OFFICE OF THE MAYOR
CITY OF CHICAGO
LORI E. LIGHTFOOT MAYOR
November 16, 2022
TO THE HONORABLE. THE CITY COUNCIL OF THE CITY OF CHICAGO
Ladies and Gentlemen:
At the request ofthe Commissioner of Planning and Development, I transmit herewith an ordinance authorizing the execution ofa TIF redevelopment agreement with Chicago Market, a Community Cooperative.
Your favorable consideration ofthis ordinance will be appreciated.
Very truly yours,
ORDINANCE
WHEREAS, under ordinances adopted on June 27, 2001 and published in the Journal of Proceedings ofthe City Council ofthe City of Chicago (the "Journal") for such date at pages 62341 to 62451 thereof, and under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4.1 et seg, as amended (the "Act"), the City Council (the "City Council") of the City of Chicago (the "City"): (i) approved a redevelopment plan and project (the "Original Plan") for a portion of the City known as the "Wilson Yard Redevelopment Project Area" (the "Original Area") (the "Plan Ordinance"); (ii) designated the Original Area as a "redevelopment project area" within the requirements of the Act (the "Designation Ordinance"); and (iii) adopted tax increment financing for the Original Area (the "Adoption Ordinance" and, together with the Plan Ordinance and the Designation Ordinance, collectively, the "Original TIF Ordinances"); and
WHEREAS, the Original Plan was amended by the City Council under an ordinance ("Amending Ordinance #1") adopted on November 18,2009 and published in the Journal for such date at pages 74053 to 74131 thereof ("Plan Amendment #1"); and
WHEREAS, the Original Plan, as amended by Plan Amendment #1, was further amended, and the Original Area was amended, all under an ordinance ("Amending Ordinance #2") adopted on February 10, 2010 and published in the Journal for such date at pages 83890 to 83990 thereof ("Plan Amendment s and Area Amendment #1") (the Original Plan, the Plan Amendment #1 and the Plan Amendment #2, collectively, the "TIF Plan") (the Original Area and the Area Amendment #1, collectively, the "TIF Area") (the Original TIF Ordinances, the Amending Ordinance #1 and the Amending Ordinance #2, collectively, the "TIF Ordinances"); and
WHEREAS, Chicago Cooperative, an Illinois corporation d/b/a Chicago Market - a Community Co-op ("Developer"), has a lease with the Chicago Transit Authority for a certain property located within the TIF Area at 4620 North Broadway, Chicago, Illinois 60640 (the "Property"), which Property has been improved with a currently-vacant building (the "Building") known as the historic Gerber Building at the Wilson Red Line stop in Uptown; and
WHEREAS, Developer will rehabilitate the Building into an approximately 18,237 square foot grocery store and will operate a full-service grocery therein (the "Project"); and
WHEREAS, the Developer proposes to undertake the Project in accordance with the TIF Plan and pursuant to the terms and conditions of a proposed redevelopment agreement to be executed by the Developer and the City, including but not limited to the completion ofthe Project, to be financed in part by incremental taxes, if any, deposited in the Special Tax Allocation Fund (as defined in the TIF Ordinances) for the TIF Area; and
WHEREAS, pursuant to Resolution 22-CDC-39 (the "Resolution") adopted by the Community Development Commission of the City (the "Commission") on August 9, 2022, the Commission recommended that the Developer be designated as the developer for the Project and that the City's Department of Planning and Development ("DPD") be authorized to negotiate, execute and deliver on behalf of the City a redevelopment agreement with the Developer for the Project; now therefore,
NOW, THEREFORE, BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO:|1010|
SECTION 1. Recitals. The above recitals are incorporated herein and made a part
hereof.
SECTION 2. Designation of Developer. The Developer is hereby designated as the developer for the Project pursuant to Section 5/11-74.4-4 of the Act.
SECTION 3. Redevelopment Agreement. The Commissioner of DPD (the "Commissioner") and a designee of the Commissioner (collectively, the "Authorized Officer") are each hereby authorized, with the approval ofthe City's Corporation Counsel as to form and legality, to negotiate, execute and deliver: (a) a redevelopment agreement between the Developer and the City in substantially the form attached hereto as Exhibit A and made a part hereof (the "Redevelopment Agreement"), and (b) such other supporting documents as may be necessary to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement, with such execution by the Authorized Officer to constitute conclusive evidence ofthe City's approval of any changes or revisions from the form of Redevelopment Agreement attached to this ordinance.
SECTION 4. Invalidity of Anv Section. If any provision of this ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such provision shall not affect any ofthe remaining provisions of this ordinance.
SECTION 5. Superseder. All ordinances (including, without limitation, the TIF Ordinances), resolutions, motions or orders in conflict with this ordinance are hereby repealed to the extent of such conflicts.
SECTION 6. Effective Date. This ordinance shall be in full force and effect immediately upon its passage and approval.
|1010|
EXHIBIT A REDEVELOPMENT AGREEMENT (attached)
|1010|
This agreement was prepared by and after recording return to: Tenniecia Williams, Esq. City of Chicago Department of Law 121 North LaSalle Street, Room 600 Chicago, IL 60602
CHICAGO COOPERATIVE REDEVELOPMENT AGREEMENT
This Chicago Cooperative Redevelopment Agreement (this "Agreement") is made as of
this day of , 2022, by and between the City of Chicago, an Illinois municipal
corporation (the "City"), through its Department of Planning and Development ("DPD"), and Chicago Cooperative, an Illinois corporation d/b/a Chicago Market - a Community Co-op (the "Developer").
RECITALS
Constitutional Authority: As a home rule unit of government under Section 6(a), Article VII of the 1970 Constitution of the State of Illinois (the "State"), the City has the power to regulate for the protection of the public health, safety, morals and welfare of its inhabitants, and pursuant thereto, has the power to encourage private development in order to enhance the local tax base, create employment opportunities and to enter into contractual agreements with private parties in order to achieve these goals.
Statutory Authority: The City is authorized under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4-1 et seg., as amended from time to time (the "Act"), to finance projects that eradicate blighted conditions and conservation area factors through the use of tax increment allocation financing for redevelopment projects.
Citv Council Authority: Under ordinances adopted on June 27, 2001 and published in the Journal of Proceedings of the City Council of the City of Chicago (the "Journal") for such date at pages 62341 to 62451 thereof, and under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4.1 et seq., as amended (the "Act"), the City Council (the
|1010|
"City Council") of the City: (i) approved a redevelopment plan and project (the "Original Plan") for a portion ofthe City known as the "Wilson Yard Redevelopment Project Area" (the "Original Area") (the "Plan Ordinance"); (ii) designated the Original Area as a "redevelopment project area" within the requirements of the Act (the "Designation Ordinance"); and (iii) adopted tax increment financing for the Original Area (the "Adoption Ordinance" and, together with the Plan Ordinance and the Designation Ordinance, collectively, the "Original TIF Ordinances").
The Original Plan was amended by the City Council under an ordinance ("Amending Ordinance #1") adopted on November 18, 2009 and published in the Journal for such date at pages 74053 to 74131 thereof ("Plan Amendment #1").
The Original Plan, as amended by Plan Amendment #1, was further amended, and the Original Area was amended, all under an ordinance ("Amending Ordinance #2") adopted on February 10, 2010 and published in the Journal for such date at pages 83890 to 83990 thereof ("Plan Amendment #2 and Area Amendment #1") (the Original Plan, the Plan Amendment #1 and the Plan Amendment #2, collectively, the "TIF Plan") (the Original Area and the Area Amendment #1, collectively, the "TIF Area") (the Original TIF Ordinances, the Amending Ordinance #1 and the Amending Ordinance #2, collectively, the "TIF Ordinances").
The Project: Developer has a lease with the Chicago Transit Authority for a certain property located within the Redevelopment Area at 4620 North Broadway, Chicago, Illinois 60640 and legally described on Exhibit B hereto (the "Property"), and its improvement consisting of a currently-vacant building (the "Building") known as the historic Gerber Building at the Wilson Red Line stop in Uptown and, within the time frames set forth in Section 3.01 hereof, shall rehabilitate the Building into an approximately 18,237 square foot full-service grocery store (13,000 square feet main floor, a basement with close to 5,000 square feet, and a 44-space parking lot) (the "Facility") thereon. The Facility and related improvements (including but not limited to those TIF-Funded Improvements as defined below and set forth on Exhibit C), are collectively referred to herein as the "Project." Ancillary to the Project, the Developer shall employ 71 new full time equivalent employees at the Facility. The completion of the Project would not reasonably be anticipated without the financing contemplated in this Agreement.
Redevelopment Plan: The Project will be carried out in accordance with this Agreement and the Redevelopment Plan.
Citv Financing: The City agrees to use, in the amounts set forth in Section 4.03 hereof, Incremental Taxes (as defined below), to pay for or reimburse Developer for the costs of TIF-Funded Improvements pursuant to the terms and conditions of this Agreement.
Now, therefore, in consideration of the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:
|1010|
SECTION 1. RECITALS, HEADINGS AND EXHIBITS
The foregoing recitals are hereby incorporated into this Agreement by reference. The paragraph and section headings contained in this Agreement, including without limitation those set forth in the following table of contents, are for convenience only and are not intended to limit, vary, define or expand the content thereof. Developer agrees to comply with the requirements set forth in the following exhibits which are attached to and made a part of this Agreement. All provisions listed in the Exhibits have the same force and effect as if they had been listed in the body of this Agreement.
Table of Contents List of Exhibits
1. Recitals, Headings and Exhibits 2. Definitions 3. The Project 4. Financing 5. Conditions Precedent 6. Agreements with Contractors 7. Completion of Construction or Rehabilitation 8. Covenants/Representations/Warranties of Developer 9. Covenants/Representations/Warranties of the City 10. Developer's Employment Obligations 11. Environmental Matters 12.Insurance 13. Indemnification 14. Maintaining Records/Right to Inspect 15. Defaults and Remedies 16. Mortgaging of the Project 17. Notice 18. Miscellaneous A * [intentionally omitted] B * Property C TIF-Funded Improvements D [intentionally omitted] E Construction Contract F Escrow Agreement G * Permitted Liens H-1 *Project Budget H-2 *MBE/WBE Budget I Approved Prior Expenditures J Opinion of Developer's Counsel K [intentionally omitted] L Requisition Form M [intentionally omitted] N Form of Subordination Agreement 0 Form of Payment Bond (An asterisk (*) indicates which exhibits are to be recorded.)
SECTION 2. DEFINITIONS
For purposes of this Agreement, in addition to the terms defined in the foregoing recitals, the following terms shall have the meanings set forth below:
"Act" shall have the meaning set forth in the Recitals hereof.
"Acquisition" shall have the meaning set forth in the Recitals hereof.
|1010|
"Affiliate" shall mean any person or entity directly or indirectly controlling, controlled by or under common control with Developer.
"Annual Compliance Report" shall mean a signed report from Developer to the City (a) itemizing each of Developer's obligations under the Agreement during the preceding calendar year, (b) certifying Developer's compliance or noncompliance with such obligations, (c) attaching evidence (whether or not previously submitted to the City) of such compliance or noncompliance and (d) certifying that Developer is not in default with respect to any provision of the Agreement, the agreements evidencing the Lender Financing, if any, or any related agreements; provided, that the obligations to be covered by the Annual Compliance Report shall include the following: (1) compliance with the operations covenant (Section 8.06-); (2) compliance with the jobs covenant and a jobs report (Section 8.06'): (3) delivery of Financial Statements and unaudited financial statements (Section 8.13): (4) delivery of updated insurance certificates, if applicable (Section
; (5) delivery of evidence of payment of Non-Governmental Charges, if applicable (Section
; Community Benefits compliance (Section 8.24).
"Available Incremental Taxes" shall mean an amount equal to the Incremental Taxes in the TIF Fund from time to time, as adjusted to reflect the amount of the TIF District Administration Fee described in Section 4.05 hereof.
"Available Project Funds" shall have the meaning set forth for such term in Section 4.07
hereof.
"Certificate" shall mean the Certificate of Completion of Rehabilitation described in Section 7.01 hereof.
"Change Order" shall mean any amendment or modification to the Scope Drawings, Plans and Specifications or the Project Budget as described in Section 3.03, Section 3.04 and Section 3.05, respectively.
"Citv Contract" shall have the meaning set forth in Section 8.01(1) hereof.
"Citv Council" shall have the meaning set forth in the Recitals hereof.
"Citv Funds" shall mean the funds described in Section 4.03(b) hereof.
"Closing Date" shall mean the date of execution and delivery of this Agreement by all parties hereto, which shall be deemed to be the date appearing in the first paragraph of this Agreement.
"Contract" shall have the meaning set forth in Section 10.03 hereof. "Contractor" shall have the meaning set forth in Section 10.03 hereof.
|1010|
"Construction Contract" shall mean that certain contract, substantially in the form attached hereto as Exhibit E, to be entered into between Developer and the General Contractor providing for construction of the Project.
"Corporation Counsel" shall mean the City's Department of Law.
"EDS" shall mean the City's Economic Disclosure Statement and Affidavit, on the City's then-current form, whether submitted on paper or via the City's online submission process.
"Emplover(s)" shall have the meaning set forth in Section 10 hereof.
"Employment Plan" shall have the meaning set forth in Section 5.12 hereof.
"Environmental Laws" shall mean any and all federal, state or local statutes, laws, regulations, ordinances, codes, rules, orders, licenses, judgments, decrees or requirements relating to public health and safety and the environment now or hereafter in force, as amended and hereafter amended, including but not limited to (i) the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. Section 9601 et seg,.); (ii) any so-called "Superfund" or "Superlien" law; (iii) the Hazardous Materials Transportation Act (49 U.S.C. Section 1802 et seq.); (iv) the Resource Conservation and Recovery Act (42 U.S.C. Section 6902 et seg); (v) the Clean Air Act (42 U.S.C. Section 7401 et seg.); (vi) the Clean Water Act (33 U.S.C. Section 1251 et seg); (vii) the Toxic Substances Control Act (15 U.S.C. Section 2601 et seg); (viii) the Federal Insecticide, Fungicide and Rodenticide Act (7 U.S.C. Section 136 et seg.); (ix) the Illinois Environmental Protection Act (415 ILCS 5/1 et seg.); and (x) the Municipal Code.
"Equity" shall mean funds of Developer (other than funds derived from Lender Financing) irrevocably available for the Project, in the amount set forth in Section 4.01 hereof, which amount may be increased pursuant to Section 4.06 (Cost Overruns).
"Escrow" shall mean the construction escrow established pursuant to the Escrow Agreement.
"Escrow Agreement" shall mean the Escrow Agreement establishing a construction escrow, to be entered into as of the date hereof by the Title Company (or an affiliate of the Title Company), Developer and Developer's lender(s), substantially in the form of Exhibit F attached hereto.
"Event of Default" shall have the meaning set forth in Section 15 hereof. "Facility" shall have the meaning set forth in the Recitals hereof.
|1010|
"Financial Interest" shall have the meaning set forth for such term in Section 2-156-010 of the Municipal Code.
"Financial Statements" shall mean complete audited financial statements of Developer prepared by a certified public accountant in accordance with generally accepted accounting principles and practices consistently applied throughout the appropriate periods.
"General Contractor" shall mean the general contractor(s) hired by Developer pursuant to Section 6.01.
"Hazardous Materials" shall mean any toxic substance, hazardous substance, hazardous material, hazardous chemical or hazardous, toxic or dangerous waste defined or qualifying as such in (or for the purposes of) any Environmental Law, or any pollutant or contaminant, and shall include, but not be limited to, petroleum (including crude oil), any radioactive material or byproduct material, polychlorinated biphenyls and asbestos in any form or condition.
"Human Rights Ordinance" shall have the meaning set forth in Section 10 hereof.
"In Balance" shall have the meaning set forth in Section 4.07 hereof.
"Incremental Taxes" shall mean such ad valorem taxes which, pursuant to the TIF Adoption Ordinance and Section 5/ll-74.4-8(b) of the Act, are allocated to and when collected are paid to the Treasurer of the City of Chicago for deposit by the Treasurer into the TIF Fund established to pay Redevelopment Project Costs and obligations incurred in the payment thereof.
