plan: The Project will be carried out in accordance with this Agreement and the City's Chicago/Central Perk Redevelopment Project Area Tax Increment Finance Program Redevelopment Plan and Project (the "Redevelopment Plan") attached hereto as Exhibit D.
Citv Financing: The City agrees to use, in the amounts set forth in Section 4.03 hereof, Incremental Taxes (as defined below), to pay for or reimburse the Developer for the costs of TIF-Funded Improvements pursuant to the terms and conditions of this Agreement.

In addition, the City may, in its discretion, issue tax increment allocation bonds ("TIF Bonds") secured by Incremental Taxes pursuant to a TIF bond ordinance (the "TIF Bond Ordinance") at a later date as described in Section 4.03(d) hereof, the proceeds of which (the "TIF Bond Proceeds") may be used to pay for the costs of the TIF-Funded Improvements not previously paid for from Incremental Taxes, in order to reimburse the City for the costs of TIF-Funded Improvements.

Now, therefore, in consideration of the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:

SECTION 1. RECITALS

The foregoing recitals are hereby incorporated into this agreement by reference.

SECTION 2. DEFINITIONS

For purposes of this Agreement, in addition to the terms defined in the foregoing recitals, the following terms shall have the meanings set forth below:

"Act" shall have the meaning set forth in the Recitals hereof.

"Actual residents of the Citv" shall mean persons domiciled within the City.

"Acguisition" shall have the meaning set forth in the Recitals hereof.

4844-0160-8726.2

"Affiliate" shall mean any person or entity directly or indirectly controlling, controlled by or under common control with the Developer.

"Annual Compliance Report" shall mean a signed report from the Developer to the City (a) itemizing each of the Developer's obligations under this Agreement during the preceding calendar year, (b) certifying the Developer's compliance or noncompliance with such obligations, (c) attaching evidence (whether or not previously submitted to the City) of such compliance or noncompliance and (d) certifying that the Developer is not in default with respect to any provision of this Agreement, the agreements evidencing the Lender Financing, if any, or any related agreements; provided, that the obligations to be covered by the Annual Compliance Report shall include the following: (1) compliance with the Operating Covenant (Section 8.06); (2) compliance with the Jobs Covenant (Section 8.06); (3) delivery of Financial Statements and unaudited financial statements (Section 8.13); (4) delivery of updated insurance certificates, if applicable (Section 8.14); (5) delivery of evidence of payment of Non-Governmental Charges, if applicable (Section 8.15); and (6) compliance with all other executory provisions of this Agreement.

"Architect's Certificate" shall mean a certificate from an architect indicating that the Project is 25% complete, 50% complete or 75% complete, as applicable.

"Available Project Funds" shall have the meaning set forth for such term in Section 4.07

hereof.

"Bond(s)" shall have the meaning set forth for such term in Section 8.05 hereof.

"Bond Ordinance" shall mean the City ordinance authorizing the issuance of Bonds.

"Business Relationship" shall have the meaning set forth for such term in Section 2-156-080 of the Municipal Code of Chicago.

"Certificate" shall mean the Certificate of Completion of Construction described in Section 7.01 hereof.

"Change Order" shall mean any amendment or modification to the Scope Drawings, Plans and Specifications or the Project Budget as described in Section 3.03, Section 3.04 and Section 3.05. respectively.

"Chicago/Central Park TIF Fund" shall mean the special tax allocation fund created by the City in connection with the Redevelopment Area into which the Incremental Taxes will be deposited.

"Citv Contract" shall have the meaning set forth in Section 8.01(1) hereof.

"Citv Council" shall have the meaning set forth in the Recitals hereof.

"Citv Funds" shall mean the funds described in Section 4.03(b) hereof.

"Closing Date" shall mean the date of execution and delivery of this "Agreement by all parties hereto, which shall be deemed to be the date appearing in the first paragraph of this Agreement.

"Contract" shall have the meaning set forth in Section 10.03 hereof.

"Contractor" shall have the meaning set forth in Section 10.03 hereof.

4844-0160-8726.2

"Construction Contract" shall mean that certain contract, substantially in the form attached hereto as Exhibit E, to be entered into between the Developer and the General Contractor providing for construction of the Project.

"Corporation Counsel" shall mean the City's Office of Corporation Counsel.

"Employees)" shall have the meaning set forth in Section 10 hereof.

"Environmental Laws" shall mean any and all federal, state or local statutes, laws, regulations, ordinances, codes, rules, orders, licenses, judgments, decrees or requirements relating to public health and safety and the environment now or hereafter in force, as amended and hereafter amended, including but not limited to (i) the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. Section 9601 et seg); (ii) any so-called "Superfund" or "Superlien" law; (iii) the Hazardous Materials Transportation Act (49 U.S.C. Section 1802 et seq.); (iv) the Resource Conservation and Recovery Act (42 U.S.C. Section 6902 et seg.); (v) the Clean Air Act (42 U.S.C. Section 7401 et seg ); (vi) the Clean Water Act (33 U.S.C. Section 1251 et seg.); (vii) the Toxic Substances Control Act (15 U.S.C. Section 2601 et seg.); (viii) the Federal Insecticide, Fungicide and Rodenticide Act (7 U.S.C. Section 136 et seg.); (ix) the Illinois Environmental Protection Act (415 ILCS 5/1 et seg.); and (x) the Municipal Code of Chicago.

"Equity" shall mean funds of the Developer (other than funds derived from Lender Financing) irrevocably available for the Project, in the amount set forth in Section 4.01 hereof, which amount may be increased pursuant to Section 4.06 (Cost Overruns) or Section 4.03(b).

"Escrow" shall mean the construction escrow established pursuant to the Escrow Agreement.

"Escrow Agreement" shall mean the Escrow Agreement establishing a construction escrow, to be entered into as of the date hereof by the Title Company (or an affiliate of the Title Company), the Developer and the Developer's lender(s), substantially in the form of Exhibit F attached hereto.

"Event of Default" shall have the meaning set forth in Section 15 hereof.

"Facility" shall have the meaning set forth in the Recitals hereof.

"Financial Statements" shall mean complete audited financial statements of the Developer prepared by a certified public accountant in accordance with generally accepted accounting principles and practices consistently applied throughout the appropriate periods.

"General Contractor" shall mean the general contractor(s) hired by the Developer pursuant to Section 6.01.

"Hazardous Materials" shall mean any toxic substance, hazardous substance, hazardous material, hazardous chemical or hazardous, toxic or dangerous waste defined or qualifying as such in (or for the purposes of) any Environmental Law, or any pollutant or contaminant, and shall include, but not be limited to, petroleum (including crude oil), any radioactive material or by-product material, polychlorinated biphenyls and asbestos in any form or condition.

"Human Rights Ordinance" shall have the meaning set forth in Section 10 hereof.

4844-0160-8726.2

"In Balance" shall have the meaning set forth in Section 4.07 hereof.

"Incremental Taxes" shall mean such ad valorem taxes which, pursuant to the TIF Adoption Ordinance and Section 5/11 -74.4-8(b) of the Act, are allocated to and when collected are paid to the Treasurer of the City of Chicago for deposit by the Treasurer into the Chicago/Central Park TIF Fund established to pay Redevelopment Project Costs and obligations incurred in the payment thereof.

"Indemnitee" and "Indemnitees" shall have the meanings set forth in Section 13.01 hereof.

"Lender Financing" shall mean funds borrowed by the Developer from lenders and irrevocably available to pay for Costs of the Project, in the amount set forth in Section 4.01 hereof.

"MBE(s)" shall mean a business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a minority-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.

"MBE/WBE Program" shall have the meaning set forth in Section 10.03 hereof.

"Municipal Code" shall mean the Municipal Code of the City of Chicago.

"New Mortgage" shall have the meaning set forth in Article 16 hereof.

"Non-Governmental Charges" shall mean all non-governmental charges, liens, claims, or encumbrances relating to the Developer, the Property or the Project.

"Permitted Liens" shall mean those liens and encumbrances against the Property and/or the Project set forth on Exhibit G hereto.

"Permitted Mortgage" shall have the meaning set forth in Article 16 hereof.

"Plans and Specifications" shall mean initial construction documents containing a site plan and working drawings and specifications for the Project, as submitted to the City as the basis for obtaining building permits for the Project.

"Prior Expenditure(s)" shall have the meaning set forth in Section 4.05(a) hereof.

"Prior Obligations" shall mean the various City obligations listed on Exhibit K attached hereto that will be paid out of Incremental Taxes and which are prior liens on the Chicago/Central Park TIF Fund.

"Project" shall have the meaning set forth in the Recitals hereof.

"Project Budget" shall mean the budget attached hereto as Exhibit H, showing the total cost of the Project by line item, furnished by the Developer to DHED, in accordance with Section 3.03 hereof.

"Property" shall have the meaning set forth in the Recitals hereof. "Redevelopment Area" shall have the meaning set forth in the Recitals hereof. "Redevelopment Plan" shall have the meaning set forth in the Recitals hereof.

4844-0160-8726.2

"Redevelopment Project Costs" shall mean redevelopment project costs as defined in Section 5/11 -74.4-3(q) of the Act that are included in the budget set forth in the Redevelopment Plan or otherwise referenced in the Redevelopment Plan.

"Requisition Form" shall mean the document, in the form attached hereto as Exhibit L, to be delivered by the Developer to DHED pursuant to Section 4.04 of this Agreement.

"Scope Drawings" shall mean preliminary construction documents containing a site plan and preliminary drawings and specifications for the Project.

"Survey" shall mean a Class A plat of survey in the most recently revised form of ALTA/ACSM urban survey of the Property dated within 45 days prior to the Closing Date, acceptable in form and content to the City and the Title Company, prepared by a surveyor registered in the State of Illinois, certified to the City and the Title Company, and indicating whether the Property is in a flood hazard area as identified by the United States Federal Emergency Management Agency (and updates thereof to reflect improvements to the Property in connection with the construction of the Facility and related improvements as required by the City or lender(s) providing Lender Financing).

"Term" shall mean the period of time commencing on the Closing Date and ending on the date on which the Redevelopment Area is no longer in effect (through and including December 31, 2024).

"TIF Adoption Ordinance" shall have the meaning set forth in the Recitals hereof.

"TIF Bonds" shall have the meaning set forth in the Recitals hereof.

"TIF Bond Ordinance" shall have the meaning set forth in the Recitals hereof.

"TIF-Funded Improvements" shall mean those improvements of the Project which (i) qualify as Redevelopment Project Costs, (ii) are eligible costs under the Redevelopment Plan and (iii) the City has agreed to pay for out of the City Funds, subject to the terms of this Agreement. Exhibit C lists the TIF-Funded Improvements for the Project.

"TIF Ordinances" shall have the meaning set forth in the Recitals hereof.

"Title Company" shall mean Chicago Title Insurance Company.

"Title Policy" shall mean a title insurance policy in the most recently revised ALTA or equivalent form, showing the Developer as the insured, noting the recording of this Agreement as an encumbrance against the Property, and a subordination agreement in favor of the City with respect to previously recorded liens against the Property related to Lender Financing, if any, issued by the Title Company.

"WARN Act" shall mean the Worker Adjustment and Retraining Notification Act (29 U.S.C. Section 2101 et seq.).

"WBE(s)" shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by

4844-0160-8726.2

the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.

SECTION 3. THE PROJECT

The Project. With respect to the Facility, the Developer shall, pursuant to the Plans and Specifications and subject to the provisions of Section 18.17 hereof: (i) commence construction no later than June 30, 2014; and (ii) complete construction and conduct business operations therein no later than June 29, 2015.
Scope Drawings and Plans and Specifications. The Developer has delivered the Scope Drawings and Plans and Specifications to DHED and DHED has approved same. After such initial approval, subsequent proposed changes to the Scope Drawings or Plans and Specifications shall be submitted to DHED as a Change Order pursuant to Section 3.04 hereof. The Scope Drawings and Plans and Specifications shall at all times conform to the Redevelopment Plan and all applicable federal, state and local laws, ordinances and regulations. The Developer shall submit all necessary documents to the City's Building Department, Department of Transportation and such other City departments or governmental authorities as may be necessary to acquire building permits and other required approvals for the Project.
Project Budget. The Developer has furnished to DHED, and DHED has approved, a Project Budget showing total costs for the Project in an amount not less than Five Million One Hundred Twenty Five Thousand Three Hundred Twenty-Four Dollars ($5,125,324). The Developer hereby certifies to the City that (a) it has Lender Financing and Equity in an amount sufficient to pay for all Project costs; and (b) the Project Budget is true, correct and complete in all material respects. The Developer shall promptly deliver to DHED certified copies of any Change Orders with respect to the Project Budget for approval pursuant to Section 3.04 hereof.
Change Orders. All Change Orders (and documentation substantiating the need and identifying the source of funding therefor) relating to material changes to the Project must be submitted by the Developer to DHED for DHED's prior written approval. The Developer shall not authorize or permit the performance of any work relating to any Change Order or the furnishing of materials in connection therewith prior to the receipt by the Developer of DHED's written approval. The Construction Contract, and each contract between the General Contractor and any subcontractor, shall contain a provision to this effect. An approved Change Order shall not be deemed to imply any obligation on the part of the City to increase the amount of City Funds which the City has pledged pursuant to this Agreement or provide any other additional assistance to the Developer.
DHED Approval. Any approval granted by DHED of the Scope Drawings, Plans and Specifications and the Change Orders is for the purposes of this Agreement only and does not affect or constitute any approval required by any other City department or pursuant to any City ordinance, code, regulation or any other governmental approval, nor does any approval by DHED pursuant to this Agreement constitute approval of the quality, structural soundness or safety of the Property or the Project.
Other Approvals. Any DHED approval under this Agreement shall have no effect upon, nor shall it operate as a waiver of, the Developer's obligations to comply with the provisions of Section 5.03 (Other Governmental Approvals) hereof. The Developer shall not commence construction of the Project until the Developer has obtained all necessary permits and approvals

4844-0160-8726 2

(including but not limited to DHED's approval of the Scope Drawings and Plans and Specifications) and proof of the General Contractor's and each subcontractor's bonding as required hereunder.

Progress Reports and Survey Updates. The Developer shall provide DHED with written quarterly progress reports detailing the status of the Project, including a revised completion date, if necessary (with any change in completion date being considered a Change Order, requiring DHED's written approval pursuant to Section 3.04). The Developer shall provide three (3) copies of an updated Survey to DHED upon the request of DHED or any lender providing Lender Financing, reflecting improvements made to the Property.
Inspecting Agent or Architect. An independent agent or architect (other than the Developer's architect) approved by DHED shall be selected to act as the inspecting agent or architect, at the Developer's expense, for the Project. The inspecting agent or architect shall perform periodic inspections with respect to the Project, providing certifications with respect thereto to DHED, prior to requests for disbursement for costs related to the Project hereunder.

3.09 Barricades. Prior to commencing any construction requiring barricades, the Developer

shall install a construction barricade of a type and appearance satisfactory to the City and

constructed in compliance with all applicable federal, state or City laws, ordinances and regulations.

DHED retains the right to approve the maintenance, appearance, color scheme, painting, nature,

type, content and design of all barricades.

