Record #: O2013-4996   
Type: Ordinance Status: Passed
Intro date: 6/26/2013 Current Controlling Legislative Body: Committee on Finance
Final action: 7/24/2013
Title: Loan and redevelopment agreement with Lake Street Studios LP and Interfaith Housing Development Corporation for acquisition and construction of affordable multi-story building at 727 W Lake St
Sponsors: Emanuel, Rahm
Topic: AGREEMENTS - Redevelopment
Attachments: 1. O2013-4996.pdf
ORDINANCE
WHEREAS, by virtue of Section 6(a) of Article VII of the 1970 Constitution of the State of Illinois, the City of Chicago (the "City") is a home rule unit of local government and as such may exercise any power and perform any function pertaining b its government and affairs; and
WHEREAS, by this Ordinance, the City Council has determined that it is necessary and in the best interests of the City to provide certain financing to Lake Street Studios Limited Partnership (the "Borrower"), an Illinois limited partnership, the general partner of which is Lake Street Studios LLC, an Illinois limited liability company ("General Partner"), to pay a portion of the costs of acquiring and constructing the Lake Street Studios (the "Development'), an affordable housing development consisting of approximately 61 units in a multi-story building located at 727 West Lake Street in Chicago, Illinois; and
WHEREAS, the City has certain funds available from a variety of funding sources ("Multi-Family Program Funds") to make loans and grants for the development of multi-family residential housing to increase the number of families served with decent, safe, sanitary and affordable housing and to expand the long-term supply of affordable housing, and such Multi-Family Program Funds are administered by the City's Department of Housing and Economic Development ("DHED"); and
 
WHEREAS, DHED has preliminarily reviewed and approved the making of a loan to the Borrower in an amount not to exceed $4,100,000 (the "Affordable Housing Loan") for purposes of funding a portion of the Development, to be funded from Multi-Family Program Funds pursuant to the terms and conditions set forth in Exhibit A attached hereto and made a part hereof; and
WHEREAS, the Development will also be financed with proceeds of Additional Financing as outlined in Exhibit A hereto; and
WHEREAS, under ordinances adopted on March 23, 1989, and published in the Journal of Proceedings (the "Journal") of the City Council of the City (the "City Council") for such date at pages 25874 to 25933, and under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4.1 et seg., as amended (the uAcf), the City Council: (i) approved a redevelopment plan and project (the "Original Plan") for a portion of the City known as the "Madison/Racine Redevelopment Project Area" (the "Original Area"); (ii) designated the Original Area as a "redevelopment project area" within the requirements of the Act; and (iii) adopted tax increment financing for the Original Area (the foregoing items three ordinances are collectively referred to herein as the 'TIF Ordinances"); and
WHEREAS, the City Council subsequently determined it was necessary to expand the Original Area to include additional contiguous areas (such areas, together with the Original Area, the "Expanded Area") and to name the Expanded Area the "Near West Redevelopment Project Area"; and
WHEREAS, in connection with the Expanded Area, under ordinances adopted on June 10,1996, and published in the Journal for such date at pages 23188 to 23367, and under the provisions of the Act, the City Council amended and supplemented the TIF Ordinances by: (i) approving the "Near West Redevelopment Plan and Project" (the "Expanded Area Plan,") for the Expanded Area; (ii) designating the Expanded Project Area as a "redevelopment project area" pursuant to the Act, which reconfirmed the designation of the Original Area and designated the Expanded Area as a "redevelopment project area"; and (iii) adopting tax increment allocation
 
S:\SHARED\Finance\Lake Street Studios\Ordinance\HOME TIF ordinance v4
 
financing for the Expanded Area (the foregoing three ordinances are collectively referred to herein as the "Expanded Area TIF Ordinances"); and
 
WHEREAS, pursuant to ordinances adopted on (a) June 6, 2001, and published in the Journal for such date at pages 59235 to 59240, and (b) July 28, 2011, and published in the Journal for such date at pages 3859 to 4018, and (c) June 5, 2013 and soon to be published in the Journal for such date, the City Council amended the Expanded Area Plan (the Expanded Area Plan, as amended, referred to herein as the "Plan" and the Expanded Area, as amended, referred to herein as the "Area"), in order to, among other things, change the dates of completion of the redevelopment project described in the Plan, increase the total estimated redevelopment project costs and amend the land use map; and
WHEREAS, pursuant to Section 5/11-74.4-8(b) of the Act and the Expanded Area TIF Ordinances, incremental taxes ("Incremental Taxes") are deposited from time to time in the special tax allocation fund for the Area established pursuant to the Expanded Area TIF Ordinances (the "Fund"); and
WHEREAS, the Borrower and The Interfaith Housing Development Corporation of Chicago, an Illinois not-for-profit corporation ("IHDC" and collectively with the Borrower, the "Developer") have proposed to undertake the Development in accordance with the Plan and pursuant to the terms and conditions of a proposed Redevelopment Agreement (as defined in Section 14 below) to be executed by the Developer and the City, and the Developer will finance a portion of the construction of the Development with a portion of the Incremental Taxes in the Fund; and
WHEREAS, pursuant to Resolution 13-CDC-14 adopted by the Community Development Commission of the City (the "Commission") on May 14, 2013, the Commission authorized DHED to negotiate a Redevelopment Agreement with the Developer for the Development and to recommend that the Developer be designated as the developer for the Development; and
WHEREAS, the Development is necessary for the redevelopment of the Area;
NOW, THEREFORE, BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO, AS FOLLOWS:
Section 1. Incorporation of Recitals. The recitals contained in the preambles to this Ordinance are hereby incorporated into this Ordinance by this reference. All capitalized terms used in this Ordinance, unless otherwise defined herein, shall have the meanings ascribed thereto in the Indentures.
Section 2. Affordable Housing Loan. Upon the approval and availability of the Additional Financing as shown in Exhibit A hereto, the Commissioner of DHED (the "Commissioner") or a designee of the Commissioner (the "DHED Officer") are each hereby authorized, subject to approval by the Corporation Counsel, to enter into and execute such agreements and instruments, and perform any and all acts as shall be necessary or advisable in connection with the implementation of the Affordable Housing Loan. The DHED Officer is hereby authorized, subject to the approval of the Corporation Counsel, to negotiate any and all terms and provisions in connection with the Affordable Housing Loan which do not substantially modify the terms described in Exhibit A hereto. Upon the execution and receipt of proper documentation, the
 
 
-2-
 
 
DHED Officer is hereby authorized to disburse the proceeds of the Affordable Housing Loan to the Borrower or as otherwise provided in Exhibit A hereto.
Section 3. Developer Designation. The Developer is hereby designated as the developer for the Development pursuant to Section 5/11-74.4-4 of the Act.
 
Section 4. Redevelopment Agreement. The Commissioner or a designee of the Commissioner are each hereby authorized, with the approval of the City's Corporation Counsel as to form and legality, to negotiate, execute and deliver a redevelopment agreement between the Developer and the City substantially in the form attached hereto as Exhibit B and made a part hereof (the "Redevelopment Agreement'), and such other supporting documents as may be necessary to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement.
Section 5. Payment. The City Council hereby finds that the City is authorized to pay an amount not to exceed $3,100,000 from Incremental Taxes deposited in the General Account of the Fund (as defined in the Redevelopment Agreement), to finance a portion of the eligible redevelopment project costs (as such term is defined under the Act) included within the Project (such costs shall be known herein and in the Redevelopment Agreement as "TIF-Funded Improvements").
Section 6. Separability. If any provision of this Ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such provision shall not affect any of the remaining provisions of this Ordinance.
 
Section 7. Inconsistent Provisions. All ordinances, resolutions, motions or orders in conflict with this Ordinance are hereby repealed to the extent of such conflict.
Section 8. Effective Date. This Ordinance shall be in full force and effect immediately upon its passage.
Section 9. Certified Copies. The City Clerk shall provide to the Corporation Counsel, without charge, certified copies of this ordinance in such amount as shall be requested by the Corporation Counsel.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
-3-
 
 
EXHIBIT A
 
Affordable Housing Loan
 
Source:        Multi-Family Program Funds Amount:       Not to exceed $4,100,000
Term:      Not to exceed 52 years, or such other term as may be acceptable to the
Commissioner Interest:       0% per annum
Security: A mortgage no lower priority than a second mortgage during the construction period and a mortgage no lower priority than a first mortgage during the permanent period
 
Additional Financing
The following additional financing sources will also be available as follows:
 
1.       Low-Income Housing Tax Credits
Amount Approximately $11,321,000 or such amount as may be acceptable to the Commissioner, a portion of which will be applied to the payment of the Citibank, NA. construction ban
 
Source: To be derived from the syndication of Low-Income Housing Tax Credits allocated to the Development
 
2.      Construction Period Financing
 
Amount:       Approximately $8,650,000 or such amount as may be acceptable to the Commissioner
Source:        A loan to Borrowerfrom Citibank, N.A., or any such other entity acceptable to
the Commissioner
Term:      Not to exceed 30 months
Interest: Variable
Security:      A first position mortgage on the Development 3.      Tax Increment Financing
 
Amount:
 
 
Term:
Interest:
Security:
An amount not to exceed $3,100,000 of TIF proceeds granted by the City to IHDC, and loaned to the Borrower by IHDC or contributed as capital to the Borrower by the General Partner, or another source acceptable to the Commissioner.
Any loan not to exceed 52 years
Any loan not to exceed 5.30% per annum
Any loan to be secured by a mortgage on the Development junior to the lien of the City Mortgage.
 
 
4.      FHLB AHP Financing
 
Amount:
 
Approximately $549,000 or such amount as may be acceptable to the
 
 
 
 
Source:
 
 
 
Term:
Interest:
Security:
Commissioner
A loan from IHDC to the Borrower or a capital contribution by the General Partner to the Borrower, or any combination of the foregoing, derived from the proceeds of an FHLB AHP grant or another source acceptable to the Commissioner.
Any loan not to exceed 52 years
Any loan not to exceed 5.30% per annum
Any loan to be secured by a mortgage on the Development junior to the lien of the City Mortgage.
 
DCEO Financing
 
Amount: Approximately $145,346 or such amount as may be acceptable to the Commissioner
Source: A loan from IHDC to the Borrower or a capital contribution by the General Partner to the Borrower, or any combination of the foregoing, derived from the proceeds of a DCEO grant or another source acceptable to the Commissioner.
Term:      Any loan not to exceed 52 years
Interest:       Any loan not to exceed 5.30% per annum
Security: Any loan to be secured by a mortgage on the Development junior to the lien of the City Mortgage.
Deferred Developer Fee
The Development may also be financed by the deferral, at closing, of certain fees payable to the Developer.
 
EXHIBIT B Form of Redevelopment Agreement
(See Attached)
 
LAKE STREET STUDIOS REDEVELOPMENT AGREEMENT
 
 
 
 
 
 
BY AND BETWEEN
 
THE CITY OF CHICAGO AND
LAKE STREET STUDIOS LIMITED PARTNERSHIP
AND
THE INTERFAITH HOUSING DEVELOPMENT CORPORATION OF CHICAGO
 
 
 
This agreement was prepared by and after recording return to: Ann R. Kaplan-Perkins, Esq. City of Chicago Law Department 121 North LaSalle Street, Room 600 Chicago, IL 60602
 
 
 
 
 
 
 
 
1
 
 
TABLE OF CONTENTS
 
PAGE
SECTION 1. RECITALS      3
SECTION 2. DEFINITIONS      3
SECTION 3. THE PROJECT      10
  1. The Project      10
  2. Scope Drawings and Plans and Specifications      10
  3. Project Budget      10
  4. Change Orders      11
  5. DHED Approval      11
  6. Other Approvals      12
  7. Progress Reports and Survey Updates      12
  8. Inspecting Agent or Architect      12
  9. Barricades      12
  10. Signs and Public Relations      12
  11. Utility Connections      12
  12. Permit Fees      12
 
SECTION 4.      FINANCING      13
  1. Total Project Cost and Sources of Funds      13
  2. Developer Funds      13
  3. City Funds      13
  4. Reguisition Form      15
  5. Treatment of Prior Expenditures and Subseguent Disbursements      16
  6. Cost Overruns      17
  7. Preconditions of Disbursement      18
  8. Conditional Grant      19
  9. Cost of Issuance      19
SECTION 5. CONDITIONS PRECEDENT      19
  1. Project Budget      19
  2. Scope Drawings and Plans and Specifications      19
  3. Other Governmental Approvals      19
  4. Financing      20
  5. Acguisition and Title      20
  6. Evidence of Clean Title      20
  7. Surveys      21
  8. Insurance      21
  9. Opinion of the Developer's Counsel      21
  10. Evidence of Prior Expenditures      21
  11. Financial Statements      21
  12. Documentation      21
  13. Environmental      21
  14. Corporate Documents; Economic Disclosure Statement      21
  15. Litigation      22
 
SECTION 6. AGREEMENTS WITH CONTRACTORS      22
 
2
 
  1. Bid Requirement for General Contractor and Subcontractors      22
  2. Construction Contract      23
  3. Performance and Payment Bonds      23
  4. Employment Opportunity      23
  5. Other Provisions      23
 
SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION      23
  1. Certificate of Completion of Construction or Rehabilitation      23
  2. Effect of Issuance of Certificate; Continuing Obligations      24
  3. Failure to Complete      24
  4. Notice of Expiration of Term of Agreement      25
 
SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF THE DEVELOPER      25
  1. General      25
  2. Covenant to Redevelop      27
  3. Redevelopment Plan      27
  4. Use of City Funds      27
  5. Other Bonds      27
  6. Job Creation and Retention; Covenant to Remain in the City      28
  7. Employment Opportunity!; Progress Reports]      28
  8. Employment Profile      28
  9. Prevailing Wage      28
  10. Arms-Length Transactions      29
  11. Conflict of Interest      29
  12. Disclosure of Interest      29
  13. Financial Statements      29
  14. Insurance      29
  15. Non-Governmental Charges      29
  16. Developer's Liabilities      30
  17. Compliance with Laws      30
  18. Recording and Filing      30
  19. Real Estate Provisions      31
  20. Survival of Covenants      35
  21. Annual Compliance Report      35
 
SECTION .9. COVENANTS/REPRESENTATIONS/WARRANTIES OF CITY      35
  1. General Covenants      35
  2. Survival of Covenants      35
 
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS      35
  1. Employment Opportunity      35
  2. City Resident Construction Worker Employment Requirement      36
SECTION 11. ENVIRONMENTAL MATTERS      40
SECTION 12. INSURANCE      41
SECTION 13. INDEMNIFICATION      45
13.01 General Indemnity      45
 
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT      46
 
3
 
  1. Books and Records      46
  2. Inspection Rights      46
 
SECTION 15. DEFAULT AND REMEDIES      46
  1. Events of Default      46
  2. Remedies      48
  3. Curative Period      48
SECTION 16. MORTGAGING OF THE PROJECT      48
SECTION 17. NOTICE      49
SECTION 18. MISCELLANEOUS      50
  1. Amendment      50
  2. Entire Agreement      51
  3. Limitation of Liability      51
  4. Further Assurances      51
  5. Waiver      51
  6. Remedies Cumulative      51
  7. Disclaimer      51
  8. Headings      51
  9. Counterparts      51
  10. Severability      51
  11. Conflict      52
  12. Governing Law      52
  13. Form of Documents      52
  14. Approval      52
  15. Assignment      52
  16. Binding Effect      52
  17. Force Majeure      52
  18. Exhibits      53
  19. Business Economic Support Act      53
  20. Venue and Consent to Jurisdiction      53
  21. Costs and Expenses      53
  22. Business Relationships      53
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
4
 
 
LIST OF EXHIBITS
 
it A ►it B iitC iitD »it E ►it F •it G ■it H lit I lit J >it K ►it L
*Redevelopment Area *Property
*TIF-Funded Improvements Redevelopment Plan Construction Contract Escrow Agreement *Permitted Liens *Project Budget Approved Prior Expenditures Opinion of Developer's Counsel Requisition Form
Form of Subordination Agreement
 
 
(An asterisk (*) indicates which exhibits are to be recorded.)
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
5
 
 
[leave blank 3" x 5" space for recorder's office]
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
This agreement was prepared by and after recording return to: Ann R. Kaplan-Perkins, Esq. City of Chicago Law Department 121 North LaSalle Street, Room 600 Chicago, IL 60602
 
 
LAKE STREET STUDIOS REDEVELOPMENT AGREEMENT
 
This Lake Street Studios Redevelopment Agreement (this "Agreement") is made as of this
      day of      , 2013, by and between the City of Chicago, an Illinois municipal
corporation (the "City"), through its Department of Housing and Economic Development ("DHED"), Lake Street Studios Limited Partnership, an Illinois limited partnership (the "Owner"), and The Interfaith Housing Development Corporation of Chicago, an Illinois not-for-profit corporation ("IHDC" and sometimes collectively with the Owner, the "Developer").
RECITALS
  1. Constitutional Authority: As a home rule unit of government under Section 6(a), Article VII of the 1970 Constitution of the State of Illinois (the "State"), the City has the power to regulate for the protection of the public health, safety, morals and welfare of its inhabitants, and pursuant thereto, has the power to encourage private development in order to enhance the local tax base, create employment opportunities and to enter into contractual agreements with private parties in order to achieve these goals.
  2. Statutory Authority: The City is authorized under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4-1 et seg., as amended from time to time (the "Act"), to finance projects that eradicate blighted conditions and conservation area factors through the use of tax increment allocation financing for redevelopment projects.
  3. City Council Authority: To induce redevelopment pursuant to the Act, the City Council of the City (the "the City Council") adopted the following ordinances on March 23, 1989: (1) "An Ordinance of the City of Chicago, Illinois Approving a Redevelopment Plan for the Madison-Racine Redevelopment Project Area"; (2) "An Ordinance of the City of Chicago, Illinois Designating the Madison-Racine Redevelopment Project Area as a Redevelopment Project Area Pursuant to the
 
6
 
 
Tax Increment Allocation Redevelopment Act"; and (3) "An Ordinance of the City of Chicago, Illinois Adopting Tax Increment Allocation Financing for the Madison-Racine Redevelopment Project Area" (the "TIF Adoption Ordinance"); and, thereafter, on June 10, 1996, the City Council adopted ordinances (the "Expansion Ordinances"), expanding the boundaries of the Madison-Racine Redevelopment Project Area and renaming such expanded area the Near West Redevelopment Project Area (the "Redevelopment Area"); and, thereafter, on June 6,2001, the City Council adopted an ordinance (the "Extension Ordinance") to clarify the portability language in the redevelopment plan for the Redevelopment Area and extending the termination date of the Redevelopment Area to December 31, 2013; and thereafter, on July 28, 2011, the City Council adopted an ordinance (the "Third Amendment Ordinance") amending the redevelopment plan for the Redevelopment Area to increase the total estimated project costs; and thereafter, on June 5,2013, the City Council adopted an ordinance (the "Fourth Amendment Ordinance") amending the land use map in the redevelopment plan for the Redevelopment Area (items(1)-(3), the Expansion Ordinances, the Extension Ordinance, the Third Amendment Ordinance and the Fourth Amendment Ordinance shall be collectively referred to herein as the "TIF Ordinances"). The Redevelopment Area is legally described in Exhibit A hereto.
  1. The Project: The Developer intends to purchase (the "Acquisition") certain property located within the Redevelopment Area at 727 West Lake Street, Chicago, Illinois 60661 and legally described on Exhibit B hereto (the "Property"), and, within the time frames set forth in Section 3.01 hereof, the Developer shall commence and complete construction of a multi-story building with approximately 61 affordable studio rental units for homeless individuals, those at risk of homelessness, and other low-income residents (the "Facility") thereon. The Facility will include certain commercial space on the ground floor, which is anticipated to be used for tenant supportive services. The Facility and related improvements (including but not limited to those TIF-Funded Improvements as defined below and set forth on Exhibit C) are collectively referred to herein as the "Project." The completion of the Project would not reasonably be anticipated without the financing contemplated in this Agreement.
  2. Redevelopment Plan: The Project will be carried out in accordance with this Agreement and the City of Chicago Near West Redevelopment Project Area Tax Increment Finance Program Redevelopment Plan and Project (the "Redevelopment Plan") attached hereto as Exhibit D.
  3. City Financing: The City agrees to use, in the amounts set forth in Section 4.03 hereof, Incremental Taxes (as defined below), to pay for or reimburse IHDC for the costs of TIF-Funded Improvements pursuant to the terms and conditions of this Agreement.
 