"Indemnitee" and "Indemnitees" shall have the meanings set forth in Section 13.01 hereof.
"Lender Financing" shall mean funds borrowed by Developer from lenders and irrevocably available to pay for Costs of the Project, in the amount set forth in Section 4.01 hereof.
"MBEfsV shall mean a business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a minority-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
"MBE/WBE Budget" shall mean the budget attached hereto as Exhibit H-2, as described in Section 10.03.
"MBE/WBE Program" shall have the meaning set forth in Section 10.03 hereof.
"Municipal Code" shall mean the Municipal Code of the City of Chicago, as amended from time to time.
|1010|
"New Mortgage" shall have the meaning set forth in Article 16 hereof.
"Non-Governmental Charges" shall mean all non-governmental charges, liens, claims, or encumbrances relating to Developer, the Property or the Project.
"Permitted Liens" shall mean those liens and encumbrances against the Property and/or the Project set forth on Exhibit G hereto.
"Permitted Mortgage" shall have the meaning set forth in Article 16 hereof.
"Plans and Specifications" shall mean final construction documents containing a site plan and working drawings and specifications for the Project, as submitted to the City as the basis for obtaining building permits for the Project.
"Prior Expenditure(s)" shall have the meaning set forth in Section 4.05(a) hereof.
"Project" shall have the meaning set forth in the Recitals hereof.
"Project Budget" shall mean the budget attached hereto as Exhibit H-1, showing the total cost of the Project by line item, furnished by Developer to DPD, in accordance with Section 3.03 hereof.
"Property" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Area" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Plan" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Project Costs" shall mean redevelopment project costs as defined in Section 5/1 l-74.4-3(q) of the Act that are included in the budget set forth in the Redevelopment Plan or otherwise referenced in the Redevelopment Plan.
"Requisition Form" shall mean the document, in the form attached hereto as Exhibit L, to be delivered by Developer to DPD pursuant to Section 4.04 of this Agreement.
"Scope Drawings" shall mean preliminary construction documents containing a site plan and preliminary drawings and specifications for the Project.
"Survey" shall mean a plat of survey in the most recently revised form of ALTA/ACSM land title survey of the Property, meeting the 2011 Minimum Standard Detail Requirements for ALTA/ACSM Land Title Surveys, effective February 23, 2011, dated within 75 days prior to the Closing Date, acceptable in form and content to the City and the Title Company, prepared by a surveyor registered in the State of Illinois, certified to the City and the Title Company, and
|1010|
indicating whether the Property is in a flood hazard area as identified by the United States Federal Emergency Management Agency (and updates thereof to reflect improvements to the Property in connection with the construction of the Facility and related improvements as required by the City or lender(s) providing Lender Financing).
"Term of the Agreement" shall mean the period of time commencing on the Closing Date and ending on the 10-year anniversary of the date of the Certificate, subject to extension(s) pursuant to Section 15.03 (Cure Period).
"TIF Adoption Ordinance" shall have the meaning set forth in the Recitals hereof.
"TIF District Administration Fee" shall mean the fee described in Section 4.05(c) hereof.
"TIF Fund" shall mean the special tax allocation fund created by the City in connection with the Redevelopment Area into which the Incremental Taxes will be deposited.
"TIF-Funded Improvements" shall mean those improvements of the Project which (i) qualify as Redevelopment Project Costs, (ii) are eligible costs under the Redevelopment Plan and (iii) the City has agreed to pay for out of the City Funds, subject to the terms of this Agreement. Exhibit C lists the TIF-Funded Improvements for the Project.
"TIF Ordinances" shall have the meaning set forth in the Recitals hereof.
"Title Company" shall mean [ ].
"Title Policy" shall mean a title insurance policy in the most recently revised ALTA or equivalent form, showing Developer as the insured, noting the recording of this Agreement as an encumbrance against the Property, and a subordination agreement in favor of the City with respect to previously recorded liens against the Property related to Lender Financing, if any, issued by the Title Company.
"WARN Act" shall mean the Worker Adjustment and Retraining Notification Act (29 U.S.C. Section 2101 et seq.).
"WBE(sV shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
|1010|
SECTION 3. THE PROJECT
The Project. With respect to the Facility, Developer shall, pursuant to the Plans and Specifications and subject to the provisions of Section 18.17 hereof: (i) commence rehabilitation no later than 30 days after the Closing Date; and (ii) complete rehabilitation and conduct business operations therein no later than the 18-month anniversary of the Closing Date.
Scope Drawings and Plans and Specifications. Developer has delivered the Scope Drawings and Plans and Specifications to DPD and DPD has approved same. After such initial approval, subsequent proposed changes to the Scope Drawings or Plans and Specifications shall be submitted to DPD as a Change Order pursuant to Section 3.04 hereof. The Scope Drawings and Plans and Specifications shall at all times conform to the Redevelopment Plan and all applicable federal, state and local laws, ordinances and regulations. Developer shall submit all necessary documents to the City's Building Department, Department of Transportation and such other City departments or governmental authorities as may be necessary to acquire building permits and other required approvals for the Project.
Project Budget. Developer has furnished to DPD, and DPD has approved, a Project Budget showing total costs for the Project in an amount not less than $8,699,536. Developer hereby certifies to the City that the City Funds, together with Lender Financing and Equity described in Section 4.02 hereof, shall be sufficient to complete the Project. Developer hereby certifies to the City that (a) it has Lender Financing and Equity in an amount sufficient to pay for all Project costs; and (b) the Project Budget is true, correct and complete in all material respects. Developer shall promptly deliver to DPD certified copies of any Change Orders with respect to the Project Budget for approval pursuant to Section 3.04 hereof.
Change Orders. Except as provided below in this Section 3.04, all Change Orders (and documentation substantiating the need and identifying the source of funding therefor) relating to changes to the Project must be submitted by Developer to DPD concurrently with the progress reports described in Section 3.07 hereof; provided, that any Change Order relating to any of the following must be submitted by Developer to DPD for DPD's prior written approval: (a) a reduction in the gross or net square footage of the Project by five percent (5%) or more (either individually or cumulatively); (b) a change in the use of the Project to a use other than as described in Recital D to this Agreement; (c) a delay in the completion of the Project by six (6) months or more; or (d) Change Orders resulting in an aggregate increase to the Project Budget for the Project often percent (10%) or more. Developer shall not authorize or permit the performance of any work relating to any Change Order or the furnishing of materials in connection therewith prior to the receipt by Developer of DPD's written approval (to the extent said City prior approval is required pursuant to the terms of this Agreement). The Construction Contract, and each contract between the General Contractor and any subcontractor, shall contain a provision to this effect. An approved Change Order shall not be deemed to imply any obligation on the part of the City to increase the amount of City Funds which the City has pledged pursuant to this Agreement or provide any other additional assistance to Developer. Notwithstanding anything to the contrary in
|10 10|
this Section 3.04. Change Orders other than those set forth above do not require DPD's prior written approval as set forth in this Section 3.04, but DPD shall be notified in writing of all such Change Orders within 10 business days after the execution of such Change Order and Developer, in connection with such notice, shall identify to DPD the source of funding therefor.
DPD Approval. Any approval granted by DPD of the Scope Drawings, Plans and Specifications and the Change Orders is for the purposes of this Agreement only and does not affect or constitute any approval required by any other City department or pursuant to any City ordinance, code, regulation or any other governmental approval, nor does any approval by DPD pursuant to this Agreement constitute approval of the quality, structural soundness or safety of the Property or the Project.
Other Approvals. Any DPD approval under this Agreement shall have no effect upon, nor shall it operate as a waiver of, Developer's obligations to comply with the provisions of Section 5.03 (Other Governmental Approvals) hereof. Developer shall not commence construction of the Project until Developer has obtained all necessary permits and approvals (including but not limited to DPD's approval of the Scope Drawings and Plans and Specifications) and proof of the General Contractor's and each subcontractor's bonding as required hereunder.
Progress Reports and Survey Updates. Developer shall provide DPD with written quarterly progress reports detailing the status of the Project, including a revised completion date, if necessary (with any change in completion date being considered a Change Order, requiring DPD's written approval pursuant to Section 3.04"). Developer shall provide three (3) copies of an updated Survey to DPD upon the request of DPD or any lender providing Lender Financing, reflecting improvements made to the Property.
Inspecting Agent or Architect. An independent agent or architect (other than Developer's architect) approved by DPD shall be selected to act as the inspecting agent or architect, at Developer's expense, for the Project. The inspecting agent or architect shall perform periodic inspections with respect to the Project, providing certifications with respect thereto to DPD, prior to requests for disbursement for costs related to the Project hereunder pursuant to the Escrow Agreement, provided, however, that to the extent there is any disagreement between DPD's inspecting architect and the Lender's inspecting architect, DPD agrees to defer to the Lender's inspecting architect.
Barricades. Prior to commencing any construction requiring barricades, Developer shall install a construction barricade of a type and appearance satisfactory to the City and constructed in compliance with all applicable federal, state or City laws, ordinances and regulations. DPD retains the right to approve the maintenance, appearance, color scheme, painting, nature, type, content and design of all barricades.
Signs and Public Relations. Developer shall erect a sign of size and style approved by the City in a conspicuous location on the Property during the Project, indicating that financing
10
has been provided by the City. The sign may also name other financing sources for the Project. The City reserves the right to include the name, photograph, artistic rendering of the Project and other pertinent infonnation regarding Developer, the Property and the Project in the C'ty's promotional literature and communications.
Utility Connections. Developer may connect all on-site water, sanitary, storm and sewer lines constructed on the Property to City utility lines existing on or near the perimeter of the Property, provided Developer first complies with all City requirements governing such connections, including the payment of customary fees and costs related thereto.
Permit Fees. In connection with the Project, Developer shall be obligated to pay only those building, permit, engineering, tap on and inspection fees that are assessed on a uniform basis throughout the City of Chicago and are of general applicability to other property within the City of Chicago, [waivers for City permit fees to be negotiated if Facility has historic preservation designation(s)]
SECTION 4. FINANCING
4.01 Total Project Cost and Sources of Funds. The cost of the Project is estimated to be $8,699,536 ("Total Project Costs"), to be applied in the manner set forth in the Project Budget. Such costs shall be funded from the following sources:
Equity (subject to Section 4.06) Lender Financing
City Funds (subject to Section 4.03)
$950,000
$1,949,536
$5,800,000
ESTIMATED TOTAL
Developer Funds. Equity and/or Lender Financing may be used to pay any Project cost, including but not limited to Redevelopment Project Costs.
City Funds. City Funds may only be used to pay directly or reimburse Developer for costs of TIF-Funded Improvements that constitute Redevelopment Project Costs. Exhibit C sets forth, by line item, the TIF-Funded Improvements for the Project, and the maximum amount of costs that may be paid by or reimbursed from City Funds for each line item therein (subject to Sections 4.03(b) and 4.05(d)), contingent upon receipt by the City of documentation satisfactory in form and substance to DPD evidencing such cost and its eligibility as a Redevelopment Project Cost.
(b) Sources of City Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03 and Section 5 hereof, the City hereby agrees to provide City funds from the sources and in the amounts described directly below (the "City Funds") to pay for or reimburse Developer for the costs of the TIF-Funded Improvements:
11
Source of Citv Funds Maximum Amount
Available Incremental Taxes $5,800,000
provided, however, that the total amount of City Funds expended for TIF-Funded Improvements shall be an amount not to exceed the lesser of $5,800,000, or 66.6%, of the actual total Project costs; and
provided, however, that if the Total Project Costs do not exceed $8,699,536, then the maximum amount of City Funds shall be reduced dollar-for-dollar;
provided, however, that if a default occurs under Section 8.25 hereof, the City shall have the right to reduce the total amount of the City Funds by $250,000; and
provided further, that the City Funds to be derived from Available Incremental Taxes shall be available to pay costs related to TIF-Funded Improvements and allocated by the City for that purpose only so long as the amount of the Available Incremental Taxes deposited into the TIF Fund shall be sufficient to pay for such costs.
Developer acknowledges and agrees that the City's obligation to pay for TIF-Funded Improvements is contingent upon the fulfillment of the conditions set forth above. In the event that such conditions are not fulfilled, the amount of Equity to be contributed by Developer pursuant to Section 4.01 hereof shall increase proportionately.
(c) Disbursements of City Funds. Subject to reductions in amounts pursuant to the operation of other portions of this Agreement, the City shall commence paying City Funds, in lump sum amounts, to Developer as reimbursement for any TIF-Funded Improvements incurred by Developer, pursuant to the following schedule; provided, however, that each payment of City Funds is expressly contingent upon DPD having first received, along with the Requisition Form, documentation satisfactory in form and substance to DPD evidencing Developer's compliance with the applicable operation covenant and jobs report then due, as set forth in Section 8.06 hereof.
Date of Payment: Maximum Amount of Each Payment
First Payment: Following the issuance of the Certificate $4,350,000
Final Payment:
12
Following the first anniversary of the issuance of the Certificate
Requisition Form. To request each payment above, the Developer shall file a Requisition Form with DPD.
Treatment of Prior Expenditures and Subsequent Disbursements.
Prior Disbursements. Only those expenditures made by Developer with respect to the Project prior to the Closing Date, evidenced by documentation satisfactory to DPD and approved by DPD as satisfying costs covered in the Project Budget, shall be considered previously contributed Equity or Lender Financing hereunder (the "Prior Expenditures"). DPD shall have the right, in its sole discretion, to disallow any such expenditure as a Prior Expenditure. Exhibit I hereto sets forth the prior expenditures approved by DPD as of the date hereof as Prior Expenditures. Prior Expenditures made for items other than TIF-Funded Improvements shall not be reimbursed to Developer but shall reduce the amount of Equity and/or Lender Financing required to be contributed by Developer pursuant to Section 4.01 hereof.
TIF District Administration Fee. Annually, the City may allocate an amount (the "TIF District Administration Fee") not to exceed five percent (5%) of the Incremental Taxes for payment of costs incurred by the City for the administration and monitoring of the Redevelopment Area, including the Project. Such fee shall be in addition to and shall not be deducted from or considered a part of the City Funds, and the City shall have the right to receive such funds prior to any payment of City Funds hereunder.
(d) Allocation Among Line Items. Disbursements for expenditures related to TIF-Funded Improvements may be allocated to and charged against the appropriate line only, with transfers of costs and expenses from one line item to another, without the prior written consent of DPD, being prohibited; provided, however, that such transfers among line items, in an amount not to exceed $25,000, or $100,000 in the aggregate, may be made without the prior written consent of DPD.
Cost Overruns. If the aggregate cost of the TIF-Funded Improvements exceeds City Funds available pursuant to Section 4.03 hereof, or if the cost of completing the Project exceeds the Project Budget, Developer shall be solely responsible for such excess costs, and shall hold the City harmless from any and all costs and expenses of completing the TIF-Funded Improvements in excess of City Funds and of completing the Project.
Conditional Grant. The City Funds being provided hereunder are being granted on a conditional basis, subject to the Developer's compliance with the provisions of this Agreement. The City Funds arc subject to being reimbursed by Developer to the City, in whole or in part, pursuant to the terms of Section 15.02 hereof.
13
4.08 Cost of Issuance. Developer shall be responsible for paying all costs relating to the issuance of the opinion described in Section 5.09(b') hereof.
SECTION 5. CONDITIONS PRECEDENT
The following conditions have been complied with to the City's satisfaction on or prior to the Closing Date:
Project Budget. Developer has submitted to DPD, and DPD has approved, a Project Budget in accordance with the provisions of Section 3.03 hereof.
Scope Drawings and Plans and Specifications. Developer has submitted to DPD, and DPD has approved, the Scope Drawings and Plans and Specifications accordance with the provisions of Section 3.02 hereof.
Other Governmental Approvals. Developer has secured a final building permit and all other necessary approvals and permits required by any state, federal, or local statute, ordinance or regulation, and has submitted evidence thereof to DPD.