1. Signs and Public Relations. The Developer shall erect a sign of size and style approved by the City in a conspicuous location on the Property during the Project, indicating that financing has been provided by the City. The City reserves the right to include the name, photograph, artistic rendering of the Project and other pertinent information regarding the Developer, the Property and the Project in the City's promotional literature and communications.
Utility Connections. The Developer may connect all on-site water, sanitary, storm and sewer lines constructed on the Property to City utility lines existing on or near the perimeter of the Property, provided the Developer first complies with all City requirements governing such connections, including the payment of customary fees and costs related thereto.
Permit Fees. In connection with the Project, the Developer shall be obligated to pay only those building, permit, engineering, tap on and inspection fees that are assessed on a uniform basis throughout the City of Chicago and are of general applicability to other property within the City of Chicago.

SECTION 4. FINANCING

4.01 Total Project Cost and Sources of Funds. The cost of the Project is estimated to be $5,125,324, to be applied in the manner set forth in the Project Budget. Such costs shall be funded from the following sources:

Equity (subject to Sections 4.03(b) and 4.06) Lender Financing City Funds

$1,000,000

$5,125,324

ESTIMATED TOTAL

4844-0160-8726.2

Developer Funds. Equity and/or Lender Financing shall be used to pay all Project costs, including but not limited to Redevelopment Project costs and costs of TIF-Funded Improvements.
1. Citv Funds.

Uses of City Funds. City Funds may only be used to pay directly or reimburse the Developer for costs of TIF-Funded Improvements that constitute Redevelopment Project Costs. Exhibit C sets forth, by line item, the TIF-Funded Improvements for the Project, and the maximum amount of costs that may be paid by or reimbursed from City Funds for each line item therein (subject to Sections 4.03(b) and 4.05(d)), contingent upon receipt by the City of documentation satisfactory in form and substance to DHED evidencing such cost and its eligibility as a Redevelopment Project Cost.
Sources of Citv Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03 and Section 5 hereof, the City hereby agrees to provide City funds in a principal amount not to exceed One Million Dollars ($1,000,000) (the "City Funds") from Incremental Taxes to reimburse the Developer for the costs of the TIF-Funded Improvements in four payments on a pay-as-you-go basis in the amounts as follows: (i) the first payment of up to $250,000 will occur at 25% completion of the Project, as evidenced by an Architect's Certificate; (ii) the second payment of up to $250,000 will occur at 50% completion of the Project, as evidenced by an Architect's Certificate; (iii) the third payment of up to 250,000 will occur at 75% completion of the Project, as evidenced by an Architect's Certificate; and the final payment of up to $250,000 will occur upon issuance of the Certificate, provided, however, that the total amount of City Funds expended for TIF-Funded Improvements shall be an amount not to exceed One Million Dollars ($1,000,000) of the actual total Project costs; and provided further, that the $1,000,000 to be derived from Incremental Taxes shall be available to pay costs related to TIF-Funded Improvements and allocated by the City for that purpose only so long as the amount of the Incremental Taxes deposited into the Chicago/Central Park TIF Fund shall be sufficient to pay for such costs after payment of Prior Obligations.
Requisition Form. Every [3] months, the Developer shall provide DHED with a Requisition Form, along with the documentation described therein, until the Certificate is issued by DHED. The Developer shall meet with DHED at the request of DHED to discuss the Requisition Form(s) previously delivered.
Treatment of Prior Expenditures . Only those expenditures made by the Developer with respect to the Project prior to the Closing Date, evidenced by documentation satisfactory to DHED and approved by DHED as satisfying costs covered in the Project Budget, shall be considered previously contributed Equity or Lender Financing hereunder (the "Prior Expenditures"). DHED shall have the right, in its sole discretion, to disallow any such expenditure as a Prior Expenditure. Exhibit I hereto sets forth the prior expenditures approved by DHED as of the date hereof as Prior Expenditures. Prior Expenditures made for items other than TIF-Funded Improvements shall not be reimbursed to the Developer, but shall reduce the amount of Equity and/or Lender Financing required to be contributed by the Developer pursuant to Section 4.01 hereof.
Cost Overruns. If the aggregate cost of the TIF-Funded Improvements exceeds City Funds available pursuant to Section 4.03 hereof, or if the cost of completing the Project exceeds the Project Budget, the Developer shall be solely responsible for such excess cost, and shall hold the

4844-0160-8726.2

City harmless from any and all costs and expenses of completing the TIF-Funded Improvements in excess of City Funds and of completing the Project.

4.07 Preconditions of Disbursement. Prior to each disbursement of City Funds hereunder, and in addition to submission of the Architect's Certificate (as applicable), the Developer shall submit documentation regarding the applicable expenditures to DHED, which shall be satisfactory to DHED in its sole discretion. Delivery by the Developer to DHED of any request for disbursement of City Funds hereunder shall, in addition to the items therein expressly set forth, constitute a certification to the City, as of the date of such request for disbursement, that:

the total amount of the disbursement request represents the actual cost of the Acquisition or the actual amount payable to (or paid to) the General Contractor and/or subcontractors who have performed work on the Project, and/or their payees;
all amounts shown as previous payments on the current disbursement request have been paid to the parties entitled to such payment;

the Developer has approved all work and materials for the current disbursement request, and such work and materials conform to the Plans and Specifications;
the representations and warranties contained in this Redevelopment Agreement are true and correct and the Developer is in compliance with all covenants contained herein;
the Developer has received no notice and has no knowledge of any liens or claim of lien either filed or threatened against the Property except for the Permitted Liens;
no Event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default exists or has occurred; and
the Project is In Balance. The Project shall be deemed to be in balance ("In Balance") only if the total of the available Project funds equals or exceeds the aggregate of the amount necessary to pay all unpaid Project costs incurred or to be incurred in the completion of the Project. "Available Project Funds" as used herein shall mean: (i) the undisbursed City Funds; (ii) the undisbursed Lender Financing, if any; (iii) the undisbursed Equity and (iv) any other amounts deposited by the Developer pursuant to this Agreement. The Developer hereby agrees that, if the Project is not In Balance, the Developer shall, within 30 days after a written request by the City, deposit with the escrow agent or will make available (in a manner acceptable to the City), cash in an amount that will place the Project ln Balance, which deposit shall first be exhausted before any further disbursement of the City Funds shall be made.

The City shall have the right, in its discretion, to require the Developer to submit further documentation as the City may require in order to verify that the matters certified to above are true and correct, and any disbursement by the City shall be subject to the City's review and approval of such documentation and its satisfaction that such certifications are true and correct; provided, however, that nothing in this sentence shall be deemed to prevent the City from relying on such certifications by the Developer. In addition, the Developer shall have satisfied all other preconditions of disbursement of City Funds for each disbursement, including but not limited to requirements set forth in the Bond Ordinance, if any, TIF Bond Ordinance, if any, the Bonds, if any, the TIF Bonds, if any, the TIF Ordinances, this Agreement and/or the Escrow Agreement.

4844-0160-8726.2

SECTION 5. CONDITIONS PRECEDENT

The following conditions have been complied with to the City's satisfaction on or prior to the Closing Date:

Project Budget. The Developer has submitted to DHED, and DHED has approved, a Project Budget in accordance with the provisions of Section 3.03 hereof.
Scope Drawings and Plans and Specifications. The Developer has submitted to DHED, and DHED has approved, the Scope Drawings and Plans and Specifications accordance with the provisions of Section 3.02 hereof.
Other Governmental Approvals. The Developer has secured all other necessary approvals and permits required by any state, federal, or local statute, ordinance or regulation necessary for the construction of the Project and has submitted evidence thereof to DHED.
Financing. The Developer has furnished proof reasonably acceptable to the City that the Developer has Equity and Lender Financing in the amounts set forth in Section 4.01 hereof to complete the Project and satisfy its obligations under this Agreement. If a portion of such funds consists of Lender Financing, the Developer has furnished proof as of the Closing Date that the proceeds thereof are available to be drawn upon by the Developer as needed and are sufficient (along with other sources set forth in Section 4.01) to complete the Project. The Developer has delivered to DHED a copy of the construction escrow agreement entered into by the Developer regarding the Lender Financing. Any liens against the Property in existence at the Closing Date have been subordinated to certain encumbrances of the City (collectively, the "City Encumbrances") set forth herein pursuant to a Subordination Agreement, in a form acceptable to the City, executed on or prior to the Closing Date, which is to be recorded, at the expense of the Developer, with the Office of the Recorder of Deeds of Cook County.
Acguisition and Title. On the Closing Date, the Developer has furnished the City with a copy of the Title Policy for the Property, certified by the Title Company, showing the Developer as the named insured. The Title Policy is dated as of the Closing Date and contains only those title exceptions listed as Permitted Liens on Exhibit G hereto and evidences the recording of this Agreement pursuant to the provisions of Section 8.18 hereof. The Title Policy also contains such endorsements as shall be required by Corporation Counsel, including an owner's comprehensive endorsement and satisfactory endorsements regarding zoning (3.1 with parking), contiguity, location, access and survey (collectively, the "Required Endorsements"). The Developer has provided to DHED, on or prior to the Closing Date, documentation related to the purchase of the Property and certified copies of all easements and encumbrances of record with respect to the Property not addressed, to DHED's satisfaction, by the Title Policy and the Required Endorsements thereto.
Evidence of Clean Title. The Developer, at its own expense, has provided the City with searches (collectively, the "Lien Searches") under the Developer's name as follows:

Secretary of State Secretary of State

Cook County Recorder Cook County Recorder Cook County Recorder Cook County Recorder Cook County Recorder

UCC search Federal tax search UCC search Fixtures search Federal tax search State tax search

Memoranda of judgments search

4844-0160-8726.2

U.S. District Court Pending suits and judgments

Clerk of Circuit Court, Pending suits and judgments Cook County

showing no liens against the Developer, the Property or any fixtures now or hereafter affixed thereto, except for the Permitted Liens.

Surveys. The Developer has furnished the City with three (3) copies of the Survey.
Insurance. The Developer, at its own expense, has insured the Property in accordance with Section 12 hereof, and has delivered certificates required pursuant to Section 12 hereof evidencing the required coverages to DHED.
Opinion of the Developer's Counsel. On the Closing Date, the Developer has furnished the City with an opinion of counsel, substantially in the form attached hereto as Exhibit J, with such changes as required by or acceptable to Corporation Counsel. If the Developer has engaged special counsel in connection with the Project, and such special counsel is unwilling or unable to give some of the opinions set forth in Exhibit J hereto, such opinions were obtained by the Developer from its general corporate counsel.
Evidence of Prior Expenditures. The Developer has provided evidence satisfactory to DHED in its sole discretion of the Prior Expenditures in accordance with the provisions of Section 4.05(a) hereof. ¹
Financial Statements. The Developer has provided Financial Statements to DHED for its most recent fiscal year, and audited or unaudited interim financial statements.
Documentation. The Developer has provided documentation to DHED, satisfactory in form and substance to DHED, with respect to current employment matters.
Environmental. The Developer has provided DHED with copies of that certain phase I environmental audit completed with respect to the Property and any phase II environmental audit with respect to the Property required by the City. The Developer has provided the City with a letter from the environmental engineer(s) who completed such audit(s), authorizing the City to rely on such audits.
Corporate Documents; Economic Disclosure Statement. The Developer has provided a copy of its Articles of Organization containing the original certification of the Secretary of State of its state of its organization; certificates of good standing from the Secretary of State of its state of organization and all other states in which the Developer is qualified to do business; a secretary's certificate in such form and substance as the Corporation Counsel may require; bylaws; and such other documentation as the City has requested. The Developer has provided to the City an Economic Disclosure Statement, in the City's then current form, dated as of the Closing Date.

5.15 Litigation. The Developer has provided to Corporation Counsel and DHED, a

description of all pending or threatened litigation or administrative proceedings involving the

Developer, specifying, in each case, the amount of each claim, an estimate of probable liability, the

amount of any reserves taken in connection therewith and whether (and to what extent) such

potential liability is covered by insurance.

4844-0160-8726 2

SECTION 6. AGREEMENTS WITH CONTRACTORS

Bid Requirement for General Contractor and Subcontractors, (a) Except as set forth in Section 6.01(b) below, prior to entering into an agreement with a General Contractor or any subcontractor for construction of the Project, the Developer shall solicit, or shall cause the General Contractor to solicit, bids from qualified contractors eligible to do business with, and having an office located in, the City of Chicago, and shall submit all bids received to DHED for its inspection and written approval, (i) For the TIF-Funded Improvements, the Developer shall select the General Contractor (or shall cause the General Contractor to select the subcontractor) submitting the lowest responsible bid who can complete the Project in a timely manner. If the Developer selects a General Contractor (or the General Contractor selects any subcontractor) submitting other than the lowest responsible bid for the TIF-Funded Improvements, the difference between the lowest responsible bid and the bid selected may not be paid out of City Funds, (ii) For Project work other than the TIF-Funded Improvements, if the Developer selects a General Contractor (or the General Contractor selects any subcontractor) who has not submitted the lowest responsible bid, the difference between the lowest responsible bid and the higher bid selected shall be subtracted from the actual total Project costs for purposes of the calculation of the amount of City Funds to be contributed to the Project pursuant to Section 4.03(b) hereof. The Developer shall submit copies of the Construction Contract to DHED in accordance with Section 6.02 below. Photocopies of all subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DHED within five (5) business days of the execution thereof. The Developer shall ensure that the General Contractor shall not (and shall cause the General Contractor to ensure that the subcontractors shall not) begin work on the Project until the Plans and Specifications have been approved by DHED and all requisite permits have been obtained.

(b) If, prior to entering into an agreement with a General Contractor for construction of the Project, the Developer does not solicit bids pursuant to Section 6.01(a) hereof, then the fee of the

General Contractor proposed to be paid out of City Funds shall not exceed [ %] of the total

amount of the Construction Contract. Except as explicitly stated in this paragraph, all other provisions of Section 6.01(a) shall apply, including but not limited to the requirement that the General Contractor shall solicit competitive bids from all subcontractors.

Construction Contract. Prior to the execution thereof, the Developer shall deliver to DHED a copy of the proposed Construction Contract with the General Contractor selected to handle the Project in accordance with Section 6.01 above, for DHED's prior written approval, which shall be granted or denied within ten (10) business days after delivery thereof. Within ten (10) business days after execution of such contract by the Developer, the General Contractor and any other parties thereto, the Developer shall deliver to DHED and Corporation Counsel a certified copy of such contract together with any modifications, amendments or supplements thereto.
Performance and Payment Bonds. Prior to the commencement of any portion of the Project which includes work on the public way, the Developer shall require that the General Contractor be bonded for its payment by sureties having an AA rating or better using a bond acceptable in form to the City. The City shall be named as obligee or co-obligee on any such bonds.
Employment Opportunity. The Developer shall contractually obligate and cause the General Contractor and each subcontractor to agree to the provisions of Section 10 hereof.
Other Provisions. In addition to the requirements of this Section 6, the Construction Contract and each contract with any subcontractor shall contain provisions required pursuant to

4844-0160-8726.2

Section 3.04 (Change Orders), Section 8.09 (Prevailing Wage), Section 10.01(e) (Employment Opportunity), Section 10.02 (City Resident Employment Requirement), Section 10.03 (MBE/WBE Requirements, as applicable), Section 12 (Insurance) and Section 14.01 (Books and Records) hereof. Photocopies of all contracts or subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DHED within five (5) business days of the execution thereof.

SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION

Certificate of Completion of Construction or Rehabilitation. Upon completion of the construction of the Project in accordance with the terms of this Agreement, and upon the Developer's written request, DHED shall issue to the Developer a Certificate in recordable form certifying that the Developer has fulfilled its obligation to complete the Project in accordance with the terms of this Agreement. DHED shall respond to the Developer's written request for a Certificate within forty-five (45) days by issuing either a Certificate or a written statement detailing the ways in which the Project does not conform to this Agreement or has not been satisfactorily completed, and the measures which must be taken by the Developer in order to obtain the Certificate. The Developer may resubmit a written request for a Certificate upon completion of such measures.
Effect of Issuance of Certificate; Continuing Obligations. The Certificate relates only to the construction of the Project, and upon its issuance, the City will certify that the terms of the Agreement specifically related to the Developer's obligation to complete such activities have been satisfied. After the issuance of a Certificate, however, all executory terms and conditions of this Agreement and all representations and covenants contained herein will continue to remain in full force and effect throughout the Term of the Agreement as to the parties described in the following paragraph, and the issuance of the Certificate shall not be construed as a waiver by the City of any of its rights and remedies pursuant to such executory terms.

The City Encumbrances are the only covenants in this Agreement intended to be binding upon any transferee of the Property (including an assignee as described in the following sentence) throughout the Term of the Agreement notwithstanding the issuance of a Certificate; provided, that upon the issuance of a Certificate, the covenants set forth in Section 8.02 shall be deemed to have been fulfilled. The other executory terms of this Agreement that remain after the issuance of a Certificate shall be binding only upon the Developer or a permitted assignee of the Developer who, pursuant to Section 18.15 of this Agreement, has contracted to take an assignment of the Developer's rights under this Agreement and assume the Developer's liabilities hereunder.

Failure to Complete. If the Developer fails to complete the Project in accordance with the terms of this Agreement, then the City has, but shall not be limited to, any of the following rights and remedies, subject to any and all applicable cure periods:

the right to terminate this Agreement and cease all disbursement of City Funds not yet disbursed pursuant hereto;
the right (but not the obligation) to complete those TIF-Funded Improvements that are public improvements and to pay for the costs of TIF-Funded Improvements (including interest costs) out of City Funds or other City monies. In the event that the aggregate cost of completing the TIF-Funded Improvements exceeds the amount of City Funds available pursuant to Section 4.01, the Developer shall reimburse the City for all reasonable costs and expenses incurred by the City in completing such TIF-Funded Improvements in excess of the available City Funds; and

4844-0160-8726 2

7.04 Notice of Expiration of Term of Agreement. Upon the expiration of the Term of the Agreement, DHED shall provide the Developer, at the Developer's written request, with a written notice in recordable form stating that the Term of the Agreement has expired.

SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF THE DEVELOPER.

8.01 General. The Developer represents, warrants and covenants, as of the date of this Agreement and as of the date of each disbursement of City Funds hereunder, that:

CPA is an Illinois not-for-profit corporation and Owner is an Illinois limited liability company, each duly organized, validly existing, qualified to do business in Illinois, and licensed to do business in any other state where, due to the nature of its respective activities or properties, such qualification or license is required;
the Developer has the right, power and authority to enter into, execute, deliver and perform this Agreement;
the execution, delivery and performance by the Developer of this Agreement has been duly authorized by all necessary action, and does not and will not violate its Articles of Incorporation as amended or its operating agreement, as applicable, any applicable provision of law, or constitute a breach of, default under or require any consent under any agreement, instrument or document to which the Developer is now a party or by which the Developer is now or may become bound;
unless otherwise permitted or not prohibited pursuant to or under the terms of this Agreement, the Owner shall acquire and shall maintain good, indefeasible and merchantable fee simple title to the Property (and all improvements thereon) free and clear of all liens (except for the Permitted Liens, Lender Financing as disclosed in the Project Budget, public utility easements granted for the construction or operation of the Project and non-governmental charges that the Developer is contesting in good faith pursuant to Section 8.15 hereof)
the Developer is now and for the Term of the Agreement shall remain solvent and able to pay its debts as they mature;
there are no actions or proceedings by or before any court, governmental commission, board, bureau or any other administrative agency pending, threatened (to Developer's knowledge) or affecting the Developer which would impair its ability to perform under this Agreement;
the Developer has and shall maintain all government permits, certificates and consents (including, without limitation, appropriate environmental approvals) necessary to conduct its business and to construct, complete and operate the Project;
the Developer is not in default with respect to any indenture, loan agreement, mortgage, deed, note or any other agreement or instrument related to the borrowing of money to which the Developer is a party or by which the Developer is bound;

(i) the Financial Statements are, and when hereafter required to be submitted will be,

complete, correct in all material respects and accurately present the assets, liabilities, results of

operations and financial condition of the Developer, and there has been no material adverse change

4844-0160-8726.2

in the assets, liabilities, results of operations or financial condition of the Developer since the date of the Developer's most recent Financial Statements;

(j) prior to the issuance of a Certificate, the Developer shall not do any of the following without the prior written consent of DHED: (1) be a party to any merger, liquidation or consolidation; (2) sell, transfer, convey, lease or otherwise dispose of all or substantially all of its assets or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) except in the ordinary course of business; (3) enter into any transaction outside the ordinary course of the Developer's business; (4) assume, guarantee, endorse, or otherwise become liable in connection with the obligations of any other person or entity other than in connection with any Lender Financing; or (5) enter into any transaction that would cause a material and detrimental change to the Developer's financial condition;

(k) the Developer has not incurred, and, prior to the issuance of a Certificate, shall not, without the prior written consent of the Commissioner of DHED, allow the existence of any liens against the Property (or improvements thereon) other than the Permitted Liens and public utility easements granted for the construction or operation of the Project; or incur any indebtedness, secured or to be secured by the Property (or improvements thereon) or any fixtures now or hereafter attached thereto, except Lender Financing disclosed in the Project Budget; and

(I) has not made or caused to be made, directly or indirectly, any payment, gratuity or offer of employment in connection with the Agreement or any contract paid from the City treasury or pursuant to City ordinance, for services to any City agency ("City Contract") as an inducement for the City to enter into the Agreement or any City Contract with the Developer in violation of Chapter 2-156-120 of the Municipal Code of the City; and

(m) neither the Developer nor any affiliate of the Developer is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List. For purposes of this subparagraph (m) only, the term "affiliate," when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.

8.02 Covenant to Redevelop. Subject to any Change Orders permitted under the terms of this Agreement, upon DHED's approval of the Project Budget, the Scope Drawings and Plans and Specifications as provided in Sections 3.02 and 3.03 hereof, and the Developer's receipt of all required building permits and governmental approvals, the Developer shall redevelop the Property in accordance with this Agreement and all Exhibits attached hereto, the TIF Ordinances, the Scope Drawings, Plans and Specifications, Project Budget and all amendments thereto, and all federal, state and local laws, ordinances, rules, regulations, executive orders and codes applicable to the Project, the Property and/or the Developer. The covenants set forth in this Section shall run with the land and be binding upon any transferee, but shall be deemed satisfied upon issuance by the City of a Certificate with respect thereto.

4844-0160-8726.2

Redevelopment Plan. The Developer represents that the Project is and shall be in compliance with all of the terms of the Redevelopment Plan.
Use of Citv Funds. City Funds disbursed to the Developer shall be used by the Developer solely to pay for (or to reimburse the Developer for its payment for) the TIF-Funded Improvements as provided in this Agreement.
Other Bonds. The Developer shall, at the request of the City, agree to any reasonable amendments to this Agreement that are necessary or desirable in order for the City to issue (in its sole discretion) any bonds in connection with the Redevelopment Area, the proceeds of which may be used to reimburse the City for expenditures made in connection with, or provide a source of funds for the payment for, the TIF-Funded Improvements (the "Bonds"); provided, however, that any such amendments shall not change any of the economic terms of this Agreement or otherwise have a material adverse effect on the Developer or the Project. The Developer shall, at the Developer's expense, cooperate and provide reasonable assistance in connection with the marketing of any such Bonds, including but not limited to providing written descriptions of the Project, re-making the representations contained herein, providing information regarding its financial condition and assisting the City in preparing an offering statement with respect thereto.
Job Creation and Retention; Covenant to Remain in the City. The Developer shall use its best efforts to retain nine full-time equivalent, permanent jobs relating to supportive services, two part-time building property staff and one part-time summer position at the Project within six months of the completion thereof and through the Term. The Developer hereby covenants and agrees to maintain its operations within the City of Chicago at the site described above through the Term.
Employment Opportunity; Progress Reports. The Developer covenants and agrees to abide by, and contractually obligate and use reasonable efforts to cause the General Contractor and each subcontractor to abide by the terms set forth in Section 10 hereof. The Developer shall deliver to the City monthly written progress reports detailing compliance with the requirements of Sections 8.09,10.02 and 10.03 of this Agreement. If any such reports indicate a shortfall in compliance, the Developer shall also deliver a plan to DHED which shall outline, to DHED's satisfaction, the manner in which the Developer shall correct any shortfall.
Employment Profile. The Developer shall submit, and contractually obligate and cause the General Contractor or any subcontractor to submit, to DHED, from time to time, statements of its employment profile upon DHED's request.
Prevailing Wage. The Developer covenants and agrees to pay, and to contractually obligate and cause the General Contractor and each subcontractor to pay, the prevailing wage rate as ascertained by the Illinois Department of Labor (the "Department"), to all Project employees. All such contracts shall list the specified rates to be paid to all laborers, workers and mechanics for each craft or type of worker or mechanic employed pursuant to such contract. If the Department revises such prevailing wage rates, the revised rates shall apply to all such contracts. Upon the City's request, the Developer shall provide the City with copies of all such contracts entered into by the Developer or the General Contractor to evidence compliance with this Section 8.09.
Arms-Length Transactions. Unless DHED has given its prior written consent with respect thereto, no Affiliate of the Developer may receive any portion of City Funds, directly or indirectly, in payment for work done, services provided or materials supplied in connection with any TIF-Funded Improvement. The Developer shall provide information with respect to any entity to

4844-0160-8726.2

receive City Funds directly or indirectly (whether through payment to the Affiliate by the Developer and reimbursement to the Developer for such costs using City Funds, or otherwise), upon DHED's request, prior to any such disbursement.

Conflict of Interest. Pursuant to Section 5/11-74.4-4(n) of the Act, the Developer represents, warrants and covenants that, to the best of its knowledge, no member, official, or employee of the City, or of any commission or committee exercising authority over the Project, the Redevelopment Area or the Redevelopment Plan, or any consultant hired by the City or the Developer with respect thereto, owns or controls, has owned or controlled or will own or control any interest, and no such person shall represent any person, as agent or otherwise, who owns or controls, has owned or controlled, or will own or control any interest, direct or indirect, in the Developer's business, the Property or any other property in the Redevelopment Area.
Disclosure of Interest. The Developer's counsel has no direct or indirect financial ownership interest in the Developer, the Property or any other aspect of the Project.
Financial Statements. The Developer shall obtain and provide to DHED Financial Statements for the Developer's fiscal year ended 2011 and each year thereafter for the Term of the Agreement. In addition, the Developer shall submit unaudited financial statements as soon as reasonably practical following the close of each fiscal year and for such other periods as DHED may request.
Insurance. The Developer, at its own expense, shall comply with all provisions of Section 12 hereof.
Non-Governmental Charges, (a) Payment of Non-Governmental Charges. Except for the Permitted Liens, the Developer agrees to pay or cause to be paid when due any Non-Governmental Charge assessed or imposed upon the Project, the Property or any fixtures that are or may become attached thereto, which creates, may create, or appears to create a lien upon all or any portion of the Property or Project; provided however, that if such Non-Governmental Charge may be paid in installments, the Developer may pay the same together with any accrued interest thereon in installments as they become due and before any fine, penalty, interest, or cost may be added thereto for nonpayment. The Developer shall furnish to DHED, within thirty (30) days of DHED's request, official receipts from the appropriate entity, or other proof satisfactory to DHED, evidencing payment of the Non-Governmental Charge in question.

(b) Right to Contest. The Developer has the right, before any delinquency occurs:

(i) to contest or object in good faith to the amount or validity of any Non-Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted, in such manner as shall stay the collection of the contested Non-Governmental Charge, prevent the imposition of a lien or remove such lien, or prevent the sale or forfeiture of the Property (so long as no such contest or objection shall be deemed or construed to relieve, modify or extend the Developer's covenants to pay any such Non-Governmental Charge at the time and in the manner provided in this Section 8.15).

Developer's Liabilities. The Developer shall not enter into any transaction that would materially and adversely affect its ability to perform its obligations hereunder or to repay any material liabilities or perform any material obligations of the Developer to any other person or entity. The Developer shall immediately notify DHED of any and all events or actions which may materially

4844-0160-8726.2

affect the Developer's ability to carry on its business operations or perform its obligations under this Agreement or any other documents and agreements.

Compliance with Laws. To the best of the Developer's knowledge, after reasonable inquiry, the Property and the Project are and shall be in compliance with all applicable federal, state and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the Project and the Property. Upon the City's request, the Developer shall provide evidence satisfactory to the City of such compliance.
Recording and Filing. The Developer shall cause this Agreement, certain exhibits (as specified by Corporation Counsel), all amendments and supplements hereto to be recorded and filed against the Property on the date hereof in the conveyance and real property records of the county in which the Project is located. The Developer shall pay all fees and charges incurred in connection with any such recording. Upon recording, the Developer shall immediately transmit to the City an executed original of this Agreement showing the date and recording number of record.
Real Estate Provisions.

Governmental Charges.

Payment of Governmental Charges. The Developer agrees to pay or cause to be paid when due all Governmental Charges (as defined below) which are assessed or imposed upon the Developer, the Property or the Project, or become due and payable, and which create or may create a lien upon the Developer or all or any portion of the Property or the Project. "Governmental Charge" shall mean all federal, State, county, the City, or other governmental (or any instrumentality, division, agency, body, or department thereof) taxes, levies, assessments, charges, liens, claims or encumbrances (except for those assessed by foreign nations, states other than the State of Illinois, counties of the State other than Cook County, and municipalities other than the City) relating to the Developer, the Property or the Project including but not limited to real estate taxes.
Right to Contest. The Developer has the right before any delinquency occurs to contest or object in good faith to the amount or validity of any Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted in such manner as shall stay the collection of the contested Governmental Charge and prevent the imposition of a lien or the sale or forfeiture of the Property. No such contest or objection shall be deemed or construed in any way as relieving, modifying or extending the Developer's covenants to pay any such Governmental Charge at the time and in the manner provided in this Agreement unless the Developer has given prior written notice to DHED of the Developer's intent to contest or object to a Governmental Charge and, unless, at DHED's sole option,

(i) the Developer shall demonstrate to DHED's satisfaction that legal proceedings instituted by the Developer contesting or objecting to a Governmental Charge shall conclusively operate to prevent or remove a lien against, or the sale or forfeiture of, all or any part of the Property to satisfy such Governmental Charge prior to final determination of such proceedings.