In addition, the City may, in its discretion, issue tax increment allocation bonds ("TIF Bonds") secured by Incremental Taxes pursuant to a TIF bond ordinance (the "TIF Bond Ordinance") at a later date as described in Section 4.03(d) hereof, the proceeds of which (the "TIF Bond Proceeds") may be used to pay for the costs of the TIF-Funded Improvements not previously paid for from Incremental Taxes, in order to reimburse the City for the costs of TIF-Funded Improvements.
 
Now, therefore, in consideration of the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:
 
SECTION 1. RECITALS
 
The foregoing recitals are hereby incorporated into this agreement by reference.
 
7
 
 
SECTION 2. DEFINITIONS
 
For purposes of this Agreement, in addition to the terms defined in the foregoing recitals, the following terms shall have the meanings set forth below:
"Act" shall have the meaning set forth in the Recitals hereof.
"Actual residents of the City" shall mean persons domiciled within the City.
"Acquisition" shall have the meaning set forth in the Recitals hereof.
"Affiliate" shall mean any person or entity directly or indirectly controlling, controlled by or under common control with the Developer.
 
"Annual Compliance Report" shall mean a signed report from the Developer to the City (a) itemizing each of the Developer's obligations under the RDA during the preceding calendar year, (b) certifying the Developer's compliance or noncompliance with such obligations, (c) attaching evidence (whether or not previously submitted to the City) of such compliance or noncompliance and (d) certifying that the Developer is not in default with respect to any provision of the RDA, the agreements evidencing the Lender Financing, if any, or any related agreements; provided, that the obligations to be covered by the Annual Compliance Report shall include the following: (1) compliance with the Operating Covenant (Section 8.06); (2) compliance with the Jobs Covenant (Section 8.06); (3) delivery of Financial Statements and unaudited financial statements (Section 8.13); (4) delivery of updated insurance certificates, if applicable (Section 8.14); (5) delivery of evidence of payment of Non-Governmental Charges, if applicable (Section 8.15); and (6) compliance with all other executory provisions of the RDA.
 
"Available Project Funds" shall have the meaning set forth for such term in Section 4.07
hereof.
"Bond(s)" shall have the meaning set forth for such term in Section 8.05 hereof.
"Bond Ordinance" shall mean the City ordinance authorizing the issuance of Bonds.
"Business Relationship" shall have the meaning set forth for such term in Section 2-156-080 of the Municipal Code of Chicago.
 
"Certificate" shall mean the Certificate of Completion of Construction described in Section 7.01 hereof.
 
"Change Order" shall mean any amendment or modification to the Scope Drawings, Plans and Specifications or the Project Budget as described in Section 3.03, Section 3.04 and Section 3.05. respectively.
"City Contract" shall have the meaning set forth in Section 8.01(1) hereof.
"City Council" shall have the meaning set forth in the Recitals hereof.
"City Funds" shall mean the funds described in Section 4.03(b) hereof.
 
8
 
 
"Closing Date" shall mean the date of execution and delivery of this Agreement by all parties hereto, which shall be deemed to be the date appearing in the first paragraph of this Agreement.
 
"Contract" shall have the meaning set forth in Section 10.03 hereof.
 
"Contractor" shall have the meaning set forth in Section 10.03 hereof.
 
"Construction Contract" shall mean that certain contract, substantially in the form attached hereto as Exhibit E, to be entered into between the Developer and the General Contractor providing for construction of the Project.
 
"Corporation Counsel" shall mean the City's Office of Corporation Counsel.
"Emplover(s)" shall have the meaning set forth in Section 10 hereof.
 
"Environmental Laws" shall mean any and all federal, state or local statutes, laws, regulations, ordinances, codes, rules, orders, licenses, judgments, decrees or requirements relating to public health and safety and the environment now or hereafter in force, as amended and hereafter amended, including but not limited to (i) the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. Section 9601 et seg.); (ii) any so-called "Superfund" or "Superlien" law; (iii) the Hazardous Materials Transportation Act (49 U.S.C. Section 1802 et seg.); (iv) the Resource Conservation and Recovery Act (42 U.S.C. Section 6902 et seg.); (v) the Clean Air Act (42 U.S.C. Section 7401 et seg.); (vi) the Clean Water Act (33 U.S.C. Section 1251 et seg.); (vii) the Toxic Substances Control Act (15 U.S.C. Section 2601 et seg.); (viii) the Federal Insecticide, Fungicide and Rodenticide Act (7 U.S.C. Section 136 et seg); (ix) the Illinois Environmental Protection Act (415 ILCS 5/1 et seg.); and (x) the Municipal Code of Chicago.
"Eguitv" shall mean funds of the Developer (other than funds derived from Lender Financing) irrevocably available for the Project, in the amount set forth in Section 4.01 hereof, which amount may be increased pursuant to Section 4.06 (Cost Overruns) or Section 4.03(b).
"Escrow" shall mean the construction escrow established pursuant to the Escrow Agreement.
"Escrow Agreement" shall mean the Escrow Agreement establishing a construction escrow, to be entered into as of the date hereof by the Title Company (or an affiliate of the Title Company), the Developer and the Developer's lender(s), substantially in the form of Exhibit F attached hereto.
"Event of Default" shall have the meaning set forth in Section 15 hereof.
 
"Facility" shall have the meaning set forth in the Recitals hereof.
 
"Financial Statements" shall mean complete audited financial statements of the Developer prepared by a certified public accountant in accordance with generally accepted accounting principles and practices consistently applied throughout the appropriate periods.
 
"General Contractor" shall mean the general contractor(s) hired by the Developer pursuant to Section 6.01.
 
 
9
 
 
"Hazardous Materials" shall mean any toxic substance, hazardous substance, hazardous material, hazardous chemical or hazardous, toxic or dangerous waste defined or qualifying as such in (or for the purposes of) any Environmental Law, or any pollutant or contaminant, and shall include, but not be limited to, petroleum (including crude oil), any radioactive material or by-product material, polychlorinated biphenyls and asbestos in any form or condition.
 
"Human Rights Ordinance" shall have the meaning set forth in Section 10 hereof.
 
"In Balance" shall have the meaning set forth in Section 4.07 hereof.
"Incremental Taxes" shall mean such ad valorem taxes which, pursuant to the TIF Adoption Ordinance and Section 5/11 -74.4-8(b) of the Act, are allocated to and when collected are paid to the Treasurer of the City of Chicago for deposit by the Treasurer into the Near West TIF Fund established to pay Redevelopment Project Costs and obligations incurred in the payment thereof.
 
"Indemnitee" and "Indemnitees" shall have the meanings set forth in Section 13.01 hereof.
"Lender Financing" shall mean funds borrowed by the Developer from lenders and irrevocably available to pay for Costs of the Project, in the amount set forth in Section 4.01 hereof.
 
"MBE(s)" shall mean a business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a minority-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
"MBE/WBE Program" shall have the meaning set forth in Section 10.03 hereof.
"Municipal Code" shall mean the Municipal Code of the City of Chicago.
 
"Near West TIF Fund" shall mean the special tax allocation fund created by the City in connection with the Redevelopment Area into which the Incremental Taxes will be deposited.
"New Mortgage" shall have the meaning set forth in Article 16 hereof.
"Non-Governmental Charges" shall mean all non-governmental charges, liens, claims, or encumbrances relating to the Developer, the Property or the Project.
"Permitted Liens" shall mean those liens and encumbrances against the Property and/or the Project set forth on Exhibit G hereto.
 
"Permitted Mortgage" shall have the meaning set forth in Article 16 hereof.
 
"Plans and Specifications" shall mean initial construction documents containing a site plan and working drawings and specifications for the Project, as submitted to the City as the basis for obtaining building permits for the Project.
 
"Prior Expenditure(s)" shall have the meaning set forth in Section 4.05(a) hereof.
 
"Project" shall have the meaning set forth in the Recitals hereof.
 
 
 
10
 
 
"Project Budget" shall mean the budget attached hereto as Exhibit H, showing the total cost of the Project by line item, furnished by the Developer to DHED, in accordance with Section 3.03 hereof.
"Property" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Area" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Plan" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Project Costs" shall mean redevelopment project costs as defined in Section 5/11 -74.4-3(q) of the Act that are included in the budget set forth in the Redevelopment Plan or otherwise referenced in the Redevelopment Plan.
 
"Reguisition Form" shall mean the document, in the form attached hereto as Exhibit K, to be delivered by the Developer to DHED pursuant to Section 4.04 of this Agreement.
 
"Scope Drawings" shall mean preliminary construction documents containing a site plan and preliminary drawings and specifications for the Project.
 
"Survey" shall mean a Class A plat of survey in the most recently revised form of ALTA/ACSM urban survey of the Property dated within 45 days prior to the Closing Date, acceptable in form and content to the City and the Title Company, prepared by a surveyor registered in the State of Illinois, certified to the City and the Title Company, and indicating whether the Property is in a flood hazard area as identified by the United States Federal Emergency Management Agency (and updates thereof to reflect improvements to the Property in connection with the construction of the Facility and related improvements as required by the City or lender(s) providing Lender Financing).
"Term" shall mean the period of time commencing on the Closing Date and ending on the later of (a) [September 1, 2023], and (b) the date on which the Redevelopment Area is no longer in effect (through and including December 31, 2013).
"TIF Adoption Ordinance" shall have the meaning set forth in the Recitals hereof.
"TIF Bonds" shall have the meaning set forth in the Recitals hereof.
"TIF Bond Ordinance" shall have the meaning set forth in the Recitals hereof.
"TIF-Funded Improvements" shall mean those improvements of the Project which (i) qualify as Redevelopment Project Costs, (ii) are eligible costs under the Redevelopment Plan and (iii) the City has agreed to pay for out of the City Funds, subject to the terms of this Agreement. Exhibit C lists the TIF-Funded Improvements for the Project.
 
"TIF Ordinances" shall have the meaning set forth in the Recitals hereof.
 
"Title Company" shall mean Title Services, Inc., or such other title company acceptable to the City and the Developer.
 
 
 
 
11
 
 
"Title Policy" shall mean a title insurance policy in the most recently revised ALTA or equivalent form, showing the Developer as the insured, noting the recording of this Agreement as an encumbrance against the Property, and a subordination agreement in favor of the City with respect to previously recorded liens against the Property related to Lender Financing, if any, issued by the Title Company.
 
"WARN Act" shall mean the Worker Adjustment and Retraining Notification Act (29 U.S.C. Section 2101 et seg ).
 
"WBE(s)" shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
SECTION 3. THE PROJECT
  1. The Project. With respect to the Facility, the Developer shall, pursuant to the Plans and Specifications and subject to the provisions of Section 18.17 hereof: (i) commence construction no later than thirty (30) days after the Closing Date; and (ii) complete construction and conduct business operations therein no later than the second (2nd) anniversary of the Closing Date, subject to the provisions of Section 18.17 (Force Majeure).
  2. Scope Drawings and Plans and Specifications. The Developer has delivered the Scope Drawings and Plans and Specifications to DHED and DHED has approved same. After such initial approval, subsequent proposed changes to the Scope Drawings or Plans and Specifications shall be submitted to DHED as a Change Order pursuant to Section 3.04 hereof. The Scope Drawings and Plans and Specifications shall at all times conform to the Redevelopment Plan and all applicable federal, state and local laws, ordinances and regulations. The Developer shall submit all necessary documents to the City's Building Department, Department of Transportation and such other City departments or governmental authorities as may be necessary to acquire building permits and other required approvals for the Project.
  3. Project Budget. The Developer has furnished to DHED, and DHED has approved, a Project Budget showing total costs for the Project in an amount not less than Seventeen Million One Hundred Eighty Eight Thousand Four Hundred Eighty-Nine Dollars ($17,188,489). The Developer hereby certifies to the City that (a) it has Lender Financing and Equity in an amount sufficient to pay for all Project costs; and (b) the Project Budget is true, correct and complete in all material respects. The Developer shall promptly deliver to DHED certified copies of any Change Orders with respect to the Project Budget for approval pursuant to Section 3.04 hereof.
  4. Change Orders. Except as provided below, all Change Orders (and documentation substantiating the need and identifying the source of funding therefor) relating to material changes to the Project must be submitted by the Developer to DHED for DHED's prior written approval. The Developer shall not authorize or permit the performance of any work relating to any Change Order or the furnishing of materials in connection therewith prior to the receipt by the Developer of DHED's written approval. The Construction Contract, and each contract between the General Contractor and any subcontractor, shall contain a provision to this effect. An approved Change Order shall not be deemed to imply any obligation on the part of the City to increase the amount of City Funds which the City has pledged pursuant to this Agreement or provide any other additional assistance to the Developer.
 
 
12
 
  1. DHED Approval. Any approval granted by DHED of the Scope Drawings, Plans and Specifications and the Change Orders is for the purposes of this Agreement only and does not affect or constitute any approval required by any other City department or pursuant to any City ordinance, code, regulation or any other governmental approval, nor does any approval by DHED pursuant to this Agreement constitute approval of the quality, structural soundness or safety of the Property or the Project.
  2. Other Approvals. Any DHED approval under this Agreement shall have no effect upon, nor shall it operate as a waiver of, the Developer's obligations to comply with the provisions of Section 5.03 (Other Governmental Approvals) hereof. The Developer shall not commence construction of the Project until the Developer has obtained all necessary permits and approvals (including but not limited to DHED's approval of the Scope Drawings and Plans and Specifications) and proof of the General Contractor's and each subcontractor's bonding as required hereunder.
  3. Progress Reports and Survey Updates. The Developer shall provide DHED with written quarterly progress reports detailing the status of the Project, including a revised completion date, if necessary (with any change in completion date being considered a Change Order, requiring DHED's written approval pursuant to Section 3.04). The Developer shall provide three (3) copies of an updated Survey to DHED upon the request of DHED or any lender providing Lender Financing, reflecting improvements made to the Property.
  4. Inspecting Agent or Architect. An independent agent or architect (other than the Developer's architect) approved by DHED shall be selected to act as the inspecting agent or architect, at the Developer's expense, for the Project. The inspecting agent or architect shall perform periodic inspections with respect to the Project, providing certifications with respect thereto to DHED, prior to requests for disbursement for costs related to the Project hereunder.
 
3.09      Barricades. Prior to commencing any construction requiring barricades, the Developer
shall install a construction barricade of a type and appearance satisfactory to the City and
constructed in compliance with all applicable federal, state or City laws, ordinances and regulations.
DHED retains the right to approve the maintenance, appearance, color scheme, painting, nature,
type, content and design of all barricades.
  1. Signs and Public Relations. The Developer shall erect a sign of size and style approved by the City in a conspicuous location on the Property during the Project, indicating that financing has been provided by the City. The City reserves the right to include the name, photograph, artistic rendering of the Project and other pertinent information regarding the Developer, the Property and the Project in the City's promotional literature and communications.
  2. Utility Connections. The Developer may connect all on-site water, sanitary, storm and sewer lines constructed on the Property to City utility lines existing on or near the perimeter of the Property, provided the Developer first complies with all City requirements governing such connections, including the payment of customary fees and costs related thereto.
  3. Permit Fees. In connection with the Project, the Developer shall be obligated to pay only those building, permit, engineering, tap on and inspection fees that are assessed on a uniform basis throughout the City of Chicago and are of general applicability to other property within the City of Chicago.
 
 
 
 
13
 
 
SECTION 4. FINANCING
 
4.01 Total Project Cost and Sources of Funds.      The cost of the Project is estimated to be
not less than $17,188,489, to be applied in the manner set forth in the Project Budget. Such costs
shall be funded from the following sources:
 
Equity (subject to Sections 4.03(b) and 4.06)      $12,015,346*
City Multi-Family Loan Funds      $ 4,100,000**
City Funds      $ 3,100,000**
ESTIMATED TOTAL      $17,188,489**
'Includes approximately $8,650,000 of Section 42 tax credit equity to be bridged with a private construction loan during construction, approximately $549,000 of FHLB AHP funds anticipated to be loaned to the Owner by IHDC, and approximately $145,346 of DCEO funds anticipated to be loaned to the Owner by IHDC.
 
**The amounts of the City Multi-Family Loan Funds and the City Funds identified here are each maximum amounts, with the expectation that, among the two sources, the City will provide total funds of approximately $5,173,143. DHED may, prior to the Closing Date, determine the allocation of funds between City Multi-Family Loan Funds and the City Funds, and the final amount of such funds will be inserted into this Agreement prior to its execution.
4.02 Developer Funds. Equity and/or Lender Financing shall be used to pay all Project costs, including but not limited to Redevelopment Project costs and costs of TIF-Funded Improvements.
4.03 City Funds.
  1. Uses of City Funds. City Funds may only be used to pay directly or reimburse IHDC for costs of TIF-Funded Improvements that constitute Redevelopment Project Costs. Exhibit C sets forth, by line item, the TIF-Funded Improvements for the Project, and the maximum amount of costs that may be paid by or reimbursed from City Funds for each line item therein (subject to Sections 4.03(b) and 4.05(d)), contingent upon receipt by the City of documentation satisfactory in form and substance to DHED evidencing such cost and its eligibility as a Redevelopment Project Cost.
  2. Sources of City Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03 and Section 5 hereof, the City hereby agrees to provide City funds of (i) up to $1,500,000 upon execution of this Agreement, and (ii) up to $1,600,000 on or before December 31,2013, in Incremental Taxes (the "City Funds") to pay for or reimburse the Developer for the costs of the TIF-Funded Improvements, provided, however, that the $3,100,000 to be derived from Incremental Taxes shall be available to pay costs related to TIF-Funded Improvements and allocated by the City for that purpose only so long as the amount of the Incremental Taxes deposited into the Near West TIF Fund shall be sufficient to pay for such costs.
 
The Developer acknowledges and agrees that the City's obligation to pay for TIF-Funded Improvements is contingent upon the fulfillment of the conditions set forth above. In the event that such conditions are not fulfilled, the amount of Equity to be contributed by the Developer pursuant to Section 4.01 hereof shall increase proportionately.
 
 
 
14
 
  1. Requisition Form. On or before the Closing Date with respect to the first Requisition and not later than November 30, 2013 (or such other date as the parties may agree to) with respect to the second Requisition, IHDC shall provide DHED with a Requisition Form, along with the documentation described therein. Requisition for reimbursement of TIF-Funded Improvements shall be made only twice (or as otherwise permitted by DHED), and in amounts not to exceed the amounts set forth above in Section 4.03(b). IHDC shall meet with DHED at the request of DHED to discuss the Requisition Form(s) previously delivered.
  2. Treatment of Prior Expenditures . Only those expenditures made by the Owner or IHDC with respect to the Project prior to the Closing Date, evidenced by documentation satisfactory to DHED and approved by DHED as satisfying costs covered in the Project Budget, shall be considered previously contributed Equity or Lender Financing hereunder (the "Prior Expenditures"). DHED shall have the right, in its sole discretion, to disallow any such expenditure as a Prior Expenditure. Exhibit I hereto sets forth the prior expenditures approved by DHED as of the date hereof as Prior Expenditures. Prior Expenditures made for items other than TIF-Funded Improvements shall not be reimbursed to the Owner or IHDC, but shall reduce the amount of Equity and/or Lender Financing required to be contributed by the Developer pursuant to Section 4.01 hereof.
  3. Cost Overruns. If the aggregate cost of the TIF-Funded Improvements exceeds City Funds available pursuant to Section 4.03 hereof, or if the cost of completing the Project exceeds the Project Budget, the Developer shall be solely responsible for such excess cost, and shall hold the City harmless from any and all costs and expenses of completing the TIF-Funded Improvements in excess of City Funds and of completing the Project.
  4. Preconditions of Disbursement. Prior to each disbursement of City Funds hereunder, IHDC shall submit documentation regarding the applicable expenditures to DHED, which shall be satisfactory to DHED in its sole discretion. Delivery by IHDC to DHED of any request for disbursement of City Funds hereunder shall, in addition to the items therein expressly set forth, constitute a certification to the City, as of the date of such request for disbursement, that:
  1. the total amount of the disbursement request represents the actual cost of the Acquisition or the actual amount payable to (or paid to) the General Contractor and/or subcontractors who have performed work on the Project, and/or their payees;
  2. all amounts shown as previous payments on the current disbursement request have been paid to the parties entitled to such payment;
  1. the Developer has approved all work and materials for the current disbursement request, and such work and materials conform to the Plans and Specifications;
  2. the representations and warranties contained in this Redevelopment Agreement are true and correct and the Developer is in compliance with all covenants contained herein;
  3. the Developer has received no notice and has no knowledge of any liens or claim of lien either filed or threatened against the Property except for the Permitted Liens and/or liens bonded by the Developer or insured by the Title Company;
  4. no Event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default exists or has occurred; and
 
 
15
 
 
(g) the Project is In Balance. The Project shall be deemed to be in balance ("In Balance") only if the total of the available Project funds equals or exceeds the aggregate of the amount necessary to pay all unpaid Project costs incurred or to be incurred in the completion of the Project. "Available Project Funds" as used herein shall mean: (i) the undisbursed City Funds; (ii) the undisbursed Lender Financing, if any; (iii) the undisbursed Equity and (iv) any other amounts deposited by the Developer pursuant to this Agreement. The Developer hereby agrees that, if the Project is not In Balance, the Developer shall, within 10 days after a written request by the City, deposit with the escrow agent or will make available (in a manner acceptable to the City), cash in an amount that will place the Project In Balance, which deposit shall first be exhausted before any further disbursement of the City Funds shall be made.
 