Financing. Developer has furnished proof reasonably acceptable to the City that Developer has Equity and Lender Financing in the amounts set forth in Section 4.01 hereof to complete the Project and satisfy its obligations under this Agreement. If a portion of such funds consists of Lender Financing, Developer has furnished proof as of the Closing Date that the proceeds thereof are available to be drawn upon by Developer as needed and are sufficient (along with the Equity set forth in Section 4.01 to complete the Project. Any liens against the Property in existence at the Closing Date shall have been subordinated to certain encumbrances of the City set forth herein pursuant to a Subordination Agreement, in a form acceptable to the City, executed on or prior to the Closing Date, which is to be recorded, at the expense of Developer, with the Office of the Cook County Clerk.
Evidence of Lease. On the Closing Date, Developer has furnished the City with a copy ofthe lease for the Property and a title policy evidencing Developer's leasehold interest in the Property (the "Title Policy"). Developer has provided to DPD, on or prior to the Closing Date, certified copies of all easements and encumbrances of record with respect to the Property not addressed, to DPD's satisfaction, by the Title Policy and any endorsements thereto.
Evidence of Clean Title. Developer, at its own expense, has provided the City with searches as indicated in the chart below under Developer's name (and the following trade names of Developer: "Chicago Market - A Community Co-op") showing no liens against Developer, the Property or any fixtures now or hereafter affixed thereto, except for the Permitted Liens:
Jurisdiction Searches
Secretary of State UCC, Federal tax
14
Cook County Recorder UCC, Fixtures, Federal tax, State tax, Memoranda of judgments
U.S. District Court Pending suits and judgments
Clerk of Circuit Court, Cook County Pending suits and judgments
Surveys. Developer has furnished the City with a copy of the Survey.
Insurance. Developer, at its own expense, has insured the Property in accordance with Section 12 hereof, and has delivered certificates required pursuant to Section 12 hereof evidencing the required coverages to DPD.
Opinion of Developer's Counsel. On the Closing Date, Developer has furnished the City with an opinion of counsel, substantially in the form attached hereto as Exhibit J, with such changes as required by or acceptable to Corporation Counsel. If Developer has engaged special counsel in connection with the Project, and such special counsel is unwilling or unable to give some of the opinions set forth in Exhibit J hereto, such opinions were obtained by Developer from its general corporate counsel.
Evidence of Prior Expenditures. Developer has provided evidence satisfactory to DPD in its sole discretion of the Prior Expenditures in accordance with the provisions of Section 4.05(a) hereof.
Financial Statements. Developer has provided Financial Statements to DPD for its most recent fiscal year and audited or unaudited interim financial statements.
Documentation; Employment Plan. The Developer has provided documentation to DPD, satisfactory in form and substance to DPD, with respect to current employment matters in connection with the construction or rehabilitation work on the Project, including the reports described in Section 8.07.
Environmental, [intentionally omitted]
Corporate Documents; Economic Disclosure Statement. Developer has provided a copy of its Articles of Certificate of Incorporation containing the original certification of the Secretary of State of its state of incorporation; certificates of good standing from trie-Secretary of State of its state of incorporation and all other states in which Developer is qualified to do business; a secretary's certificate in such form and substance as the Corporation Counsel may require; bylaws of the corporation; and such other corporate documentation as the City has requested.
Developer has provided to the City an EDS, dated as of the Closing Date, which is incorporated by reference, and Developer further will provide any other affidavits or certifications as may be required by federal, state or local law in the award of public contracts, all of which
15
affidavits or certifications are incorporated by reference. Notwithstanding acceptance by the City of the EDS, failure of the EDS to include all information required under the Municipal Code renders this Agreement voidable at the option of the City. Developer and any other parties required by this Section 5.14 to complete an EDS must promptly update their EDS(s) on file with the City whenever any information or response provided in the EDS(s) is no longer complete and accurate, including changes in ownership and changes in disclosures and information pertaining to ineligibility to do business with the City under Chapter 1-23 of the Municipal Code, as such is required under Sec. 2-154-020, and failure to promptly provide the updated EDS(s) to the City will constitute an event of default under this Agreement.
5.15 Litigation. Developer has provided to Corporation Counsel and DPD, a description of all pending or threatened litigation or administrative proceedings involving Developer, specifying, in each case, the amount of each claim, an estimate of probable liability, the amount of any reserves taken in connection therewith and whether (and to what extent) such potential liability is covered by insurance.
SECTION 6. AGREEMENTS WITH CONTRACTORS
6.01 Bid Requirement for General Contractor and Subcontractors, (a) Except as set forth in Section 6.01(b) below, prior to entering into an agreement with a General Contractor or any subcontractor for construction of the Project, Developer shall solicit, or shall cause the General Contractor to solicit, bids from qualified contractors eligible to do business with, and having an office located in, the City of Chicago, and shall submit all bids received to DPD for its inspection and written approval, (i) For the TIF-Funded Improvements, Developer shall select the General Contractor (or shall cause the General Contractor to select the subcontractor) submitting the lowest responsible bid who can complete the Project in a timely manner. If Developer selects a General Contractor (or the General Contractor selects any subcontractor) submitting other than the lowest responsible bid for the TIF-Funded Improvements, the difference between the lowest responsible bid and the bid selected may not be paid out of City Funds, (ii) For Project work other than the TIF-Funded Improvements, if Developer selects a General Contractor (or the General Contractor selects any subcontractor) who has not submitted the lowest responsible bid, the difference between the lowest responsible bid and the higher bid selected shall be subtracted from the actual total Project costs for purposes of the calculation of the amount of City Funds to be contributed to the Project pursuant to Section 4.03(b) hereof. Developer shall submit copies ofthe Construction Contract to DPD in accordance with Section 6.02 below. Photocopies of all subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DPD within five (5) business days of the execution thereof. Developer shall ensure that the General Contractor shall not (and shall cause the General Contractor to ensure that the subcontractors shall not) begin work on the Project until the Plans and Specifications have been approved by DPD and all requisite permits have been obtained.
(b) If, prior to entering into an agreement with a General Contractor for construction of the Project, Developer does not solicit bids pursuant to Section 6.01(a) hereof, then the fee of the
16
General Contractor proposed to be paid out of City Funds shall not exceed [ J% of the total
amount of the Construction Contract. Except as explicitly stated in this paragraph, all other provisions of Section 6.01(a) shall apply, including but not limited to the requirement that the General Contractor shall solicit competitive bids from all subcontractors.
Construction Contract. Prior to the execution thereof, Developer shall deliver to DPD a copy ofthe proposed Construction Contract with the General Contractor selected to handle the Project in accordance with Section 6.01 above, for DPD's prior written approval, which shall be granted or denied within ten (10) business days after delivery thereof. Within ten (10) business days after execution of such contract by Developer, the General Contractor and any other parties thereto, Developer shall deliver to DPD and Corporation Counsel a certified copy of such contract together with any modifications, amendments or supplements thereto.
Performance and Payment Bonds. Prior to the commencement of any portion of the Project which includes work on the public way, Developer shall require that the General Contractor be bonded for its payment by sureties having an AA rating or better using a bond in the form attached as Exhibit O hereto. The City shall be named as obligee or co-obligee on any such bonds.
Employment Opportunitv. Developer shall contractually obligate and cause the General Contractor and each subcontractor to agree to the provisions of Section 10 hereof.
6.05 Other Provisions. In addition to the requirements ofthis Section 6, the Construction
Contract and each contract with any subcontractor shall contain provisions required pursuant to
Section 3.04 (Change Orders), Section 8.09 (Prevailing Wage), Section 10.01(e) (Employment
Opportunity), Section 10.02 (City Resident Employment Requirement), Section 10.03
(MBE/WBE Requirements, as applicable), Section 12 (Insurance) and Section 14.01 (Books and
Records) hereof. Photocopies of all contracts or subcontracts entered or to be entered into in
connection with the TIF-Funded Improvements shall be provided to DPD within five (5) business
days of the execution thereof.
SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION
7.01 Certificate of Completion of Construction or Rehabilitation.
Upon:
completion of the rehabilitation of the Project,
the receipt by Developer of a Certificate of Occupancy,
the commencement of full-service grocery store operations within the Facility,
issuance by DPD's construction compliance division of a closeout letter showing compliance with MBE and WBE, prevailing wage, and City Residency,
evidence acceptable to DPD that the Project has complied with the Chicago Sustainable Development Policy,
17
(f) evidence that Developer has incurred Total Project Costs that equal or exceed
$8,699,536, and
(g) evidence that Developer has incurred TIF-Funded Improvements that equal or exceed
the amount of City Funds,
all in accordance with the terms of this Agreement and after the final disbursement from the Escrow, and upon Developer's written request, DPD shall issue to Developer a Certificate in recordable form certifying that Developer has fulfilled its obligation to complete the Project in accordance with the terms of this Agreement. DPD shall respond to Developer's written request for a Certificate within forty-five (45) days by issuing either a Certificate or a written statement detailing the ways in which the Project does not conform to this Agreement or has not been satisfactorily completed, and the measures which must be taken by Developer in order to obtain the Certificate. Developer may resubmit a written request for a Certificate upon completion of such measures.
Effect of Issuance of Certificate; Continuing Obligations. The Certificate relates only to the rehabilitation of the Project, and upon its issuance, the City will certify that the terms of the Agreement specifically related to Developer's obligation to complete such activities have been satisfied. After the issuance of a Certificate, however, all executory terms and conditions of this Agreement and all representations and covenants contained herein will continue to remain in full force and effect throughout the Term of the Agreement as to the parties described in the following paragraph, and the issuance of the Certificate shall not be construed as a waiver by the City of any of its rights and remedies pursuant to such executory terms.
Those covenants specifically described at Sections 8.02. 8.19 and 18.14 as covenants that run with the land are the only covenants in this Agreement intended to be binding upon any transferee of the Property (including an assignee as described in the following sentence) throughout the Term of the Agreement notwithstanding the issuance of a Certificate; provided, that upon the issuance of a Certificate, the covenants set forth in Section 8.02 shall be deemed to have been fulfilled.
Failure to Complete. If the Developer fails to complete the Project in accordance with the terms of this Agreement, then the City has, but shall not be limited to, the right to terminate this Agreement and cease all disbursement of City Funds not yet disbursed pursuant hereto; and the right to seek reimbursement of the City Funds from the Developer.
Notice of Expiration of Term of Agreement. Upon the expiration of the Term ofthe Agreement, DPD shall provide the Developer, at the Developer's written request, with a written notice in recordable form stating that the Term of the Agreement has expired.
SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF DEVELOPER.
8.01 General. Developer represents, warrants and covenants, as of the date of this
18
Agreement and as ofthe date of each disbursement of City Funds hereunder, that:
Developer is an Illinois corporation duly organized, validly existing, qualified to do business in Illinois, and licensed to do business in any other state where, due to the nature of its activities or properties, such qualification or license is required;
Developer has the right, power and authority to enter into, execute, deliver and perform this Agreement;
the execution, delivery and performance by Developer of this Agreement has been duly authorized by all necessary corporate action, and does not and will not violate its Articles of Incorporation or by-laws as amended and supplemented, any applicable provision of law, or constitute a breach of, default under or require any consent under any agreement, instrument or document to which Developer is now a party or by which Developer is now or may become bound;
unless otherwise permitted or not prohibited pursuant to or under the terms of this Agreement, Developer has acquired and maintained a leasehold on the Property (and all improvements thereon) free and clear of all liens (except for the Permitted Liens, Lender Financing as disclosed in the Project Budget and non-governmental charges that Developer is contesting in good faith pursuant to Section 8.15 hereof);
Developer is now and for the Term of the Agreement shall remain solvent and able to pay its debts as they mature;
there are no actions or proceedings by or before any court, governmental commission, board, bureau or any other administrative agency pending, threatened or affecting Developer which would impair its ability to perform under this Agreement;
Developer has and shall maintain all government permits, certificates and consents (including, without limitation, appropriate environmental approvals) necessary to conduct its business and to construct, complete and operate the Project;
Developer is not in default with respect to any indenture, loan agreement, mortgage, deed, note or any other agreement or instrument related to the borrowing of money to which Developer is a party or by which Developer is bound, the Financial Statements are, and when hereafter required to be submitted will be, complete, correct in all material respects and accurately present the assets, liabilities, results of operations and financial condition of Developer, and there has been no material adverse change in the assets, liabilities, results of operations or financial condition of Developer since the date of Developer's most recent Financial Statements;
(j) prior to the issuance of a Certificate, Developer shall not do any of the following without the prior written consent of DPD: (1) be a party to any merger, liquidation or consolidation; (2) sell, transfer, convey, lease or otherwise dispose of all or substantially all of its assets or any portion
19
of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) except in the ordinary course of business; (3) enter into any transaction outside the ordinary course of Developer's business; (4) assume, guarantee, endorse, or otherwise become liable in connection with the obligations of any other person or entity; or (5) enter into any transaction that would cause a material and detrimental change to Developer's financial condition, provided that the City expressly consents to the Lender Financing and Equity and all guarantees, indemnities, and obligations associated therewith;
(k) Developer has not incurred, and, prior to the issuance of a Certificate, shall not, without the prior written consent of the Commissioner of DPD, allow the existence of any liens against the Property (or improvements thereon) other than the Permitted Liens; or incur any indebtedness, secured or to be secured by the Property (or improvements thereon) or any fixtures now or hereafter attached thereto, except Lender Financing disclosed in the Project Budget;
(1) has not made or caused to be made, directly or indirectly, any payment, gratuity or offer of employment in connection with the Agreement or any contract paid from the City treasury or pursuant to City ordinance, for services to any City agency ("City Contract") as an inducement for the City to enter into the Agreement or any City Contract with Developer in violation of Chapter 2-156-120 ofthe Municipal Code;
(m) neither Developer nor any affiliate of Developer is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List. For purposes of this subparagraph (m) only, the term "affiliate," when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.
(n) Developer understands that (i) the City Funds are limited obligations of the City, payable solely from moneys on deposit in the TIF Fund; (ii) the City Funds do not constitute indebtedness of the City within the meaning of any constitutional or statutory provision or limitation; (iii) Developer will have no right to compel the exercise of any taxing power of the City for payment of the City Funds; and (iv) the City Funds do not and will not represent or constitute a general obligation or a pledge of the faith and credit of the City, the State of Illinois or any political subdivision thereof;
20
(o) Developer has sufficient knowledge and experience in financial and business matters, including municipal projects and revenues of the kind represented by the City Funds, and has been supplied with access to information to be able to evaluate the risks associated with the receipt of City Funds;
(p) Developer understands that there is no assurance as to the amount or timing of receipt of City Funds;
(q) Developer understands it may not sell, assign, pledge or otherwise transfer its interest in this Agreement or City Funds in whole or in part except in accordance with the terms of Section 18.21 of this Agreement, and, to the fullest extent permitted by law, agrees to indemnify the City for any losses, claims, damages or expenses relating to or based upon any sale, assignment, pledge or transfer of City Funds in violation ofthis Agreement; and Developer acknowledges that with respect to City Funds, the City has no obligation to provide any continuing disclosure to the Electronic Municipal Market Access System maintained by the Municipal Securities Rulemaking Board, to any holder of a note relating to City Funds or any other person under Rule 15c2-12 of the Commission promulgated under the Securities Exchange Act of 1934 or otherwise, and shall have no liability with respect thereto.
Covenant to RedevelopError! Bookmark not defined Upon DPD's approval of the Project Budget, the Scope Drawings and Plans and Specifications as provided in Sections 3.02 and 3.03 hereof, and Developer's receipt of all required building permits and governmental approvals, Developer shall redevelop the Property in accordance with this Agreement and all Exhibits attached hereto, the TIF Ordinances, the Scope Drawings, Plans and Specifications, Project Budget and all amendments thereto, and all federal, state and local laws, ordinances, rules, regulations, executive orders and codes applicable to the Project, the Property and/or Developer. The covenants set forth in this Section shall run with the land and be binding upon any transferee, but shall be deemed satisfied upon issuance by the City of a Certificate with respect thereto.
Redevelopment Plan. Developer represents that the Project is and shall be in compliance with all of the terms of the Redevelopment Plan, which is hereby incorporated by reference into this Agreement.