Developer's Failure To Pay Or Discharge Lien. If the Developer fails to pay any Governmental Charge or to obtain discharge of the same, the Developer shall advise DHED thereof in writing, at which time DHED may, but shall not be obligated to, and without waiving or releasing

4844-0160-8726.2

any obligation or liability of the Developer under this Agreement, in DHED's sole discretion, make such payment, or any part thereof, or obtain such discharge and take any other action with respect thereto which DHED deems advisable. All sums so paid by DHED, if any, and any expenses, if any, including reasonable attorneys' fees, court costs, expenses and other charges relating thereto, shall be promptly disbursed to DHED by the Developer. Notwithstanding anything contained herein to the contrary, this paragraph shall not be construed to obligate the City to pay any such Governmental Charge. Additionally, if the Developer fails to pay any Governmental Charge, the City, in its sole discretion, may require the Developer to submit to the City audited Financial Statements at the Developer's own expense.

8.20 Survival of Covenants. All warranties, representations, covenants and agreements of

the Developer contained in this Section 8 and elsewhere in this Agreement shall be true, accurate

and complete at the time of the Developer's execution of this Agreement, and shall survive the

execution, delivery and acceptance hereof by the parties hereto and (except as provided in Section

7 hereof upon the issuance of a Certificate) shall be in effect throughout the Term of the Agreement.

8.21 Annual Compliance Report. Beginning with the issuance of the Certificate and

continuing throughout the Term of the Agreement, the Developer shall submit to DHED the Annual

Compliance Report within 30 days after the end of the calendar year to which the Annual

Compliance Report relates.

SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF CITY

General Covenants. The City represents that it has the authority as a home rule unit of local government to execute and deliver this Agreement and to perform its obligations hereunder.
Survival of Covenants. All warranties, representations, and covenants of the City contained in this Section 9 or elsewhere in this Agreement shall be true, accurate, and complete at the time of the City's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and be in effect throughout the Term of the Agreement.

SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS

10.01 Employment Opportunity. The Developer, on behalf of itself and its successors and assigns, hereby agrees, and shall contractually obligate its or their various contractors, subcontractors or any Affiliate of the Developer operating on the Property (collectively, with the Developer, the "Employers" and individually an "Employer") to agree, that for the Term of this Agreement with respect to Developer and during the period of any other party's provision of services in connection with the construction of the Project or occupation of the Property:

(a) No Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Chapter 2-160, Section 2-160-010 et seq., Municipal Code, except as otherwise provided by said ordinance and as amended from time to time (the "Human Rights Ordinance"). Each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status,

4844-0160-8726.2

marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including without limitation: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Employers, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.

To the greatest extent feasible, each Employer is required to present opportunities for training and employment of low- and moderate-income residents of the City and preferably of the Redevelopment Area; and to provide that contracts for work in connection with the construction of the Project be awarded to business concerns that are located in, or owned in substantial part by persons residing in, the City and preferably in the Redevelopment Area.
Each Employer shall comply with all federal, state and local equal employment and affirmative action statutes, rules and regulations, including but not limited to the City's Human Rights Ordinance and the Illinois Human Rights Act, 775 ILCS 5/1-101 et seq. (1993), and any subsequent amendments and regulations promulgated thereto.
Each Employer, in order to demonstrate compliance with the terms of this Section, shall cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of federal, state and municipal agencies.
Each Employer shall include the foregoing provisions of subparagraphs (a) through (d) in every contract entered into in connection with the Project, and shall require inclusion of these provisions in every subcontract entered into by any subcontractors, and every agreement with any Affiliate operating on the Property, so that each such provision shall be binding upon each contractor, subcontractor or Affiliate, as the case may be.
Failure to comply with the employment obligations described in this Section 10.01 shall be a basis for the City to pursue remedies under the provisions of Section 15.02 hereof.

10.02 Citv Resident Construction Worker Employment Requirement. The Developer agrees for itself and its successors and assigns, and shall contractually obligate its General Contractor and shall cause the General Contractor to contractually obligate its subcontractors, as applicable, to agree, that during the construction of the Project they shall comply with the minimum percentage of total worker hours performed by actual residents of the City as specified in Section 2-92-330 of the Municipal Code of Chicago (at least 50 percent of the total worker hours worked by persons on the site of the Project shall be performed by actual residents of the City); provided, however, that in addition to complying with this percentage, the Developer, its General Contractor and each subcontractor shall be required to make good faith efforts to utilize qualified residents of the City in both unskilled and skilled labor positions.

The Developer may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code of Chicago in accordance with standards and procedures developed by the Chief Procurement Officer of the City.

4844-0160-8726.2

"Actual residents of the City" shall mean persons domiciled within the City. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.

The Developer, the General Contractor and each subcontractor shall provide for the maintenance of adequate employee residency records to show that actual Chicago residents are employed on the Project. Each Employer shall maintain copies of personal documents supportive of every Chicago employee's actual record of residence.

Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) shall be submitted to the Commissioner of DHED in triplicate, which shall identify clearly the actual residence of every employee on each submitted certified payroll. The first time that an employee's name appears on a payroll, the date that the Employer hired the employee should be written in after the employee's name.

The Developer, the General Contractor and each subcontractor shall provide full access to their employment records to the Chief Procurement Officer, the Commissioner of DHED, the Superintendent of the Chicago Police Department, the Inspector General or any duly authorized representative of any of them. The Developer, the General Contractor and each subcontractor shall maintain all relevant personnel data and records for a period of at least three (3) years after final acceptance of the work constituting the Project.

At the direction of DHED, affidavits and other supporting documentation will be required of the Developer, the General Contractor and each subcontractor to verify or clarify an employee's actual address when doubt or lack of clarity has arisen.

Good faith efforts on the part of the Developer, the General Contractor and each subcontractor to provide utilization of actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) shall not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.

When work at the Project is completed, in the event that the City has determined that the Developer has failed to ensure the fulfillment of the requirement of this Section concerning the worker hours performed by actual Chicago residents or failed to report in the manner as indicated above, the City will thereby be damaged in the failure to provide the benefit of demonstrable employment to Chicagoans to the degree stipulated in this Section. Therefore, in such a case of non-compliance, it is agreed that 1/20 of 1 percent (0.0005) of the aggregate hard construction costs set forth in the Project budget (the product of .0005 x such aggregate hard construction costs) (as the same shall be evidenced by approved contract value for the actual contracts) shall be surrendered by the Developer to the City in payment for each percentage of shortfall toward the stipulated residency requirement. Failure to report the residency of employees entirely and correctly shall result in the surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the certification of payroll data may subject the Developer, the General Contractor and/or the subcontractors to prosecution. Any retainage to cover contract performance that may become due to the Developer pursuant to Section 2-92-250 of the Municipal Code of Chicago may be withheld by the City pending the Chief Procurement Officer's determination as to whether the Developer must surrender damages as provided in this paragraph.

Nothing herein provided shall be construed to be a limitation upon the "Notice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order

4844-0160-8726.2

11246 " and "Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement or related documents.

The Developer shall cause or require the provisions of this Section 10.02 to be included in all construction contracts and subcontracts related to the Project.

10.03. MBEAA/BE Commitment. The Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements set forth herein, shall contractually obligate the General Contractor to agree that during the Project:

Consistent with the findings which support, as applicable, (i) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seq., Municipal Code of Chicago (the "Procurement Program"), and (ii) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seq., Municipal Code of Chicago (the "Construction Program," and collectively with the Procurement Program, the "MBEAA/BE Program"), and in reliance upon the provisions of the MBEAA/BE Program to the extent contained in, and as qualified by, the provisions of this Section 10.03, during the course of the Project, at least the following percentages of the Project Budget shall be expended for contract participation by MBEs and by WBEs:

1. At least 24 percent by MBEs.
2. At least four percent by WBEs.
For purposes of this Section 10.03 only, the Developer (and any party to whom a contract is let by the Developer in connection with the Project) shall be deemed a "contractor" and this Agreement (and any contract let by the Developer in connection with the Project) shall be deemed a "contract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670, Municipal Code of Chicago, as applicable.
Consistent with Sections 2-92-440 and 2-92-720, Municipal Code of Chicago, the Developer's MBEAA/BE commitment may be achieved in part by the Developer's status as an MBE or WBE (but only to the extent of any actual work performed on the Project by the Developer) or by a joint venture with one or more MBEs or WBEs (but only to the extent of the lesser of (i) the MBE or WBE participation in such joint venture or (ii) the amount of any actual work performed on the Project by the MBE or WBE), by the Developer utilizing a MBE or a WBE as the General Contractor (but only to the extent of any actual work performed on the Project by the General Contractor), by subcontracting or causing the General Contractor to subcontract a portion of the Project to one or more MBEs or WBEs, or by the purchase of materials or services used in the Project from one or more MBEs or WBEs, or by any combination of the foregoing. Those entities which constitute both a MBE and a WBE shall not be credited more than once with regard to the Developer's MBEAA/BE commitment as described in this Section 10.03. In accordance with Section 2-92-730, Municipal Code of Chicago, the Developer shall not substitute any MBE or WBE General Contractor or subcontractor without the prior written approval of DHED.
The Developer shall deliver quarterly reports to the City's monitoring staff during the Project describing its efforts to achieve compliance with this MBEAA/BE commitment. Such reports shall include, inter alia, the name and business address of each MBE and WBE solicited by the Developer or the General Contractor to work on the Project, and the responses received from such solicitation, the name and business address of each MBE or WBE actually involved in the Project, a description of the work performed or products or services supplied, the date and amount of such

4844-0160-8726 2

work, product or service, and such other information as may assist the City's monitoring staff in determining the Developer's compliance with this MBEAA/BE commitment. The Developer shall maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with the Project for at least five years after completion of the Project, and the City's monitoring staff shall have access to all such records maintained by the Developer, on five Business Days' notice, to allow the City to review the Developer's compliance with its commitment to MBEAA/BE participation and the status of any MBE or WBE performing any portion of the Project.

Upon the disqualification of any MBE or WBE General Contractor or subcontractor, if such status was misrepresented by the disqualified party, the Developer shall be obligated to discharge or cause to be discharged the disqualified General Contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (e), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730, Municipal Code of Chicago, as applicable.
Any reduction or waiver of the Developer's MBEAA/BE commitment as described in this Section 10.03 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730, Municipal Code of Chicago, as applicable.
Prior to the commencement of the Project, the Developer shall be required to meet with the City's monitoring staff with regard to the Developer's compliance with its obligations under this Section 10.03. The General Contractor and all major subcontractors shall be required to attend this pre-construction meeting. During said meeting, the Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 10.03, the sufficiency of which shall be approved by the City's monitoring staff. During the Project, the Developer shall submit the documentation required by this Section 10.03 to the City's monitoring staff, including the following: (i) subcontractor's activity report; (ii) contractor's certification concerning labor standards and prevailing wage requirements; (iii) contractor letter of understanding; (iv) monthly utilization report; (v) authorization for payroll agent; (vi) certified payroll; (vii) evidence that MBEAA/BE contractor associations have been informed of the Project via written notice and hearings; and (viii) evidence of compliance with job creation/job retention requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that the Developer is not complying with its obligations under this Section 10.03, shall, upon the delivery of written notice to the Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to the Developer to halt the Project, (2) withhold any further payment of any City Funds to the Developer or the General Contractor, or (3) seek any other remedies against the Developer available at law or in equity.

SECTION 11. ENVIRONMENTAL MATTERS

The Developer hereby represents and warrants to the City that the Developer has conducted environmental studies sufficient to conclude that the Project may be constructed, completed and operated in accordance with all Environmental Laws and this Agreement and all Exhibits attached hereto, the Scope Drawings, Plans and Specifications and all amendments thereto, the Bond Ordinance, if any, and the Redevelopment Plan.

Without limiting any other provisions hereof, the Developer agrees to indemnify, defend and hold the City harmless from and against any and all losses, liabilities, damages, injuries, costs, expenses or claims of any kind whatsoever including, without limitation, any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any Environmental Laws

4844-0160-8726 2

incurred, suffered by or asserted against the City as a direct or indirect result of any of the following, regardless of whether or not caused by, or within the control of the Developer: (i) the presence of any Hazardous Material on or under, or the escape, seepage, leakage, spillage, emission, discharge or release of any Hazardous Material from (A) all or any portion of the Property or (B) any other real property in which the Developer, or any person directly or indirectly controlling, controlled by or under common control with the Developer, holds any estate or interest whatsoever (including, without limitation, any property owned by a land trust in which the beneficial interest is owned, in whole or in part, by the Developer), or (ii) any liens against the Property permitted or imposed by any Environmental Laws, or any actual or asserted liability or obligation of the City or the Developer or any of its Affiliates under any Environmental Laws relating to the Property.

SECTION 12. INSURANCE

The Developer must provide and maintain, at Developer's own expense, or cause to be provided and maintained during the term of this Agreement, the insurance coverage and requirements specified below, insuring all operations related to the Agreement.

Prior to execution and delivery of this Agreement.

Workers Compensation and Employers Liability

Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $100,000 each accident, illness or disease.

Commercial General Liability (Primary and Umbrella)

Commercial General Liability Insurance or eguivalent with limits of not less than $1,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.

All Risk Property

All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.

Construction. Prior to the construction of any portion of the Project, Developer will cause its architects, contractors, subcontractors, project managers and other parties constructing the Project to procure and maintain the following kinds and amounts of insurance:

(i) Workers Compensation and Employers Liability

4844-0160-8726.2

Commercial General Liability (Primary and Umbrella)

Commercial General Liability Insurance or equivalent with limits of not less than $2.000.000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations (fora minimum of two (2) years following project completion), explosion, collapse, underground, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.

Automobile Liability (Primary and Umbrella)

When any motor vehicles (owned, non-owned and hired) are used in connection with work to be performed, the Automobile Liability Insurance with limits of not less than $2,000,000 per occurrence for bodily injury and property damage. The City of Chicago is to be named as an additional insured on a primary, non-contributory basis.

Railroad Protective Liability

When any work is to be done adjacent to or on railroad or transit property, Developer must provide cause to be provided with respect to the operations that Contractors perform, Railroad Protective Liability Insurance in the name of railroad or transit entity. The policy must have limits of not less than $2,000,000 per occurrence and $6,000,000 in the aggregate for losses arising out of injuries to or death of all persons, and for damage to or destruction of property, including the loss of use thereof.

All Risk /Builders Risk

When Developer undertakes any construction, including improvements, betterments, and/or repairs, the Developer must provide or cause to be provided All Risk Builders Risk Insurance at replacement cost for materials, supplies, equipment, machinery and fixtures that are or will be part of the project. The City of Chicago is to be named as an additional insured and loss payee/mortgagee if applicable.

Professional Liability

When any architects, engineers, construction managers or other professional consultants perform work in connection with this Agreement, Professional Liability Insurance covering acts, errors, or omissions must be maintained with limits of not less than $ 1,000,000. Coverage must include contractual liability. When policies are renewed or replaced, the policy retroactive date must coincide with, or precede, start of work on the Contract. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years.

Valuable Papers

When any plans, designs, drawings, specifications and documents are produced or used under this Agreement, Valuable Papers Insurance must be maintained in an amount to insure against any loss whatsoever, and must have limits sufficient to pay for the re-creation and reconstruction of such records.