The City shall have the right, in its discretion, to require the Developer to submit further documentation as the City may require in order to verify that the matters certified to above are true and correct, and any disbursement by the City shall be subject to the City's review and approval of such documentation and its satisfaction that such certifications are true and correct; provided, however, that nothing in this sentence shall be deemed to prevent the City from relying on such certifications by the Developer. In addition, the Developer shall have satisfied all other preconditions of disbursement of City Funds for each disbursement, including but not limited to requirements set forth in the Bond Ordinance, if any, TIF Bond Ordinance, if any, the Bonds, if any, the TIF Bonds, if any, the TIF Ordinances, this Agreement and/or the Escrow Agreement.
 
SECTION 5. CONDITIONS PRECEDENT
The following conditions have been complied with to the City's satisfaction on or prior to the Closing Date:
  1. Project Budget. The Developer has submitted to DHED, and DHED has approved, a Project Budget in accordance with the provisions of Section 3.03 hereof.
  2. Scope Drawings and Plans and Specifications. The Developer has submitted to DHED, and DHED has approved, the Scope Drawings and Plans and Specifications accordance with the provisions of Section 3.02 hereof.
  3. Other Governmental Approvals. The Developer has secured all other necessary approvals and permits required by any state, federal, or local statute, ordinance or regulation and has submitted evidence thereof to DHED.
  4. Financing. The Developer has furnished proof reasonably acceptable to the City that the Developer has Equity and Lender Financing in the amounts set forth in Section 4.01 hereof to complete the Project and satisfy its obligations under this Agreement. If a portion of such funds consists of Lender Financing, the Developer has furnished proof as of the Closing Date that the proceeds thereof are available to be drawn upon by the Developer as needed and are sufficient (along with other sources set forth in Section 4.01) to complete the Project. The Developer has delivered to DHED a copy of the construction escrow agreement entered into by the Developer regarding the Lender Financing. Any liens against the Property in existence at the Closing Date have been subordinated to certain encumbrances of the City set forth herein pursuant to a Subordination Agreement, in a form acceptable to the City, executed on or prior to the Closing Date, which is to be recorded, at the expense of the Developer, with the Office of the Recorder of Deeds of Cook County.
 
 
 
16
 
  1. Acquisition and Title. On the Closing Date, the Developer has furnished the City with a copy of the Title Policy for the Property, certified by the Title Company, showing the Owner as the named insured. The Title Policy is dated as of the Closing Date and contains only those title exceptions listed as Permitted Liens on Exhibit G hereto and evidences the recording of this Agreement pursuant to the provisions of Section 8.18 hereof. The Title Policy also contains such endorsements as shall be required by Corporation Counsel, including but not limited to an owner's comprehensive endorsement and satisfactory endorsements regarding zoning (3.1 with parking), contiguity, location, access and survey. The Developer has provided to DHED, on or prior to the Closing Date, documentation related to the purchase of the Property and certified copies of all easements and encumbrances of record with respect to the Property not addressed, to DHED's satisfaction, by the Title Policy and any endorsements thereto.
  2. Evidence of Clean Title. The Developer, at its own expense, has provided the City with searches under the Developer's name as follows:
Secretary of State      UCC search
Secretary of State      Federal tax search
Cook County Recorder        UCC search
Cook County Recorder        Fixtures search
Cook County Recorder        Federal tax search
Cook County Recorder        State tax search
Cook County Recorder        Memoranda of judgments search
U.S. District Court      Pending suits and judgments
Clerk of Circuit Court, Pending suits and judgments Cook County
showing no liens against the Developer, the Property or any fixtures now or hereafter affixed thereto, except for the Permitted Liens.
  1. Surveys. The Developer has furnished the City with three (3) copies of the Survey.
  2. Insurance. The Developer, at its own expense, has insured the Property in accordance with Section 12 hereof, and has delivered certificates required pursuant to Section 12 hereof evidencing the required coverages to DHED.
  3. Opinion of the Developer's Counsel. On the Closing Date, the Developer has furnished the City with an opinion of counsel, substantially in the form attached hereto as Exhibit J, with such changes as required by or acceptable to Corporation Counsel. If the Developer has engaged special counsel in connection with the Project, and such special counsel is unwilling or unable to give some of the opinions set forth in Exhibit J hereto, such opinions were obtained by the Developer from its general corporate counsel.
  4. Evidence of Prior Expenditures. The Developer has provided evidence satisfactory to DHED in its sole discretion of the Prior Expenditures in accordance with the provisions of Section 4.05(a) hereof.
  5. Financial Statements. The Developer has provided Financial Statements to DHED for its most recent fiscal year, and audited or unaudited interim financial statements.
  6. Documentation. The Developer has provided documentation to DHED, satisfactory in form and substance to DHED, with respect to current employment matters.
 
17
 
  1. Environmental. The Developer has provided DHED with copies of that certain phase I environmental audit completed with respect to the Property and any phase II environmental audit with respect to the Property required by the City. The Developer has provided the City with a letter from the environmental engineer(s) who completed such audit(s), authorizing the City to rely on such audits.
  2. Corporate Documents; Economic Disclosure Statement. The Owner has provided a copy of its Certificate of Existence and IHDC has provided a copy of its Articles of Incorporation, each containing the original certification of the Secretary of State of its state of its organization; certificates of good standing from the Secretary of State of its state of organization and all other states in which the Developer is qualified to do business; a secretary's certificate in such form and substance as the Corporation Counsel may require; Limited Partnership Agreement of the limited partner; By-laws of the corporation; and such other documentation as the City has requested. The Developer has provided to the City an Economic Disclosure Statement, in the City's then current form, dated as of the Closing Date.
  3. Litigation. The Developer has provided to Corporation Counsel and DHED, a description of all pending or threatened litigation or administrative proceedings involving the Developer, specifying, in each case, the amount of each claim, an estimate of probable liability, the amount of any reserves taken in connection therewith and whether (and to what extent) such potential liability is covered by insurance.
SECTION 6. AGREEMENTS WITH CONTRACTORS
6.01 Bid Requirement for General Contractor and Subcontractors, (a) Except as set forth in Section 6.01(b) below, prior to entering into an agreement with a General Contractor or any subcontractor for construction of the Project, the Developer shall solicit, or shall cause the General Contractor to solicit, bids from qualified contractors eligible to do business with, and having an office located in, the City of Chicago, and shall submit all bids received to DHED for its inspection and written approval, (i) For the TIF-Funded Improvements, the Developer shall select the General Contractor (or shall cause the General Contractor to select the subcontractor) submitting the lowest responsible bid who can complete the Project in a timely manner. If the Developer selects a General Contractor (or the General Contractor selects any subcontractor) submitting other than the lowest responsible bid for the TIF-Funded Improvements, the difference between the lowest responsible bid and the bid selected may not be paid out of City Funds, (ii) For Project work other than the TIF-Funded Improvements, if the Developer selects a General Contractor (or the General Contractor selects any subcontractor) who has not submitted the lowest responsible bid, the difference between the lowest responsible bid and the higher bid selected shall be subtracted from the actual total Project costs for purposes of the calculation of the amount of City Funds to be contributed to the Project pursuant to Section 4.03(b) hereof. The Developer shall submit copies of the Construction Contract to DHED in accordance with Section 6.02 below. Photocopies of all subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DHED within five (5) business days of the execution thereof. The Developer shall ensure that the General Contractor shall not (and shall cause the General Contractor to ensure that the subcontractors shall not) begin work on the Project until the Plans and Specifications have been approved by DHED and all requisite permits have been obtained.
 
(b) If, prior to entering into an agreement with a General Contractor for construction of the Project, the Developer does not solicit bids pursuant to Section 6.01(a) hereof, then the fee of the General Contractor proposed to be paid out of City Funds shall not exceed [14%] of the total amount
 
18
 
 
of the Construction Contract. Except as explicitly stated in this paragraph, all other provisions of Section 6.01(a) shall apply, including but not limited to the requirement that the General Contractor shall solicit competitive bids from all subcontractors.
  1. Construction Contract. Prior to the execution thereof, the Developer shall deliver to DHED a copy of the proposed Construction Contract with the General Contractor selected to handle the Project in accordance with Section 6.01 above, for DHED's prior written approval, which shall be granted or denied within ten (10) business days after delivery thereof. Within ten (10) business days after execution of such contract by the Developer, the General Contractor and any other parties thereto, the Developer shall deliver to DHED and Corporation Counsel a certified copy of such contract together with any modifications, amendments or supplements thereto.
  2. Performance and Payment Bonds. Prior to the commencement of any portion of the Project which includes work on the public way, the Developer shall require that the General Contractor be bonded for its payment by sureties having an AA rating or better using a bond acceptable in form to the City. The City shall be named as obligee or co-obligee on any such bonds.
  3. Employment Opportunity. The Developer shall contractually obligate and cause the General Contractor and each subcontractor to agree to the provisions of Section 10 hereof.
  4. Other Provisions. In addition to the requirements of this Section 6. the Construction Contract and each contract with any subcontractor shall contain provisions required pursuant to Section 3.04 (Change Orders), Section 8.09 (Prevailing Wage), Section 10.01(e) (Employment Opportunity), Section 10.02 (City Resident Employment Requirement), Section 10.03 (MBE/WBE Requirements, as applicable), Section 12 (Insurance) and Section 14.01 (Books and Records) hereof. Photocopies of all contracts or subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DHED within five (5) business days of the execution thereof.
SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION
  1. Certificate of Completion of Construction or Rehabilitation. Upon completion of the construction of the Project in accordance with the terms of this Agreement, and upon the Developer's written request, DHED shall issue to the Developer a Certificate in recordable form certifying that the Developer has fulfilled its obligation to complete the Project in accordance with the terms of this Agreement. DHED shall respond to the Developer's written request for a Certificate within forty-five (45) days by issuing either a Certificate or a written statement detailing the ways in which the Project does not conform to this Agreement or has not been satisfactorily completed, and the measures which must be taken by the Developer in order to obtain the Certificate. The Developer may resubmit a written request for a Certificate upon completion of such measures.
  2. Effect of Issuance of Certificate; Continuing Obligations. The Certificate relates only to the construction of the Project, and upon its issuance, the City will certify that the terms of the Agreement specifically related to the Developer's obligation to complete such activities have been satisfied. After the issuance of a Certificate, however, all executory terms and conditions of this Agreement and all representations and covenants contained herein will continue to remain in full force and effect throughout the Term of the Agreement as to the parties described in the following paragraph, and the issuance of the Certificate shall not be construed as a waiver by the City of any of its rights and remedies pursuant to such executory terms.
 
 
 
19
 
 
Those covenants specifically described at Sections 8.02, 8.06, and 8.19 as covenants that run with the land are the only covenants in this Agreement intended to be binding upon any transferee of the Property (including an assignee as described in the following sentence) throughout the Term of the Agreement notwithstanding the issuance of a Certificate; provided, that upon the issuance of a Certificate, the covenants set forth in Section 8.02 shall be deemed to have been fulfilled. The other executory terms of this Agreement that remain after the issuance of a Certificate shall be binding only upon the Developer or a permitted assignee of the Developer who, pursuant to Section 18.15 of this Agreement, has contracted to take an assignment of the Developer's rights under this Agreement and assume the Developer's liabilities hereunder.
  1. Failure to Complete. If the Developer fails to complete the Project in accordance with the terms of this Agreement, then the City has, but shall not be limited to, any of the following rights and remedies:
  1. the right to terminate this Agreement and cease all disbursement of City Funds not yet disbursed pursuant hereto;
  2. the right (but not the obligation) to complete those TIF-Funded Improvements that are public improvements and to pay for the costs of TIF-Funded Improvements (including interest costs) out of City Funds or other City monies. In the event that the aggregate cost of completing the TIF-Funded Improvements exceeds the amount of City Funds available pursuant to Section 4.01, the Developer shall reimburse the City for all reasonable costs and expenses incurred by the City in completing such TIF-Funded Improvements in excess of the available City Funds; and
  3. the right to seek reimbursement of the City Funds from the Developer.
  4. Notice of Expiration of Term of Agreement. Upon the expiration of the Term of the Agreement, DHED shall provide the Developer, at the Developer's written request, with a written notice in recordable form stating that the Term of the Agreement has expired.
SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF THE DEVELOPER.
 
8.01 General. Each of the Owner and IHDC represents, warrants and covenants, as of the date of this Agreement and as of the date of each disbursement of City Funds hereunder, that:
  1. the Owner is an Illinois limited partnership and IHDC is an Illinois not-for-profit corporation, each duly organized, validly existing, qualified to do business in Illinois, and each licensed to do business in any other state where, due to the nature of its activities or properties, such qualification or license is required;
  2. the Developer has the right, power and authority to enter into, execute, deliver and perform this Agreement;
  3. the execution, delivery and performance by the Developer of this Agreement has been duly authorized by all necessary action, and does not and will not violate (as applicable) its organizational documents, as amended and supplemented, any applicable provision of law, or constitute a breach of, default under or require any consent under any agreement, instrument or document to which the Developer is now a party or by which the Developer is now or may become bound;
 
 
 
20
 
  1. unless otherwise permitted or not prohibited pursuant to or under the terms of this Agreement, the Owner shall acquire and shall maintain good, indefeasible and merchantable fee simple title to the Property (and all improvements thereon) free and clear of all liens (except for the Permitted Liens, Lender Financing as disclosed in the Project Budget and non-governmental charges that the Developer is contesting in good faith pursuant to Section 8.15 hereof)
  2. the Developer is now and for the Term of the Agreement shall remain solvent and able to pay its debts as they mature;
  3. there are no actions or proceedings by or before any court, governmental commission, board, bureau or any other administrative agency pending, threatened or affecting the Developer which would impair its ability to perform under this Agreement;
  4. the Developer has and shall maintain all government permits, certificates and consents (including, without limitation, appropriate environmental approvals) necessary to conduct its business and to construct, complete and operate the Project;
  5. the Developer is not in default with respect to any indenture, loan agreement, mortgage, deed, note or any other agreement or instrument related to the borrowing of money to which the Developer is a party or by which the Developer is bound;
(i)      the Financial Statements are, and when hereafter required to be submitted will be,
complete, correct in all material respects and accurately present the assets, liabilities, results of
operations and financial condition of the Developer, and there has been no material adverse change
in the assets, liabilities, results of operations or financial condition of the Developer since the date of
the Developer's most recent Financial Statements;
(j) prior to the issuance of a Certificate, the Developer shall not do any of the following without the prior written consent of DHED: (1) be a party to any merger, liquidation or consolidation; (2) sell, transfer, convey, lease or otherwise dispose of all or substantially all of its assets or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) except in the ordinary course of business; (3) enter into any transaction outside the ordinary course of the Developer's business; (4) assume, guarantee, endorse, or otherwise become liable in connection with the obligations of any other person or entity; or (5) enter into any transaction that would cause a material and detrimental change to the Developer's financial condition;
 
(k) the Developer has not incurred, and, prior to the issuance of a Certificate, shall not, without the prior written consent of the Commissioner of DHED, allow the existence of any liens against the Property (or improvements thereon) other than the Permitted Liens; or incur any indebtedness, secured or to be secured by the Property (or improvements thereon) or any fixtures now or hereafter attached thereto, except Lender Financing disclosed in the Project Budget; and
 
(I) has not made or caused to be made, directly or indirectly, any payment, gratuity or offer of employment in connection with the Agreement or any contract paid from the City treasury or pursuant to City ordinance, for services to any City agency ("City Contract") as an inducement for the City to enter into the Agreement or any City Contract with the Developer in violation of Chapter 2-156-120 of the Municipal Code of the City; and
(m) neither the Developer nor any affiliate of the Developer is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the
 
21
 
 
Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List. For purposes of this subparagraph (m) only, the term "affiliate," when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.
  1. Covenant to Redevelop. Upon DHED's approval of the Project Budget, the Scope Drawings and Plans and Specifications as provided in Sections 3.02 and 3.03 hereof, and the Developer's receipt of all required building permits and governmental approvals, the Developer shall redevelop the Property in accordance with this Agreement and all Exhibits attached hereto, the TIF Ordinances, the Scope Drawings, Plans and Specifications, Project Budget and all amendments thereto, and all federal, state and local laws, ordinances, rules, regulations, executive orders and codes applicable to the Project, the Property and/or the Developer. The covenants set forth in this Section shall run with the land and be binding upon any transferee, but shall be deemed satisfied upon issuance by the City of a Certificate with respect thereto.
  2. Redevelopment Plan. The Developer represents that the Project is and shall be in compliance with all of the terms of the Redevelopment Plan.
  3. Use of City Funds. City Funds disbursed to IHDC shall be used by IHDC solely to pay for (or to reimburse the Developer for its payment for) the TIF-Funded Improvements as provided in this Agreement.
  4. Other Bonds. The Developer shall, at the request of the City, agree to any reasonable amendments to this Agreement that are necessary or desirable in order for the City to issue (in its sole discretion) any bonds in connection with the Redevelopment Area, the proceeds of which may be used to reimburse the City for expenditures made in connection with, or provide a source of funds for the payment for, the TIF-Funded Improvements (the "Bonds"); provided, however, that any such amendments shall not have a material adverse effect on the Developer or the Project. The Developer shall, at the Developer's expense, cooperate and provide reasonable assistance in connection with the marketing of any such Bonds, including but not limited to providing written descriptions of the Project, making representations, providing information regarding its financial condition and assisting the City in preparing an offering statement with respect thereto.
  5. Job Creation and Retention; Covenant to Remain in the City. The Developer shall strive to retain: (a) 81 temporary construction jobs during the construction of the Project; and (b) four full-time equivalent, permanent jobs at the Project within six months of the completion thereof and through the Term. The Developer hereby covenants and agrees to maintain its operations within the City of Chicago at the site described above through the Term.
  6. Employment Opportunity; Progress Reports. The Developer covenants and agrees to abide by, and contractually obligate and use reasonable efforts to cause the General Contractor and each subcontractor to abide by the terms set forth in Section 10 hereof. The Developer shall deliver to the City monthly written progress reports detailing compliance with the requirements of Sections
 
22
 
 
8.09,10.02 and 10.03 of this Agreement. If any such reports indicate a shortfall in compliance, the Developer shall also deliver a plan to DHED which shall outline, to DHED's satisfaction, the manner in which the Developer shall correct any shortfall.
  1. Employment Profile. The Developer shall submit, and contractually obligate and cause the General Contractor or any subcontractor to submit, to DHED, from time to time, statements of its employment profile upon DHED's request.
  2. Prevailing Wage. The Project is subject to the requirements of the Davis-Bacon Act, 40 U.S.C. Section 276a et seg. Accordingly, pursuant to 820 ILCS 130/11, Section 11 of the Illinois Prevailing Wage Act (820 ILCS 130/0/01 et seq.), the requirements of Illinois Prevailing Wage Act shall not apply to the Project.
  3. Arms-Length Transactions. Unless DHED has given its prior written consent with respect thereto, no Affiliate of the Developer may receive any portion of City Funds, directly or indirectly, in payment for work done, services provided or materials supplied in connection with any TIF-Funded Improvement. The Developer shall provide information with respect to any entity to receive City Funds directly or indirectly (whether through payment to the Affiliate by the Developer and reimbursement to the Developer for such costs using City Funds, or otherwise), upon DHED's request, prior to any such disbursement.
  4. Conflict of Interest. Pursuant to Section 5/11-74.4-4(n) of the Act, the Developer represents, warrants and covenants that, to the best of its knowledge, no member, official, or employee of the City, or of any commission or committee exercising authority over the Project, the Redevelopment Area or the Redevelopment Plan, or any consultant hired by the City or the Developer with respect thereto, owns or controls, has owned or controlled or will own or control any interest, and no such person shall represent any person, as agent or otherwise, who owns or controls, has owned or controlled, or will own or control any interest, direct or indirect, in the Developer's business, the Property or any other property in the Redevelopment Area.
  5. Disclosure of Interest. The Developer's counsel has no direct or indirect financial ownership interest in the Developer, the Property or any other aspect of the Project.
  6. Financial Statements. The Developer shall obtain and provide to DHED Financial Statements for the Developer's fiscal year ended 2011 and each year thereafter for the Term of the Agreement. In addition, the Developer shall submit unaudited financial statements as soon as reasonably practical following the close of each fiscal year and for such other periods as DHED may request.
  7. Insurance. The Developer, at its own expense, shall comply with all provisions of Section 12 hereof.
  8. Non-Governmental Charges, (a) Payment of Non-Governmental Charges. Except for the Permitted Liens, the Developer agrees to pay or cause to be paid when due any Non-Governmental Charge assessed or imposed upon the Project, the Property or any fixtures that are or may become attached thereto, which creates, may create, or appears to create a lien upon all or any portion of the Property or Project; provided however, that if such Non-Governmental Charge may be paid in installments, the Developer may pay the same together with any accrued interest thereon in installments as they become due and before any fine, penalty, interest, or cost may be added thereto for nonpayment. The Developer shall furnish to DHED, within thirty (30) days of
 
 
23
 
 
DHED's request, official receipts from the appropriate entity, or other proof satisfactory to DHED, evidencing payment of the Non-Governmental Charge in question.
 