Use of Citv Funds. City Funds disbursed to Developer shall be used by Developer solely to pay for (or to reimburse Developer for its payment for) the TIF-Funded Improvements as provided in this Agreement.
Other Bonds. Developer shall, at the request of the City, agree to any reasonable amendments to this Agreement that are necessary or desirable in order for the City to issue (in its sole discretion) any bonds in connection with the Redevelopment Area, the proceeds of which may be used to reimburse the City for expenditures made in connection with, or provide a source of funds for the payment for, the TIF-Funded Improvements (the "Bonds"); provided, however, that any such amendments shall not have a material adverse effect on Developer, the lender providing
21
Lender Financing, or the Project. Developer shall, at Developer's expense, cooperate and provide reasonable assistance in connection with the marketing of any such Bonds, including but not limited to providing written descriptions of the Project, making representations, providing information regarding its financial condition and assisting the City in preparing an offering statement with respect thereto.
Job Creation Aspirations and Retention; Operations Covenant. Developer aspires to create 71 full-time equivalent, permanent jobs on-site at the Project upon the commencement of business operations through and including the Term of the Agreement. Developer aspires to create
[ ] full-time equivalent construction jobs on-site at the Project during the rehabilitation of
the Facility. As part of each Annual Compliance Report, Developer will prepare and submit to DPD a jobs report detailing (a) each employee's status as full-time or part-time, (b) ZIP code of primary residency for each employee, (c) total employment tenure in months, and (d) wages above or below the "Living Wage" rate as defined for that year. Developer's failure to reach the goals herein will not constitute an Event of Default.
Developer covenants and agrees to maintain a full-service grocery store within the Facility upon the commencement of business operations through and including the Term of the Agreement. This covenant is subject to special cure period provisions as set forth in Section 15.03 hereof.
Employment Opportunity. Developer covenants and agrees to abide by, and contractually obligate and use reasonable efforts to cause the General Contractor and each subcontractor to abide by the terms set forth in Section 10 hereof.
Employment Profile. Developer shall submit, and contractually obligate and cause the General Contractor or any subcontractor to submit, to DPD, from time to time, statements of its employment profile upon DPD's request.
Prevailing Wage. Developer covenants and agrees to pay, and to contractually obligate and cause the General Contractor and each subcontractor to pay, the prevailing wage rate as ascertained by the Illinois Department of Labor (the "Department"), to all Project employees. All such contracts shall list the specified rates to be paid to all laborers, workers and mechanics for each craft or type of worker or mechanic employed pursuant to such contract. If the Department revises such prevailing wage rates, the revised rates shall apply to all such contracts. Upon the City's request, Developer shall provide the City with copies of all such contracts entered into by Developer or the General Contractor to evidence compliance with this Section 8.09.
Arms-Length Transactions. Unless DPD has given its prior written consent with respect thereto, no Affiliate of Developer may receive any portion of City Funds, directly or indirectly, in payment for work done, services provided or materials supplied in connection with any TIF-Funded Improvement. Developer shall provide information with respect to any entity to receive City Funds directly or indirectly (whether through payment to the Affiliate by Developer
22
and reimbursement to Developer for such costs using City Funds, or otherwise), upon DPD's request, prior to any such disbursement.
Conflict of Interest. Pursuant to Section 5/1 l-74.4-4(n) of the Act, Developer represents, warrants and covenants that, to the best of its knowledge, no member, official, or employee of the City, or of any commission or committee exercising authority over the Project, the Redevelopment Area or the Redevelopment Plan, or any consultant hired by the City or Developer with respect thereto, owns or controls, has owned or controlled or will own or control any interest, and no such person shall represent any person, as agent or otherwise, who owns or controls, has owned or controlled, or will own or control any interest, direct or indirect, in Developer's business, the Property or any other property in the Redevelopment Area.
Disclosure of Interest. Developer's counsel has no direct or indirect financial ownership interest in Developer, the Property or any other aspect of the Project.
Financial Statements. Developer shall obtain and provide to DPD Financial Statements for Developer's fiscal year ended 2022 and each fiscal year thereafter for the Term of the Agreement. In addition, Developer shall submit unaudited financial statements as soon as reasonably practical following the close of each fiscal year and for such other periods as DPD may request.
Insurance. Developer, at its own expense, shall comply with all provisions of Section 12 hereof
Non-Governmental Charges.
Payment of Non-Governmental Charges. Except for the Permitted Liens, Developer agrees to pay or cause to be paid when due any Non-Governmental Charge assessed or imposed upon the Project, the Property or any fixtures that are or may become attached thereto, which creates, may create, or appears to create a lien upon all or any portion of the Property or Project; provided however, that if such Non-Governmental Charge may be paid in installments, Developer may pay the same together with any accrued interest thereon in installments as they become due and before any fine, penalty, interest, or cost may be added thereto for nonpayment. Developer shall furnish to DPD, within 30 days of DPD's request, official receipts from the appropriate entity, or other proof satisfactory to DPD, evidencing payment of the Non-Governmental Charge in question.
Right to Contest. Developer has the right, before any delinquency occurs:
(i) to contest or object in good faith to the amount or validity of any Non-Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted, in such manner as shall stay the collection of the contested Non-Governmental Charge, prevent the imposition of a lien or remove such lien, or prevent the sale or forfeiture of the
23
Property (so long as no such contest or objection shall be deemed or construed to relieve, modify or extend Developer's covenants to pay any such Non-Governmental Charge at the ' time and in the manner provided in this Section 8.151; or
(ii) at DPD's sole option, to furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property or any portion thereof or any fixtures that are or may be attached thereto, during the pendency of such contest, adequate to pay fully any such contested Non-Governmental Charge and all interest and penalties upon the adverse determination of such contest.
Developer's Liabilities. Developer shall not enter into any transaction that would materially and adversely affect its ability to perform its obligations hereunder or to repay any material liabilities or perform any material obligations of Developer to any other person or entity. Developer shall immediately notify DPD of any and all events or actions which may materially affect Developer's ability to carry on its business operations or perform its obligations under this Agreement or any other documents and agreements.
Compliance with Laws. To the best of Developer's knowledge, after diligent inquiry, the Property and the Project are' and shall be in compliance with all applicable federal, state and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the Project and the Property. Upon the City's request, Developer shall provide evidence satisfactory to the City of such compliance.
Recording and Filing. Developer shall cause this Agreement, certain exhibits (as specified by Corporation Counsel), all amendments and supplements hereto to be recorded and filed against the Property on the date hereof in the conveyance and real property records of the county in which the Project is located. This Agreement shall be recorded prior to any mortgage made in connection with Lender Financing. Developer shall pay all fees and charges incurred in connection with any such recording. Upon recording, Developer shall immediately transmit to the City an executed original of this Agreement showing the date and recording number of record.
Real Estate Provisions.
(a) Governmental Charges
(i) Payment of Governmental Charges. Developer agrees to pay or cause to be paid when due all Governmental Charges (as defined below) which are assessed or imposed upon Developer, the Property or the Project, or become due and payable, and which create or may create a lien upon Developer or all or any portion of the Property or the Project. "Governmental Charge" shall mean all federal, State, county, the City, or other governmental (or any instrumentality, division, agency, body, or department thereof) taxes,
24
levies, assessments, charges, liens, claims or encumbrances (except for those assessed by foreign nations, states other than the State of Illinois, counties of the State other than Cook County, and municipalities other than the City) relating to Developer, the Property or the Project including but not limited to Leasehold Taxes.
(ii) Right to Contest. Developer has the right before any delinquency occurs to contest or object in good faith to the amount or validity of any Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted in such manner as shall stay the collection of the contested Governmental Charge and prevent the imposition ofa lien or the sale or forfeiture of the Property. Developer's right to challenge Leasehold Taxes applicable to the Property is limited as provided for in Section 8.19(c) below; provided, that such Leasehold Taxes must be paid in full when due and may be disputed only after such payment is made. No such contest or objection shall be deemed or construed in any way as relieving, modifying or extending Developer's covenants to pay any such Governmental Charge at the time and in the manner provided in this Agreement unless Developer has given prior written notice to DPD of Developer's intent to contest or object to a Governmental Charge and, unless, at DPD's sole option, (i) Developer shall demonstrate to DPD's satisfaction that legal proceedings instituted by Developer contesting or objecting to a Governmental Charge shall conclusively operate to prevent or remove a lien against, or the sale or forfeiture of, all or any part of the Property to satisfy such Governmental Charge prior to final determination of such proceedings; and/or (ii) Developer shall furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property during the pendency of such contest, adequate to pay fully any such contested Governmental Charge and all interest and penalties upon the adverse determination of such contest.
(b) Developer's Failure To Pay Or Discharge Lien. If Developer fails to pay any Governmental Charge or to obtain discharge of the same, Developer shall advise DPD thereof in writing, at which time DPD may, but shall not be obligated to, and without waiving or releasing any obligation or liability of Developer under this Agreement, in DPD's sole discretion, make such payment, or any part thereof, or obtain such discharge and take any other action with respect thereto which DPD deems advisable. All sums so paid by DPD, if any, and any expenses, if any, including reasonable attorneys' fees, court costs, expenses and other charges relating thereto, shall be promptly disbursed to DPD by Developer. Notwithstanding anything contained herein to the contrary, this paragraph shall not be construed to obligate the City to pay any such Governmental Charge. Additionally, if Developer fails to pay any Governmental Charge, the City, in its sole discretion, may require Developer to submit to the City audited Financial Statements at Developer's own expense.
8.20 Annual Compliance Reports. Developer shall submit to DPD an Annual Compliance Report beginning on the one-year anniversary of the date of issuance of the Certificate and
25
continuing annually on each one-year anniversary thereafter throughout the Term of the Agreement,
Developer's failure to submit an Annual Compliance Report within 60 days after its due date shall incur liquidated damages (not a penalty) from Developer to DPD of $10,000 per occurrence, payable immediately.
8.21 Inspector General. It is the duty of Developer and the duty of any bidder, proposer,
contractor, subcontractor, and every applicant for certification of eligibility for a City contract or
program, and all of Developer's officers, directors, agents, partners, and employees and any such
bidder, proposer, contractor, subcontractor or such applicant, to cooperate with the Inspector
General in any investigation or hearing undertaken pursuant to Chapter 2-56 of the Municipal
Code. Developer represents that it understands and will abide by all provisions of Chapter 2-56 of
the Municipal Code and that it will inform subcontractors of this provision and require their
compliance.
8.22 LEED Certification, [intentionally omitted]
8.23. FOIA and Local Records Act Compliance.
FOIA. The Developer acknowledges that the City is subject to the Illinois Freedom of Information Act, 5 ILCS 140/1 et. seq., as amended ("FOIA"). The FOIA requires the City to produce records (very broadly defined in FOIA) in response to a FOIA request in a very short period of time, unless the records requested are exempt under the FOIA. If the Developer receives a request from the City to produce records within the scope of FOIA, then the Developer covenants to comply with such request within 48 hours of the date of such request. Failure by the Developer to timely comply with such request shall be an Event of Default.
Exempt Information. Documents that the Developer submits to the City under Section 8.21 (Annual Compliance Report) or otherwise during the Term of the Agreement that contain trade secrets and commercial or financial information may be exempt if disclosure would result in competitive harm. However, for documents submitted by the Developer to be treated as a trade secret or information that would cause competitive harm, FOIA requires that Developer mark any such documents as "proprietary, privileged or confidential." If the Developer marks a document as "proprietary, privileged and confidential," then DPD will evaluate whether such document may be withheld under the FOIA. DPD, in its discretion, will determine whether a document will be exempted from disclosure, and that determination is subject to review by the Illinois Attorney General's Office and/or the courts.
Local Records Act. The Developer acknowledges that the City is subject to the Local Records Act, 50 ILCS 205/1 et. seq, as amended (the "Local Records Act"). The Local Records Act provides that public records may only be disposed of as provided in the Local Records
26
Act. If requested by the City, the Developer covenants to use its best efforts consistently applied to assist the City in its compliance with the Local Records Act.
Community Benefits. [Subject to further revision] Developer covenants to create and operate at the Facility during the Term of the Agreement:
A food access program that will make shopping at Chicago Market more affordable to low-income households by offering a substantial standing discount on most items and services to those who demonstrate financial need through use of qualifying food assistance programs such as SNAP or WIC. Such a program shall exist from day one of operations and shall be continuous for the term of this agreement. Annual Compliance Report will document existence of food access program for prior year.
A grant program for target populations that demonstrate need or circumstances that will provide the benefits of Co-op Ownership at no out-of-pocket cost to the grantee. Grant equity could be used for life, never expiring. Grantees not only get the power of the vote and access to our array of programs, including substantial savings on food, but would also have priority, often free, access to our classes and programs for their households. Grants shall be made such that the total number of grants issued shall number 100 by the end of year one of operation, with the total target number increasing by 15% per year for the subsequent 9 years of operation. (Year 2 total 115, Year 3 total 132, Year 4 total 152, and so forth)
Chicago Market Kitchen Classroom and Studio - The Kitchen Classroom will be located within Chicago Market. The space will allow 20+ participants for classes and presentations, support/interest group sessions, demonstrations, meetings, trainings, and more. The Chicago Market Kitchen will allow chefs and instructors to provide a wide array of classes, including cooking classes, instruction on the food system, special dietary needs classes, connections with farmers and other Chicago Market purveyors, and food policies that can affect everyone in the community. Beyond classes, the space will be used for interest and support groups, community gatherings, demonstrations promoting local produce, lunchtime general seating, and other functions. Of note, free programming specific to at-risk youth and at-risk adult populations will be offered. An average of not less than 48 classes/events per year - with no charge or at least 10% of class participation being available via free of charge scholarship - shall be hosted by the co-op.
Sustainable Development Policy. Within one year of the date of the issuance of the Certificate, Developer must provide evidence satisfactory to DPD that the Project has complied with DPD's Sustainable Development Policy.
If a default occurs under DPD's Sustainable Development Policy requirement, the City shall have the right to reduce the amount of the TIF Funds by $250,000.
27
8.26 Survival of Covenants. All warranties, representations, covenants and agreements of Developer contained in this Section 8 and elsewhere in this Agreement shall be true, accurate and complete at the time of Developer's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and (except as provided in Section 7 hereof upon the issuance of a Certificate) shall be in effect throughout the Term of the Agreement.
SECTION 9. COVENANTS/REPRESENTATIONSAVARRANTIES OF CITY
General Covenants. The City represents that it has the authority as a home rule unit of local government to execute and deliver, this Agreement and to perform its obligations hereunder.
Survival of Covenants. All warranties, representations, and covenants of the City contained in this Section 9 or elsewhere in this Agreement shall be true, accurate, and complete at the time of the City's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and be in effect throughout the Term of the Agreement.
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS
10.01 Employment Opportunity. Developer, on behalf of itself and its successors and assigns, hereby agrees, and shall contractually obligate its or their various contractors, subcontractors or any Affiliate of Developer operating on the Property (collectively, with Developer, the "Employers" and individually an "Employer") to agree, that for the Term of this Agreement with respect to Developer and during the period of any other party's provision of services in connection with the construction of the Project or rehabilitation of the Facility:
(a) No Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Chapter 2-160, Section 2-160-010 et seq Municipal Code, except as otherwise provided by said ordinance and as amended from time to time (the "Human Rights Ordinance"). Each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including without limitation: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Employers, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon
28
race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.
To the greatest extent feasible, each Employer is required to present opportunities for training and employment of low- and moderate-income residents of the City and preferably of the Redevelopment Area; and to provide that contracts for work in connection with the construction of the Project be awarded to business concerns that are located in, or owned in substantial part by persons residing in, the City and preferably in the Redevelopment Area.
Each Employer shall comply with all federal, state and local equal employment and affirmative action statutes, rules and regulations, including but not limited to the City's Human Rights Ordinance and the Illinois Human Rights Act, 775 ILCS 5/1-101 et seg. (1993), and any subsequent amendments and regulations promulgated thereto.
Each Employer, in order to demonstrate compliance with the terms of this Section, shall cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of federal, state and municipal agencies.