4844-0160-8726.2

(viii) Contractors Pollution Liability

When any remediation work is performed which may cause a pollution exposure, the Developer must cause remediation contractor to provide Contractor Pollution Liability covering bodily injury, property damage and other losses caused by pollution conditions that arise from the contract scope of work with limits of not less than $1,000,000 per occurrence. Coverage must include completed operations, contractual liability, defense, excavation, environmental cleanup, remediation and disposal. When policies are renewed or replaced, the policy retroactive date must coincide with or precede, start of work on the Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years. The City of Chicago is to be named as an additional insured.

Post Construction:

(i) All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.

Other Requirements:

The Developer must furnish the City of Chicago, Department of Housing and Economic Development, City Hall, Room 1000,121 North LaSalle Street 60602, original Certificates of Insurance, or such similar evidence, to be in force on the date of this Agreement, and Renewal Certificates of Insurance, or such similar evidence, if the coverages have an expiration or renewal date occurring during the term of this Agreement. The Developer must submit evidence of insurance on the City of Chicago Insurance Certificate Form (copy attached) or equivalent prior to closing. The receipt of any certificate does not constitute agreement by the City that the insurance requirements in the Agreement have been fully met or that the insurance policies indicated on the certificate are in compliance with all Agreement requirements. The failure of the City to obtain certificates or other insurance evidence from Developer is not a waiver by the City of any requirements for the Developer to obtain and maintain the specified coverages. The Developer shall advise all insurers of the Agreement provisions regarding insurance. Non-conforming insurance does not relieve Developer of the obligation to provide insurance as specified herein. Nonfulfillment of the insurance conditions may constitute a violation of the Agreement, and the City retains the right to stop work and/or terminate agreement until proper evidence of insurance is provided.

The insurance must provide for 60 days prior written notice to be given to the City in the event coverage is substantially changed, canceled, or non-renewed.

Any deductibles or self insured retentions on referenced insurance coverages must be borne by Developer and Contractors.

The Developer hereby waives and agrees to require their insurers to waive their rights of subrogation against the City of Chicago, its employees, elected officials, agents, or representatives.

The coverages and limits furnished by Developer in no way limit the Developer's liabilities and responsibilities specified within the Agreement or by law.

4844-0160-8726.2

Any insurance or self insurance programs maintained by the City of Chicago do not contribute with insurance provided by the Developer under the Agreement.

The required insurance to be carried is not limited by any limitations expressed in the indemnification language in this Agreement or any limitation placed on the indemnity in this Agreement given as a matter of law.

If Developer is a joint venture or limited liability company, the insurance policies must name the joint venture or limited liability company as a named insured.

The Developer must require Contractor and subcontractors to provide the insurance required herein, or Developer may provide the coverages for Contractor and subcontractors. All Contractors and subcontractors are subject to the same insurance requirements of Developer unless otherwise specified in this Agreement.

If Developer, any Contractor or subcontractor desires additional coverages, the party desiring the additional coverages is responsible for the acquisition and cost.

The City of Chicago Risk Management Department maintains the right to modify, delete, alter or change these requirements.

SECTION 13. INDEMNIFICATION

13.01 General Indemnity. Developer agrees to indemnify, pay, defend and hold the City, and its elected and appointed officials, employees, agents and affiliates (individually an "Indemnitee," and collectively the "Indemnitees") harmless from and against, any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, claims, costs, expenses and disbursements of any kind or nature whatsoever (and including without limitation, the reasonable fees and disbursements of counsel for such Indemnitees in connection with any investigative, administrative or judicial proceeding commenced or threatened, whether or not such Indemnitees shall be designated a party thereto), that may be imposed on, suffered, incurred by or asserted against the Indemnitees in any manner relating or arising out of:

the Developer's failure to comply with any of the terms, covenants and conditions contained within this Agreement; or
the Developer's or any contractor's failure to pay General Contractors, subcontractors or materialmen in connection with the TIF-Funded Improvements or any other Project improvement; or
the existence of any material misrepresentation or omission in this Agreement, any offering memorandum or information statement or the Redevelopment Plan or any other document related to this Agreement that is the result of information supplied or omitted by the Developer or any Affiliate Developer or any agents, employees, contractors or persons acting under the control or at the request of the Developer or any Affiliate of Developer; or
the Developer's failure to cure any misrepresentation in this Agreement or any other agreement relating hereto;

provided, however, that Developer shall have no obligation to an Indemnitee arising from the wanton or willful misconduct of that Indemnitee. To the extent that the preceding sentence may be

4844-0160-8726.2

unenforceable because it is violative of any law or public policy, Developer shall contribute the maximum portion that it is permitted to pay and satisfy under the applicable law, to the payment and satisfaction of all indemnified liabilities incurred by the Indemnitees or any of them. The provisions of the undertakings and indemnification set out in this Section 13.01 shall survive the termination of this Agreement.

SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT

14.01 Books and Records. The Developer shall keep and maintain separate, complete,

accurate and detailed books and records necessary to reflect and fully disclose the total actual cost

of the Project and the disposition of all funds from whatever source allocated thereto, and to monitor

the Project. All such books, records and other documents, including but not limited to the

Developer's loan statements, if any, General Contractors' and contractors' sworn statements,

general contracts, subcontracts, purchase orders, waivers of lien, paid receipts and invoices, shall

be available at the Developer's offices for inspection, copying, audit and examination by an

authorized representative of the City, at the Developer's expense. The Developer shall incorporate

this right to inspect, copy, audit and examine all books and records into all contracts entered into by

the Developer with respect to the Project.

14.02 Inspection Rights. Upon three (3) business days' notice, any authorized

representative of the City has access to all portions of the Project and the Property during normal

business hours for the Term of the Agreement.

SECTION 15. DEFAULT AND REMEDIES

15.01 Events of Default. The occurrence of any one or more of the following events, subject to the provisions of Section 15.03, shall constitute an "Event of Default" by the Developer hereunder:

the failure of the Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of the Developer under this Agreement or any related agreement;
the failure of the Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of the Developer under any other agreement with any person or entity if such failure may have a material adverse effect on the Developer's business, property, assets, operations or condition, financial or otherwise, all subject to applicable cure periods contained in any such agreements;

the making or furnishing by the Developer to the City of any representation, warranty, certificate, schedule, report or other communication within or in connection with this Agreement or any related agreement which is untrue or misleading in any material respect;
except as otherwise permitted hereunder, the creation (whether voluntary or involuntary) of, or any attempt to create, any lien or other encumbrance upon the Property, including any fixtures now or hereafter attached thereto, other than the Permitted Liens, or the making or any attempt to make any levy, seizure or attachment thereof;
the commencement of any proceedings in bankruptcy by or against the Developer or for the liquidation or reorganization of the Developer, or alleging that the Developer is insolvent or unable to pay its debts as they mature, or for the readjustment or arrangement of the Developer's debts, whether under the United States Bankruptcy Code or under any other state or federal law,

4844-0160-8726.2

now or hereafter existing for the relief of debtors, or the commencement of any analogous statutory or non-statutory proceedings involving the Developer; provided, however, that if such commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such proceedings are not dismissed within sixty (60) days after the commencement of such proceedings;

the appointment of a receiver or trustee for the Developer, for any substantial part of the Developer's assets or the institution of any proceedings for the dissolution, or the full or partial liquidation, or the merger or consolidation, of the Developer; provided, however, that if such appointment or commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such appointment is not revoked or such proceedings are not dismissed within sixty (60) days after the commencement thereof;
the entry of any judgment or order against the Developer which remains unsatisfied or undischarged and in effect for sixty (60) days after such entry without a stay of enforcement or execution;
the occurrence of an event of default under the Lender Financing, which default is not cured within any applicable cure period;

(i) the dissolution of the Developer or the death of any natural person who owns a material

interest in the Developer;

(j) the institution in any court of a criminal proceeding (other than a misdemeanor) against the Developer or any natural person who owns a material interest in the Developer, which is not dismissed within thirty (30) days, or the indictment of the Developer or any natural person who owns a material interest in the Developer, for any crime (other than a misdemeanor); or

(k) prior to the payment of all City Funds hereunder, the sale or transfer of a majority of the ownership interests of the Developer without the prior written consent of the City.

For purposes of Sections 15.01(i) and 15.01 (p hereof, a person with a material interest in the Developer shall be one owning in excess often (10%) of the Developer's membership interests.

Remedies. Upon the occurrence of an Event of Default, the City may terminate this Agreement and any other agreements to which the City and the Developer are or shall be parties, suspend disbursement of City Funds, place a lien on the Project in the amount of City Funds paid, and/or seek reimbursement of any City Funds paid. The City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to damages, injunctive relief or the specific performance of the agreements contained herein.
Curative Period. In the event the Developer shall fail to perform a monetary covenant which the Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless the Developer has failed to perform such monetary covenant within ten (10) days of its receipt of a written notice from the City specifying that it has failed to perform such monetary covenant. In the event the Developer shall fail to perform a non-monetary covenant which the Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless the

4844-0160-8726.2

Developer has failed to cure such default within thirty (30) days of its receipt of a written notice from the City specifying the nature of the default; provided, however, with respect to those non-monetary defaults which are not capable of being cured within such thirty (30) day period, the Developer shall not be deemed to have committed an Event of Default under this Agreement if it has commenced to cure the alleged default within such thirty (30) day period and thereafter diligently and continuously prosecutes the cure of such default until the same has been cured.

SECTION 16. MORTGAGING OF THE PROJECT

All mortgages or deeds of trust in place as of the date hereof with respect to the Property or any portion thereof are listed on Exhibit G hereto (including but not limited to mortgages made prior to or on the date hereof in connection with Lender Financing) and are referred to herein as the "Existing Mortgages." Any mortgage or deed of trust that the Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof is referred to herein as a "New Mortgage." Any New Mortgage that the Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof with the prior written consent of the City is referred to herein as a "Permitted Mortgage." It is hereby agreed by and between the City and the Developer as follows:

(a) In the event that a mortgagee or any other party shall succeed to the Developer's

interest in the Property or any portion thereof pursuant to the exercise of remedies under a New

Mortgage (other than a Permitted Mortgage), whether by foreclosure or deed in lieu of foreclosure,

and in conjunction therewith accepts an assignment of the Developer's interest hereunder in

accordance with Section 18.15 hereof, the City may, but shall not be obligated to, attorn to and

recognize such party as the successor in interest to the Developer for all purposes under this

Agreement and, unless so recognized by the City as the successor in interest, such party shall be

entitled to no rights or benefits under this Agreement, but such party shall be bound by the City

Encumbrances.

(b) In the event that any mortgagee shall succeed to the Developer's interest in the Property

or any portion thereof pursuant to the exercise of remedies under an Existing Mortgage or a

Permitted Mortgage, whether by foreclosure or deed in lieu of foreclosure, and in conjunction

therewith accepts an assignment of the Developer's interest hereunder in accordance with Section

18.15 hereof, the City hereby agrees to attorn to and recognize such party as the successor in

interest to the Developer for all purposes under this Agreement so long as such party accepts all of

the obligations and liabilities of "the Developer" hereunder; provided, however, that, notwithstanding

any other provision of this Agreement to the contrary, it is understood and agreed that if such party

accepts an assignment of the Developer's interest under this Agreement, such party has no liability

under this Agreement for any Event of Default of the Developer which accrued prior to the time such

party succeeded to the interest of the Developer under this Agreement, in which case the Developer

shall be solely responsible. However, if such mortgagee under a Permitted Mortgage or an Existing

Mortgage does not expressly accept an assignment of the Developer's interest hereunder, such

party shall be entitled to no rights and benefits under this Agreement, and such party shall be bound

only by those provisions of this Agreement, if any, which are covenants expressly running with the

land.

7 hereof, no New Mortgage shall be executed with respect to the Property or any portion thereof

without the prior written consent of the Commissioner of DHED.

4844-0160-8726.2

SECTION 17. NOTICE

Unless otherwise specified, any notice, demand or request required hereunder shall be given in writing at the addresses set forth below, by any of the following means: (a) personal service; (b) telecopy or facsimile; (c) overnight courier, or (d) registered or certified mail, return receipt requested.

If to the City:

City of Chicago

Department of Housing and Economic Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner

With Copies To:

City of Chicago

Department of Law

121 North LaSalle Street, Room 600

Chicago, Illinois 60602

Attention: Finance and Economic Development Division

If to the Developer:

The Children's Place Association 1436 West Randolph, 5^th Floor Chicago, Illinois 60607 Attention:

Children's Place Community Living LLC 1436 West Randolph, 5^th Floor Chicago, Illinois 60607 Attention:

With Copies To:

Ungaretti & Harris LLP 70 West Madison, Suite 3500 Chicago, Illinois 60602 Attention: Frank J. Callero, Esq.

Such addresses may be changed by notice to the other parties given in the same manner provided above. Any notice, demand, or request sent pursuant to either clause (a) or (b) hereof shall be deemed received upon such personal service or upon dispatch. Any notice, demand or request sent pursuant to clause (c) shall be deemed received on the day immediately following deposit with the overnight courier and any notices, demands or requests sent pursuant to subsection (d) shall be deemed received two (2) business days following deposit in the mail.

4844-0160-8726.2

SECTION 18. MISCELLANEOUS

Amendment. This Agreement and the Exhibits attached hereto may not be amended or modified without the prior written consent of the parties hereto; provided, however, that the City, in its sole discretion, may amend, modify or supplement Exhibit D hereto without the consent of any party hereto. It is agreed that no material amendment or change to this Agreement shall be made or be effective unless ratified or authorized by an ordinance duly adopted by the City Council. The term "material" for the purpose of this Section 18.01 shall be defined as any deviation from the terms of the Agreement which operates to cancel or otherwise reduce any developmental, construction or job-creating obligations of Developer (including those set forth in Sections 10.02 and 10.03 hereof) by more than five percent (5%) or materially changes the Project site or character of the Project or any activities undertaken by Developer affecting the Project site, the Project, or both, or increases any time agreed for performance by the Developer by more than ninety (90) days.
Entire Agreement. This Agreement (including each Exhibit attached hereto, which is hereby incorporated herein by reference) constitutes the entire Agreement between the parties hereto and it supersedes all prior agreements, negotiations and discussions between the parties relative to the subject matter hereof.
Limitation of Liability. No member, official or employee of the City shall be personally liable to the Developer or any successor in interest in the event of any default or breach by the City or for any amount which may become due to the Developer from the City or any successor in interest or on any obligation under the terms of this Agreement.
Further Assurances. The Developer agrees to take such actions, including the execution and delivery of such documents, instruments, petitions and certifications as may become necessary or appropriate to carry out the terms, provisions and intent of this Agreement.
Waiver. Waiver by the City or the Developer with respect to any breach of this Agreement shall not be considered or treated as a waiver of the rights of the respective party with respect to any other default or with respect to any particular default, except to the extent specifically waived by the City or the Developer in writing. No delay or omission on the part of a party in exercising any right shall operate as a waiver of such right or any other right unless pursuant to the specific terms hereof. A waiver by a party of a provision of this Agreement shall not prejudice or constitute a waiver of such party's right otherwise to demand strict compliance with that provision or any other provision of this Agreement. No prior waiver by a party, nor any course of dealing between the parties hereto, shall constitute a waiver of any such parties' rights or of any obligations of any other party hereto as to any future transactions.
Remedies Cumulative. The remedies of a party hereunder are cumulative and the exercise of any one or more of the remedies provided for herein shall not be construed as a waiver of any other remedies of such party unless specifically so provided herein.
Disclaimer. Nothing contained in this Agreement nor any act of the City shall be deemed or construed by any of the parties, or by any third person, to create or imply any relationship of third-party beneficiary, principal or agent, limited or general partnership or joint venture, or to create or imply any association or relationship involving the City.