(b) Right to Contest. The Developer has the right, before any delinquency occurs:
  1. to contest or object in good faith to the amount or validity of any Non-Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted, in such manner as shall stay the collection of the contested Non-Governmental Charge, prevent the imposition of a lien or remove such lien, or prevent the sale or forfeiture of the Property (so long as no such contest or objection shall be deemed or construed to relieve, modify or extend the Developer's covenants to pay any such Non-Governmental Charge at the time and in the manner provided in this Section 8.15): or
  2. at DHED's sole option, to furnish a good and sufficient bond or other security satisfactory to DHED in such form and amounts as DHED shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property or any portion thereof or any fixtures that are or may be attached thereto, during the pendency of such contest, adequate to pay fully any such contested Non-Governmental Charge and all interest and penalties upon the adverse determination of such contest.
  1. Developer's Liabilities. The Developer shall not enter into any transaction that would materially and adversely affect its ability to perform its obligations hereunder or to repay any material liabilities or perform any material obligations of the Developer to any other person or entity. The Developer shall immediately notify DHED of any and all events or actions which may materially affect the Developer's ability to carry on its business operations or perform its obligations under this Agreement or any other documents and agreements.
  2. Compliance with Laws. To the best of the Developer's knowledge, after diligent inquiry, the Property and the Project are and shall be in compliance with all applicable federal, state and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the Project and the Property. Upon the City's request, the Developer shall provide evidence satisfactory to the City of such compliance.
  3. Recording and Filing. The Developer shall cause this Agreement, certain exhibits (as specified by Corporation Counsel), all amendments and supplements hereto to be recorded and filed against the Property on the date hereof in the conveyance and real property records of the county in which the Project is located. The Developer shall pay all fees and charges incurred in connection with any such recording. Upon recording, the Developer shall immediately transmit to the City an executed original of this Agreement showing the date and recording number of record.
  4. Real Estate Provisions.
(a) Governmental Charges.
 
(i) Payment of Governmental Charges. The Developer agrees to pay or cause to be paid when due all Governmental Charges (as defined below) which are assessed or imposed upon the Developer, the Property or the Project, or become due and payable, and which create or may create a lien upon the Developer or all or any portion of the Property or the Project. "Governmental Charge" shall mean all federal, State, county, the City, or other governmental (or any instrumentality, division, agency, body, or department thereof) taxes,
 
24
 
 
levies, assessments, charges, liens, claims or encumbrances (except for those assessed by foreign nations, states other than the State of Illinois, counties of the State other than Cook County, and municipalities other than the City) relating to the Developer, the Property or the Project including but not limited to real estate taxes.
 
(ii) Right to Contest. The Developer has the right before any delinquency occurs to contest or object in good faith to the amount or validity of any Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted in such manner as shall stay the collection of the contested Governmental Charge and prevent the imposition of a lien or the sale or forfeiture of the Property. No such contest or objection shall be deemed or construed in any way as relieving, modifying or extending the Developer's covenants to pay any such Governmental Charge at the time and in the manner provided in this Agreement unless the Developer has given prior written notice to DHED of the Developer's intent to contest or object to a Governmental Charge and, unless, at DHED's sole option,
  1. the Developer shall demonstrate to DHED's satisfaction that legal proceedings instituted by the Developer contesting or objecting to a Governmental Charge shall conclusively operate to prevent or remove a lien against, or the sale or forfeiture of, all or any part of the Property to satisfy such Governmental Charge prior to final determination of such proceedings; and/or
  2. the Developer shall furnish a good and sufficient bond or other security satisfactory to DHED in such form and amounts as DHED shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property during the pendency of such contest, adequate to pay fully any such contested Governmental Charge and all interest and penalties upon the adverse determination of such contest.
 
(b) Developer's Failure To Pay Or Discharge Lien. If the Developer fails to pay any Governmental Charge or to obtain discharge of the same, the Developer shall advise DHED thereof in writing, at which time DHED may, but shall not be obligated to, and without waiving or releasing any obligation or liability of the Developer under this Agreement, in DHED's sole discretion, make such payment, or any part thereof, or obtain such discharge and take any other action with respect thereto which DHED deems advisable. All sums so paid by DHED, if any, and any expenses, if any, including reasonable attorneys' fees, court costs, expenses and other charges relating thereto, shall be promptly disbursed to DHED by the Developer. Notwithstanding anything contained herein to the contrary, this paragraph shall not be construed to obligate the City to pay any such Governmental Charge. Additionally, if the Developer fails to pay any Governmental Charge, the City, in its sole discretion, may require the Developer to submit to the City audited Financial Statements at the Developer's own expense.
 
8.20      Survival of Covenants. All warranties, representations, covenants and agreements of
the Developer contained in this Section 8 and elsewhere in this Agreement shall be true, accurate
and complete at the time of the Developer's execution of this Agreement, and shall survive the
execution, delivery and acceptance hereof by the parties hereto and (except as provided in Section
7 hereof upon the issuance of a Certificate) shall be in effect throughout the Term of the Agreement.
 
8.21      Annual Compliance Report. Beginning with the issuance of the Certificate and
continuing throughout the Term of the Agreement, the Developer shall submit to DHED the Annual
 
 
25
 
 
Compliance Report within 30 days after the end of the calendar year to which the Annual Compliance Report relates.
SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF CITY
  1. General Covenants. The City represents that it has the authority as a home rule unit of local government to execute and deliver this Agreement and to perform its obligations hereunder.
  2. Survival of Covenants. All warranties, representations, and covenants of the City contained in this Section 9 or elsewhere in this Agreement shall be true/accurate, and complete at the time of the City's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and be in effect throughout the Term of the Agreement.
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS
 
10.01 Employment Opportunity. The Developer, on behalf of itself and its successors and assigns, hereby agrees, and shall contractually obligate its or their various contractors, subcontractors or any Affiliate of the Developer operating on the Property (collectively, with the Developer, the "Employers" and individually an "Employer") to agree, that for the Term of this Agreement with respect to Developer and during the period of any other party's provision of services in connection with the construction of the Project or occupation of the Property:
  1. No Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Chapter 2-160, Section 2-160-010 et seg., Municipal Code, except as otherwise provided by said ordinance and as amended from time to time (the "Human Rights Ordinance"). Each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including without limitation: employment, upgrading, demotion ortransfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Employers, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.
  2. To the greatest extent feasible, each Employer is required to present opportunities for training and employment of low- and moderate-income residents of the City and preferably of the Redevelopment Area; and to provide that contracts for work in connection with the construction of the Project be awarded to business concerns that are located in, or owned in substantial part by persons residing in, the City and preferably in the Redevelopment Area.
  3. Each Employer shall comply with all federal, state and local equal employment and affirmative action statutes, rules and regulations, including but not limited to the City's Human Rights Ordinance and the Illinois Human Rights Act, 775 ILCS 5/1-101 et seg. (1993), and any subsequent amendments and regulations promulgated thereto.
 
26
 
  1. Each Employer, in order to demonstrate compliance with the terms of this Section, shall cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of federal, state and municipal agencies.
  2. Each Employer shall include the foregoing provisions of subparagraphs (a) through (d) in every contract entered into in connection with the Project, and shall require inclusion of these provisions in every subcontract entered into by any subcontractors, and every agreement with any Affiliate operating on the Property, so that each such provision shall be binding upon each contractor, subcontractor or Affiliate, as the case may be.
  3. Failure to comply with the employment obligations described in this Section 10.01 shall be a basis for the City to pursue remedies under the provisions of Section 15.02 hereof.
 
10.02 City Resident Construction Worker Employment Requirement. The Developer agrees for itself and its successors and assigns, and shall contractually obligate its General Contractor and shall cause the General Contractor to contractually obligate its subcontractors, as applicable, to agree, that during the construction of the Project they shall comply with the minimum percentage of total worker hours performed by actual residents of the City as specified in Section 2-92-330 of the Municipal Code of Chicago (at least 50 percent of the total worker hours worked by persons on the site of the Project shall be performed by actual residents of the City); provided, however, that in addition to complying with this percentage, the Developer, its General Contractor and each subcontractor shall be required to make good faith efforts to utilize qualified residents of the City in both unskilled and skilled labor positions.
 
The Developer may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code of Chicago in accordance with standards and procedures developed by the Chief Procurement Officer of the City.
"Actual residents of the City" shall mean persons domiciled within the City. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.
 
The Developer, the General Contractor and each subcontractor shall provide for the maintenance of adequate employee residency records to show that actual Chicago residents are employed on the Project. Each Employer shall maintain copies of personal documents supportive of every Chicago employee's actual record of residence.
Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) shall be submitted to the Commissioner of DHED in triplicate, which shall identify clearly the actual residence of every employee on each submitted certified payroll. The first time that an employee's name appears on a payroll, the date that the Employer hired the employee should be written in after the employee's name.
 
The Developer, the General Contractor and each subcontractor shall provide full access to their employment records to the Chief Procurement Officer, the Commissioner of DHED, the Superintendent of the Chicago Police Department, the Inspector General or any duly authorized representative of any of them. The Developer, the General Contractor and each subcontractor shall maintain all relevant personnel data and records for a period of at least three (3) years after final acceptance of the work constituting the Project.
 
 
27
 
 
At the direction of DHED, affidavits and other supporting documentation will be required of the Developer, the General Contractor and each subcontractor to verify or clarify an employee's actual address when doubt or lack of clarity has arisen.
 
Good faith efforts on the part of the Developer, the General Contractor and each subcontractor to provide utilization of actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) shall not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.
 
When work at the Project is completed, in the event that the City has determined that the Developer has failed to ensure the fulfillment of the requirement of this Section concerning the worker hours performed by actual Chicago residents or failed to report in the manner as indicated above, the City will thereby be damaged in the failure to provide the benefit of demonstrable employment to Chicagoans to the degree stipulated in this Section. Therefore, in such a case of non-compliance, it is agreed that 1/20 of 1 percent (0.0005) of the aggregate hard construction costs set forth in the Project budget (the product of .0005 x such aggregate hard construction costs) (as the same shall be evidenced by approved contract value for the actual contracts) shall be surrendered by the Developer to the City in payment for each percentage of shortfall toward the stipulated residency requirement. Failure to report the residency of employees entirely and correctly shall result in the surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the certification of payroll data may subject the Developer, the General Contractor and/or the subcontractors to prosecution. Any retainage to cover contract performance that may become due to the Developer pursuant to Section 2-92-250 of the Municipal Code of Chicago may be withheld by the City pending the Chief Procurement Officer's determination as to whether the Developer must surrender damages as provided in this paragraph.
Nothing herein provided shall be construed to be a limitation upon the "Notice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order 11246" and "Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement or related documents.
The Developer shall cause or require the provisions of this Section 10.02 to be included in all construction contracts and subcontracts related to the Project.
10.03. MBE/WBE Commitment. The Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements set forth herein, shall contractually obligate the General Contractor to agree that during the Project:
 
(a) Consistent with the findings which support, as applicable, (i) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seg., Municipal Code of Chicago (the "Procurement Program"), and (ii) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seg Municipal Code of Chicago (the "Construction Program," and collectively with the Procurement Program, the "MBE/WBE Program"), and in reliance upon the provisions of the MBE/WBE Program to the extent contained in, and as qualified by, the provisions of this Section 10.03, during the course of the Project, at least the following percentages of the construction Project Budget shall be expended for contract participation by MBEs and by WBEs:
 
 
28
 
  1. At least 24 percent by MBEs.
  2. At least four percent by WBEs.
    1. For purposes of this Section 10.03 only, the Developer (and any party to whom a contract is let by the Developer in connection with the Project) shall be deemed a "contractor" and this Agreement (and any contract let by the Developer in connection with the Project) shall be deemed a "contract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670, Municipal Code of Chicago, as applicable.
    2. Consistent with Sections 2-92-440 and 2-92-720, Municipal Code of Chicago, the Developer's MBE/WBE commitment may be achieved in part by the Developer's status as an MBE or WBE (but only to the extent of any actual work performed on the Project by the Developer) or by a joint venture with one or more MBEs or WBEs (but only to the extent of the lesser of (i) the MBE or WBE participation in such joint venture or (ii) the amount of any actual work performed on the Project by the MBE or WBE), by the Developer utilizing a MBE or a WBE as the General Contractor (but only to the extent of any actual work performed on the Project by the General Contractor), by subcontracting or causing the General Contractor to subcontract a portion of the Project to one or more MBEs or WBEs, or by the purchase of materials or services used in the Project from one or more MBEs or WBEs, or by any combination of the foregoing. Those entities which constitute both a MBE and a WBE shall not be credited more than once with regard to the Developer's MBE/WBE commitment as described in this Section 10.03. In accordance with Section 2-92-730, Municipal Code of Chicago, the Developer shall not substitute any MBE or WBE General Contractor or subcontractor without the prior written approval of DHED.
    3. The Developer shall deliver quarterly reports to the City's monitoring staff during the Project describing its efforts to achieve compliance with this MBE/WBE commitment. Such reports shall include, inter alia, the name and business address of each MBE and WBE solicited by the Developer or the General Contractor to work on the Project, and the responses received from such solicitation, the name and business address of each MBE or WBE actually involved in the Project, a description of the work performed or products or services supplied, the date and amount of such work, product or service, and such other information as may assist the City's monitoring staff in determining the Developer's compliance with this MBE/WBE commitment. The Developer shall maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with the Project for at least five years after completion of the Project, and the City's monitoring staff shall have access to all such records maintained by the Developer, on five Business Days' notice, to allow the City to review the Developer's compliance with its commitment to MBE/WBE participation and the status of any MBE or WBE performing any portion of the Project.
    4. Upon the disqualification of any MBE or WBE General Contractor or subcontractor, if such status was misrepresented by the disqualified party, the Developer shall be obligated to discharge or cause to be discharged the disqualified General Contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (e), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730, Municipal Code of Chicago, as applicable.
  2. Any reduction or waiver of the Developer's MBE/WBE commitment as described in this Section 10.03 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730, Municipal Code of Chicago, as applicable.
  3. Prior to the commencement of the Project, the Developer shall be required to meet with the City's monitoring staff with regard to the Developer's compliance with its obligations under this
29
 
 
Section 10.03. The General Contractor and all major subcontractors shall be required to attend this pre-construction meeting. During said meeting, the Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 10.03, the sufficiency of which shall be approved by the City's monitoring staff. During the Project, the Developer shall submit the documentation required by this Section 10.03 to the City's monitoring staff, including the following: (i) subcontractor's activity report; (ii) contractor's certification concerning labor standards and prevailing wage requirements; (iii) contractor letter of understanding; (iv) monthly utilization report; (v) authorization for payroll agent; (vi) certified payroll; (vii) evidence that MBE/WBE contractor associations have been informed of the Project via written notice and hearings; and (viii) evidence of compliance with job creation/job retention requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that the Developer is not complying with its obligations under this Section 10.03, shall, upon the delivery of written notice to the Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to the Developer to halt the Project, (2) withhold any further payment of any City Funds to the Developer or the General Contractor, or (3) seek any other remedies against the Developer available at law or in equity.
SECTION 11. ENVIRONMENTAL MATTERS
 
The Owner hereby represents and warrants to the City that the Owner has conducted environmental studies sufficient to conclude that the Project may be constructed, completed and operated in accordance with all Environmental Laws and this Agreement and all Exhibits attached hereto, the Scope Drawings, Plans and Specifications and all amendments thereto, the Bond Ordinance, if any, and the Redevelopment Plan.
 
Without limiting any other provisions hereof, the Developer agrees to indemnify, defend and hold the City harmless from and against any and all losses, liabilities, damages, injuries, costs, expenses or claims of any kind whatsoever including, without limitation, any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any Environmental Laws incurred, suffered by or asserted against the City as a direct or indirect result of any of the following, regardless of whether or not caused by, or within the control of the Developer: (i) the presence of any Hazardous Material on or under, or the escape, seepage, leakage, spillage, emission, discharge or release of any Hazardous Material from (A) all or any portion of the Property or (B) any other real property in which the Developer, or any person directly or indirectly controlling, controlled by or under common control with the Developer, holds any estate or interest whatsoever (including, without limitation, any property owned by a land trust in which the beneficial interest"is owned, in whole or in part, by the Developer), or (ii) any liens against the Property permitted or imposed by any Environmental Laws, or any actual or asserted liability or obligation of the City or the Developer or any of its Affiliates under any Environmental Laws relating to the Property.
 
SECTION 12. INSURANCE
 
The Developer must provide and maintain, at Developer's own expense, or cause to be provided and maintained during the term of this Agreement, the insurance coverage and requirements specified below, insuring all operations related to the Agreement.
 
(a)     Prior to execution and delivery of this Agreement.
 