Each Employer shall include the foregoing provisions of subparagraphs (a) through (d) in every contract entered into in connection with the Project, and shall require inclusion of these provisions in every subcontract entered into by any subcontractors, and every agreement with any Affiliate operating on the Property, so that each such provision shall be binding upon each contractor, subcontractor or Affiliate, as the case may be.
Failure to comply with the employment obligations described in this Section 10.01 shall be a basis for the City to pursue remedies under the provisions of Section 15.02 hereof.
10.02 Citv Resident Construction Worker Employment Requirement. Developer agrees for itself and its successors and assigns, and shall contractually obligate its General Contractor and shall cause the General Contractor to contractually obligate its subcontractors, as applicable, to agree, that during the construction of the Project they shall comply with the minimum percentage of total worker hours performed by actual residents of the City as specified in Section 2-92-330 of the Municipal Code (at least 50 percent of the total worker hours worked by persons on the site of the Project shall be performed by actual residents of the City); provided, however, that in addition to complying with this percentage, Developer, its General Contractor and each subcontractor shall be required to make good faith efforts to utilize qualified residents of the City in both unskilled and skilled labor positions.
Developer may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code in accordance with standards and procedures developed by the Chief Procurement Officer of the City.
29
"Actual residents of the City" shall mean persons domiciled within the City. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.
Developer, the General Contractor and each subcontractor shall provide for the maintenance of adequate employee residency records to show that actual Chicago residents are employed on the Project. Each Employer shall maintain copies of personal documents supportive of every Chicago employee's actual record of residence.
Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) shall be submitted to the Commissioner of DPD in triplicate, which shall identify clearly the actual residence of every employee on each submitted certified payroll The first time that an employee's name appears on a payroll, the date that the Employer hired the employee should be written in after the employee's name.
Developer, the General Contractor and each subcontractor shall provide full access to their employment records to the Chief Procurement Officer, the Commissioner of DPD, the Superintendent of the Chicago Police Department, the Inspector General or any duly authorized representative of any of them. Developer, the General Contractor and each subcontractor shall maintain all relevant personnel data and records for a period of at least three (3) years after final acceptance of the work constituting the Project.
At the direction of DPD, affidavits and other supporting documentation will be required of Developer, the General Contractor and each subcontractor t' verify or clarify an employee's actual address when doubt or lack of clarity has arisen.
Good faith efforts on the part of Developer, the General Contractor and each subcontractor to provide utilization of actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) shall not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.
When work at the Project is completed, in the event that the City has determined that Developer has failed to ensure the fulfillment of the requirement of this Section concerning the worker hours performed by actual Chicago residents or failed to report in the manner as indicated above, the City will thereby be damaged in the failure to provide the benefit of demonstrable employment to Chicagoans to the degree stipulated in this Section. Therefore, in such a case of non-compliance, it is agreed that 1/20 of 1 percent (0.0005) of the aggregate hard construction costs set forth in the Project budget (the product of .0005 x such aggregate hard construction costs) (as the same shall be evidenced by approved contract value for the actual contracts) shall be surrendered by Developer to the City in payment for each percentage of shortfall toward the stipulated residency requirement. Failure to report the residency of employees entirely and correctly shall result in the surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the
30
certification of payroll data may subject Developer, the General Contractor and/or the subcontractors to prosecution. Any retainage to cover contract performance that may become due to Developer pursuant to Section 2-92-250 of the Municipal Code may be withheld by the City pending the Chief Procurement Officer's determination as to whether Developer must surrender damages as provided in this paragraph.
Nothing herein provided shall be construed to be a limitation upon the "Notice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order 11246" and "Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement or related documents.
Developer shall cause or require the provisions of this Section 10.02 to be included in all contracts and subcontracts related to the construction of the Project.
10.03. MBE/WBE Commitment. Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements set forth herein, Developer shall contractually obligate the General Contractor to agree that, during the Project:
Consistent with the findings which support, as applicable, (i) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seg., Municipal Code (the "Procurement Program"), and (ii) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seg., Municipal Code (the "Construction Program," and collectively with the Procurement Program, the "MBE/WBE Program"), and in reliance upon the provisions of the MBE/WBE Program to the extent contained in, [and as qualified by, the provisions of this Section 10.03, during the course of the Project, at least the following percentages of the MBE/WBE Budget (as set forth in Exhibit H-2 hereto) shall be expended for contract participation by MBEs and by WBEs:
At least 26 percent by MBEs.
At least six percent by WBEs.
For purposes of this Section 10.03 only, Developer (and any party to whom a contract is let by Developer in connection with the Project) shall be deemed a "contractor" and this Agreement (and any contract let by Developer in connection with the Project) shall be deemed a "contract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670 of the Municipal Code, as applicable.
Consistent with Sections 2-92-440 and 2-92-720 ofthe Municipal Code, Developer's MBE/WBE commitment may be achieved in part by Developer's status as an MBE or WBE (but only to the extent of any actual work performed on the Project by Developer) or by a joint venture with one or more MBEs or WBEs (but only to the extent of the lesser of (i) the MBE or WBE participation in such joint venture or (ii) the amount of any actual work performed on the Project
31
by the MBE or WBE), by Developer utilizing a MBE or a WBE as the General Contractor (but only to the extent of any actual work performed on the Project by the General Contractor), by subcontracting or causing the General Contractor to subcontract a portion of the Project to one or more MBEs or WBEs, or by the purchase of materials or services used in the Project from one or more MBEs or WBEs, or by any combination of the foregoing. Those entities which constitute both a MBE and a WBE shall not be credited more than once with regard to Developer's MBE/WBE commitment as described in this Section 10.03. In accordance with Section 2-92-730 of the Municipal Code, Developer shall not substitute any MBE or WBE General Contractor or subcontractor without the written approval of DPD.
Developer shall deliver quarterly reports to the City's monitoring staff during the Project describing its efforts to achieve compliance with this MBE/WBE commitment. Such reports shall include, inter alia, the name and business address of each MBE and WBE solicited by Developer or the General Contractor to work on the Project, and the responses received from such solicitation, the name and business address of each MBE or WBE actually involved in the Project, a description of the work performed or products or services supplied, the date and amount of such work, product or service, and such other information as may assist the City's monitoring staff in determining Developer's compliance with this MBE/WBE commitment. Developer shall maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with the Project for at least five years after completion of the Project, and the City's monitoring staff shall have access to all such records maintained by Developer, on five Business Days' notice, to allow the City to review Developer's compliance with its commitment to MBE/WBE participation and the status of any MBE or WBE performance regarding any portion of the Project.
Upon the disqualification of any MBE or WBE General Contractor or subcontractor, • if such status was misrepresented by the disqualified party, Developer shall be obligated to discharge or cause to be discharged the disqualified General Contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (e), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730 of the Municipal Code, as applicable.
Any reduction or waiver of Developer's MBE/WBE commitment as described in this Section 10.03 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730 of the Municipal Code, as applicable.
Prior to the commencement of the Project, Developer shall be required to meet with the City's monitoring staff with regard to Developer's compliance with its obligations under this Section 10.03. The General Contractor and all major subcontractors shall be required to attend this pre-construction meeting. During said meeting, Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 10.03, the sufficiency of which shall be approved by the City's monitoring staff. During the Project, Developer shall submit the documentation required by this Section 10.03 to the City's monitoring staff, including the
32
following: (i) subcontractor's activity report; (ii) contractor's certification concerning labor standards and prevailing wage requirements; (iii) contractor letter of understanding; (iv) monthly utilization report; (v) authorization for payroll agent; (vi) certified payroll; (vii) evidence that MBE/WBE contractor associations have been informed of the Project via written notice and hearings; and (viii) evidence of compliance with job creation/job retention requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that Developer is not complying with its obligations under this Section 10.03, shall, upon the delivery of written notice to Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to Developer to halt the Project, (2) withhold any further payment of any City Funds to Developer or the General Contractor, or (3) seek any other remedies against Developer available at law or in equity.
SECTION 11. ENVIRONMENTAL MATTERS
Developer hereby represents and warrants to the City that Developer has conducted environmental studies sufficient to conclude that the Project may be constructed, completed and operated in accordance with all Environmental Laws and this Agreement and all Exhibits attached hereto, the Scope Drawings, Plans and Specifications and all amendments thereto, and the Redevelopment Plan.
Without limiting any other provisions hereof, Developer agrees to indemnify, defend and hold the City harmless from and against any and all losses, liabilities, damages, injuries, costs, expenses or claims of any kind whatsoever including, without limitation, any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any Environmental Laws incurred, suffered by or asserted against the City as a direct or indirect result of any of the following, regardless of whether or not caused by, or within the control of Developer: (i) the presence of any Hazardous Material on or under, or the escape, seepage, leakage, spillage, emission, discharge or release of any Hazardous Material from (A) all or any portion of the Property or (B) any other real property in which Developer, or any person directly or indirectly controlling, controlled by or under common control with Developer, holds any estate or interest whatsoever (including, without limitation, any property owned by a land trust in which the beneficial interest is owned, in whole or in part, by Developer), or (ii) any liens against the Property permitted or imposed by any Environmental Laws, or any actual or asserted liability or obligation of the City or Developer or any of its Affiliates under any Environmental Laws relating to the Property.
SECTION 12. INSURANCE
Developer must provide and maintain, at Developer's own expense, or cause to be provided and maintained during the term of this Agreement, the insurance coverage and requirements specified below, insuring all operations related to the Agreement.
33
Prior to execution and delivery of this Agreement.
Workers Compensation and Employers Liability
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $100,000 each accident, illness or disease.
Commercial General Liability (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $ 1,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
All Risk Property
All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.
Construction. Prior to the construction of any portion of the Project, Developer will cause its architects, contractors, subcontractors, project managers and other parties constructing the Project to procure and maintain the following kinds and amounts of insurance:
Workers Compensation and Employers Liability
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $500,000 each accident, illness or disease.
Commercial General Liability (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $2,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations (for a minimum of two (2) years following project completion), explosion, collapse, underground, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a
34
primary, non-contributory basis for any liability arising directly or indirectly from the work.
Automobile Liability (Primary and Umbrella)
When any motor vehicles (owned, non-owned and hired) are used in connection with work to be performed, the Automobile Liability Insurance with limits of not less than $2,000.000 per occurrence for bodily injury and property damage. The City of Chicago is to be named as an additional insured on a primary, non-contributory basis.
Railroad Protective Liability
When any work is to be done adjacent to or on railroad or transit property, Developer must provide cause to be provided with respect to the operations that Contractors perform, Railroad Protective Liability Insurance in the name of railroad or transit entity. The policy must have limits of not less than $2,000,000 per occurrence and $6,000,000 in the aggregate for losses arising out of injuries to or death of all persons, and for damage to or destruction of property, including the loss of use thereof.
All Risk /Builders Risk
When Developer undertakes any construction, including improvements, betterments, and/or repairs, Developer must provide or cause to be provided All Risk Builders Risk Insurance at replacement cost for materials, supplies, equipment, machinery and fixtures that are or will be part of the project. The City of Chicago is to be named as an additional insured and loss payee/mortgagee if applicable.
Professional Liability
When any architects, engineers, construction managers or other professional consultants perform work in connection with this Agreement, Professional Liability Insurance covering acts, errors, or omissions must be maintained with limits of not less than $ 1,000,000. Coverage'must include contractual liability. When policies are renewed or replaced, the policy retroactive date must coincide with, or precede, start of work on the Contract. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years.
Valuable Papers
When any plans, designs, drawings, specifications and documents are produced or used under this Agreement, Valuable Papers Insurance must be maintained in an amount to insure against any loss whatsoever, and must have limits sufficient to pay for the re-creation and reconstruction of such records.
35
Contractors Pollution Liability
When any remediation work is performed which may cause a pollution exposure, Developer must cause remediation contractor to provide Contractor Pollution Liability covering bodily injury, property damage and other losses caused by pollution conditions that arise from the contract scope of work with limits of not less than $1,000,000 per occurrence. Coverage must include completed operations, contractual liability, defense, excavation, environmental cleanup, remediation and disposal. When policies are renewed or replaced, the policy retroactive date must coincide with or precede, start of work on the Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years. The City of Chicago is to be named as an anal insured.
(c) Post Construction:
All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and payee/mortgagee if applicable.
(d) Other Requirements:
Developer must furnish the City of Chicago, Department of Planning and Development, City Hall, Room 1000,121 North LaSalle Street 60602, original Certificates of Insurance, or such similar evidence, to be in force on the date of this Agreement, and Renewal Certificates of Insurance, or such similar evidence, if the coverages have an expiration or renewal date occurring during the term ofthis Agreement. Developer must submit evidence of insurance on the City of Chicago Insurance Certificate Form (copy attached) or equivalent prior to closing. The receipt of any certificate does not constitute agreement by the City that the insurance requirements in the Agreement have been fully met or that the insurance policies indicated on the certificate are in compliance with all Agreement requirements. The failure of the City to obtain certificates or other insurance evidence from Developer is not a waiver by the City of any requirements for Developer to obtain and maintain the specified coverages. Developer shall advise all insurers of the Agreement provisions regarding insurance. Non-conforming insurance does not relieve Developer of the obligation to provide insurance as specified herein. Nonfulfillment of the insurance conditions may constitute a violation of the Agreement, and the City retains the right to stop work and/or terminate agreement until proper evidence of insurance is provided.
The insurance must provide for 60 days prior written notice to be given to the City in the event coverage is substantially changed, canceled, or non-renewed.
Any deductibles or self-insured retentions on referenced insurance coverages must be borne by Developer and Contractors.
36
Developer hereby waives and agrees to require their insurers to waive their rights of subrogation against the City of Chicago, its employees, elected officials, agents, or representatives.
The coverages and limits furnished by Developer in no way limit Developer's liabilities and responsibilities specified within the Agreement or by law.
Any insurance or self-insurance programs maintained by the City of Chicago do not contribute with insurance provided by Developer under the Agreement.
The required insurance to be carried is not limited by any limitations expressed in the indemnification language in this Agreement or any limitation placed on the indemnity in this Agreement given as a matter of law.
If Developer is a joint venture or limited liability company, the insurance policies must name the joint venture or limited liability company as a named insured.
Developer must require Contractor and subcontractors to provide the insurance required herein, or Developer may provide the coverages for Contractor and subcontractors. All Contractors and subcontractors are subject to the same insurance requirements of Developer unless otherwise specified in this Agreement.
If Developer, any Contractor or subcontractor desires additional coverages, the party desiring the additional coverages is responsible for the acquisition and cost.
The City of Chicago Risk Management Department maintains the right to modify, delete, alter or change these requirements.
SECTION 13. INDEMNIFICATION
13.01 General Indemnity. Developer agrees to indemnify, pay, defend and hold the City, and its elected and appointed officials, employees, agents and affiliates (individually an "Indemnitee," and collectively the "Indemnitees") harmless from and against, any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, claims, costs, expenses and disbursements of any kind or nature whatsoever (and including without limitation, the reasonable fees and disbursements of counsel for such Indemnitees in connection with any investigative, administrative or judicial proceeding commenced or threatened, whether or not such Indemnitees shall be designated a party thereto), that may be imposed on, suffered, incurred by or asserted against the Indemnitees in manner relating or arising out of:
(i) Developer's failure to comply with any of the terms, covenants and conditions contained within this Agreement; or
37
Developer's or any contractor's failure to pay General Contractors, subcontractors or materialmen in connection with the TIF-Funded Improvements or any other Project improvement; or
the existence of any material misrepresentation or omission in this Agreement, any official statement, limited offering memorandum or private placement memorandum or the Redevelopment Plan or any other document related to this Agreement that is the result of information supplied or omitted by Developer or any Affiliate Developer or any agents, employees, contractors or persons acting under the control or at the request of Developer or any Affiliate of Developer; or
Developer's failure to cure any misrepresentation in this Agreement or any other agreement relating hereto;
provided, however, that Developer shall have no obligation to an Indemnitee arising from the wanton or willful misconduct of that Indemnitee. To the extent that the preceding sentence may be unenforceable because it is violative of any law or public policy, Developer shall contribute the maximum portion that it is permitted to pay and satisfy under the applicable law, to the payment and satisfaction of all indemnified liabilities incurred by the Indemnitees or any of them. The provisions of the undertakings and indemnification set out in this Section 13.01 shall survive the termination of this Agreement.