18.08 Headings. The paragraph and section headings contained herein are for

convenience only and are not intended to limit, vary, define or expand the content thereof.

4844-0160-8726.2

Counterparts. This Agreement may be executed in several counterparts, each of which shall be deemed an original and all of which shall constitute one and the same agreement.
Severability. If any provision in this Agreement, or any paragraph, sentence, clause, phrase, word or the application thereof, in any circumstance, is held invalid, this Agreement shall be construed as if such invalid part were never included herein and the remainder of this Agreement shall be and remain valid and enforceable to the fullest extent permitted by law.
Conflict. In the event of a conflict between any provisions of this Agreement and the provisions of the TIF Ordinances and/or the Bond Ordinance, if any, such ordinance(s) shall prevail and control.
Governing Law. This Agreement shall be governed by and construed in accordance with the internal laws of the State of Illinois, without regard to its conflicts of law principles.
Form of Documents. All documents reasonably required by this Agreement to be submitted, delivered or furnished to the City shall be in form and content satisfactory to the City.
Approval. Wherever this Agreement provides for the approval or consent of the City, DHED or the Commissioner, or any matter is to be to the City's, DHED's or the Commissioner's satisfaction, unless specifically stated to the contrary, such approval, consent or satisfaction shall be made, given or determined by the City, DHED or the Commissioner in writing and in the reasonable discretion thereof. The Commissioner or other person designated by the Mayor of the City shall act for the City or DHED in making all approvals, consents and determinations of satisfaction, granting the Certificate or otherwise administering this Agreement for the City.
Assignment. The Developer may not sell, assign or otherwise transfer its interest in this Agreement in whole or in part without the written consent of the City. Any successor in interest to the Developer under this Agreement shall certify in writing to the City its agreement to abide by all remaining executory terms of this Agreement, including but not limited to Sections 8.19 (Real Estate Provisions) and 8.20 (Survival of Covenants) hereof, for the Term of the Agreement. The Developer consents to the City's sale, transfer, assignment or other disposal of this Agreement at any time in whole or in part.
Binding Effect. This Agreement shall be binding upon the Developer, the City and their respective successors and permitted assigns (as provided herein) and shall inure to the benefit of the Developer, the City and their respective successors and permitted assigns (as provided herein). Except as otherwise provided herein, this Agreement shall not run to the benefit of, or be enforceable by, any person or entity other than a party to this Agreement and its successors and permitted assigns. This Agreement should not be deemed to confer upon third parties any remedy, claim, right of reimbursement or other right.
Force Majeure. Neither the City nor the Developer nor any successor in interest to either of them shall be considered in breach of or in default of its obligations under this Agreement in the event of any delay caused by damage or destruction by fire or other casualty, strike, shortage of material, unusually adverse weather conditions such as, by way of illustration and not limitation, severe rain storms or below freezing temperatures of abnormal degree or for an abnormal duration, tornadoes or cyclones, and other events or conditions beyond the reasonable control of the party affected which in fact interferes with the ability of such party to discharge its obligations hereunder. The individual or entity relying on this section with respect to any such delay shall, upon the occurrence of the event causing such delay, immediately give written notice to the other parties to

4844-0160-8726.2

this Agreement. The individual or entity relying on this section with respect to any such delay may rely on this section only to the extent of the actual number of days of delay effected by any such events described above.

Exhibits. All of the exhibits attached hereto are incorporated herein by reference.
Business Economic Support Act. Pursuant to the Business Economic Support Act (30 ILCS 760/1 et seg.), if the Developer is required to provide notice under the WARN Act, the Developer shall, in addition to the notice required under the WARN Act, provide at the same time a copy of the WARN Act notice to the Governor of the State, the Speaker and Minority Leader of the House of Representatives of the State, the President and minority Leader of the Senate of State, and the Mayor of each municipality where the Developer has locations in the State. Failure by the Developer to provide such notice as described above may result in the termination of all or a part of the payment or reimbursement obligations of the City set forth herein.
Venue and Consent to Jurisdiction. If there is a lawsuit under this Agreement, each party may hereto agrees to submit to the jurisdiction of the courts of Cook County, the State of Illinois and the United States District Court for the Northern District of Illinois.
Costs and Expenses. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorney's fees, incurred in connection with the enforcement of the provisions of this Agreement. This includes, subject to any limits under applicable law, attorney's fees and legal expenses, whether or not there is a lawsuit, including attorney's fees for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals and any anticipated post-judgment collection services. Developer also will pay any court costs, in addition to all other sums provided by law.

18.22 Business Relationships. The Developer acknowledges (A) receipt of a copy of

Section 2-156-030 (b) of the Municipal Code of Chicago, (B) that Developer has read such provision

and understands that pursuant to such Section 2-156-030 (b), it is illegal for any elected official of

the City, or any person acting at the direction of such official, to contact, either orally or in writing,

any other City official or employee with respect to any matter involving any person with whom the

elected City official or employee has a "Business Relationship" (as defined in Section 2-156-080 of

the Municipal Code of Chicago), or to participate in any discussion in any City Council committee

hearing or in any City Council meeting or to vote on any matter involving any person with whom the

elected City official or employee has a "Business Relationship" (as defined in Section 2-156-080 of

the Municipal Code of Chicago), or to participate in any discussion in any City Council committee

hearing or in any City Council meeting or to vote on any matter involving the person with whom an

elected official has a Business Relationship, and (C) that a violation of Section 2-156-030 (b) by an

elected official, or any person acting at the direction of such official, with respect to any transaction

contemplated by this Agreement shall be grounds for termination of this Agreement and the

transactions contemplated hereby. The Developer hereby represents and warrants that, to the best

of its knowledge after due inquiry, no violation of Section 2-156-030 (b) has occurred with respect to

this Agreement or the transactions contemplated hereby.

[THE REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK.]

4844-0160-8726.2

IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment Agreement to be executed on or as of the day and year first above written.

THE CHILDREN'S PLACE ASSOCIATION

By:

Its:

CHILDREN'S PLACE COMMUNITY LIVING LLC

By:

Its:

CITY OF CHICAGO

By:

Andrew J. Mooney, Commissioner

Department of Housing and Economic Development

4844-0160-8726 2

STATE OF ILLINOIS )

) SS

COUNTY OF COOK )

I, , a notary public in and for the said County, in the State aforesaid,

DO HEREBY CERTIFY that personally known to me to be the

of The Children's Place Association, an Illinois not-for-profit

corporation ("CPA"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by the Board of CPA, as his/her free and voluntary act and as the free and voluntary act of CPA, for the uses and purposes therein set forth.

GIVEN under my hand and official seal this day of , .

Notary Public

My Commission Expires.

(SEAL)

4844-0160-8726.2

STATE OF ILLINOIS )

)SS

COUNTY OF COOK )

I, , a notary public in and for the said County, in the State aforesaid,

DO HEREBY CERTIFY that personally known to me to be the

of Children's Place Community Living LLC, an Illinois limited

liability company ("Owner"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by the member of Owner, as his/her free and voluntary act and as the free and voluntary act of Owner, for the uses and purposes therein set forth.

GIVEN under my hand and official seal this day of , .

Notary Public

My Commission Expires

(SEAL)

4844-0160-8726.2

STATE OF ILLINOIS COUNTY OF COOK

)

)SS

)

I, , a notary public in and for the said County, in the State

aforesaid, DO HEREBY CERTIFY that Andrew J. Mooney, personally known to me to be the Commissioner of the Department of Housing and Economic Development of the City of Chicago (the "City"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument pursuant to the authority given to him/her by the City, as his/her free and voluntary act and as the free and voluntary act of the City, for the uses and purposes therein set forth.

GIVEN under my hand and official seal this day of , .

Notary Public

My Commission Expires.

4844-0160-8726.2

EXHIBIT A

REDEVELOPMENT AREA

(see Ex. of the Redevelopment Plan - Ex. D to the Agreement)

Not attached for ordinance.

4844-0160-8726.2

EXHIBIT B

PROPERTY

Lots 1,2,3 and 4 in Block 4 in Harding's Subdivision of the West Half of the Northeast Quarter of Section 11, Township 39 North, Range 13, East of the Third Principal Meridian, in Cook County, Illinois.

PIN: 16-11-200-019-0000; 16-11-200-020-0000

Commonly known as: 3533-45 West Chicago Avenue, Chicago, Illinois

4844-0160-8726.2

EXHIBIT C TIF-FUNDED IMPROVEMENTS

Land Acquisition $212,000

Cost of Construction of Affordable Units $3,269,919

Related Soft Costs (Architect) $174,160

Total $ 3,656,079*

*Notwithstanding this amount, the total amount payable for TIF-Eligible costs will not exceed $1,000,000.

4844-0160-8726.2

EXHIBIT D REDEVELOPMENT PLAN Not attached for ordinance.

EXHIBIT E CONSTRUCTION CONTRACT Not attached for ordinance.

4844-0160-8726.2

EXHIBIT F ESCROW AGREEMENT Not attached for ordinance.

4844-0160-8726.2

EXHIBIT G

PERMITTED LIENS

1. Liens or encumbrances against the Property:

Those matters set forth as Schedule B title exceptions in the owner's title insurance policy issued by the Title Company as of the date hereof, but only so long as applicable title endorsements issued in conjunction therewith on the date hereof, if any, continue to remain in full force and effect.

2. Liens or encumbrances against the Developer or the Project, other than liens against the

Property, if any: None.

4844-0160-8726.2

EXHIBIT H PROJECT BUDGET

Land Acquisition $212,000

Hard Costs

Construction $3,269,919

Contingency $172,905

Other Construction Costs $211,182

Soft Costs

Architect's Fee $174,160

Legal Fees $64,750

Other Professional Fees $ 149,025

Consultants $125,707

Developer Fee $389,111

Reserves $59,513

Lender Fees $ 175,302

Other soft costs $121,750

TOTAL $5,125,324

4844-0160-8726.2

EXHIBIT I APPROVED PRIOR EXPENDITURES Not attached for ordinance.

EXHIBIT J

OPINION OF DEVELOPER'S COUNSEL [To be retyped on the Developer's Counsel's letterhead]

City of Chicago

121 North LaSalle Street

Chicago, IL 60602

ATTENTION: Corporation Counsel

Ladies and Gentlemen:

We have acted as counsel to , an [Illinois]

(the "Developer"), in connection with the purchase of certain land and the construction of certain

facilities thereon located in the Redevelopment Project

Area (the "Project"). In that capacity, we have examined, among other things, the following agreements, instruments and documents of even date herewith, hereinafter referred to as the "Documents":

(a) Redevelopment Agreement (the "Agreement") of even

date herewith, executed by the Developer and the City of Chicago (the "City");

[insert other documents including but not limited to documents related to purchase and financing of the Property and all lender financing related to the Project]; and
all other agreements, instruments and documents executed in connection with the foregoing.

In addition to the foregoing, we have examined

the original or certified, conformed or photostatic copies of the Developer's (i) Articles of Incorporation, as amended to date, (ii) qualifications to do business and certificates of good standing in all states in which the Developer is qualified to do business, (iii) By-Laws, as amended to date, and (iv) records of all corporate proceedings relating to the Project [revise if the Developer is not a corporation]; and
such other documents, records and legal matters as we have deemed necessary or relevant for purposes of issuing the opinions hereinafter expressed.

In all such examinations, we have assumed the genuineness of all signatures (other than those of the Developer), the authenticity of documents submitted to us as originals and conformity to the originals of all documents submitted to us as certified, conformed or photostatic copies.

Based on the foregoing, it is our opinion that:

4844-0160-8726.2

The Developer is a corporation duly organized, validly existing and in good standing under the laws of its state of [incorporation] [organization], has full power and authority to own and lease its properties and to carry on its business as presently conducted, and is in good standing and duly qualified to do business as a foreign [corporation] [entity] under the laws of every state in which the conduct of its affairs or the ownership of its assets requires such qualification, except for those states in which its failure to qualify to do business would not have a material adverse effect on it or its business.
The Developer has full right, power and authority to execute and deliver the Documents to which it is a party and to perform its obligations thereunder. Such execution, delivery and performance will not conflict with, or result in a breach of, the Developer's [Articles of Incorporation or By-Laws] [describe any formation documents if the Developer is not a corporation] or result in a breach or other violation of any of the terms, conditions or provisions of any law or regulation, order, writ, injunction or decree of any court, government or regulatory authority, or, to the best of our knowledge after diligent inquiry, any of the terms, conditions or provisions of any agreement, instrument or document to which the Developer is a party or by which the Developer or its properties is bound. To the best of our knowledge after diligent inquiry, such execution, delivery and performance will not constitute grounds for acceleration of the maturity of any agreement, indenture, undertaking or other instrument to which the Developer is a party or by which it or any of its property may be bound, or result in the creation or imposition of (or the obligation to create or impose) any lien, charge or encumbrance on, or security interest in, any of its property pursuant to the provisions of any of the foregoing, other than liens or security interests in favor of the lender providing Lender Financing (as defined in the Agreement).
The execution and delivery of each Document and the performance of the transactions contemplated thereby have been duly authorized and approved by all requisite action on the part of the Developer.
Each of the Documents to which the Developer is a party has been duly executed and delivered by a duly authorized officer of the Developer, and each such Document constitutes the legal, valid and binding obligation of the Developer, enforceable in accordance with its terms, except as limited by applicable bankruptcy, reorganization, insolvency or similar laws affecting the enforcement of creditors' rights generally.
Exhibit A attached hereto (a) identifies each class of capital stock of the Developer, (b) sets forth the number of issued and authorized shares of each such class, and (c) identifies the record owners of shares of each class of capital stock of the Developer and the number of shares held of record by each such holder. To the best of our knowledge after diligent inquiry, except as set forth on Exhibit A, there are no warrants, options, rights or commitments of purchase, conversion, call or exchange or other rights or restrictions with respect to any of the capital stock of the Developer. Each outstanding share of the capital stock of the Developer is duly authorized, validly issued, fully paid and nonassessable.
To the best of our knowledge after diligent inquiry, no judgments are outstanding against the Developer, nor is there now pending or threatened, any litigation, contested claim or governmental proceeding by or against the Developer or affecting the Developer or its property, or seeking to restrain or enjoin the performance by the Developer of the Agreement or the transactions contemplated by the Agreement, or contesting the validity thereof. To the best of our knowledge after diligent inquiry, the Developer is not in default with respect to any order, writ, injunction or decree of any court, government or regulatory authority or in default in any respect

4844-0160-8726.2

under any law, order, regulation or demand of any governmental agency or instrumentality, a default under which would have a material adverse effect on the Developer or its business.