(i)      Workers Compensation and Employers Liability
 
 
30
 
 
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $100,000 each accident, illness or disease.
  1. Commercial General Liability (Primary and Umbrella)
 
Commercial General Liability Insurance or equivalent with limits of not less than $1,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
  1. All Risk Property
 
All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.
(b) Construction. Prior to the construction of any portion of the Project, Developer will cause its architects, contractors, subcontractors, project managers and other parties constructing the Project to procure and maintain the following kinds and amounts of insurance:
  1. Workers Compensation and Employers Liability
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $ 500,000 each accident, illness or disease.
  1. Commercial General Liability (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $2,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations (for a minimum of two (2) years following project completion), explosion, collapse, underground, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
  1. Automobile Liability (Primary and Umbrella)
 
When any motor vehicles (owned, non-owned and hired) are used in connection with work to be performed, the Automobile Liability Insurance with limits of not less than $2,000,000 per occurrence for bodily injury and property damage. The City of Chicago is to be named as an additional insured on a primary, non-contributory basis.
  1. Railroad Protective Liability
When any work is to be done adjacent to or on railroad or transit property, Developer must provide cause to be provided with respect to the operations that Contractors perform,
 
31
 
 
Railroad Protective Liability Insurance in the name of railroad or transit entity. The policy must have limits of not less than $2,000,000 per occurrence and $6,000,000 in the aggregate for losses arising out of injuries to or death of all persons, and for damage to or destruction of property, including the loss of use thereof.
  1. All Risk /Builders Risk
When Developer undertakes any construction, including improvements, betterments, and/or repairs, the Developer must provide or cause to be provided All Risk Builders Risk Insurance at replacement cost for materials, supplies, equipment, machinery and fixtures that are or will be part of the project. The City of Chicago is to be named as an additional insured and loss payee/mortgagee if applicable.
  1. Professional Liability
 
When any architects, engineers, construction managers or other professional consultants perform work in connection with this Agreement, Professional Liability Insurance covering acts, errors, or omissions must be maintained with limits of not less than $ 1,000,000. Coverage must include contractual liability. When policies are renewed or replaced, the policy retroactive date must coincide with, or precede, start of work on the Contract. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years.
  1. Valuable Papers
 
When any plans, designs, drawings, specifications and documents are produced or used under this Agreement, Valuable Papers Insurance must be maintained in an amount to insure against any loss whatsoever, and must have limits sufficient to pay for the re-creation and reconstruction of such records.
  1. Contractors Pollution Liability
 
When any remediation work is performed which may cause a pollution exposure, the Developer must cause remediation contractor to provide Contractor Pollution Liability covering bodily injury, property damage and other losses caused by pollution conditions that arise from the contract scope of work with limits of not less than $1,000.000 per occurrence. Coverage must include completed operations, contractual liability, defense, excavation, environmental cleanup, remediation and disposal. When policies are renewed or replaced, the policy retroactive date must coincide with or precede, start of work on the Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years. The City of Chicago is to be named as an additional insured.
  1. Post Construction:
 
(i) All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.
  1. Other Requirements:
 
The Developer must furnish the City of Chicago, Department of Housing and Economic
 
32
 
 
Development, City Hall, Room 1000,121 North LaSalle Street 60602, original Certificates of Insurance, or such similar evidence, to be in force on the date of this Agreement, and Renewal Certificates of Insurance, or such similar evidence, if the coverages have an expiration or renewal date occurring during the term of this Agreement. The Developer must submit evidence of insurance on the City of Chicago Insurance Certificate Form (copy attached) or equivalent prior to closing. The receipt of any certificate does not constitute agreement by the City that the insurance requirements in the Agreement have been fully met or that the insurance policies indicated on the certificate are in compliance with all Agreement requirements. The failure of the City to obtain certificates or other insurance evidence from Developer is not a waiver by the City of any requirements for the Developer to obtain and maintain the specified coverages. The Developer shall advise all insurers of the Agreement provisions regarding insurance. Non-conforming insurance does not relieve Developer of the obligation to provide insurance as specified herein. Nonfulfillment of the insurance conditions may constitute a violation of the Agreement, and the City retains the right to stop work and/or terminate agreement until proper evidence of insurance is provided.
The insurance must provide for 60 days prior written notice to be given to the City in the event coverage is substantially changed, canceled, or non-renewed.
 
Any deductibles or self insured retentions on referenced insurance coverages must be borne by Developer and Contractors.
 
The Developer hereby waives and agrees to require their insurers to waive their rights of subrogation against the City of Chicago, its employees, elected officials, agents, or representatives.
 
The coverages and limits furnished by Developer in no way limit the Developer's liabilities and responsibilities specified within the Agreement or by law.
 
Any insurance or self insurance programs maintained by the City of Chicago do not contribute with insurance provided by the Developer under the Agreement.
 
The required insurance to be carried is not limited by any limitations expressed in the indemnification language in this Agreement or any limitation placed on the indemnity in this Agreement given as a matter of law.
 
If Developer is a joint venture or limited liability company, the insurance policies must name the joint venture or limited liability company as a named insured.
 
The Developer must require Contractor and subcontractors to provide the insurance required herein, or Developer may provide the coverages for Contractor and subcontractors. All Contractors and subcontractors are subject to the same insurance requirements of Developer unless otherwise specified in this Agreement.
 
If Developer, any Contractor or subcontractor desires additional coverages, the party desiring the additional coverages is responsible for the acquisition and cost.
 
The City of Chicago Risk Management Department maintains the right to modify, delete, alter or change these requirements.
 
SECTION 13. INDEMNIFICATION
 
33
 
 
13.01 General Indemnity. Developer agrees to indemnify, pay, defend and hold the City, and its elected and appointed officials, employees, agents and affiliates (individually an "Indemnitee," and collectively the "Indemnitees") harmless from and against, any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, claims, costs, expenses and disbursements of any kind or nature whatsoever (and including without limitation, the reasonable fees and disbursements of counsel for such Indemnitees in connection with any investigative, administrative or judicial proceeding commenced or threatened, whether or not such Indemnitees, shall be designated a party thereto), that may be imposed on, suffered, incurred by or asserted against the Indemnitees in any manner relating or arising out of:
  1. the Developer's failure to comply with any of the terms, covenants and conditions contained within this Agreement; or
  2. the Developer's or any contractor's failure to pay General Contractors, subcontractors or materialmen in connection with the TIF-Funded Improvements or any other Project improvement; or
  3. the existence of any material misrepresentation or omission in this Agreement, any offering memorandum or information statement or the Redevelopment Plan or any other document related to this Agreement that is the result of information supplied or omitted by the Developer or any Affiliate Developer or any agents, employees, contractors or persons acting under the control or at the request of the Developer or any Affiliate of Developer; or
  4. the Developer's failure to cure any misrepresentation in this Agreement or any other agreement relating hereto;
provided, however, that Developer shall have no obligation to an Indemnitee arising from the wanton or willful misconduct of that Indemnitee. To the extent that the preceding sentence may be unenforceable because it is violative of any law or public policy, Developer shall contribute the maximum portion that it is permitted to pay and satisfy under the applicable law, to the payment and satisfaction of all indemnified liabilities incurred by the Indemnitees or any of them. The provisions of the undertakings and indemnification set out in this Section 13.01 shall survive the termination of this Agreement.
 
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT
 
14.01      Books and Records. The Developer shall keep and maintain separate, complete,
accurate and detailed books and records necessary to reflect and fully disclose the total actual cost
of the Project and the disposition of all funds from whatever source allocated thereto, and to monitor
the Project. All such books, records and other documents, including but not limited to the
Developer's loan statements, if any, General Contractors' and contractors' sworn statements,
general contracts, subcontracts, purchase orders, waivers of lien, paid receipts and invoices, shall
be available at the Developer's offices for inspection, copying, audit and examination by an
authorized representative of the City, at the Developer's expense. The Developer shall incorporate
this right to inspect, copy, audit and examine all books and records into all contracts entered into by
the Developer with respect to the Project.
 
14.02      Inspection Rights. Upon three (3) business days' notice, any authorized
representative of the City has access to all portions of the Project and the Property during normal
business hours for the Term of the Agreement.
 
34
 
 
SECTION 15. DEFAULT AND REMEDIES
 
15.01 Events of Default. The occurrence of any one or more of the following events, subject to the provisions of Section 15.03, shall constitute an "Event of Default" by the Developer hereunder:
  1. the failure of the Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of the Developer under this Agreement or any related agreement;
  2. the failure of the Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of the Developer under any other agreement with any person or entity if such failure may have a material adverse effect on the Developer's business, property, assets, operations or condition, financial or otherwise;
  1. the making or furnishing by the Developer to the City of any representation, warranty, certificate, schedule, report or other communication within or in connection with this Agreement or any related agreement which is untrue or misleading in any material respect;
  2. except as otherwise permitted hereunder, the creation (whether voluntary or involuntary) of, or any attempt to create, any lien or other encumbrance upon the Property, including any fixtures now or hereafter attached thereto, other than the Permitted Liens, or the making or any attempt to make any levy, seizure or attachment thereof;
  3. the commencement of any proceedings in bankruptcy by or against the Developer or for the liquidation or reorganization of the Developer, or alleging that the Developer is insolvent or unable to pay its debts as they mature, or for the readjustment or arrangement of the Developer's debts, whether under the United States Bankruptcy Code or under any other state or federal law, now or hereafter existing for the relief of debtors, or the commencement of any analogous statutory or non-statutory proceedings involving the Developer; provided, however, that if such commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such proceedings are not dismissed within sixty (60) days after the commencement of such proceedings;
  4. the appointment of a receiver or trustee for the Developer, for any substantial part of the Developer's assets or the institution of any proceedings for the dissolution, or the full or partial liquidation, or the merger or consolidation, of the Developer; provided, however, that if such appointment or commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such appointment is not revoked or such proceedings are not dismissed within sixty (60) days after the commencement thereof;
  1. the entry of any judgment or order against the Developer which remains unsatisfied or undischarged and in effect for sixty (60) days after such entry without a stay of enforcement or execution;
  2. the occurrence of an event of default under the Lender Financing, which default is not cured within any applicable cure period;
 
(i)      the dissolution of the Developer or the death of any natural person who owns a material
interest in the Developer;
 
 
35
 
 
(j) the institution in any court of a criminal proceeding (other than a misdemeanor) against the Developer or any natural person who owns a material interest in the Developer, which is not dismissed within thirty (30) days, or the indictment of the Developer or any natural person who owns a material interest in the Developer, for any crime (other than a misdemeanor); or
 
(k) prior to the payment of all City Funds hereunder, the sale or transfer of a majority of the ownership interests of the Developer without the prior written consent of the City.
 
For purposes of Sections 15.01 (i) and 15.01 (j) hereof, a person with a material interest in the Developer shall be one owning in excess often (10%) of the Developer's membership interests.
  1. Remedies. Upon the occurrence of an Event of Default, the City may terminate this Agreement and any other agreements to which the City and the Developer are or shall be parties, suspend disbursement of City Funds, place a lien on the Project in the amount of City Funds paid, and/or seek reimbursement of any City Funds paid. The City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to damages, injunctive relief or the specific performance of the agreements contained herein.
  2. Curative Period. In the event the Developer shall fail to perform a monetary covenant which the Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless the Developer has failed to perform such monetary covenant within ten (10) days of its receipt of a written notice from the City specifying that it has failed to.perform such monetary covenant. In the event the Developer shall fail to perform a non-monetary covenant which the Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless the Developer has failed to cure such default within thirty (30) days of its receipt of a written notice from the City specifying the nature of the default; provided, however, with respect to those non-monetary defaults which are not capable of being cured within such thirty (30) day period, the Developer shall not be deemed to have committed an Event of Default under this Agreement if it has commenced to cure the alleged default within such thirty (30) day period and thereafter diligently and continuously prosecutes the cure of such default until the same has been cured. Any cure tendered by the limited partner of the Owner shall be treated as a cure tendered by the Owner and shall be accepted or rejected on the same terms as if such cure had been tendered by the Owner.
 
SECTION 16. MORTGAGING OF THE PROJECT
 
All mortgages or deeds of trust in place as of the date hereof with respect to the Property or any portion thereof are listed on Exhibit G hereto (including but not limited to mortgages made prior to or on the date hereof in connection with Lender Financing) and are referred to herein as the "Existing Mortgages." Any mortgage or deed of trust that the Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof is referred to herein as a "New Mortgage." Any New Mortgage that the Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof with the prior written consent of the City is referred to herein as a "Permitted Mortgage." It is hereby agreed by and between the City and the Developer as follows:
 
(a) In the event that a mortgagee or any other party shall succeed to the Developer's interest in the Property or any portion thereof pursuant to the exercise of remedies under a New
 
36
 
 
Mortgage (other than a Permitted Mortgage), whether by foreclosure or deed in lieu of foreclosure, and in conjunction therewith accepts an assignment of the Developer's interest hereunder in accordance with Section 18.15 hereof, the City may, but shall not be obligated to, attorn to and recognize such party as the successor in interest to the Developer for all purposes under this Agreement and, unless so recognized by the City as the successor in interest, such party shall be entitled to no rights or benefits under this Agreement, but such party shall be bound by those provisions of this Agreement that are covenants expressly running with the land.
 
(b)      In the event that any mortgagee shall succeed to the Developer's interest in the Property
or any portion thereof pursuant to the exercise of remedies under an Existing Mortgage or a
Permitted Mortgage, whether by foreclosure or deed in lieu of foreclosure, and in conjunction
therewith accepts an assignment of the Developer's interest hereunder in accordance with Section
18.15 hereof, the City hereby agrees to attorn to and recognize such party as the successor in
interest to the Developer for all purposes under this Agreement so long as such party accepts all of
the obligations and liabilities of "the Developer" hereunder; provided, however, that, notwithstanding
any other provision of this Agreement to the contrary, it is understood and agreed that if such party
accepts an assignment of the Developer's interest under this Agreement, such party has no liability
under this Agreement for any Event of Default of the Developer which accrued prior to the time such
party succeeded to the interest of the Developer under this Agreement, in which case the Developer
shall be solely responsible. However, if such mortgagee under a Permitted Mortgage or an Existing
Mortgage does not expressly accept an assignment of the Developer's interest hereunder, such
party shall be entitled to no rights and benefits under this Agreement, and such party shall be bound
only by those provisions of this Agreement, if any, which are covenants expressly running with the
land.
  1. Prior to the issuance by the City to the Developer of a Certificate pursuant to Section 7 hereof, no New Mortgage shall be executed with respect to the Property or any portion thereof without the prior written consent of the Commissioner of DHED.
  2. If an Event of Default occurs under this Agreement, then any mortgagee under an Existing Mortgage or a Permitted Mortgage shall have the same right, but not the obligation, as the Developer has under this Agreement to cure such default, subject to the applicable cure periods described in Section 15.02 and Section 15.03, and the City shall accept such performance by such mortgagee for the account of the Developer and with the same force and effect as if performed by the Developer
SECTION 17. NOTICE
Unless otherwise specified, any notice, demand or request required hereunder shall be given in writing at the addresses set forth below, by any of the following means: (a) personal service; (b) telecopy or facsimile; (c) overnight courier, or (d) registered or certified mail, return receipt requested.
 
If to the City:      City of Chicago
Department of Housing and Economic Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner
 
 
 
 
37
 
 
With Copies To:      City of Chicago
Department of Law
121 North LaSalle Street, Room 600
Chicago, Illinois 60602
Attention: Finance and Economic Development Division
 
If to the Developer:      Lake Street Studios Limited Partnership
c/o Lake Street Studios LLC 219 West Chicago Avenue Chicago, Illinois 60654 Attention". Ms. Gladys Jordan
 
The Interfaith Housing Development Corporation of Chicago 219 West Chicago Avenue Chicago, Illinois 60654 Attention: Ms. Gladys Jordan
With Copies To:      Applegate & Thorne-Thomsen
626 West Jackson Boulevard Chicago, Illinois 60661 Attention: Warren Wenzloff
And to:      Enterprise Community Asset Management, Inc.
11000 Broken Land Parkway, Suite 700 Columbia, Maryland 21044 Attention: General Counsel
 
Such addresses may be changed by notice to the other parties given in the same manner provided above. Any notice, demand, or request sent pursuant to either clause (a) or (b) hereof shall be deemed received upon such personal service or upon dispatch. Any notice, demand or request sent pursuant to clause (c) shall be deemed received on the day immediately following deposit with the overnight courier and any notices, demands or requests sent pursuant to subsection (d) shall be deemed received two (2) business days following deposit in the mail.
 
SECTION 18. MISCELLANEOUS
  1. Amendment. This Agreement and the Exhibits attached hereto may not be amended or modified without the prior written consent of the parties hereto; provided, however, that the City, in its sole discretion, may amend, modify or supplement Exhibit D hereto without the consent of any party hereto. It is agreed that no material amendment or change to this Agreement shall be made or be effective unless ratified or authorized by an ordinance duly adopted by the City Council. The term "material" for the purpose of this Section 18.01 shall be defined as any deviation from the terms of the Agreement which operates to cancel or otherwise reduce any developmental, construction or job-creating obligations of Developer (including those set forth in Sections 10.02 and 10.03 hereof) by more than five percent (5%) or materially changes the Project site or character of the Project or any activities undertaken by Developer affecting the Project site, the Project, or both, or increases any time agreed for performance by the Developer by more than ninety (90) days.
  2. Entire Agreement. This Agreement (including each Exhibit attached hereto, which is hereby incorporated herein by reference) constitutes the entire Agreement between the parties
 
 
38
 
 
hereto and it supersedes all prior agreements, negotiations and discussions between the parties relative to the subject matter hereof.
 
18.03      Limitation of Liability. No member, official or employee of the City shall be personally
liable to the Developer or any successor in interest in the event of any default or breach by the City
or for any amount which may become due to the Developer from the City or any successor in
interest or on any obligation under the terms of this Agreement.
    1. Further Assurances. The Developer agrees to take such actions, including the execution and delivery of such documents, instruments, petitions and certifications as may become necessary or appropriate to carry out the terms, provisions and intent of this Agreement.
    2. Waiver. Waiver by the City or the Developer with respect to any breach of this Agreement shall not be considered or treated as a waiver of the rights of the respective party with respect to any other default or with respect to any particular default, except to the extent specifically waived by the City or the Developer in writing. No delay or omission on the part of a party in exercising any right shall operate as a waiver of such right or any other right unless pursuant to the specific terms hereof. A waiver by a party of a provision of this Agreement shall not prejudice or constitute a waiver of such party's right otherwise to demand strict compliance with that provision or any other provision of this Agreement. No prior waiver by a party, nor any course of dealing between the parties hereto, shall constitute a waiver of any such parties' rights or of any obligations of any other party hereto as to any future transactions.
    3. Remedies Cumulative. The remedies of a party hereunder are cumulative and the exercise of any one or more of the remedies provided for herein shall not be construed as a waiver of any other remedies of such party unless specifically so provided herein.
    4. Disclaimer. Nothing contained in this Agreement nor any act of the City shall be deemed or construed by any of the parties, or by any third person, to create or imply any relationship of third-party beneficiary, principal or agent, limited or general partnership or joint venture, or to create or imply any association or relationship involving the City.
  2. Headings. The paragraph and section headings contained herein are for convenience only and are not intended to limit, vary, define or expand the content thereof.
    1. Counterparts. This Agreement may be executed in several counterparts, each of which shall be deemed an original and all of which shall constitute one and the same agreement.
    2. Severability. If any provision in this Agreement, or any paragraph, sentence, clause, phrase, word or the application thereof, in any circumstance, is held invalid, this Agreement shall be construed as if such invalid part were never included herein and the remainder of this Agreement shall be and remain valid and enforceable to the fullest extent permitted by law.
    3. Conflict. In the event of a conflict between any provisions of this Agreement and the provisions of the TIF Ordinances and/or the Bond Ordinance, if any, such ordinance(s) shall prevail and control.
    4. Governing Law. This Agreement shall be governed by and construed in accordance with the internal laws of the State of Illinois, without regard to its conflicts of law principles.
 