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT
14.01 Books and Records. Developer shall keep and maintain separate, complete, accurate
and detailed books and records necessary to reflect and fully disclose the total actual cost of the
Project and the disposition of all funds from whatever source allocated thereto, and to monitor the
Project. All such books, records and other documents, including but not limited to Developer's
loan statements, if any, General Contractors' and contractors' swom statements, general contracts,
subcontracts, purchase orders, waivers of lien, paid receipts and invoices, shall be available at
Developer's offices for inspection, copying, audit and examination by an authorized representative
of the City, at Developer's expense. Developer shall incorporate this right to inspect, copy, audit
and examine all books and records into all contracts entered into by Developer with respect to the
Project.
14.02 Inspection Rights. Upon three (3) business days' notice, any authorized
representative of the City has access to all portions of the Project and the Property during normal
business hours for the Term of the Agreement.
38
SECTION 15. DEFAULT AND REMEDIES
15.01 Events of Default. The occurrence of any one or more of the following events, subject to the provisions of Section 15.03, shall constitute an "Event of Default" by Developer hereunder:
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under this Agreement or any related agreement;
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under any other agreement with any person or entity if such failure may have a material adverse effect on Developer's business, property, assets, operations or condition, financial or otherwise;
the making or furnishing by Developer to the City of any representation, warranty, certificate, schedule, report or other communication within or in connection with this Agreement or any related agreement which is untrue or misleading in any-material respect;
(d) except as otherwise permitted hereunder, the creation (whether voluntary or
involuntary) of, or any attempt to create, any lien or other encumbrance upon the Property,
including any fixtures now or hereafter attached thereto, other than the Permitted Liens, or the
making or any attempt to make any levy, seizure or attachment thereof;
the commencement of any proceedings in bankruptcy by or against Developer or for the liquidation or reorganization of Developer, or alleging that Developer is insolvent or unable to pay its debts as they mature, or for the readjustment or arrangement of Developer's debts, whether under the United States Bankruptcy Code or under any other state or federal law, now or hereafter existing for the relief of debtors, or the commencement of any analogous statutory or non-statutory proceedings involving Developer; provided, however, that if such commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such proceedings are not dismissed within sixty (60) days after the commencement of such proceedings;
the appointment of a receiver or trustee for Developer, for any substantial part of Developer's assets or the institution of any proceedings for the dissolution, or the full or partial liquidation, or the merger or consolidation, of Developer; provided, however, that if such appointment or commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such appointment is not revoked or such proceedings are not dismissed within sixty (60) days after the commencement thereof;
the entry of any judgment or order against Developer which remains unsatisfied or undischarged and in effect for sixty (60) days after such entry without a stay of enforcement or execution;
39
(h) the occurrence of a default under the Lender Financing, which default is not cured
within any applicable cure period;
(i) the dissolution of Developer or the death of any natural person who owns a material
interest in Developer;
(j) the institution in any court of a criminal proceeding (other than a misdemeanor) against Developer or any natural person who owns a material interest in Developer, which is not dismissed within thirty (30) days, or the indictment of Developer or any natural person who owns a material interest in Developer, for any crime (other than a misdemeanor);
(k) prior to the expiration of the Term of the Agreement, the sale or transfer of a majority of the ownership interests of Developer without the prior written consent of the City; or
(1) The failure of Developer, or the failure by any party that is a Controlling Person (defined in Section 1-23-010 of the Municipal Code) with respect to Developer, to maintain eligibility to do business with the City in violation of Section 1-23-030 of the Municipal Code; such failure shall render this Agreement voidable or subject to termination, at the option of the Chief Procurement Officer.
For purposes of Sections 15.01(0 and 15.01(0 hereof, a person with a material interest in Developer shall be one having a direct or indirect beneficial interest (including ownership) in excess of 10% of Developer.
Remedies. Upon the occurrence of an Event of Default, the City may terminate this Agreement and any other agreements to which the City and Developer are or shall be parties, suspend disbursement of City Funds or seek reimbursement of any City Funds paid. The City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to damages, injunctive relief or the specific performance of the agreements contained herein. Upon the occurrence of an Event of Default under Section 8.06. Developer shall be obligated to repay to the City all previously disbursed City Funds.
In addition to the remedies listed in the prior paragraph, the City shall have liquidated damages remedies for Developer's failure to timely submit a completed Annual Compliance Report as set forth in Section 8.20 hereof.
For a Developer failure to comply with Section 8.25 hereof, the City may reduce City Funds by $250,000.
Cure Period. In the event Developer shall fail to perform a monetary covenant which Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless
40
Developer has failed to perform such monetary covenant within ten (10) days of its receipt of a written notice from the City specifying that it has failed to perform such monetary covenant.
•In the event Developer shall fail to perform a non-monetary covenant which Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless Developer has failed to cure such default within thirty (30) days of its receipt of a written notice from the City specifying the nature of the default; provided, however, with respect to those non-monetary defaults which are not capable of being cured within such thirty (30) day period, Developer shall not be deemed to have committed an Event of Default under this Agreement if it has commenced, to cure the alleged default within such thirty (30) day period and thereafter diligently and continuously prosecutes the cure of such default until the same has been cured.
The Developer shall be entitled to not to exceed two, non-consecutive, one-year cure periods for a default of the operations covenant set forth in Section 8.06, provided, however, that any year during which an operations covenant default occurs shall extend the Term of this Agreement by one year, and further provided'that payment of any City Funds otherwise due to Developer during a cure year shall by suspended until the cure period has ended.
SECTION 16. MORTGAGING OF THE PROJECT
All mortgages or deeds of trust in place as of the date hereof with respect to the Property or any portion thereof are listed on Exhibit G hereto (including but not limited to mortgages made prior to or on the date hereof in connection with Lender Financing) and are referred to herein as the "Existing Mortgages." Any mortgage or deed of trust that Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof is referred to herein as a "New Mortgage." Any New Mortgage that Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof with the prior written consent of the City is referred to herein as a "Permitted Mortgage." It is hereby agreed by between the City and Developer as follows:
(a) In the event that a mortgagee or any other party shall succeed to Developer's interest in the Property or any portion thereof pursuant to the exercise of remedies under a New Mortgage (other than a Permitted Mortgage), whether by foreclosure or deed in lieu of foreclosure, and in conjunction therewith accepts an assignment of Developer's interest hereunder in accordance with Section 18.15 hereof, the City may, but shall not be obligated to, attorn to and recognize such party as the successor in interest to Developer for all purposes under this Agreement and, unless so recognized by the City as the successor in interest, such party shall be entitled to no rights or benefits under this Agreement, but such party shall be bound by those provisions of this Agreement that are covenants expressly running with the land.
41
(b) Prior to the issuance by the City to Developer of a Certificate pursuant to Section 7 hereof, no New Mortgage shall be executed with respect to the Property or any portion thereof without the prior written consent of the Commissioner of DPD.
SECTION 17. NOTICE
Unless otherwise specified, any notice, demand or request required hereunder shall be given in writing at the addresses set forth below, by any of the following means: (a) personal service; (b) telecopy or facsimile; (c) overnight courier, or (d) registered or certified mail, return receipt requested.
If to the Developer:
Chicago Cooperative, an Illinois corporation d/b/a Chicago Market PO Box 408560 Chicago IL 60640
With a copy to:
Applegate and Thorne-Thomsen 425 S. Financial Place Suite 1900 Chicago, IL 60605 Attn: Nick Brunick
If to the City:
City of Chicago
Department of Planning and Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602
With a copy to:
City of Chicago
Department of Law
121 North LaSalle Street, Room 600
Chicago, Illinois 60602
Such addresses may be changed by notice to the other parties given in the same manner provided above. Any notice, demand, or request sent pursuant to either clause (a) or (b) hereof shall be deemed received upon such personal service or upon dispatch. Any notice, demand or
42
request sent pursuant to clause (c) shall be deemed received on the day immediately following deposit with the overnight courier and any notices, demands or requests sent pursuant to subsection (d) shall be deemed received two (2) business days following deposit in the mail.
SECTION 18. MISCELLANEOUS
Amendment. This Agreement and the Exhibits attached hereto may not be amended or modified without the prior written consent of the parties hereto; provided, however, that the City, in its sole discretion, may amend, modify or supplement the Redevelopment Plan without the consent of any party hereto. It is agreed that no material amendment or change to this Agreement shall be made or be effective unless ratified or authorized by an ordinance duly adopted by the City Council. The term "material" for the purpose of this Section 18.01 shall be defined as any deviation from the terms of the Agreement which operates to cancel or otherwise reduce any developmental, construction or job-creating obligations of Developer (including those set forth in Sections 10.02 and 10.03 hereof) by more than five percent (5%) or materially changes the Project site or character ofthe Project or any activities undertaken by Developer affecting the Project site, the Project, or both, or increases any time agreed for performance by Developer by more than 90 , days.
Entire Agreement. This Agreement (including each Exhibit attached hereto, which is hereby incorporated herein by reference) constitutes the entire Agreement between the parties hereto and it supersedes all prior agreements, negotiations and discussions between the parties relative to the subject matter hereof.
Limitation of Liability. No member, official or employee of the City shall be personally liable to Developer or any successor in interest in the event of any default or breach by the City or for any amount which may become due to Developer from the City or any successor in interest or on any obligation under the terms of this Agreement.
Further Assurances. Developer agrees to take such actions, including the execution and delivery of such documents, instruments, petitions and certifications as may become necessary or appropriate to carry out the terms, provisions and intent of this Agreement.
18.05 Waiver. Waiver by the City or Developer with respect to any breach of this
Agreement shall not be considered or treated as a waiver ofthe rights of the respective party with
respect to any other default or with respect to any particular default, except to the extent
specifically waived by the City or Developer in writing. No delay or omission on the part of a party
in exercising any right shall operate as a waiver of such right or any other right unless pursuant to
the specific terms hereof. A waiver by a party of a provision of this Agreement shall not prejudice
or constitute a waiver of such party's right otherwise to demand strict compliance with that
provision or any other provision of this Agreement. No prior waiver by a party, nor any course of
dealing between the parties hereto, shall constitute a waiver of any such parties' rights or of any
obligations of any other party hereto as to any future transactions.
43
Remedies Cumulative. The remedies of a party hereunder are cumulative and the exercise of any one or more of the remedies provided for herein shall not be construed as a waiver of any other remedies of such party unless specifically so provided herein.
Disclaimer. Nothing contained in this Agreement nor any act of the City shall be deemed or construed by any of the parties, or by any third person, to create or imply any relationship of third-party beneficiary, principal or agent, limited or general partnership or joint venture, or to create or imply any association or relationship involving the City.
Counterparts. This Agreement may be executed in several counterparts, each of which shall be deemed an original and all of which shall constitute one and the same agreement.
Severability. If any provision in this Agreement, or any paragraph, sentence, clause, phrase, word or the application thereof, in any circumstance, is held invalid, this Agreement shall be construed as if such invalid part were never included herein and the remainder of this Agreement shall be and remain valid and enforceable to the fullest extent permitted by law.
Conflict. In the event of a conflict between any provisions of this Agreement and the provisions of the TIF Ordinances, such ordinance(s) shall prevail and control.
Governing Law. This Agreement shall be governed by and construed in accordance with the internal laws of the State of Illinois, without regard to its conflicts of law principles.
Form of Documents. All documents required by this Agreement to be submitted, delivered or furnished to the City shall be in form and content satisfactory to the City.
Approval. Wherever this Agreement provides for the approval or consent of the City, DPD or the Commissioner, or any matter is to be to the City's, DPD's or the Commissioner's satisfaction, unless specifically stated to the contrary, such approval, consent or satisfaction shall be made, given or determined by the City, DPD or the Commissioner in writing and in the reasonable discretion thereof. The Commissioner or other person designated by the Mayor of the City shall act for the City or DPD in making all approvals, consents and determinations of satisfaction, granting the Certificate or otherwise administering this Agreement for the City.
No Assignment; No Transfer. Notwithstanding anything in this Agreement to the contrary, Developer may not sell, assign or otherwise transfer its interest in this Agreement in whole or in part. This covenant runs with the land.
Developer consents to the City's sale, transfer, assignment or other disposal of this Agreement at any time in whole or in part.
44
Binding Effect. This Agreement shall be binding upon Developer, the City and their respective successors and permitted assigns (as provided herein) and shall inure to the benefit of Developer, the City and their respective successors and permitted assigns (as provided herein). Except as otherwise provided herein, this Agreement shall not run to the benefit of, or be enforceable by, any person or entity other than a party to this Agreement and its successors and permitted assigns. This Agreement should not be deemed to confer upon third parties any remedy, claim, right of reimbursement or other right.
Force Majeure. Neither the City nor Developer nor any successor in interest to either of them shall be considered in breach of or in default of its obligations under this Agreement in the event of any delay caused by damage or destruction by fire or other casualty, strike, shortage of material, unusually adverse weather conditions such as, by way of illustration and not limitation, severe rain storms or below freezing temperatures of abnormal degree or for an abnormal duration, tornadoes or cyclones, and other events or conditions beyond the reasonable control of the party affected which in fact interferes with the ability of such party to discharge its obligations hereunder. The individual or entity relying on this section with respect to any such delay shall, upon the occurrence of the event causing such delay, immediately give written notice to the other parties to this Agreement. The individual or entity relying on this section with respect to any such delay may rely on this section only to the extent of the actual number of days of delay effected by any such events described above.
Business Economic Support Act. Pursuant to the Business Economic Support Act (30 ILCS 760/1 et seg.), if Developer is required to provide notice under the WARN Act, Developer shall, in addition to the notice required under the WARN Act, provide at the same time a copy of the WARN Act notice to the Governor ofthe State, the Speaker and Minority Leader of the House of Representatives of the State, the President and minority Leader of the Senate of State, and the Mayor of each municipality where Developer has locations in the State. Failure by Developer to provide such notice as described above may result in the termination of all or a part of the payment or reimbursement obligations of the City set forth herein.
Venue and Consent to Jurisdiction. If there is a lawsuit under this Agreement, each party may hereto agrees to submit to the jurisdiction of the courts of Cook County, the State of Illinois and the United States District Court for the Northern District of Illinois.
Costs and Expenses. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorney's fees, incurred in connection with the enforcement of the provisions ofthis Agreement. This includes, subject to any limits under applicable law, attorney's fees and legal expenses, whether or not there is a lawsuit, including attorney's fees for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals and any anticipated post-judgment collection services. Developer also will pay any court costs, in addition to all other sums provided by law.
45
18.20 Business Relationships. Developer acknowledges (A) receipt of a copy of Section 2-156-030 (b) of the Municipal Code, (B) that Developer has read such provision and understands that pursuant to such Section 2-156-030 (b), it is illegal for any elected official of the City, or any person acting at the direction of such official, to contact, either orally or in writing, any other City official or employee with respect to any matter involving any person with whom the elected City official or employee has a business relationship that creates a "Financial Interest" (as defined in Section 2-156-010 of the Municipal Code)(a "Financial Interest"), or to participate in any discussion in any City Council committee hearing or in any City Council meeting or to vote on any matter involving any person with whom the elected City official or employee has a business relationship that creates a Financial Interest, or to participate in any discussion in any City Council committee hearing or in any City Council meeting or to vote on any matter involving the person with whom an elected official has a business relationship that creates a Financial Interest, and (C) that a violation of Section 2-156-030 (b) by an elected official, or any person acting at the direction of such official, with respect to any transaction contemplated by this Agreement shall be grounds for termination of this Agreement and the transactions contemplated hereby. Developer hereby represents and warrants that, to the best of its knowledge after due inquiry, no violation of Section 2-156-030 (b) has occurred with respect to this Agreement or the transactions contemplated hereby.
[THE REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK.]
46
IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment Agreement to be executed on or as of the day and year first above written.