To the best of our knowledge after diligent inquiry, there is no default by the Developer or any other party under any material contract, lease, agreement, instrument or commitment to which the Developer is a party or by which the company or its properties is bound.
To the best of our knowledge after diligent inquiry, all of the assets of the Developer are free and clear of mortgages, liens, pledges, security interests and encumbrances except for those specifically set forth in the Documents.
The execution, delivery and performance of the Documents by the Developer have not and will not require the consent of any person or the giving of notice to, any exemption by, any registration, declaration or filing with or any taking of any other actions in respect of, any person, including without limitation any court, government or regulatory authority.
To the best of our knowledge after diligent inquiry, the Developer owns or possesses or is licensed or otherwise has the right to use all licenses, permits and other governmental approvals and authorizations, operating authorities, certificates of public convenience, goods carriers permits, authorizations and other rights that are necessary for the operation of its business.
A federal or state court sitting in the State of Illinois and applying the choice of law provisions of the State of Illinois would enforce the choice of law contained in the Documents and apply the law of the State of Illinois to the transactions evidenced thereby.

We are attorneys admitted to practice in the State of Illinois and we express no opinion as to any laws other than federal laws of the United States of America and the laws of the State of Illinois.

[Note: include a reference to the laws of the state of incorporation/organization of the Developer, if other than Illinois.]

This opinion is issued at the Developer's request for the benefit of the City and its counsel, and may not be disclosed to or relied upon by any other person.

Very truly yours,

By:

Name:

4844-0160-8726.2

EXHIBIT K PRIOR OBLIGATIONS Not attached for ordinance.

EXHIBIT L REQUISITION FORM

STATE OF ILLINOIS )

) SS

COUNTY OF COOK )

The affiant, , of , a

(the "Developer"), hereby certifies that with respect to that

certain Redevelopment Agreement between the Developer and the City of

Chicago dated , (the "Agreement"):

Expenditures for the Project, in the total amount of $ , have been

made:

This paragraph B sets forth and is a true and complete statement of all costs of TIF-Funded Improvements for the Project reimbursed by the City to date:

The Developer requests reimbursement for the following cost of TIF-Funded Improvements:

None of the costs referenced in paragraph C above have been previously reimbursed by the City.
The Developer hereby certifies to the City that, as of the date hereof:

Except as described in the attached certificate, the representations and warranties contained in the Agreement are true and correct and the Developer is in compliance with all applicable covenants contained herein.
No event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default, exists or has occurred.

All capitalized terms which are not defined herein has the meanings given such terms in the Agreement.

4844-0160-8726.2

[Developer]

By:

Name Title:

Subscribed and sworn before me this day of.

My commission expires: Agreed and accepted:

Name Title:

City of Chicago

Department of Housing and Economic Development

4844-0160-8726.2

EXHIBIT M

FORM OF SUBORDINATION AGREEMENT

This document prepared by and after recording return to:

, Esq.

Assistant Corporation Counsel Department of Law 121 North LaSalle Street, Room 600 Chicago, IL 60602

SUBORDINATION AGREEMENT

This Subordination Agreement ("Agreement") is made and entered into as of the

day of , between the City of Chicago by and through its Department of Housing and

Economic Development (the "City"), [Name Lender], a [national banking association] (the "Lender")-

WITNESSETH:

WHEREAS, The Children's Place Association, an Illinois not-for-profit corporation (the "Developer"), has purchased certain property located within the Chicago/Central Park Redevelopment Project Area at 3533-45 West Chicago Avenue, Chicago, Illinois 60651 and legally described on Exhibit A hereto (the "Property"), in order to rehabilitate the building (the "Building") located on the Property to develop commercial space for an art gallery, artist warehouse space and another commercial space, as well as 16 units of residential/work space for artists (the "Project."); and

WHEREAS, as part of obtaining financing for the Project, the Developer has entered

into a certain Construction Loan Agreement dated as of with the Lender pursuant to

which the Lender has agreed to make a loan to the Developer in an amount not to exceed

$ (the "Loan"), which Loan is evidenced by a Mortgage Note and executed by the

Borrower in favor of the Lender (the "Note"), and the repayment of the Loan is secured by, among other things, certain liens and encumbrances on the Property and other property of the Borrower

pursuant to the following: (i) Mortgage dated and recorded on as

document number made by the Developer to the Lender; and (ii) Assignment of

Leases and Rents recorded as document number made by the

4844-0160-8726.2

Developer to the Lender (all such agreements referred to above and otherwise relating to the Loan referred to herein collectively as the "Loan Documents");

WHEREAS, the Developer desires to enter into a certain Redevelopment Agreement dated the date hereof with the City in order to obtain additional financing for the Project (the "Redevelopment Agreement," referred to herein along with various other agreements and documents related thereto as the "City Agreements");

WHEREAS, pursuant to the Redevelopment Agreement, the Developer will agree to be bound by certain covenants expressly running with the Property, as set forth in Sections 8.02, 8.06 and 8.19 of the Redevelopment Agreement (the "City Encumbrances");

WHEREAS, the City has agreed to enter into the Redevelopment Agreement with the Developer as of the date hereof, subject, among other things, to (a) the execution by the Developer of the Redevelopment Agreement and the recording thereof as an encumbrance against the Property; and (b) the agreement by the Lender to subordinate their respective liens under the Loan Documents to the City Encumbrances; and

NOW, THEREFORE, for good and valuable consideration, the receipt, adequacy and sufficiency of which are hereby acknowledged, the Lender and the City agree as hereinafter set forth:

1. Subordination. All rights, interests and claims of the Lender in the Property

pursuant to the Loan Documents are and shall be subject and subordinate to the City

Encumbrances. In all other respects, the Redevelopment Agreement shall be subject and

subordinate to the Loan Documents. Nothing herein, however, shall be deemed to limit the Lender's

right to receive, and the Developer's ability to make, payments and prepayments of principal and

interest on the Note, or to exercise its rights pursuant to the Loan Documents except as provided

herein.

Notice of Default. The Lender shall use reasonable efforts to give to the City, and the City shall use reasonable efforts to give to the Lender, (a) copies of any notices of default which it may give to the Developer with respect to the Project pursuant to the Loan Documents or the City Agreements, respectively, and (b) copies of waivers, if any, of the Developer's default in connection therewith. Under no circumstances shall the Developer or any third party be entitled to rely upon the agreement provided for herein.
Waivers. No waiver shall be deemed to be made by the City or the Lender of any of their respective rights hereunder, unless the same shall be in writing, and each waiver, if any, shall be a waiver only with respect to the specific instance involved and shall in no way impair the rights of the City or the Lender in any other respect at any other time.
Governing Law; Binding Effect. This Agreement shall be interpreted, and the rights and liabilities of the parties hereto determined, in accordance with the internal laws and decisions of the State of Illinois, without regard to its conflict of laws principles, and shall be binding upon and inure to the benefit of the respective successors and assigns of the City and the Lender.
Section Titles; Plurals. The section titles contained in this Agreement are and shall be without substantive meaning or content of any kind whatsoever and are not a part of the agreement between the parties hereto. The singular form of any word used in this Agreement shall include the plural form.

4844-0160-8726.2

6. Notices. Any notice required hereunder shall be in writing and addressed to the party to be notified as follows:

If to the City: City of Chicago Department of Housing and Economic

Development

121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner

With a copy to: City of Chicago Department of Law

121 North LaSalle Street, Room 600 Chicago, Illinois 60602

Attention: Finance and Economic Development Division

If to the Lender:

Attention:

With a copy to:

Attention:

or to such other address as either party may designate for itself by notice. Notice shall be deemed to have been duly given (i) if delivered personally or otherwise actually received, (ii) if sent by overnight delivery service, (iii) if mailed by first class United States mail, postage prepaid, registered or certified, with return receipt requested, or (iv) if sent by facsimile with facsimile confirmation of receipt (with duplicate notice sent by United States mail as provided above). Notice mailed as provided in clause (iii) above shall be effective upon the expiration of three (3) business days after its deposit in the United States mail. Notice given in any other manner described in this paragraph shall be effective upon receipt by the addressee thereof; provided, however, that if any notice is tendered to an addressee and delivery thereof is refused by such addressee, such notice shall be effective upon such tender.

7. Counterparts. This Agreement may be executed in two or more counterparts, each of which shall constitute an original and all of which, when taken together, shall constitute one instrument.

[The remainder of this page is intentionally left blank.]

4844-0160-8726.2

IN WITNESS WHEREOF, this Subordination Agreement has been signed as of the date first written above.

[LENDER], [a national banking association]

By:

Its:

CITY OF CHICAGO

By:

Its: Commissioner,

Department of Housing and Economic

Development

ACKNOWLEDGED AND AGREED TO THIS

DAY OF

[Developer], a

By: Its:

4844-0160-8726.2

STATE OF ILLINOIS )

)SS

COUNTY OF COOK )

I, the undersigned, a notary public in and for the County and State aforesaid, DO HEREBY

CERTIFY THAT , personally known to me to be the Commissioner of the

Department of Housing and Economic Development of the City of Chicago, Illinois (the "City") and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that as such Commissioner, (s)he signed and delivered the said instrument pursuant to authority, as his/her free and voluntary act, and as the free and voluntary act and deed of said City, for the uses and purposes therein set forth.

GIVEN under my hand and notarial seal this day of

Notary Public

(SEAL)

4844-0160-8726.2

STATE OF ILLINOIS COUNTY OF COOK

)

)SS

)

, personally known to me to be the

, a notary public in and for the said County, in the State

of [Lender], a.

aforesaid, DO HEREBY CERTIFY THAT

, and personally known to me to

be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed and delivered said instrument, pursuant to the authority given to him/her by Lender, as his/her free and voluntary act and as the free and voluntary act of the Lender, for the uses and purposes therein set forth.

GIVEN under my hand and notarial seal this day of

(SEAL)

4844-0160-8726.2

Notary Public

My Commission Expires

EXHIBIT A - LEGAL DESCRIPTION

Lots 1, 2, 3 and 4 in Block 4 in Harding's Subdivision of the West Half of the Northeast Quarter of Section 11, Township 39 North, Range 13, East of the Third Principal Meridian, in Cook County, Illinois.

PIN: 16-11-200-019-0000; 16-11-200-020-0000

Commonly known as: 3533-45 West Chicago Avenue, Chicago, Illinois

4844-0160-8726.2

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION I -- GENERAL INFORMATION

Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable:

fh)lv®rtf<> Pkcz (ammfrj ti^rm Lie

Check ONE of the following three boxes:

Indicate whether the Disclosing Party submitting this EDS is:

1. tfcf the Applicant

' OR

2. [ ] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the

Applicant in which the Disclosing Party holds an interest:

' OR

3. [ ] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in

which the Disclosing Party holds a right of control:

Business address of the Disclosing Party:

Name of contact person:
Federal Employer Identification No. (if you have one): t)dc?
Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include projeqLnumber and location df property, if applicable)}

G. Which City agency or depailmeht is requesting this EDS? f/^T^H ^TjO U(S>n^>H > C_

If the Matter is a contract being handled by the City's Department of Procurement services, please complete the following:

Specification # and Contract tt

Ver. 01-01-12

Page 1 of 13

SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY

1. Indicate the nature of the Disclosing Party:

[ ] Person

[ ] Publicly registered business corporation [ ] Privately held business corporation [ ] Sole proprietorship [ ] General partnership [ ] Limited partnership [] Trust

Limited liability company Limited liability partnership [ ] Joint venture [ ] Not-for-profit corporation (Is the not-for-profit corporation also a 501(c)(3))?

[ ] Yes [ ] No

[ ] Other (please specify)

2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable:

3)Vtkx

- 3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?

[ ] Yes [ ] No [ ] N/A

B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:

1. List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).

If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity.that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.

2. Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,

Page 2 of 13

interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.

Name

Business Address

Percentage Interest in the Disclosing Party

7orf)<o

SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS

Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?

[JYes

If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):

SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.

"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.

If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.

Page 3 of 13

Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether

retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:

to be retained) y lobbyist, etc.) "hourly rate" or "t.b.d." is

not an acceptable response.

^tTS/ .< l -« , . ,

(Add sheets if necessary)

^j^Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V -- CERTIFICATIONS

COURT-ORDERED CHILD SUPPORTCOMPLIANCE

Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.

Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?

[ ] Yes [ ] No \jWo person directly or indirectly owns 10% or more of the

r Disclosing Party.

If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?

[]Yes []No

FURTHER CERTIFICATIONS

1. Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.

Page 4 of 13

The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:

1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
3. arc not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The certifications in subparts 3, 4 and 5 concern:

the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");

any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Parly, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").

Page 5 of 13

Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:

bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).

Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.

The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further

Certifications), the Disclosing Party must explaiirbelow:-j i ^ _A .

Page 6 of ]3

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").

thXfci .

9. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or^one^'). As to any gift listed below, please also list the name of the City recipient.

C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION

1. The Disclosing Party certifies that the Disclosing Party (check one)

[ ] is ^|is not

a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.

2. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:

"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."

If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):

Page 7 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS

Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.

In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter? , n

[ ] Yes \ /X^No

NOTE: If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D. 1., proceed to Part E.

Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to (he City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.

Does the Matter involve a City Property Sale?

[ ] Yes

3. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:

Name Business Address Nature of Interest

4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check cither 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to

Page 8 of 13

comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.

^ 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.

2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the

Disclosing Parly has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:

SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS

NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not fedj/ally ^y

funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the CifyT . J.<a_T

and proceeds of debt obligations of the City are not federal funding. ' *-^//X/(7 / ^/>j

A. CERTIFICATION REGARDING LOBBYING

1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):

(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)

2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.

Page 9 of 13

The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.

B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY

If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.

Is the Disclosing Party the Applicant?

[ ] Yes [ ] No

If "Yes," answer the three questions below:

Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)

[ ] Yes [ ] No

Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?

[ ] Yes [ ] No

Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?

[ ] Yes [ ] No

If you checked "No" to question 1. or 2. above, please provide an explanation:

Page 10 of 13

SECTION VII -- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE

The Disclosing Party understands and agrees that:

The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.

Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.

If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1 -23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.

The Disclosing Party represents and warrants that:

Page 11 of 13

F. 1. The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.

F.2 If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.

F.3 If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.

NOTE: If the Disclosing Party cannot certify as to any of the items in F.L, F.2. or F.3. above, an explanatory statement must be attached to this EDS.

CERTIFICATION

Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.

(Print or type name of person signing)

^J=g>

(Print or type title of person signing)

Signed and sworn to before mc on (<\ate^\/(\}jPrnhe f

at Prrtk. County, ~pUnn\^ (state).

Notary Public.

Commission expires: f)^L[l/ Q~jM (\l 7

OFFICIAL SEAL NOEMi RIVERA

NOTARY PuBUC - STATE OF ILLINOIS MY COMMISSION EXPIRE3-.M/12M

Page 12 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

APPENDIX A

FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS

This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.

Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.

"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section ILB. 1 .a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.

Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?

[JYes

If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.

Page 13 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION I - GENERAL INFORMATION

A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable:

Check ONE of the following three boxes:

Indicate whether the Disclosing Party submitting this EDS is:

^ the Applicant

[ ] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the

Applicant in which the Disclosing Party holds an interest:

3. _f. a legal entity with a right of control (see Section .B.L)^fat(Kthe leeal name o_f>tlie entitv j_n

which the Disclosing Party holds a right of control^- .