 
 
39
 
  1. Form of Documents. All documents required by this Agreement to be submitted, delivered or furnished to the City shall be in form and content satisfactory to the City.
  2. Approval. Wherever this Agreement provides for the approval or consent of the City, DHED or the Commissioner, or any matter is to be to the City's, DHED's or the Commissioner's satisfaction, unless specifically stated to the contrary, such approval, consent or satisfaction shall be made, given or determined by the City, DHED or the Commissioner in writing and in the reasonable discretion thereof. The Commissioner or other person designated by the Mayor of the City shall act for the City or DHED in making all approvals, consents and determinations of satisfaction, granting the Certificate or otherwise administering this Agreement for the City.
  3. Assignment. The Developer may not sell, assign or otherwise transfer its interest in this Agreement in whole or in part without the written consent of the City. Any successor in interest to the Developer under this Agreement shall certify in writing to the City its agreement to abide by all remaining executory terms of this Agreement, including but not limited to Sections 8.19 (Real Estate Provisions) and 8.20 (Survival of Covenants) hereof, for the Term of the Agreement. The Developer consents to the City's sale, transfer, assignment or other disposal of this Agreement at any time in whole or in part.
  4. Binding Effect. This Agreement shall be binding upon the Developer, the City and their respective successors and permitted assigns (as provided herein) and shall inure to the benefit of the Developer, the City and their respective successors and permitted assigns (as provided herein). Except as otherwise provided herein, this Agreement shall not run to the benefit of, or be enforceable by, any person or entity other than a party to this Agreement and its successors and permitted assigns. This Agreement should not be deemed to confer upon third parties any remedy, claim, right of reimbursement or other right.
  5. Force Majeure. Neither the City nor the Developer nor any successor in interest to either of them shall be considered in breach of or in default of its obligations under this Agreement in the event of any delay caused by damage or destruction by fire or other casualty, strike, shortage of material, unusually adverse weather conditions such as, by way of illustration and not limitation, severe rain storms or below freezing temperatures of abnormal degree or for an abnormal duration, tornadoes or cyclones, and other events or conditions beyond the reasonable control of the party affected which in fact interferes with the ability of such party to discharge its obligations hereunder. The individual or entity relying on this section with respect to any such delay shall, upon the occurrence of the event causing such delay, immediately give written notice to the other parties to this Agreement. The individual or entity relying on this section with respect to any such delay may rely on this section only to the extent of the actual number of days of delay effected by any such events described above.
  6. Exhibits. All of the exhibits attached hereto are incorporated herein by reference.
  7. Business Economic Support Act. Pursuant to the Business Economic Support Act (30 ILCS 760/1 et seg), if the Developer is required to provide notice under the WARN Act, the Developer shall, in addition to the notice required under the WARN Act, provide at the same time a copy of the WARN Act notice to the Governor of the State, the Speaker and Minority Leader of the House of Representatives of the State, the President and minority Leader of the Senate of State, and the Mayor of each municipality where the Developer has locations in the State. Failure by the Developer to provide such notice as described above may result in the termination of all or a part of the payment or reimbursement obligations of the City set forth herein.
 
 
40
 
  1. Venue and Consent to Jurisdiction. If there is a lawsuit under this Agreement, each party may hereto agrees to submit to the jurisdiction of the courts of Cook County, the State of Illinois and the United States District Court for the Northern District of Illinois.
  2. Costs and Expenses. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorney's fees, incurred in connection with the enforcement of the provisions of this Agreement. This includes, subject to any limits under applicable law, attorney's fees and legal expenses, whether or not there is a lawsuit, including attorney's fees for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals and any anticipated post-judgment collection services. Developer also will pay any court costs, in addition to all other sums provided by law.
 
18.22      Business Relationships. The Developer acknowledges (A) receipt of a copy of
Section 2-156-030 (b) of the Municipal Code of Chicago, (B) that Developer has read such provision
and understands that pursuant to such Section 2-156-030 (b), it is illegal for any elected official of
the City, or any person acting at the direction of such official, to contact, either orally or in writing,
any other City official or employee with respect to any matter involving any person with whom the
elected City official or employee has a "Business Relationship" (as defined in Section 2-156-080 of
the Municipal Code of Chicago), or to participate in any discussion in any City Council committee
hearing or in any City Council meeting or to vote on any matter involving any person with whom the
elected City official or employee has a "Business Relationship" (as defined in Section 2-156-080 of
the Municipal Code of Chicago), or to participate in any discussion in any City Council committee
hearing or in any City Council meeting or to vote on any matter involving the person with whom an
elected official has a Business Relationship, and (C) that a violation of Section 2-156-030 (b) by an
elected official, or any person acting at the direction of such official, with respect to any transaction
contemplated by this Agreement shall be grounds for termination of this Agreement and the
transactions contemplated hereby. The Developer hereby represents and warrants that, to the best
of its knowledge after due inquiry, no violation of Section 2-156-030 (b) has occurred with respect to
this Agreement or the transactions contemplated hereby.
[THE REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK.]
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
41
 
 
IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment Agreement to be executed on or as of the day and year first above written.
 
 
 
LAKE STREET STUDIOS LIMITED PARTNERSHIP, an Illinois limited partnership
 
By:     LAKE STREET STUDIOS LLC, its general partner
By: THE INTERFAITH HOUSING DEVELOPMENT CORPORATION OF CHICAGO, an Illinois not-for-profit corporation, a member
 
By: Its:
 
 
 
INTERFAITH HOUSING DEVELOPMENT CORPORATION, an Illinois not-for-profit corporation
 
By: Its:
 
 
 
CITY OF CHICAGO, by and through its Department of Housing and Economic Development
 
 
By:      
Andrew J. Mooney, Commissioner
 
 
 
 
 
 
 
 
 
 
 
 
 
42
 
 
STATE OF ILLINOIS )
)SS
COUNTY OF COOK )
 
 
 
I,      , a notary public in and for the said County, in the State aforesaid,
DO HEREBY CERTIFY that      personally known to me to be the
      of Lake Street Studios Limited Partnership, an Illinois limited
partnership (the "Owner"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by the General Partner of the Owner, as his/her free and voluntary act and as the free and voluntary act of the Owner, for the uses and purposes therein set forth.
 
GIVEN under my hand and official seal this      day of      ,      .
 
 
Notary Public
 
 
My Commission Expires
(SEAL)
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
43
 
 
STATE OF ILLINOIS )
)SS
COUNTY OF COOK )
 
 
 
I,      , a notary public in and for the said County, in the State aforesaid,
DO HEREBY CERTIFY that      personally known to me to be the
      of Interfaith Housing Development Corporation, an Illinois not-for-
profit corporation ("IHDC"), and personally known to me to be the same person whose name is
subscribed to the foregoing instrument, appeared before me this day in person and acknowledged
that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her
by the [trustees] of IHDC, as his/her free and voluntary act and as the free and voluntary act of
IHDC, for the uses and purposes therein set forth.
 
GIVEN under my hand and official seal this      day of      ,      .
 
 
Notary Public
 
 
My Commission Expires
(SEAL)
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
44
 
 
 
STATE OF ILLINOIS COUNTY OF COOK
)
)SS
)
 
 
 
I,      , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that Andrew J. Mooney, personally known to me to be the Commissioner of the Department of Housing and Economic Development of the City of Chicago (the "City"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument pursuant to the authority given to him/her by the City, as his/her free and voluntary act and as the free and voluntary act of the City, for the uses and purposes therein set forth.
 
GIVEN under my hand and official seal this      th day of      ,      .
 
 
 
Notary Public
 
 
My Commission Expires.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
45
 
 
EXHIBIT A
 
REDEVELOPMENT AREA
(see Ex.      of the Redevelopment Plan - Ex. D to the Agreement)
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
46
 
 
EXHIBIT B PROPERTY
Legal Description: [to come]
PIN: 17-09-318-003-000
Commonly known as: 727 West Lake Street, Chicago, Illinois
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
47
 
 
EXHIBIT C
 
TIF-FUNDED IMPROVEMENTS
 
Acquisition      $530,000
Asbestos Removal      $3,000
Demolition      $180,800
New Construction      $6,131,497
Construction Permits and Fees      $37,500
Utility fees      $10,000
Architect's Fee - Design      $235,250
Architect's Fee - Supervision      $75,250
Engineering      $15,000
Appraisal      $15,000
Environmental Report      $5,000
HERS Testing      $7,500
Total      $7,245,797*
 
 
*Notwithstanding this amount, the total amount payable for TIF-Eligible costs will not exceed $3,100,000.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
48
 
 
EXHIBIT D REDEVELOPMENT PLAN Not attached for ordinance
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
49
 
 
EXHIBIT E CONSTRUCTION CONTRACT Not attached for ordinance
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
50
 
 
EXHIBIT F ESCROW AGREEMENT Not attached for ordinance
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
51
 
 
EXHIBIT G
 
PERMITTED LIENS
 
1. Liens or encumbrances against the Property:
 
Those matters set forth as Schedule B title exceptions in the owner's title insurance policy issued by the Title Company as of the date hereof, but only so long as applicable title endorsements issued in conjunction therewith on the date hereof, if any, continue to remain in full force and effect.
 
2. Liens or encumbrances against the Developer or the Project, other than liens against the Property, if any:
 
[Existing Construction Mortgage, With Assignment of Rents, Security Agreement and Fixture
Filing by Developer to Citibank, N.A., dated October      , 2013.]
[To be completed by Developer's counsel, subject to City approval]
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
52
 
 
EXHIBIT H
 
PROJECT BUDGET
 
Acquisition $530,000 Demolition 180,800 Net Construction Costs 12,016,057 Overhead 246,937 Profit 370,406 Bond Premium / LOC fee 101,285 Building Permits 75,000 Utility Fees 10,000
Contingency      645,774
Construction Total:      13,646,259
Asbestos Removal      3,000
Environmental Total:      3,000
Real Estate Taxes 40,000
Hazard Insurance      55,000
Construction Period Total:      95,000
Architect -- Design 470,500
Architect--Supervision 150,500
Engineering Fees 30,000
Predevelopment Interest 20,000
Legal - Organizational 101,500
Legal - Zoning 16,538
Accountant -- General 25.000
Plats & Surveys 20,000
Appraisal 15,000
Environmental Reports 10,000
Market Study      9,911
Title & Recording Fees 25,000
HERS Testing      15,000
Professional Fees Total:      908,949
Marketing & Leasing      25,000
Marketing & Leasing Total:      25,000
Application Fee 10,000 LI HTC Reservation Fee 113,212 Construction Points 75,034 Lender Legal Costs 45,000
Construction Inspection      20,000
Lender Fees Total:       263,246
 
 
53
 
 
Developer Fee 800,000
Consultant -- Financial      200,000
Developer Fee Total:      1,000,000
Tax & Insurance Escrow 51,413
Replacement Reserve 21,350
Section 8 Reserve 65,000
Lease-Up Expense 38,991
Operating Deficit      217,080
Reserves Total:      393,834
Equity Bridge Loan 323,201 Total Development Cost $17,188,489
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
54
 
 
EXHIBIT I APPROVED PRIOR EXPENDITURES Not attached for ordinance
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
55
 
 
EXHIBIT J
OPINION OF DEVELOPER'S COUNSEL [To be retyped on the Developer's Counsel's letterhead]
 
 
 
City of Chicago
121 North LaSalle Street
Chicago, IL 60602
 
ATTENTION: Corporation Counsel
 
Ladies and Gentlemen:
 
We have acted as counsel to      , an [Illinois]      
(the "Developer"), in connection with the purchase of certain land and the construction of certain
facilities thereon located in the      Redevelopment Project
Area (the "Project"). In that capacity, we have examined, among other things, the following agreements, instruments and documents of even date herewith, hereinafter referred to as the "Documents":
(a)      Redevelopment Agreement (the "Agreement") of even
date herewith, executed by the Developer and the City of Chicago (the "City");
  1. [insert other documents including but not limited to documents related to purchase and financing of the Property and all lender financing related to the Project]; and
  2. all other agreements, instruments and documents executed in connection with the foregoing.
 
In addition to the foregoing, we have examined
  1. the original or certified, conformed or photostatic copies of the Developer's (i) Articles of Incorporation, as amended to date, (ii) qualifications to do business and certificates of good standing in all states in which the Developer is qualified to do business, (iii) By-Laws, as amended to date, and (iv) records of all corporate proceedings relating to the Project [revise if the Developer is not a corporation]; and
  2. such other documents, records and legal matters as we have deemed necessary or relevant for purposes of issuing the opinions hereinafter expressed.
 
In all such examinations, we have assumed the genuineness of all signatures (other than those of the Developer), the authenticity of documents submitted to us as originals and conformity to the originals of all documents submitted to us as certified, conformed or photostatic copies.
Based on the foregoing, it is our opinion that:
 
 
56
 
  1. The Developer is a corporation duly organized, validly existing and in good standing under the laws of its state of [incorporation] [organization], has full power and authority to own and lease its properties and to carry on its business as presently conducted, and is in good standing and duly qualified to do business as a foreign [corporation] [entity] under the laws of every state in which the conduct of its affairs or the ownership of its assets requires such qualification, except for those states in which its failure to qualify to do business would not have a material adverse effect on it or its business.
  2. The Developer has full right, power and authority to execute and deliver the Documents to which it is a party and to perform its obligations thereunder. Such execution, delivery and performance will not conflict with, or result in a breach of, the Developer's [Articles of Incorporation or By-Laws] [describe any formation documents if the Developer is not a corporation] or result in a breach or other violation of any of the terms, conditions or provisions of any law or regulation, order, writ, injunction or decree of any court, government or regulatory authority, or, to the best of our knowledge after diligent inquiry, any of the terms, conditions or provisions of any agreement, instrument or document to which the Developer is a party or by which the Developer or its properties is bound. To the best of our knowledge after diligent inquiry, such execution, delivery and performance will not constitute grounds for acceleration of the maturity of any agreement, indenture, undertaking or other instrument to which the Developer is a party or by which it or any of its property may be bound, or result in the creation or imposition of (or the obligation to create or impose) any lien, charge or encumbrance on, or security interest in, any of its property pursuant to the provisions of any of the foregoing, other than liens or security interests in favor of the lender providing Lender Financing (as defined in the Agreement).
  3. The execution and delivery of each Document and the performance of the transactions contemplated thereby have been duly authorized and approved by all requisite action on the part of the Developer.
  4. Each of the Documents to which the Developer is a party has been duly executed and delivered by a duly authorized officer of the Developer, and each such Document constitutes the legal, valid and binding obligation of the Developer, enforceable in accordance with its terms, except as limited by applicable bankruptcy, reorganization, insolvency or similar laws affecting the enforcement of creditors' rights generally.
  5. Exhibit A attached hereto (a) identifies each class of capital stock of the Developer, (b) sets forth the number of issued and authorized shares of each such class, and (c) identifies the record owners of shares of each class of capital stock of the Developer and the number of shares held of record by each such holder. To the best of our knowledge after diligent inquiry, except as set forth on Exhibit A, there are no warrants, options, rights or commitments of purchase, conversion, call or exchange or other rights or restrictions with respect to any of the capital stock of the Developer. Each outstanding share of the capital stock of the Developer is duly authorized, validly issued, fully paid and nonassessable.
  6. To the best of our knowledge after diligent inquiry, no judgments are outstanding against the Developer, nor is there now pending or threatened, any litigation, contested claim or governmental proceeding by or against the Developer or affecting the Developer or its property, or seeking to restrain or enjoin the performance by the Developer of the Agreement or the transactions contemplated by the Agreement, or contesting the validity thereof. To the best of our knowledge after diligent inquiry, the Developer is not in default with respect to any order, writ, injunction or decree of any court, government or regulatory authority or in default in any respect
 
 
57
 
 
under any law, order, regulation or demand of any governmental agency or instrumentality, a default under which would have a material adverse effect on the Developer or its business.
  1. To the best of our knowledge after diligent inquiry, there is no default by the Developer or any other party under any material contract, lease, agreement, instrument or commitment to which the Developer is a party or by which the company or its properties is bound.
  2. To the best of our knowledge after diligent inquiry, all of the assets of the Developer are free and clear of mortgages, liens, pledges, security interests and encumbrances except for those specifically set forth in the Documents.
  3. The execution, delivery and performance of the Documents by the Developer have not and will not require the consent of any person or the giving of notice to, any exemption by, any registration, declaration or filing with or any taking of any other actions in respect of, any person, including without limitation any court, government or regulatory authority.
  4. To the best of our knowledge after diligent inquiry, the Developer owns or possesses or is licensed or otherwise has the right to use all licenses, permits and other governmental approvals and authorizations, operating authorities, certificates of public convenience, goods carriers permits, authorizations and other rights that are necessary for the operation of its business.
  5. A federal or state court sitting in the State of Illinois and applying the choice of law provisions of the State of Illinois would enforce the choice of law contained in the Documents and apply the law of the State of Illinois to the transactions evidenced thereby.
 
We are attorneys admitted to practice in the State of Illinois and we express no opinion as to any laws other than federal laws of the United States of America and the laws of the State of Illinois.
[Note: include a reference to the laws of the state of incorporation/organization of the Developer, if other than Illinois.]
 
This opinion is issued at the Developer's request for the benefit of the City and its counsel, and may not be disclosed to or relied upon by any other person.
Very truly yours,
 
 
 
 
 
 
By:_ Name:
 
 
 
 
 
 
 
58
 
 
EXHIBIT K REQUISITION FORM
 
STATE OF ILLINOIS )
) SS
COUNTY OF COOK )
 
The affiant,       ,             of      , a
      (the "Developer"), hereby certifies that with respect to that
certain      Redevelopment Agreement between the Developer and the City of
Chicago dated      ,      (the "Agreement"):
  1. Expenditures for the Project, in the total amount of $      , have been
made:
  1. This paragraph B sets forth and is a true and complete statement of all costs of TIF-Funded Improvements for the Project reimbursed by the City to date:
 
$      
  1. The Developer requests reimbursement for the following cost of TIF-Funded Improvements:
 
$      
  1. None of the costs referenced in paragraph C above have been previously reimbursed by the City.
    1. The Developer hereby certifies to the City that, as of the date hereof:
  1. Except as described in the attached certificate, the representations and warranties contained in the Agreement are true and correct and the Developer is in compliance with all applicable covenants contained herein.
  2. No event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default, exists or has occurred.
 
All capitalized terms which are not defined herein has the meanings given such terms in the Agreement.
 
 
 
 
 
 
 
 
 
 
 
59
 
 
[Developer]
 
 
By:      
Name
Title:      
 
Subscribed and sworn before me this      day of
 
 
 
 
My commission expires:.
 
 
Agreed and accepted:
 
 
Name
Title:      
City of Chicago
Department of Housing and Economic Development
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
60
 
 
EXHIBIT L
FORM OF SUBORDINATION AGREEMENT Not attached for ordinance
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
61
 
 
OFFICE OF THE MAYOR
CITY OF CHICAGO
RAHM EMANUEL MAYOR
June 26, 2013
 
 
 
 
 
 
 
 
 
 
TO THE HONORABLE, THE CITY COUNCIL OF THE CITY OF CHICAGO
 
 
Ladies and Gentlemen:
 
At the request of the Commissioner of Housing and Economic Development, I transmit herewith an ordinance authorizing the execution of a redevelopment agreement for Lake Street Studios LP and Int-: rfaith Housing Development Corporation.
 
Your favorable consideration of this ordinance will be appreciated.
 
Mayor
 
Very truly yours,
 
CHICAGO July 24, 2013
 
To the President and Members of the City Council:
 
Your Committee on Finance having had under consideration
 
 
A communication recommending a proposed ordinance concerning the authority to enter into and execute a Redevelopment Agreement and Loan Agreement with Lake Street Studios LP and Interfaith Housing Development Corporation.
 
02013-4996
 
$4,100,000
 
Amount of Loan not to exceed:
 
 
 
 
 
 
 
 
 
 
 
 
 
Having had the same under advisement, begs leave to report and recommend that your Honorable Body pass the proposed Ordinance Transmitted Herewith
 
(a (viva voce vote
 
 
 
dissenting vote(s)T
 
This recommendation was concurred in by
of members of the committee with
Alderman Burke abstains from voting pursuant to Rule 14.
 