Chicago Cooperative, an Illinois corporation d/b/a Chicago Market - a Community Co-op
Matthew L. Ruffi, Board President
CITY OF CHICAGO, by and through its Department of Planning and Development
By: :
Maurice D. Cox, Commissioner
47
STATE OF ILLINOIS )
)SS
COUNTY OF COOK )
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that , personally known to
me to be the of Chicago Cooperative, an Illinois corporation
d/b/a Chicago Market - a Community Co-op, an Illinois corporation (the "Developer"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by the Board of Directors of Developer, as his/her free and voluntary act and as the free and voluntary act of Developer, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this day of , .
Notary Public
My Commission Expires
(SEAL)
48
STATE OF ILLINOIS COUNTY OF COOK
)
)SS )
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that , personally
known to me to be the Commissioner of the Department of Planning and
Development of the City of Chicago (the "City"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument pursuant to the authority given to him/her by the City, as his/her free and voluntary act and as the free and voluntary act of the City, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this th day of , .
Notary Public
My Commission Expires
49
EXHIBIT A [intentionally omitted]
50
EXHIBIT B PROPERTY
4620 North Broadway, Chicago, Illinois PIN:
14-17-500-006-0000 [subject to title policy updates]
51
EXHIBIT C
TIF-FUNDED IMPROVEMENTS
Line Item Cost
TIF- Eligible Budget
Acquisition Costs $0
Hard Costs
Building Rehabilitation $4,481,639
Hard Cost Contingency $407,401
Total Hard Costs $4,889,040
Soft Costs/Fees
Architecture and Engineering $924,776
Soft Cost Contingency $0
Total Soft Costs $924,776
Total $5,813,816
?Notwithstanding the total of TIF-Funded Improvements incurred by Developer, the assistance to be provided by the City is limited to the amount described in Section 4.03 and shall not exceed the lesser of $5,800,000 or 66.6% of the Project Budget.
52
EXHIBIT E CONSTRUCTION CONTRACT
[omitted for ordinance]
53
EXHIBIT F
ESCROW AGREEMENT
[omitted for ordinance]
54
EXHIBIT G
PERMITTED LIENS
1. Liens or encumbrances against the Property:
Those matters set forth as Schedule B title exceptions in the owner's title insurance policy issued by the Title Company as of the date hereof, but only so long as applicable title endorsements issued in conjunction therewith on the date hereof, if any, continue to remain in full force and effect.
2. Liens or encumbrances against Developer or the Project, other than liens against the
Property, if any:
[To be completed by Developer's counsel, subject to City approval.]
55
EXHIBIT H-1 PROJECT BUDGET
Project Budget
Acquisition Costs $0
Hard Costs
Building Rehabilitation $4,481,639
FF&E $2,727,525
Hard Cost Contingency $407,401
Total Hard Costs $7,616,565
Soft Costs/Fees
Architecture and Engineering $989,471
Survey/Title/Appraisal $0
Bridge Loan Interest $0
Construction Interest $93,500
Soft Cost Contingency $0
Total Soft Costs $1,082,971
Total $8,699,536
56
EXHIBIT H-2 MBE/WBE BUDGET
MBE/WBE Budget
Hard Costs
Building Rehabilitation $4,481,639
FF&E $0
Hard Cost Contingency $407,401
Total Hard Costs $4,889,040
Total $4,889,040
Project MBE Total at 26% $1,271,150
Project WBE Total at 6% $293,342
57
EXHIBIT I
APPROVED PRIOR EXPENDITURES
[omitted for ordinance]
58
EXHIBIT J OPINION OF DEVELOPER'S COUNSEL [To be retyped on Developer's Counsel's letterhead]
City of Chicago
121 North LaSalle Street
Chicago, IL 60602
ATTENTION: Corporation Counsel
Ladies and Gentlemen:
We have acted as counsel to , an [Illinois]
(the "Developer"), in connection with the purchase of certain land and the construction of certain
facilities thereon located in the Redevelopment Project
Area (the "Project"). In that capacity, we have examined, among other things, the following agreements, instruments and documents of even date herewith, hereinafter referred to as the "Documents":
(a) Redevelopment Agreement (the "Agreement") of even
date herewith, executed by Developer and the City of Chicago (the "City");
[(b) the Escrow Agreement of even date herewith executed by Developer and the City;]
[insert other documents including but not limited to documents related to purchase and financing of the Property and all lender financing related to the Project]; and
all other agreements, instruments and documents executed in connection with the foregoing.
In addition to the foregoing, we have examined
(a) the original or certified, conformed or photostatic copies of Developer's (i) Articles of Incorporation, as amended to date, (ii) qualifications to do business and certificates of good standing in all states in which Developer is qualified to do business, (iii) By-Laws, as amended to date, and (iv) records of all corporate proceedings relating to the Project [revise if Developer is not a corporation]; and
59
(b) such other documents, records and legal matters as we have deemed necessary or relevant for purposes of issuing the opinions hereinafter expressed.
In all such examinations, we have assumed the genuineness of all signatures (other than those of Developer), the authenticity of documents submitted to us as originals and conformity to the originals of all documents submitted to us as certified, conformed or photostatic copies.
Based on the foregoing, it is our opinion that:
Developer is a corporation duly organized, validly existing and in good standing under the laws of its state of [incorporation] [organization], has full power and authority to own and lease its properties and to carry on its business as presently conducted, and is in good standing and duly qualified to do business as a foreign [corporation] [entity] under the laws of every state in which the conduct of its affairs or the ownership of its assets requires such qualification, except for those states in which its failure to qualify to do business would not have a material adverse effect on it or its business.
Developer has full right, power and authority to execute and deliver the Documents to which it is a party and to perform its obligations thereunder. Such execution, delivery and performance will not conflict with, or result in a breach of, Developer's [Articles of Incorporation or By-Laws] [describe any formation documents if Developer is not a corporation] or result in a breach or other violation of any of the terms, conditions or provisions of any law or regulation, order, writ, injunction or decree of any court, government or regulatory authority, or, to the best of our knowledge after diligent inquiry, any of the terms, conditions or provisions of any agreement, instrument or document to which Developer is a party or by which Developer or its properties is bound. To the best of our knowledge after diligent inquiry, such execution, delivery and performance will not constitute grounds for acceleration of the maturity of any agreement, indenture, undertaking or other instrument to which Developer is a party or by which it or any of its property may be bound, or result in the creation or imposition of (or the obligation to create or impose) any lien, charge or encumbrance on, or security interest in, any of its property pursuant to the provisions of any of the foregoing, other than liens or security interests in favor of the lender providing Lender Financing (as defined in the Agreement).
The execution and delivery of each Document and the performance of the transactions contemplated thereby have been duly authorized and approved by all requisite action on the part of Developer.
Each of the Documents to which Developer is a party has been duly executed and delivered by a duly authorized officer of Developer, and each such Document constitutes the legal, valid and binding obligation of Developer, enforceable in accordance with its terms, except as limited by applicable bankruptcy, reorganization, insolvency or similar laws affecting the enforcement of creditors' rights generally.
60
Exhibit A attached hereto (a) identifies each class of capital stock of Developer, (b) sets forth the number of issued and authorized shares of each such class, and (c) identifies the record owners of shares of each class of capital stock of Developer and the number of shares held of record by each such holder. To the best of our knowledge after diligent inquiry, except as set forth on Exhibit A. there are no warrants, options, rights or commitments of purchase, conversion, call or. exchange or other rights or restrictions with respect to any of the capital stock of Developer. Each outstanding share of the capital stock of Developer is duly authorized, validly issued, fully paid and nonassessable.
To the best of our knowledge after diligent inquiry, no judgments are outstanding against Developer, nor is there now pending or threatened, any litigation, contested claim or governmental proceeding by or against Developer or affecting Developer or its property, or seeking to restrain or enjoin the performance by Developer of the Agreement or the transactions contemplated by the Agreement, or contesting the validity thereof. To the best of our knowledge after diligent inquiry, Developer is not in default with respect to any order, writ, injunction or decree of any court, government or regulatory authority or in default in any respect under any law, order, regulation or demand of any governmental agency or instrumentality, a default under which would have a material adverse effect on Developer or its business.
To the best of our knowledge after diligent inquiry, there is no default by Developer or any other party under any material contract, lease, agreement, instrument or commitment to which Developer is a party or by which the company or its properties is bound.
To the best of our knowledge after diligent inquiry, all of the assets of Developer are free and clear of mortgages, liens, pledges, security interests and encumbrances except for those specifically set forth in the Documents.
The execution, delivery and performance of the Documents by Developer have not and will not require the consent of any person or the giving of notice to, any exemption by, any registration, declaration or filing with or any taking of any other actions in respect of, any person, including without limitation any court, government or regulatory authority.
To the best of our knowledge after diligent inquiry, Developer owns or possesses or is licensed or otherwise has the right to use all licenses, permits and other governmental approvals and authorizations, operating authorities, certificates of public convenience, goods carriers permits, authorizations and other rights that are necessary for the operation of its business.
A federal or state court sitting in the State of Illinois and applying the choice of law provisions of the State of Illinois would enforce the choice of law contained in the Documents and apply the law of the State of Illinois to the transactions evidenced thereby.
61
We are attorneys admitted to practice in the State of Illinois and we express no opinion as to any laws other than federal laws of the United States of America and the laws of the State of Illinois.
[Note: include a reference to the laws of the state of incorporation/organization of Developer, if other than Illinois.]
This opinion is issued at Developer's request for the benefit of the City and its counsel, and may not be disclosed to or relied upon by any other person.
Very truly yours,
By:_ Name:
62
EXHIBIT K [intentionally omitted]
63
EXHIBIT L
REQUISITION FORM
STATE OF ILLINOIS )
) SS
COUNTY OF COOK )
The affiant, . , of , a
(the "Developer"), hereby certifies that with respect to that
certain Redevelopment Agreement between Developer and the City of
Chicago dated , (the "Agreement"):
Expenditures for the Project, in the total amount of $ , have been
made:
This paragraph B sets forth and is a true and complete statement of all costs of TIF-Funded Improvements for the Project reimbursed by the City to date:
$
Developer requests reimbursement for the following cost of TIF-Funded Improvements:
$
None of the costs referenced in paragraph C above have been previously reimbursed by the City.
Developer hereby certifies to the City that, as of the date hereof:
Except as described in the attached certificate, the representations and warranties contained in the Agreement are true and correct and Developer is in compliance with all applicable covenants contained herein.
No event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default, exists or has occurred.
All capitalized terms which are not defined herein has the meanings given such terms in the Agreement.
64
[Developer]
By:
Name Title:
Subscribed and swom before me this day of
My commission expires: Agreed and accepted:
Name Title:
City of Chicago
Department of Planning and Development
65
EXHIBIT M [intentionally omitted]
EXHIBIT N
SAMPLE - FORM OF SUBORDINATION AGREEMENT
This document prepared by and after recording return to: , Esq.
City of Chicago
Department of Law
121 North LaSalle Street, Room 600
Chicago, IL 60602
SUBORDINATION AGREEMENT
This Subordination Agreement ("Agreement") is made and entered into as of the
day of , between the City of Chicago by and through its Department of Planning and
Development (the "City"), [Name Lender], a [national banking association] (the "Lender").
WITNESSETH:
WHEREAS, [identify Developer, Project and Property]; and
WHEREAS, [list financing and security documents] (all such agreements referred to above and otherwise relating to the Loan referred to herein collectively as the "Loan Documents");
WHEREAS, Developer desires to enter into a certain Redevelopment Agreement dated the date hereof with the City in order to obtain additional financing for the Project (the "Redevelopment Agreement," referred to herein along with various other agreements and documents related thereto as the "City Agreements");
WHEREAS, pursuant to the Redevelopment Agreement, Developer will agree to be bound by certain covenants expressly running with the Property, as set forth in Sections 8.02, 8.19 and 18.14 of the Redevelopment Agreement (the "City Encumbrances");
WHEREAS, the City has agreed to enter into the Redevelopment Agreement with Developer as ofthe date hereof, subject, among other things, to (a) the execution by Developer of the Redevelopment Agreement and the recording thereof as an encumbrance against the Property;
67
and (b) the agreement by the Lender to subordinate their respective liens under the Loan Documents to the City Encumbrances; and
NOW, THEREFORE, for good and valuable consideration, the receipt, adequacy and sufficiency of which are hereby acknowledged, the Lender and the City agree as hereinafter set forth:
Subordination. All rights, interests and claims of the Lender in the Property pursuant to the Loan Documents are and shall be subject and subordinate to the City Encumbrances. In all other respects, the Redevelopment Agreement shall be subject and subordinate to the Loan Documents. Nothing herein, however, shall be deemed to limit the Lender's right to receive, and Developer's ability to make, payments and prepayments of principal and interest on the Note, or to exercise its rights pursuant to the Loan Documents except as provided herein.
Notice of Default. The Lender shall use reasonable efforts to give to the City, and the City shall use reasonable efforts to give to the Lender, (a) copies of any notices of default which it may give to Developer with respect to the Project pursuant to the Loan Documents or the City Agreements, respectively, and (b) copies of waivers, if any, of Developer's default in connection therewith. Under no circumstances shall Developer or any third party be entitled to rely upon the agreement provided for herein.
Waivers. No waiver shall be deemed to be made by the City or the Lender of any of their respective rights hereunder, unless the same shall be in writing, and each waiver, if any, shall be a waiver only with respect to the specific instance involved and shall in no way impair the rights of the City or the Lender in any other respect at any other time.
Governing Law; Binding Effect. This Agreement shall be interpreted, and the rights and liabilities of the parties hereto determined, in accordance with the internal laws and decisions of the State of Illinois, without regard to its conflict of laws principles, and shall be binding upon and inure to the benefit of the respective successors and assigns of the City and the Lender.
Section Titles; Plurals. The section titles contained in this Agreement are and shall be without substantive meaning or content of any kind whatsoever and are not a part of the agreement between the parties hereto. The singular form of any word used in this Agreement shall include the plural form.
Notices. Any notice required hereunder shall be in writing and addressed to the party to be notified as follows:
If to Developer:
68
City of Chicago Department of Planning and Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner
Attention:
With Copies To: City of Chicago Department of Law 121 North LaSalle Street, Room 600 Chicago, Illinois 60602 Attention: Finance and Economic Development Division With Copies To:
Attention:
or to such other address as either party may designate for itself by notice. Notice shall be deemed to have been duly given (i) if delivered personally or otherwise actually received, (ii) if sent by overnight delivery service, (iii) if mailed by first class United States mail, postage prepaid, registered or certified, with return receipt requested, or (iv) if sent by facsimile with facsimile confirmation of receipt (with duplicate notice sent by United States mail as provided above). Notice mailed as provided in clause (iii) above shall be effective upon the expiration of three (3) business days after its deposit in the United States mail. Notice given in any other manner described in this paragraph shall be effective upon receipt by the addressee thereof; provided, however, that if any notice is tendered to an addressee and delivery thereof is refused by such addressee, such notice shall be effective upon such tender.
7. Counterparts. This Agreement may be executed in two or more counterparts, each of which shall constitute an original and all of which, when taken together, shall constitute one instrument.
69
IN WITNESS WHEREOF, this Subordination Agreement has been signed as of the date first written above.
[LENDER], [a national banking association] By:
Its:
CITY OF CHICAGO By:
Its: Commissioner,
Department of Planning and Development
ACKNOWLEDGED AND AGREED TO THIS
DAY OF ,
[Developer], a
By: Its:
Exhibit to Subordination Agreement - Legal Description
70
STATE OF ILLINOIS COUNTY OF COOK
)
)SS
)
I, the undersigned, a notary public in and for the County and State aforesaid, DO HEREBY
CERTIFY THAT , personally known to me to be the Commissioner of
the Department of Planning and Development of the City of Chicago, Illinois (the "City") and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that as such Commissioner, (s)he signed and delivered the said instrument pursuant to authority, as his/her free and voluntary act, and as the free and voluntary act and deed of said City, for the uses and purposes therein set forth.
GIVEN under my hand and notarial seal this day of , .
Notary Public
My Commission Expires
(SEAL)
STATE OF ILLINOIS )
)SS
COUNTY OF COOK )
71
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY THAT , personally known to me to be the
of [Lender], a , and personally known to me to
be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed and delivered said instrument, pursuant to the authority given to him/her by Lender, as his/her free and voluntary act and as the free and voluntary act of the Lender, for the uses and purposes therein set forth.