B. Business address of the Disclosing Party:

C. Telephone

D. Name of contact person:

Federal Employer Identification No. (if you have one): __:
Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to

nint Services, p

please

G. Which City agency or department is requesting this EDS?

If the Matter is a contract being handled by the City's Department of Procurei complete the following:

and Contract #

Specification #

Ver. 01-01-12

Page 1 of 13

SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY

1. Indicate the nature of the Disclosing Party:

] Person

] Publicly registered business corporation

] Privately held business corporation

] Sole proprietorship

] General partnership

] Limited partnership

] Trust

[ ] Limited liability company [ ] Limited liability partnership [J Joint venture ^f^l Not-for-profit corporation (Is the not-for-profit corporation also a 501(c)(3))?

/$ Yes [ ] No

[ ] Other (please specify)

2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable:

aifa/olS

3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?

[ ] Yes [ ] No [ ] N/A

B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:

If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.

^Nam° tJo ft)mh>p'& ^T"'^e .

Page 2 of 13

Naine Business Address Percentage Interest in the

, , ^ Disclosing Party

kki&L

SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS

Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of Ihe Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?

[ ] Yes j/^ No

If yes, please identify below the namc(s) of such City elected official(s) and describe such relationship(s):

SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

The Disclosing Party must disclose Ihe name and business address of each subcontractor, attorney, lobbyist, nccountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Malter, ns well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Parly's regular payroll.

If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.

Page 3 of 13

Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether

retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:

to be retained) a lobbyist, etc.) "hourly rate" or "t.b.d." is

Am<h?A »ou,cc^,c_rco_s.

(Add sheets if necessary)

[ ] Check here if the Disclosing Parly has not retained, nor expects to retain, any such persons or entities. SECTION V -- CERTIFICATIONS

COURT-ORDERED CHILD SUPPORT COMPLIANCE

Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the Cily must remain in compliance with their child support obligations throughoitt the contract's term.

Has any person who directly or indirectly owns 10% or more of the Disclosing Patty been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?

[ ] Yes [ ] No MNo person directly or indirectly owns 10% or more of the

Disclosing Party.

If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?

[]Ycs []No

FURTHER CERTIFICATIONS

1. Pursuant to Municipal Code Chapter 1-23, Article I ("Article !")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Parly submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.

Page 4 of 13

The Disclosing Parly and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section H.B.I, of this EDS:

are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The certifications in subparts 3, 4 and 5 concern:

the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of n business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").

Page 5 of 13

bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecvited for such conduct; or
violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).

Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:

Page 6 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, al any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").

_M2^£ .

9. To the best of the Disclosing Party's knowledge after reasonable inquiry, (he following is a complete list of all gifts that Ihe Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" docs not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicnte with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.

f/A"

C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION

The Disclosing Pat ty certifies that the Disclosing Party (check one)

[ ] is ^is not

a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.

If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:

"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. Wc further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."

If the Disclosing Party is unable to make this pledge because ii or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):

Page 7 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS

Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.

In accordance with Section 2-156-110 of the Municipal Code: Docs any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?

[ ] Yes ^ No

NOTE: If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.

Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.

Does the Matter involve a City Property Sale?

[ ] Yes No

If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:

Name Business Address Nature of Interest

4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check either 1. or 2. below. If the Disclosing Parly checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to

Page 8 of 13

comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.

1. The Disclosing Party verifies that the Disclosing Parly has searched any and nil records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.

2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the

Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:

SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS/■ l >A

NOTE: If the Matter is federally funded, complete this Section VI. If the Matter Is not fedfcfall/7) funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City^ and proceeds of debt obligations of Ihe City arc not federal funding,

A. CERTIFICATION REGARDING LOBBYING

(If no explanation appears or begins on ihe lines above, or if the letters "NA" or if the word "None" appear, il will be conclusively presumed that Ihe Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)

2. The Disclosing Parly has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.L above for his or her lobbying activities or lo pay any person or entity to influence or attempt lo influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, oj- cooperative agreement.

Page 9 of 13

The Disclosing Parly will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.I. and A.2. above.
The Disclosing Parly certifies thai cither: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
If the Disclosing Party is the Applicant, the Disclosing Parly must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Parly must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.

B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY

Is the Disclosing Party the Applicant?

[ ] Yes [ ] No

If "Yes," answer the three questions below:

Have yon developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)

[JYes [JNo

Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?

[JYes [JNo

Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?

[JYes []No

If you checked "No" to question 1. or 2. above, please provide an explanation:

Page 10 of 13

SECTION VII ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE

The Disclosing Party understands and agrees that:

The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the Cily in connection with the Matter, whether procurement, City assistance, or other City action, and arc material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.oig/Etliics, and may also be obtained from the City's Board of Ethics, 740 N.

Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.

If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of materia! fact may include incarceration and an award to the City of treble damages.
It is the Cily's policy to make this document available to ihe public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the Cily to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up (o the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, ns required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.

The Disclosing Party represents and warrants that:

Page 11 of 13

F.l. The Disclosing Parly is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, hor are the Disclosing Parly or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.

F.2 If the Disclosing Party is the Applicant, the Disclosing Parly and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A- on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.

F.3 If the Disclosing Party is the Applicant, the Disclosing Parly will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F. l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor thai does not provide such certifications or that (he Disclosing Party has reason to believe has not provided or cannot provide truthful ccrtificalibns.

NOTE: If the Disclosing Party cannot certify as to any of the items in F.l,, F.2. or F.3. above, an explanatory statement must be attached to this EDS.

CERTIFICATION

Under penalty of perjury, Ihe person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrnnls that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the Cily.

CAJ/ci^VV H Fhcg) J&6cftffiy

(Print or type name oCDfttclosKfy Party)

By:

(Sign here) . (Print or lypc name of person signing)

(Print or lypc title of person signing)

Signed and sworn lo before me on (date) \ \ \ > \&

at C County, jr/ (state).

l//'^/^f (^^^t^k^^y Notary Public.

Commission expires: | / / ^ > 13

Page 12 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

APPENDIX A

FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS

Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Part)'" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.

"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section U.B.l.a., if the Disclosing Party is a corporation; nil partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of (he Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.

Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?

[ ]Yes

If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is coiuiectcd; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.

Page 13 of 13

THE CHILDREN'S PLACE ASSOCIATION CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT NAMES AND TITLES OF ALL DIRECTORS AND EXECUTIVE OFFICERS OF THE ENTITY

Eighteen Years 1996

BOARD OF DIRECTORS FY 14

Chair Kathleen Ryan Sellew

Four Years 2009

Managing Director Marsh USA Inc. 500 West Monroe Street Chicago, IL 60661-3630

Vice Chair Brenda B. Asare

Senior Vice President, Midwest Division Manager The Alford Group 1603 Orrington Ave, Ste 200 Evanstoh, IL 60201

Treasurer Brian K. Greenblatt Twelve Years

Managing Director & Senior Vice President 2001 Private Bank 120 South LaSalle Street Chicago, IL 60603

Secretary

John J. Durso Partner

Ungaretti & Harris

3500 Three First Nalional Plaza

Chicago, IL 60602

SevenYears 2006

Board Member

Robert Bale Retired

533 Des Plaines Apt 2B

Forest Park, IL 60130

One Year 2013

Board Member Josephine Calderon Two Year

Director of Personal Trust 2011

Fifth Third Private Bank 1701 Golf Rd. Rolling Meadows, IL 60008

Board Member Ralph J. DICIemente Four Years

Professor of Public Health and Pediatrics 2009 Emory University 1518 Clifton Rd NE, Rm 554 Atlanta, GA 30322

Board Member

Betty J. Jackson

Executive Vice President and COO

Envision Unlimited

8 South Michigan Avenue

Chicago, IL 60603

Eighteen Years 1995

Board Member

Cheryl Jackson 77 West Huron Apt. 2109 Chicago, IL 60654

One year 2013

Board Member

Six Years 2007

Seventeen Years 1996

Harold A. Kessler, M.D. Professor of Medicine & Immunology/Microbiology Associate Director, Section of Infectious Disease Rush University Medical Center 600 South Paulina Street, Suite 143 Chicago, IL 60612

Raymond J. Mulligan

Vice President, Chicago Metro Sales

Blue Cross/Blue Shield

1020 W. 31st Street

Downers Grove, IL 60515

Board Member

Edward F. Otto Principal

Ted Otto Group, LLC

1335 S. Prairie Avenue, Suite 405

Chicago, IL 60605

Four Years 2009

Board Member Michael Silverman One Year

Senior Vice President, Chief Legal Officer SmlthBucklin 2439 Center Ave. Northbrook, IL 60062

Board Member

Jack W. Strand Partner

Strand & Browne Real Estate 777 Lake St., #116 River Forest, IL 60305

Twenty- Two Years 1991

Board Member

Sara W. Swift

Past Chair, Board of Directors And Community Volunteer 2046 N. Clifton Avenue Chicago, IL 60614

Sixteen Years 1997

Board Member Diana Ware Two Year

Managing Director, Corporate Risk Manager 2011

Mesirow Financial 353 North Clark Street . Chicago, IL 60654 312-595-6185

Chief Executive Cathy Krleger Twenty-Three Years

Officer The Children's Place Association

President 700 N. Sacramento, Suite 300

Chicago. Illinois 60612

o o o

CO CO

ro"

o o o in o CN 0»

o o o

co" m

p <

Q til 2

5 w ^

Q 2 <

iu 5

°- d

CO CO CO

z 5 £

m o P

S s o

R ^

w g

o ca

< </> o

«- 5

a. <

2 £0

x °-

co o

z -o p

CO CO UI DC Q

a <

co co

CNJ

CN O CD O CO ,W

o o

5 ^ .8

c o

"ts

w c o O

<D O

+2 o

CO CO

15 p

o c

c Ll ■o

to c o> i3 .5 "5

o o X O

co o co o

w oo

ro o

I CO

co B

8 COO

X ro

D. 4) W O

(0 CO

a) c o CO

c o x> c

e .co

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION I - GENERAL INFORMATION

Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable:

Check ONE of the following three boxes:

Indicate whether the Disclosing Party submitting this EDS is:

[ ] the Applicant

[ ] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the

Applicant in which the Disclosing Party holds an interest:

3. )4 a legal entity with a right of control (see SectionJI.B,!.)* State the^legaLaame of the,entity in

whicTi the Disclosing Party holds a right of control: (kl /UlPQ W S {¥&CX>> C^^fTUty

Business address of the Disclosing Party: "7Cfc> ^SlZ^^ppf^ffO 3\??T& JJ*
Name of contact person:

E. Federal Employer Identification No. (if you have one): _-■

' ^_ ' ■/ ■

Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to whichdJiis EDS>«errains, (Include projeptjrumber and location of mpperty, if applicable): i /

G. Which "City agency or departments requesting this EDS?' '^^-^H uC,

ease

If the Matter is a contract being handled by the City's Department of Proc^lm^il^e^vi^es, pi complete the following:

Specification # and Contract #

Ver. 01-01-12 Page 1 of 13

SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY

1. Indicate the nature of the Disclosing Party:

Person

Publicly registered business corporation

Privately held business corporation

Sole proprietorship

General partnership

Limited partnership

Trust

[ ] Limited liability company [ ] Limited liability partnership [ 1 Joint venture

Not-for-profit corporation (Is the not-for-profit corporation also a 501(c)(3))?

^<SYes []No [ ] Other (please specify)

2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable:

3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?

[ ] Yes [ ] No [ ] N/A

B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:

If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.

m&efoty j g)^i7m c

Page 2 of 13

Business Address

Name

Percentage Interest in the Disclosing Party

SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS

Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?

[] Yes

If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):

SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must cither ask the City whether disclosure is required or make the disclosure.

Page 3 of 13

Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether

retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:

to be retained) _j lobbyist, etc.) "hourly rate" or "t.b.d." is

not an acceptable response.

(Add sheets if necessary)

^Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS

COURT-ORDERED CHILD SUPPORT COMPLIANCE

Under Municipal Code Section 2-92-4 J 5, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.

Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?

[ ] Yes [ ] No ~^$) No person directly or indirectly owns 10% or more of the

Disclosing Party.

If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?

[ ] Yes [ ] No

FURTHER CERTIFICATIONS

1. Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Parly submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of tbe City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.

Page 4 of 13

The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:

1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The certifications in subparts 3, 4 and 5 concern:

the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").

Page 5 of 13

bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).

Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.

The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further

Certifications'L.the Disclosing/Party must explain/below: ") 1 _f <

Page 6 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

__Bfeti& -

9. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.

Ahfft ~ ~

C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION

The Disclosing Party certifies that the Disclosing Party (check one)

[ ] is JjQ is not

a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.

If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:

"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. Wc understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."

Page 7 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS

Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.

In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?

[ ] Yes V No

NOTE: If you checked "Yes" to Item D.I., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.

Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.

Does the Matter involve a City Property Sale?

[] Yes

3. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:

Name Business Address Nature of Interest

4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check cither 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to

Page 8 of 13

comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.

1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of

the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.

_2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the

SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS _A . 7^

c7d2f3Q(.

NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is nor federal} funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the Ci and proceeds of debt obligations of the City are not federal funding

ing^J;

A. CERTIFICATION REGARDING LOBBYING ^ jp^

1. List below the names of all persons or entities registered under the federal Lobby Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):

Page 9 of 13

The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.

B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY

Is the Disclosing Party the Applicant?

[ ] Yes [ ] No

If "Yes," answer the three questions below:

Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)

[ ] Yes [ ] No

Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?

[ ] Yes [ ] No

Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?

[ ] Yes [ ] No

If you checked "No" to question 1. or 2. above, please provide an explanation:

Page 10 of 13

SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE

The Disclosing Party understands and agrees that:

The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.

Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.

If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.

The Disclosing Party represents and warrants that:

Page 11 of 13

F.l. The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.

F.3 If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F. 1. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.

NOTE: If the Disclosing Party cannot certify as to any of the items in F.L, F.2. or F.3. above, an explanatory statement must be attached to this EDS.

CERTIFICATION

(Sign here) \ ^

(Print or type name of person signing)

(Print or type title of person signing)

Commission expires: fo-fl / Q, ,2-Ql7

Page 12 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

APPENDIX A

FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS

"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section JJ.B.La., if the Disclosing Party is a coiporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.

Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?

[ ] Yes

Page 13 of 13

THE CHILDREN'S PLACE HOUSING CORPORATION, INC. CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT NAMES AND TITLES OF ALL DIRECTORS AND EXECUTIVE OFFICERS OF THE ENTITY

BOARD OF DIRECTORS FY 14

Chair Jack W. Strand

Partner

Strand & Browne Real Estate 777 Lake St., #116 River Forest, IL 60305

Treasure & Secretary

John J. Durso Partner

Ungaretti & Harris

3500 Three First National Plaza

Chicago, IL 60602

Board Member

Chief Executive

Officer

President

Edward F. Otto Principal

Ted Otto Group, LLC

1335 S. Prairie Avenue, Suite 405

Chicago, IL 60605

Cathy Krieger

The Children's Place Association 700 N. Sacramento, Suite 300 Chicago, Illinois 60612

Chief Financial Officer

Curt Schubert

The Children's Place Association 700 N. Sacramento, Suite 300 . Chicago, Illinois 60612

Legislation Text

Legislation Details

Legislation Details (With Text)