GIVEN under my hand and notarial seal this day of , .
Notary Public
My Commission Expires
(SEAL)
"A
72
EXHIBIT O
FORM OF PAYMENT/PERFORMANCE BOND [omitted for ordinance]
73
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
SECTION I -- GENERAL INFORMATION
Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Chicago Cooperative (d/b/a Chicago Market - A Community Co-op)
Check ONE of the following three boxes:
Indicate whether the Disclosing Party submitting this EDS is:
1. /J the Applicant
OR
2. | a legal entity currently holding, or anticipated to hold within six months after City action on
the contract, transaction or other undertaking to which this EDS pertains (referred to below as the
"Matter"), a direct or indirect interest in excess of 7.5% in the Applicant. State the Applicant's legal
name:
OR
3. [ ] a legal entity with a direct or indirect right of control of the Applicant (see Section 11(B)(1))
State the legal name of the entity in which the Disclosing Party holds a right of control:
Business address ofthe Disclosing Party: 4620 North Broadway
Chicago, IL, 60640
(586) 212-6235 MatthewR@ChicagoMarket.coop
Telephone: Fax: Email:
N'ainc of comae, person: Matthew L. Ruffi ¦_ _
E. Federal Employer Identification No. (if you have one):
Brief description of the Matter to which this EDS pertains. (Include project numoer and location of property, if applicable):
Application for redevelopment of 4620 North Broadway, Chicago, IL 60640
Which City agency or department is requesting this EDS?
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
Specification # and Contract #
Ver.2018-l Paget of 15
SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS
A. NATURE OF THE DISCLOSING PARTY
1. Indicate the nature of the Disclosing Party:
[ ] Person [ ] Limited liability company
[ ] Publicly registered business corporation [ ] Limited liability partnership
[/] Privately held business corporation [ ] Joint venture
[ ] Sole proprietorship [ ] Not-for-profit corporation
[ ] General partnership (Is the not-for-profit corporation also a 501(c)(3))?
[ ] Limited partnership [ ] Yes [ ] No
[ ] Trust | ] Other (please specify)
For legal entities, the state (or foreign country) of incorporation or organization, if applicable:
N/A
For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
[ J Yes \ 1 No f / Organized in Illinois
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1. List below the full names and titles, if applicable, of: (i) all executive officers and all directors of the entity; (ii) for not-for-profit corporations, all members, if any, which are legal entities (if there are no such members, write "no members which are legal entities"); (iii) for trusts, estates or other similar entities, the trustee, executor, administrator, or similarly situated party; (iv) for general or limited partnerships, limited liability companies, limited liability partnerships or joint ventures, each general partner, managing member, manager or any other person or legal entity that directly or indirectly controls the day-to-day management of the Applicant.
NOTE: Each legal entity listed below must submit an EDS on its own behalf.
Name Title
See attached (Chicago Market - EDS - SECTION il (B.1) - Board of Directors Listpdf)
2. Please provide the following information concerning each person or legal entity having a direct or indirect, current or prospective (i.e. within 6 months after City action) beneficial interest (including ownership) in excess of 7.5% of the Applicant. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture, interest of a member or manager in a
Page 2 of 15
limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None."
NOTE: Each legal entity listed below may be required to submit an EDS on its own behalf.
Name Business Address Percentage Interest in the Applicant
N/A
SECTION m - INCOME OR COMPENSATION TO, OR OWNERSHIP BY, CITY ELECTED OFFICIALS
Has the Disclosing Party provided any income or compensation to any City elected official during the
12-month period preceding the date ofthis EDS? [ J Yes [/ No
Does the Disclosing Party reasonably expect to provide any income or compensation to any City
elected official during the 12-month period following the date of this EDS? [ ] Yes f/ No
If "yes" to either of the above, please identify below the name(s) of such City elected official(s) and
describe such income or compensation:
n/a
Does any City elected official or, to the best of the Disclosing Party's knowledge after reasonable
inquiry, any City elected official's spouse or domestic partner, have a financial interest (as defined in
Chapter 2-156 of the Municipal Code of Chicago (MCC) in the Disclosing Party?
f/1 Yes r 1 No
If "yes," please identify below the name(s) of such City elected official(s) and/or spouse(s)/domestic partner(s) and describe the financial interest(s).
James Cappleman, the outgoing 46th Ward Alderman, holds 10 preferred shares ($10,000), in Chicago Market, which are non voting. Additionally, he holds 2.5 ($250) in common stock which equates to less than 0.00015% of outstanding (and less than 0.04% of currently Issued) shares
SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist (as defined in MCC Chapter 2-156), accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll. Ifthe Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
Page 3 of IS
Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE;
to be retained) lobbyist, etc.) "hourly rate" or "t.b.d." is
not an acceptable response. See attached (Chicago Market - EDS - SECTION IV -Disclosure of subcontractors and other retained parties.pdf)
(Add sheets if necessary)
| | Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under MCC Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
J Yes [ j No [/_. No person directly or indirectly owns 10% or more of the Disclosing Party.
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
: | Yes | No
FURTHER CERTIFICATIONS
[This paragraph 1 applies only if the Matter is a contract being handled by the City's Department of Procurement Services.] In the 5-year period preceding the date of this EDS, neither the Disclosing Party nor any Affiliated Entity [see definition in (5) below] has engaged, in connection with the performance of any public contract, the services of an integrity monitor, independent private sector inspector general, or integrity compliance consultant (i.e., an individual or entity with legal, auditing, investigative, or other similar skills, designated by a public agency to help the agency monitor the activity of specified agency vendors as well as help the vendors reform their business practices so they can be considered for agency contracts in the future, or continue with a contract in progress).
The Disclosing Party and its Affiliated Entities are not delinquent in the payment of any fine, fee, tax or other source of indebtedness owed to the City of Chicago, including, but not limited to, water and sewer charges, license fees, parking tickets, property taxes and sales taxes, nor is the Disclosing Party delinquent in the payment of any tax administered by the Illinois Department of Revenue.
Page 4 of IS
The Disclosing Party and, ifthe Disclosing Party is a legal entity, all of those persons or entities identified in Section 11(B)(1) ofthis EDS:
are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
have not, during the 5 years before the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in subparagraph (b) above;
have not, during the 5 years before the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
have not, during the 5 years before the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The Disclosing Party understands and shall comply with the applicable requirements of MCC Chapters 2-56 (Inspector General) and 2-156 (Governmental Ethics).
Certifications (5), (6) and (7) concern:
the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity). Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity. With respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
Ver.2018-1 Page 5 of 15
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor, nor any Agents have, during the 5 years before the date of this EDS, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the 5 years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency ofthe federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in subparagraph (a) or (b) above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions referenced in MCC Subsection 2-92-3 20(a)(4)(Contracts Requiring a Base Wage); (a)(5)(Debarment Regulations); or (a)(6)(Minimum Wage Ordinance).
Neither the Disclosing Party, nor any Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on a Sanctions List maintained by the United States Department of Commerce, State, or Treasury, or any successor federal agency.
[FOR APPLICANT ONLY] (i) Neither the Applicant nor any "controlling person" [see MCC Chapter 1-23, Article I for applicability and defined terms] of the Applicant is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any "sister agency"; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If MCC Chapter 1-23, Article I applies to the Applicant, that Article's permanent compliance time frame supersedes 5-year compliance time frames in this Section V.
[FOR APPLICANT ONLY] The Applicant and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed as having an active exclusion by the U.S. EPA on the federal System for Award Management (SAM).
[FOR APPLICANT ONLY] The Applicant will obtain from any contractors/subcontractors hired
Page 6 of IS
or to be hired in connection with the Matter certifications equal in form and substance to those in Certifications (2) and (9) above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Applicant has reason to believe has not provided or cannot provide truthful certifications.
11. Ifthe Disclosing Party is unable to certify to any of the above statements in this Part B (Further
Certifications), the Disclosing Party must explain below:
N/A
Ifthe letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
12. To the best ofthe Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none"). N/A
13. To the best ofthe Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, ofthe City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $25 per recipient, or (iii) a political contribution otherwise duly reported as required by law (if none, indicate with "N/A" or
"none"). As to any gift listed below, please also list the name of the City recipient. N/A
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
The Disclosing Party certifies that the Disclosing Party (check one)
is / is not
a "financial institution" as defined in MCC Section 2-32-455(b).
If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in MCC Chapter 2-32. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in
Page 7 of 15
MCC Chapter 2-32. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
Ifthe Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in MCC Section 2-32-455(b)) is a predatory lender within the meaning of MCC Chapter 2-32, explain here (attach additional pages if necessary): N/A
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
D. CERTIFICATION REGARDING FINANCIAL INTEREST IN CITY BUSINESS
Any words or terms defined in MCC Chapter 2-156 have the same meanings if used in this Part D.
In accordance with MCC Section 2-156-110: To the best of the Disclosing Party's knowledge after reasonable inquiry, does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
|/ Yes | | No
NOTE: If you checked "Yes" to Item D(l), proceed to Items D(2) and D(3). If you checked "No" to Item D(l), skip Items D(2) and D(3) and proceed to Part E.
Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
Does the Matter involve a City Property Sale?
| Yes • /1 No
If you checked "Yes" to Item D(l), provide the names and business addresses of the City officials or employees having such financial interest and identify the nature of the financial interest:
Name Business Address Nature of Financial Interest
James Cappleman 4544 N Broadway, Chicago, IL 60640 Cappleman, the outgoing 46th Ward
Alderman, holds 10 preferred shares ($10,000), in Chicago Market, which are non voting. Additionally, he holds 2.5
($250) in common stock which equates to less than 0.00015% of outstanding (and less than 0.04% of currently issues) shares.
Page 8 of 15
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
Please check either (1) or (2) below. If the Disclosing Party checks (2), the Disclosing Party must disclose below or in an attachment to this EDS all information required by (2). Failure to comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
X 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
2. The Disclosing Party verifies that, as a result of conducting the search in step (1) above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such, records, including the names of any and all slaves or slaveholders described in those records:
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
A. CERTIFICATION REGARDING LOBBYING
1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995, as amended, who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995, as amended, have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay
Ver.2018-1 Page 9 of 15
any person or entity listed in paragraph A(l) above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A(l) and A(2) above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities," as that term is defined in the Lobbying Disclosure Act of 1995, as amended.
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A(l) through A(4) above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant? | Yes No
If "Yes," answer the three questions below:
Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
. . Yes :. No
Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
_ Yes I No Reports not required
Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
| Yes No
If you checked "No" to question (1) or (2) above, please provide an explanation:
Ver.2018-1 , Page 10 of 15
SECTION VII -- FURTHER ACKNOWLEDGMENTS AND CERTIFICATION
The Disclosing Party understands and agrees that:
The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics Ordinance, MCC Chapter 2-156, imposes certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of this ordinance and a training program is available on line at www.cityofchicago.org/Ethics , and may also be obtained from the Cit^s Board of Ethics, 740 N. Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with this ordinance.
If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other City transactions. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided in, and appended to, this EDS may be made publicly available on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to MCC Chapter 1-23, Article I (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by MCC Chapter 1 -23 and Section 2-154-020.
Page 11 of 15
CERTIFICATION
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS, and all applicable Appendices, on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS, and all applicable Appendices, are true, accurate and complete as of the date furnished to the City.
Chicago Cooperative (d/b/a Chicago Market - A Community Co-op)
(Print or type name of person signing)
President, Board of Directors
(Print or type title of person signing)
Signed and sworn to before me on (date)
County,
Notary Public
Commission expires:
Page 12 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5%. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Under MCC Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as ofthe date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section ll.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5% ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
Yes VI No
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
Page 13 of IS
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX B
BUILDING CODE SCOFFLAW7PROBLEM LANDLORD CERTIFICATION
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5% (an "Owner"). It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Pursuant to MCC Section 2-154-010, is the Applicant or any Owner identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
Yes / No
If the Applicant is a legal entity publicly traded on any exchange, is any officer or director of the Applicant identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
Yes No ? The Applicant is not publicly traded on any exchange.
If yes to (1) or (2) above, please identify below the name of each person or legal entity identified as a building code scofflaw or problem landlord and the address of each building or buildings to which the pertinent code violations apply.
Page 14 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX C
PROHIBITION ON WAGE & SALARY HISTORY SCREENING - CERTIFICATION
This Appendix is to be completed only by an Applicant that is completing this EDS as a "contractor" as defined in MCC Section 2-92-385. That section, which should be consulted (www.amlegal.com ), generally covers a party to any agreement pursuant to which they: (i) receive City of Chicago funds in consideration for services, work or goods provided (including for legal or other professional services), or (ii) pay the City money for a license, grant or concession allowing them to conduct a business on City premises.
On behalf of an Applicant that is a contractor pursuant to MCC Section 2-92-385,1 hereby certify that the Applicant is in compliance with MCC Section 2-92-385(b)(l) and (2), which prohibit: (i) screening job applicants based on their wage or salary history, or (ii) seeking job applicants' wage or salary history from current or former employers. I also certify that the Applicant has adopted a policy that includes those prohibitions.
Yes
No
/ N/A -1 am not an Applicant that is a "contractor" as defined in MCC Section 2-92-385. This certification shall serve as the affidavit required by MCC Section 2-92-385(c)(1). If you checked "no" to the above, please explain.
Page 15 of 15
A Community Co-op)
Chicago Cooperative (d/b/a Chicago Market -
Board of Directors
As of November 9, 2022
Director Name Officer Role (where applicable)
Howie Bollinger
Chris Burns
Donna Curtin
James Gignac Secretary
Kate Grimm Treasurer
Lee Herman
Leslie Jenkins
Grant Kessler
Bob Kunze
Dana McKinney Vice President
Matthew L. Ruffi President
Anthony R. Todd
fN fN O fN
cn
k.
oj .q
E
> o z
o
in <
ui ai
n ro
Q-|1010|E H
E ¦=
o
^ -o
"
4j VI|109|t!
o c
g1|9109|£
ro O
2.|910|o)|910|> u
JO Q
0) .
a i
§ >
§>|910|s C
£ UJ
U
11 11
Ol c
11 or
"0 "D <
|1010|a
11
If
QJ
E a Z
|1010|m
Tf
Tf . . LD
a- "S £
"> s ¦
CD 2 f)
« E m
'+= °-
~ IM «*1
0_
c
Ul
'l/l c
i; o
Q £
+j .a
ll CT
QJ CC
Ol 4-»
m c
o (j ^
tJ
DJ
o1
ft
O
o
11|109|fN
lo r-~
- o
~o ro
g L"
00|910|cd ro
in|910|C 0-
01
o
L0
rn JB ld ro «h~
l/l Tf
C O
u
o m m
£ ra
I
Q D
o or
Tf ¦H
CO
E
0)
Q
ti O
rM T3 in
f\j Tf|109|"8
(ft il H
• • ro ro
? E
o
tJ
o
ro
o o
OT LD
o o
a
01 3
r^ ID id E ui +j ro
o U
.c U
t o Z t—i
rM in ro
ai o or oi
2 o 2
43 LD
ro Tf E r-: rM
,f. o>
o U
Cl 10
o o o
CO
o or
o o in
I
m
4_» O
ro o
E Tf
o u
a, co
° g
&=! ¦?
z i>
ro zzi
S3 c
ro co
01
or
o u c oi
o o o_ ¦u in"
ro
I o tt o
LU O
o"
tH
¦lo
IC
o o
E
"O
c
rM ai rM
u c
Ol
Ol ^ O
"? « §|109|"g u>
CO
Ol 01 '
^ ™ s
ro"
2. S«
E
o
.= ._ o
c o U > -o|1010|
>
z
oi
> LO
~ ro
j_, cn
tt 00
cn o co
13
01
or
cm 13
¦b
ai o
™ s
.- (N
tt <^
E c
o oi
oi
L0 c
o - 10 0) o 3 tD
m c ro
O O LO
<
i5 i> .a c o U
? o
ro o E o" in
fi <
o o
O) 01
L0
in o to
o
u IS)
_i o. —
ro cn u ro
c y
ra
.E U
L0 in
oi
a
CL <
ra a.