 
(signed'
 
 
 
 
Respectfully submitted
 
Chairman
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I -- GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Lake Streel Studios Limited Partnership
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [X] the Applicant
OR
  1. [ ] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest:      
OR
3.      [ ] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
  1. Business address Of the Disclosing Party:      219 W.Chicago Avenue      
Chicago, JL 60654
  1. Telephone: (312) 274-8200      Fax; (312)274-0292      Email; gjordan@ihdc.org      
  2. Name of contact person: Gladvs Jordan      
  3. Federal Employer Identification No. (if you have one)::            i             _j      
  4. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
TIF assistance from the Near West TIF Redevelopment Area and HOME funds Tor the acquisition, demo and new construction of a 61 -unit SRO permanenl supportive housing development lo be located at 727 W. Lake Street
 
G. Which City agency or department is requesting this EDS? Hou5'nB and Economic Development      
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
 
Specification #            and Contract #       
 
Ver. 01-01-12
 
 
 
Page 1 of 13
 
 
SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS
 
A. NATURE OF THE DISCLOSING PARTY 1.  Indicate the nature of the Disclosing Party:
]      Person      [ ]
]      Publicly registered business corporation      (>9
]      Privately held business corporation      [ ]
]      Sole proprietorship      [ ]
}      General partnership      (Is
]      Limited partnership
]      Trust      [ ]
 
 
 
 
Limited liability company Limited liability partnership Joint venture
Not-for-profit corporation
the not-for-profit corporation also a 501(c)(3))?
[]Yes      [] No
Other (please specify)
 
 
2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Illinois
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      [] No      [x] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.  List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
 
Lake Street Studios, LLC      General Parmer
JG Lake Street LLC      .m.ml 'imitcd partner (will be replaced with investor at closing)
Interfoith Housing Development Corporaiion      Managing member of the GP
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
■   interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
 
Lake Street Studios LLC      219 W. Chicago. Chicago, IL      0.01%      
JG Lake Street LLC      600 w. Jackson, Chicago, IL      99.99% (initial limited partner that will be replaced
with investor at closing)
 
 
SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Parly had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[] Yes [X]No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated      Address      (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rale" or "t.b.d." is
not an acceptable response.
Linn-Mathcs      309 S. Green Street      Contractor      S13.2M(est)
Hnrley Ellis Devereaux 401W. Superior      Architect      S500k (est)
Lighten-Galc Group    39 S. LaSalle      Financial consultant      £200k (contract amount)
Applegalc & Thome -Thomsen 626 W. Lake Street Legal S100k(est.)
(Add sheets if necessary)
[ ] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V -- CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [X] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes [JNo
  1. FURTHER CERTIFICATIONS
 
I.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined lerms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is o continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
2. The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section 11.B.1. of Ibis EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
 
3.   The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person ot entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Parly, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity tbat directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the dale this EDS is signed, or, with respect lo a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting lo bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a parly to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement lo bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce ortbeir successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Parly is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
 
N/A
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified lo the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution dale of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").
 
N/A
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding Ihe execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
 
N/A
 
 
Page 7 of 13
 
 
If the letters "MA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified lo the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest iii his or her own name or in the name of any other person or entity in the Matter?
[]Ycs [X]No
 
NOTE:  If you checked "Yes" lo Item D. I., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, ot (ii) is sold fox taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[ ] Yes      pq No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4, The Disclosing Parly further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure tD
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
X      1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Parly has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI — CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
 
N/A
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt lo influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Parly will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section
501 (c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  1. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request,
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
p^Yes []No If "Yes," answer the three questions below:
  1. Hove you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 43 CFR Part 60-2.)
[ ] Yes      pq No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[]Yes pqNo
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes      [X| No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
The disclosing parly has no employees so is therefore not subject to the above requirements.
 
 
Page 10 of 13
 
 
SECTION VII- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all staUites, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicaEO.orE/Elhics. and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 33
 
 
F.l.   The Disclosing Parry is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2    If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penally of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
Lake Sfrcct Studios Limited Partnership
(Print or type name of Disclosing Party) By: Lake Street Studios. LLC,.itsj>encral partner By: InlerfaiUvHousm^ Development Corporation, ils managing member
By: _ j^e^a^A^^      
(Sign here) y
Gladys Jordan (Print or type name of person signing)
President
(Print or type title of person signing)
 
Signed^nd sworn to before me on (date)      cZ6 J?t@0,
at    dm?f'/       County, J2oM5 ' (state).
\&L u/j\/7Zc^ K^MA-U' t^'    Notary Public.
 
Commission expires:
 
Page 12 of 13
 
 
 
js^vwy^      ■**»''»''•■ ■ ■ ■
\ "OFFICIAL SEAL i       Bridgette Harris
/ Notary Public. State of HIinots |    My SiMi?^^
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Parly" means (1) all executive officers of the Disclosing Party listed in Section II.B.l.a., if the Disclosing Parry is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [X] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
A. LegBl name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Lake Street Studios LLC
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [X] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Smdios Limited Partnership      
OR
3.      [] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity iiK
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:     219 W.Chicago Avenue      
Chicago, IL 60654
  1. Telephone: (312)274-8200      pax. (312)274-0292      Emaii: gjordan@ihdc.org      
  2. Name of contact person: GladysJordan      
  3. Federal Employer Identification No. (if you have one):      
  4. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
TIF assistance from the Near West TTF Redevelopment Area and HOME funds for the acquisition, demo and new construction of a 61-unit SRO permanent supportive housing development lo be located at 727 W. Lake Street
 
G. "Which City agency or department is requesting this EDS? Housinfi and Economic Development      
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
 
Specification #      and Contract # ,       
 
Ver. 01-01-12
 
 
 
Page 1 of 13
 
 
Section ii - disclosure of ownership interests
 
A. NATURE OF THE DISCLOSING PARTY
 
1.   Indicate the nature of the Disclosing Party.
[ ] Person      [XJ Limited liability company
[ ] Publicly registered business corporation      [ ] Limited liability partnership
[ ] Privately held business corporation      [ ] Joint venture
[ ] Sole proprietorship      [ 3 Not-for-profit corporation
[ ] General partnership      (Is the not-for-profit corporation also a 501(c)(3))?
[ ] Limited partnership      [ ] Yes      [) No
[ 3 Trust      [ 3 Other (please specify)
 
2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Illinois
 
3.  For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ 3 Yes      [ ] No      [x3 N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and ail directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
 
 
 
 
InlcrfniUi Housing Development Corporation      Managing member
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
 
Intcrfaith Housing Development Corporation 2)9 W. Chicago, Chicago, IL      30% (managing member)
JG Lake Street LLC      600 W. Jackson, Chicago, IL 70%
 
 
 
SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      P9 No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
 
(Add sheets if necessary)
P3 Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
 
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Parly been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [X] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article l")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article 1 applies to the Applicant, the permanent compliance timeframe in Article 1 supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
, 2.   The Disclosing Party and, if the Disclosing Parly is a legal entity, all of those persons or entities identified in Section Il.B.l. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, slate or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain) or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or stale antitrust statutes; fraud; embezzlement; theft; forgery, bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
 
3.   The certifications in subparts 3, 4 and 5 concern:
 
•      the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant lo the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect lo a Contractor, an Affiliated Entity, or an A ffiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Mailer:
    1. bribed or attempted lo bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any slate or local government in the United States of America, in that officer's or employee's official capacity;
    2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement lo bid a fixed price or otherwise; or
    3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  2. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agenls or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither Ihe Disclosing Party nor any Affiliated Entity is listed on any of ihe following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
 
N/A
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Parly who were, at any time during the 12-month period preceding the execution dale of this EDS, an employee, or elected or appointed official, of 1he City of Chicago (if none, indicate with "N/A" or "none").
 
N/A
 
 
9.   To the best of the Disclosing Parly's knowledge after reasonable inquiry, the following is a complete, list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does nol include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
 
N/A
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Parly (check one)
[ ] is      [j] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand thai becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
 
N/A
 
 
Page 7 of 13
 
 
If the idlers "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Parly certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms thai are defined in Chapter 2-156 of the M unicipal Code have the same meanings when used in this Part D.
 
!.   In accordance with Section 2-156-110 of ihe Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[jYes [X]No
 
NOTE:  IT you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suil of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes |X]No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either I. or 2, below. If the Disclosing Parly checks 2., the Disclosing Parly must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
cojviply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
_X      1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Parly has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect lo the Matter: (Add sheets if necessary):
 
N/A
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Parly means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or enlity lisied in Paragraph A.l. above for his or her lobbying activities or to pay any person or enlity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally Tunded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A. J. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501 (c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A. 1. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
 
Is the Disclosing Party the Applicant?
[ ] Yes      pj No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[ ] Yes      [ ] No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes      [ ] No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and aD award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article 1 of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
F. I.   The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, properly taxes or sales taxes.
 
F.2    If the Disclosing Parly is the Applicant, the Disclosing Parly and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3    If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
UndeT penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
Lake Street Studios LLC
(Print or type name of Disclosing Party)
By: Intcrfnidi^usingDcvclppiiKm^Conjo/ntion^its managing member Bv: ^jZCf^^yjk^^ -"'(Sign heref //
Gladys Jordan (Print or type name of person signing)
President
(Print or type title of person signing)
 
 
Signed and sworn to before me on (date) $pjr.iC -$6 , . at   (LiW/C        County,   S?/'jWi^ ' (state). 7
 
Notary Public.
Commission expires: O
Page 12 of 13
 
 
UJ
Z
"OFFICIAL SEAL" Bridgette Harris
Notary Public. State of Illinois My Commission Expires 5/20/2013:
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Parly" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmodier, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section U.B.I .a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Parmer thereof currently have a "familial relationship" with an elected city official or department head?
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title or the elected city official or department head to whom such . person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: JG Lake Street LLC
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [Xj a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership      
OR
3.      [] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      600 W, Jackson. Sie. 275      
Chicago, IL 60661
  1. Telephone: 312-44J-9464      pax:  312-441-9502      Email: gmarks@markivrealry.com
  2. Name of contact person:  George Marks      
  3. Federal Employer Identification No. (if you have one):      
  4. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
TIF assistance from the Near West TIF Redevelopment Area and HOME funds for the acquisition, demo and new construction of a 61-unit SRO pennanent supportive housing development to be located at 727 W. Lake Street
 
G. Which City agency or department is requesting this EDS? Ho"sin£ and Econoniic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
 
Specification #      and Contract #      
 
Ver. 01-01-12
 
 
 
Page 1 of 13
 
 
SECTION II DISCLOSURE OF OWNERSHIP INTERESTS A. NATURE OF THE DISCLOSING PARTY
 
1.   Indicate the nature of the Disclosing
[ ]      Person
[ ]      Publicly registered business corporation
[ ]      Privately held business corporation
[ ]      Sole proprietorship
[ ]      General partnership
[ ]      Limited partnership
[]      Trust
 
[XJ Limited liability company
[ ] Limited liability partnership
[ ] Joint venture
[ ] Not-for-profit corporation
(Is the not-for-profit corporation also a 501(c)(3))?
[]Yes []No [ ] Other (please specify)
 
 
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable:
Illinois
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      [ ] No      [X] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE; Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
 
George Marks Manager
 
 
 
 
 
2.  Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
George Marks      600 W. Jackson, Ste. 275 50%
John Marks      600 W. Jackson, Sle. 275 50%
 
 
 
SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [X] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relalionship(s):
 
 
 
 
SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained 01 anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
P3 Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [X] No      [ ] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[ ] Yes      [ ] No
  1. FURTHER CERTIFICATIONS
 
J.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article i")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance^' timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
  1. The Disclosing Parly and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section Il.B.l. of this EDS:
    1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
    2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with; obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
    3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
    4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
    5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
  2. The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
    1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in (he United States of America, in that officer's or employee's official capacity;
    2. agreed or colluded with other bidders or prospective bidders, or been a party lo any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
    3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  2. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
 
N/A
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").
__
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
_
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
 
N/A
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[ ] Yes      [X] No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.lproceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes [XjMo
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check eidier 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
_X      1 - The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI ~ CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
J.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary);
 
N/A
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Parly will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
 
Is the Disclosing Party the Applicant?
[ ] Yes      [Xj No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements? .
[]Yes []No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes []No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement. City assistance, or other City action, and are material inducements lo the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.citYofchicago.orR/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article 1 of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
 
F.J.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. Genera] Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or lo be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason lo believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
JG Lake Street, LLC (Print or type name of Disclosing Party)
Bv g4^~-      
(Sign here)
George Marks (Print or type name of person signing)
 
Manager
(Print or type title of person signing)
 
County, si&WO/S (state).
Notary Public.
Signed^ld sworn to before me on (date) .J?*'*'*- ''"' ^ J
at  /(fejff      County, .^"^Wg/J (state).
Commission expires
 
 
 
OFFICIAL SL:AI CLAUDIA A. LORD
Notaiy Public - Sta'.r oi '■■■<•' • s
 
 
Page 12 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
"Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section n.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ]Yes [X]No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION 1 -- GENERAL INFORMATION
A. Legal name of the Disclosing Parly submitting this EDS. Include d/b/a/ if applicable: The Interfaith Housing Development Corporation of Chicago
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Parly submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [/) a legal entity holding a direct or indirect interest in the Applicant. Stale the legal name of the Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership
OR
3.      [ ] a legal entity with a right of control (see Section 1I.B.1.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:     219 W. Chicago Ave. Suite 400      
Chicago, IL 60654
  2. Email: Qjordan@ihdc.org
  3. Telephone: 312-274-8200      Fax: 312-274-0292
  4. Name of contact person: ^!!d_yi_J°L^n_      
 
E.      Federal Employer Identification No. (if you have one):                  
  1. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
TIF assistance from the Near West TIF Redevelopment Area and HOME funds for the acquisition, demo and new construction of a 61 unit SRO permanent supportive housing development to be located at 727 W. Lake Street
 
G. Which City agency or department is requesting this EDS? Housin9 and Economic Development      
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
 
Specification U      and Contract U      :      
 
Vcr. 01-01-12
 
 
 
Page 1 of 13
 
 
SECTION II -- DISCLOSURE OF OWNERSHIP INTERESTS A. NATURE OF THE DISCLOSING PARTY
 
1.   Indicate the nature of the Disclosing Parly:
[ ]      Person
f ]      Publicly registered business corporation
[ ]      Privately held business corporation
[ ]      Sole proprietorship
[ ]      General partnership
[ |      Limited partnership
[]      Trust
[ ] Limited liability company
[ ] Limited liability partnership
[ ] Joint venture
(/] Not-for-profit corporation
(Is the not-for-profit corporation also a 501(c)(3))?
fcO Yes      [ ] No
[ ] Other (please specify)
 
 
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable:
 
Illinois
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[]Yes      []No ^N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there arc no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, lisl below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title See attached list of executive officers and directors.
No members.
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
None.
 
 
 
 
 
 
 
SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Parly had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in (he 12 months before the date this EDS is signed?
 
[ ] Yes      M No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Pat ty has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Parly's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (I) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated      Address      (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
f/] Check here if the Disclosing Party has not retained, nor expects lo retain, any such persons or entities. SECTION V -- CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
 
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [/] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Ycs [JNo
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1 -23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article 1 is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
  1. The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section H.B.I, of this EDS:
    1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
    2. have not, within a five-year period preceding the dale of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or stale antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
    3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
    4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
    5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
  2. The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by ii, or, with the Contractor, is under common control of another person or enlity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Enlity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the dale of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the Stale of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
 
A.   Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  1. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  2. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  3. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Parly must explain below:
None.
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none"). None.
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient. None.
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      t/} is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the M unicipal Code, explain here (attach additional pages if necessary):
 
N/A
 
 
Page 7 of 13
 
 
]f the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Ycs K)No
 
NOTE:  If you checked "Yes" to Item D.L, proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes f/]No
  1. If you checked "Yes" lo Item D. 1., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Parly checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
X      J. The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Parly and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Parly verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: Tf the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
 
N/A
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or lo extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Parly certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Parly is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
13. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
 
Is the Disclosing Party the Applicant?
[]Yes MNo If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[]Yes []No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes      [ ] No
 
If you checked "No" to question I. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII — ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become pari of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicaKo.ora/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Acl request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up lo the time the City takes action on the Matter. If the Matter is a contract being handled by ihe City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article 1 of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1 -23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page II of 13
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2    If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.L, F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
Intcrfaiih Housing Development Corporation of Chicago
(Print or type name of Disclosing Party)
By: ('^^^^^^■^^^t^p^-^^^      
(Signhet^ ^
Gladys Jordan
(Print or type name of person signing) President
(Print or type title of person signing)
 
S at
 
 
igned and sworn to before me on (date) $D{Lll.       c3l0/3 , _ County,  Jl/jAltDiS (state).
Notary Public.
 
Commission expires:      -3_
Page 12 of 13
"OFFICIAL SEAL" Bridqette Harris
Notary Public, State of Illinois My Commission Expires 5/20/2013
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015} the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section Jl.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Parly. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Parly" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      (/] No
 
If yes, please identify below (I) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
Interfaith Housing Development Corporation of Chicago
BOARD OF DIRECTORS 2012
 
Officers
 
Mr. Clarence L. Smith, Chair
President
 
 
Ms. Catherine Galligan, Vice-Chair/Treasurer Cathy.ealliRan@cancer.ore
 
 
Ms. Gladys Jordan, President
Directors
Ms. Elizabeth Lee
 
 
Ms. Janet L. Smith, Ph. D.
 
 
 
Mr. Waymon T. Starks (Retired)
Advisory Board Mr. Jacob C. Starks
 
 
Ms. Beth McDonough
 
 
 
Ms. Barbara Shaw
 
 
 
 
Mr. Calvin Holmes, Secretary
Ms. Mildred Williamson, Ph. D, MSW
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I -- GENERAL INFORMATION
  1. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Wincopin Circle, LLLP
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [^ a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*      
OR
3.      [] a legal entity with a right of control (see Section II.B. 1.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
  1. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
C   Telephone* 410-772-5232      Fax' 410-772-2630      Email-•'rothschilcl@enteprisecommunity.com
  1. Name of contact person: Bruce Rothschild      
  2. Federal Employer Identification No. (if you have one):
F.      Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to
which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide 61 units of housing for formerly homeless tenants.
 
G.      Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
"The Disclosing Party is anticipated to acquire a 99.99% membership interest in Lake Street Studios Limited Partnership upon the closing of the Matter.
 
Ver. 01-01-12      Page 1 of 13
 
 
SECTI6N II -- DISCLOSURE OF OWNERSHIP INTERESTS
A. NATURE OF THE DISCLOSING PARTY 1.   Indicate the nature of the Disclosing Party:
Person      [ ] Limited liability company
Publicly registered business corporation       [ ] Limited liability partnership
Privately held business corporation      [ ] Joint venture
Sole proprietorship      [ ] Not-for-profit corporation
General partnership      (Is the not-for-profit corporation also a 501(c)(3))?
Limited partnership      [ ] Yes      [ ] No
Trust      [x] Other (please specify)
Limited Liability Limited Partnership
2 '.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      [*) No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
Wincopin GP, LLC      General Partner
 
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Wincopin GP, LLC      10227 Wincopin Circle      .01% General Partner
Columbia, MD 2104?
 
Enterprise Community      10227 Wincopin Circle      99.99% Limited Partner
'Housing Organization, Inc.    Columbia, MD 21044
 
 
SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[]Yes [x]No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV -- DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether     Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[x] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
rhe Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities •d in Section II.B.l. of this EDS:
 
re not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily xcluded from any transactions by any federal, state or local unit of government;
 
,ave not, within a five-year period preceding the date of this EDS, been convicted of a criminal ffense, adjudged guilty, or had a civil judgment rendered against them in connection with:
■btaining, attempting to obtain, or performing a public (federal, state or local) transaction or ontract under a public transaction; a violation of federal or state antitrust statutes; fraud;
. mbezzlement; theft; forgery; bribery; falsification or destruction of records; making false
. tatements; or receiving stolen property;
 
re not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, Late or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
 
ave not, within a five-year period preceding the date of this EDS, had one or more public •ansactions (federal, state or local) terminated for cause or default; and
 
ave not, within a five-year period preceding the date of this EDS, been convicted, adjudged uilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions i oncerning environmental violations, instituted by the City or by the federal government, any tate, or any other unit of local government.
 
he certifications in subparts 3, 4 and 5 concern:
 
Disclosing Party;
/ "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in oction with the Matter, including but not limited to all persons or legal entities disclosed under on IV, "Disclosure of Subcontractors and Other Retained Parties"); / "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the osing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under ron control of another person or entity. Indicia of control include, without limitation: ocking management or ownership; identity of interests among family members, shared facilities quipment; common use of employees; or organization of a business entity following the ability of a business entity to do business with federal or state or local government, including ity, using substantially the same management, ownership, or principals as the ineligible entity); respect to Contractors, the term Affiliated Entity means a person or entity that directly or octly controls the Contractor, is controlled by it, or, with the Contractor, is under common ol of another person or entity;
/ responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any . official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, g pursuant to the direction or authorization of a responsible official of the Disclosing Party, any sactor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[ ] Yes      [j§ No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.L, proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying
Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with
respect to the Matter: (Add sheets if necessary):
None
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[ ] Yes      [ ] No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes [JNo
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F. 1., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Wincopin GP, LLC        /      ^ y
its General Partner /M^f^. ^/P^h
(Sign here) (
 
Wincopin Circle LLLP
(Print or type name of Disclosing Party) By
Bruce Rothschild
(Print or type name of person signing)
 
Vice President and General Counsel
(Print or type title of person signing)
 
Signed and sworn to before me on (date) \j) \ \f\ \ \^ at ifcLLXXJ^i County, rj^OJ^lOnd (state).
Notary Public.
Commission expires:     <^L^c^\ 1 *H~
Page 12 of 13
 
 
 
r- *»■ --■ m it —■    -**-     " *** '**'
VERONICA KWAFO
Notary Public Baltimore County Maryland
My Commission Expiras Feb 2. 2014 J
■ W»HM-»   >>I"II"»W H>*\
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I -- GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Wincopin GP, LLC
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
1.      [ ] the Applicant
OR
2.      a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*
OR
3.      [ ] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
  1. Telephone: 41 °-772-5232      Fax-  **1«-772-2630      r£maJ] brothschild@enteprisecommunity.com
  2. Name of contact person: Bruce Rothschild      
  1. Federal Employer Identification No. (if you have one):'      
  2. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide 61 units of housing for formerly homeless tenants.
 
G. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
*The Disclosing Party is the General Partner of Wincopin Circle LLLP, which is anticipated to acquire a
99.99% membership interest in Lake Street Studios Limited Partnership upon the closing of the Matter.
 
Vcr. 01-01-12
 
Page 1 of 13
 
 
SECTION II — DISCLOSURE OF OWNERSHIP INTERESTS
A. NATURE OF THE DISCLOSING PARTY 1.   Indicate the nature of the Disclosing Party:
Person      £]      Limited liability company
Publicly registered business corporation      [ ]      Limited liability partnership
Privately held business corporation      [ ]      Joint venture
Sole proprietorship      [ ]      Not-for-profit corporation
General partnership      (Is the not-for-profit corporation also a 501(c)(3))?
Limited partnership      [ ] Yes      [ ] No
Trust      [ ]      Other (please specify)
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[]Yes      fe]No []N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Enterprise Community      10227 Wincopin Circle      100% Sole Member
Asset Management, Inc.       Columbia, MD 21044
 
 
 
 
 
 
SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[]Yes [x]No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[X] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
.2.   The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state oriocal) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
 
3.   The certifications in subparts 3, 4 and 5 concern:
    • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section TV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
    1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
    2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
    3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  2. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official,
of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in
Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter
2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes [>§No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
None
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A,.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[ ] Yes      [ ] No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes []No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
 
F. 1.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Wincopin GP, LLC
(Print or type name of Disclosing Party)
 
BV:       
/  (Sign here)
Signed and sworn to before me on (date) \Q \ \ 1
Commission expires:      \ *M
(Print or type name of person signing)
Notary Public.
(Print or type title of person signing)
 
 
 
 
 
VERONICA KWAFO
Notary Public Baltimore County Maryland
My Commission Expires Feb 2, 2014
Page 12 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AM) AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section U.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1 .a. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
 
MEMBERS
 
Name Title
 
Craig Mellendick Trustee Bruce Rothschild Trustee
 
OFFICERS
 
Elizabeth O'Leary Bruce Rothschild
 
Craig Mellendick
President & CEO
Vice President, Secretary & General Counsel
Vice President & CFO
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Enterprise Community Housing Organization, Inc.
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [j$ a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*
OR
3.      [ ] a legal entity with a right of control (see Section II.B. 1.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
 
 
C   Telephone" **1°-772-5232      Fax-  410-772-2630      £maj|.brothschild@enteprisecommunity.com
  1. Name of contact person: Bruce Rothschild      
  2. Federal Employer Identification No. (if you have one)::      
  3. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide 61 units of housing for formerly homeless tenants.
 
G. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
*The Disclosing Party is the Limited Partner of Wincopin Circle LLLP, which is anticipated to acquire a 99.99% membership interest in Lake Street Studios Limited Partnership upon the closing of the Matter.
 
Ver. Ul-Ol-12
 
Page I of 13
 
 
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
 
A. NATURE OF THE DISCLOSING PARTY
 
I.   Indicate the nature of the Disclosing Party:
Person
Publicly registered business corporation
Privately held business corporation
Sole proprietorship
General partnership
Limited partnership
Trust
[ ] Limited liability company
[ ] Limited liability partnership
[ ] Joint venture
[ ] Not-for-profit corporation
(Is the not-for-profit corporation also a 501(c)(3))?
[]Yes []No [ ] Other (please specify)
 
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      [x] No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Enterprise Community      10227 Wincopin Circle      100% Common Stock
Asset Management, Inc.       Columbia, MD 21044
 
 
 
 
 
 
SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [x] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether     Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[x] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article l")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
  1. The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
  6. The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official,
of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in
Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter
2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes MNo
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
N/A
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[ ] Yes      [ ] No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes [JNo
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII-- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
 
F.l. • The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F. 1. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Enterprise Community Housing Organization, Inc.
(Print or type name of Disclosing Party)
By: Afo-~
/  (Sign here)
(Print or type name of person signing) (Print or type title of person signing)
 
Signed and sworn to before me on (date)     (JD \ \ ^ I 1 ^>
at VteLuartA county, xyiaryAand (state).
Notary Public.
Commission expires
alalia
Page 12 of 13
 
 
 
 
.mi o <m f> m
VERONICA KWAFO
Notary Public Baltimore County Maryland My Commission Expires Feb 2. 2014 i"v v w 'v v w w u w v m>.
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1 .a. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
 
DIRECTORS
 
Name Title
 
Craig Mellendick Trustee Bruce Rothschild Trustee
 
OFFICERS
 
Charles R. Werhane Bruce Rothschild Craig Mellendick
President & CEO
Senior Vice President & General Counsel Senior Vice President & CFO
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I -- GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Enterprise Community Asset Management, Inc.
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
1.      [ ] the Applicant
OR
2.      a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*
OR
3.      [] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
 
 
C   Telephone" 410-772-5232      Fax" <*1°-772-2630 rHjjjgjj.brothschild@enteprisecommunity.coni
  1. Name of contact person: Bruco Rothsch8ld      
  2. Federal Employer Identification No. (if you have one):        ,       
  3. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide 61 units of housing for formerly homeless tenants.
 
G. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
"The Disclosing Party is the sole owner of Enterprise Community Housing Organization, Inc. which is the 99.99%
Limited Partner of Wincopin Circle, LLLP which is anticipated to acquire a 99.99% membership interest in Lake
Street Studios Limited Partnership upon the closing of the Matter.
 
Ver. 01-01-12
Page 1 of 13
 
 
SECTION II -DISCLOSURE OF OWNERSHIP INTERESTS
 
A. NATURE OF THE DISCLOSING PARTY 1.   Indicate the nature of the Disclosing Party:
[ ] Person      [ ]
[ ] Publicly registered business corporation      [ ]
[x] Privately held business corporation      [ ]
[ ] Sole proprietorship      [ ]
[ ] General partnership      (Is
[ ] Limited partnership
[ ] Trust      [ ]
 
 
 
 
Limited liability company Limited liability partnership Joint venture
Not-for-profit corporation
the not-for-profit corporation also a 501(c)(3))?
[]Yes []No Other (please specify)
 
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      |x] No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
 
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Enterprise Ownership, Inc.   10227 Wincopin Circle      100% Common Stock
Columbia, MD 21044
 
 
 
 
 
 
SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [x] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Narrie (indicate whether     Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[x] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
2:   The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
 
3.   The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than S20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes [j§No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
None
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[]Yes []No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes []No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics', 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.L, F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Enterprise Community Asset Management, Inc.
(Print or type name of Disclosing Party)
 
(Print or type name of person signing)
 
(Print or type title of person signing)
 
' —**•* ft      ft,   , |t)|
i      VERONICA KWAFO
(      Notary Public
»
Baltimore County Maryland
>
My Commission Expires Feb 2 2014 <" *' m m u y m ii in , w <a>
 
 
Signed and sworn to before me on (date)    LP \ \Q \ \
 
 
Page 12 of 13
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section U.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
La. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
 
DIRECTORS
 
Name Title
 
Craig Mellendick Trustee Bruce Rothschild Trustee Elizabeth O'Leary Trustee
 
OFFICERS
 
Elizabeth O'Leary Bruce Rothschild
 
Craig Mellendick
President & CEO
Vice President, Secretary & General Counsel
Vice President & CFO
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Enterprise Ownership, Inc.
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [)] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*      
OR
3.      [] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
 
 
C   Telephone- 410-772-5232      Fax- 41°-772-2630      Email-brothschiW@enteprisecommunity.com
  1. Name of contact person: Bruce Rothschild      
  2. Federal Employer Identification No. (if you have one): ■                  
  3. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide
61 units of housing for formerly homeless tenants.      
  1. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
*The Disclosing Party is the sole owner of Enterprise Community Asset Management, Inc. which is the sole owner
of Enterprise Community Housing Organization, Inc. which is the 99.99% Limited Partner of Wincopin Circle, LLLP
which is anticipated to acquire a 99.99% limited partner interest in Lake Street Studios Limited Partnership upon
the closing of the Matter.
Ver. 01-01-12      Page 1 of 13
 
 
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
A. NATURE OF THE DISCLOSING PARTY 1.   Indicate the nature of the Disclosing Party:
Person      [ ] Limited liability company
Publicly registered business corporation       [ ] Limited liability partnership
Privately held business corporation      [ ] Joint venture
Sole proprietorship      [ ] Not-for-profit corporation
General partnership      (Is the not-for-profit corporation also a 501(c)(3))?
Limited partnership      [ ] Yes      [ ] No
Trust      [ ] Other (please specify)
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[ ] Yes      M No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
 
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Enterprise Community      10227 Wincopin Circle      100% Common Stock
Investment, Inc.      Columbia, MD 21044
 
 
 
 
 
 
SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [x] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[X] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
  1. The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
  6. The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
    1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
    2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
    3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  2. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official,
of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-45 5(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes [j§No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
None
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[]Yes []No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes []No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII-- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information" contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.J. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Enterprise Ownership, Inc.
(Print ortype name of Disclosing Party)
/   (Sign here) (Print or type name of person signing) (Print or type title of person signing)
 
Signed and sworn to before me on (date) LP l»q\i^ at HnVPOl\r<A   County, rOO£yl01Cui. (state).
 
 
Notary Public.
Commission expires:      o2i9 1 (^
Page 12 of 13
 
VERONICA KWAFO
Notary Public Baltimore County Maryland My Commission Expires Feb 2, 2014 " v '9 m u u is u K y w
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section H.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1 .a. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
 
DIRECTORS
 
Name Title
 
Craig Mellendick Trustee Bruce Rothschild Trustee
 
OFFICERS
 
Charles R. Werhane Bruce Rothschild Craig Mellendick
President & CEO
Senior Vice President & General Counsel Senior Vice President & CFO
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Enterprise Community Investment, Inc.
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
  1. [ ] the Applicant
OR
  1. [>] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the Applicant in which the Disclosing Party holds an interest: Lake Street Studios Limited Partnership*
OR
3.      [] a legal entity with a right of control (see Section II.B. 1.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
 
B. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
C   Telephone' 410-772-5232      fax- 410-772-2630      r£maj|.brothschild@enteprisecommunity.com
  1. Name of contact person: Bruce Rothschild      
  2. Federal Employer Identification No. (if you have one):            
  1. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide
61 units of housing for formerly homeless tenants.      
  1. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
 
Specification #      and Contract #      
*The Disclosing Party is the sole owner of Enterprise Ownership, Inc., which the sole owner of Enterprise
Community Asset Management, Inc. which is the sole owner of Enterprise Community Housing Organization, Inc.
which is the 99.99% Limited Partner of Wincopin Circle, LLLP which is anticipated to acquire a 99.99%
membership interest in Lake Street Studios Limited Partnership upon the closing of the Matter.
Ver. 01 -01 -12      Page l of 13
 
 
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
 
A. NATURE OF THE DISCLOSING PARTY
 
1.   Indicate the nature of the Disclosing Party:
Person      [ ]      Limited liability company
Publicly registered business corporation      [ ]      Limited liability partnership
Privately held business corporation      [ ]      Joint venture
Sole proprietorship      [ ]      Not-for-profit corporation
General partnership      (Is the not-for-profit corporation also a 501(c)(3))?
Limited partnership      [ ] Yes      [ ] No
Trust      [ ]      Other (please specify)
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[x] Yes      [ ] No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
 
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
Enterprise Community      10227 Wincopin Circle      100% Common Stock
Partners, Inc.      Columbia, MD 21044
 
 
 
 
 
 
SECTION III -- BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [x] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether    Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
Gallagher, Evelius & Jones LLP 218 North Charles St.  Attorney                     $40,000 (estimated)
      Baltimore, MD 21201      
 
 
 
 
(Add sheets if necessary)
[ ] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V -- CERTIFICATIONS
A. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a^court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
[]Yes []No
 
B-. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article 1 ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
  1. The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section II.B.l. of this EDS:
    1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
    2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
    3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
    4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
    5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
  2. The certifications in subparts 3, 4 and 5 concern:
  • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official,
of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
 
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
 
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[ ] Yes      [j§ No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[ ] Yes      [ ] No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
None
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and. information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes      [ ] No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII -- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
 
Enterprise Community Investment, Inc.
(Print or type name of Disclosing Party)
By: d'^^ f (Sign here)
 
 
(Print or type name of person signing)
 
 
(Print or type title of person signing)
 
Jotary Public.
Page 12 of 13
Signed and sworn to before me on (date)
at VtoUUfoTfi    County, MflLfylflhd (state).
^ikSLhQ^^ Nc
Commission expires: o)\ol\l^V
 
 
 
VERONICA KWAFO
Notary Public Baltimore County Maryland My Commission Expires Feb 2, 2014
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1 .a. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
 
DIRECTORS
 
Name Title
 
Bill Beckmann      Trustee
Barry Curtis      Trustee
W. Kimball Griffith      Trustee
Ronald Grzywinski      Trustee
Arlene Isaacs-Lowe      Trustee
David D. Leopold      Trustee
Judd S. Levy      Trustee
Terri L. Ludwig      Trustee
Sal K. Mirran      Trustee
Shekar Narasimhan      Trustee
Keith D. Nisbet      Trustee
Mary K. Reilly      Trustee
Lee Rosenberg      Trustee
Tony M. Salazar      .      Trustee
Elizabeth M. Stohr      Trustee
J. Ronald Terwilliger      Trustee
Charles R. Werhane      Trustee
 
OFFICER
 
Charles R. Werhane Bruce Rothschild Craig Mellendick
President & CEO
Senior Vice President & General Counsel Senior Vice President & CFO
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
 
SECTION I - GENERAL INFORMATION
  1. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: Enterprise Community Partners, Inc.
 
Check ONE of the following three boxes:
 
Indicate whether the Disclosing Party submitting this EDS is:
1.      [ ] the Applicant
OR
2.      a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest:  Lake Street Studios Limited Partnership*      
OR
3.      [] a legal entity with a right of control (see Section II.B.l.) State the legal name of the entity in
which the Disclosing Party holds a right of control:      
  1. Business address of the Disclosing Party:      10227 Wincopin Circle      
Columbia, MD 21044
C   Telephone" 410-772-5232      Fax' 41°-772-2630      kmaj]. brothschild@enteprisecommunity.com
  1. Name of contact person: Bruce Rothschild      
  2. Federal Employer Identification No. (if you have one): - --------       
  1. Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
Lake Street Studios is a new construction project located at 727 W. Lake Street, Chicago, IL that will provide
61 units of housing for formerly homeless tenants.      
  1. Which City agency or department is requesting this EDS? Housin9 and Economic Development
 
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
N/A N/A
Specification #      and Contract #      
*The Disclosing Party is the sole owner of Enterprise Community Investment, Inc. which is the sole owner of Enterprise Ownership, Inc., which the sole owner of Enterprise Community Asset Management, Inc. which is the sole owner of Enterprise Community Housing Organization, Inc. which is is the 99.99% Limited Partner of Wincopin Circle, LLLP which is anticipated to acquire a 99,99% membership interest in Lake Street Studios
.Ver.oi-oun^             „    ,  .     ... „PageloTl~
Limited Partnership upon the closing of the Matter.
 
 
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
 
A. NATURE OF THE DISCLOSING PARTY
 
1.   Indicate the nature of the Disclosing Party:
Person
Publicly registered business corporation
Privately held business corporation
Sole proprietorship
General partnership
Limited partnership
Trust
[ ] Limited liability company
[ ] Limited liability partnership
[ ] Joint venture
[x] Not-for-profit corporation
(Is the not-for-profit corporation also a 501(c)(3))?
[x] Yes      [ ] No
[ ] Other (please specify)
 
 
2.   For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Maryland
 
3.   For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
 
[x] Yes      [ ] No      [ ] N/A
 
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
 
1.   List below the full names and titles of all executive officers and all directors of the entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management of the Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.
 
Name Title
See Exhibit A
No Members
 
 
 
 
 
2.   Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,
 
Page 2 of 13
 
 
interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.
 
Name      Business Address      Percentage Interest in the
Disclosing Party
None
 
 
 
 
 
 
 
SECTION 111 - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS
 
Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
 
[ ] Yes      [x] No
 
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):
 
 
 
 
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
 
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.
 
"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.
 
If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
 
 
 
 
 
Page 3 of 13
 
 
Name (indicate whether     Business      Relationship to Disclosing Party   Fees (indicate whether
retained or anticipated       Address       (subcontractor, attorney,      paid or estimated.) NOTE:
to be retained)      lobbyist, etc.)      "hourly rate" or "t.b.d." is
not an acceptable response.
 
 
 
 
 
(Add sheets if necessary)
[x] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V -- CERTIFICATIONS
  1. COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
 
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
 
[ ] Yes      [ ] No      [x] No person directly or indirectly owns 10% or more of the
Disclosing Party.
 
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
 
□ Yes []No
  1. FURTHER CERTIFICATIONS
 
1.   Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither the Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.
 
 
Page 4 of 13
 
 
2.      , The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities
identified in Section II.B. 1. of this EDS:
  1. are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
  2. have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
  3. are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
  4. have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
  5. have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
 
3.      The certifications in subparts 3, 4 and 5 concern:
    • the Disclosing Party;
  • any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
  • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
  • any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
 
 
Page 5 of 13
 
 
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
  1. bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
  2. agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
  3. made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
  4. violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).
  1. Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
  2. Neither the Disclosing Party nor any Affiliated Entity is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security of the U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
  3. The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
  4. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:
None
 
 
 
 
 
 
 
Page 6 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official,
of the City of Chicago (if none, indicate with "N/A" or "none").
None
 
 
 
9.   To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a
complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the
12-month period preceding the execution date of this EDS, to an employee, or elected or appointed
official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything
made generally available to City employees or to the general public, or (ii) food or drink provided in the
course of official City business and having a retail value of less than $20 per recipient (if none, indicate
with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.
None
 
 
 
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
  1. The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is      [x] is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
  1. If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 of the Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
 
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in
Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter
2-32 of the Municipal Code, explain here (attach additional pages if necessary):
N/A
 
 
 
 
Page 7 of 13
 
 
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
 
D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS
 
Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
  1. In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes [>]No
 
NOTE:  If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
  1. Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes.or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
 
Does the Matter involve a City Property Sale?
 
[]Yes []No
  1. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:
 
Name      Business Address      Nature of Interest
 
 
 
 
 
 
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
 
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
 
Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13
 
 
comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
 
x   1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
 
      2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
 
 
 
 
 
 
SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
 
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
 
A. CERTIFICATION REGARDING LOBBYING
 
1.   List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):
N/A
 
 
 
 
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
 
2.   The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13
 
  1. The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A.l. and A.2. above.
  2. The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
  3. If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
 
 
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
 
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes      [x] No
If "Yes," answer the three questions below:
  1. Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Yes []No
  1. Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes      [ ] No
  1. Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Ycs []No
 
If you checked "No" to question 1. or 2. above, please provide an explanation:
 
 
 
 
Page 10 of 13
 
 
SECTION VII - ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE
 
The Disclosing Party understands and agrees that:
  1. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
  2. The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics, and may also be obtained from the City's Board of Ethics, 740 N.
 
Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
  1. If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
  2. It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
  3. The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to Article 1 of Chapter 1-23 of the Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154-020 of the Municipal Code.
 
The Disclosing Party represents and warrants that:
 
Page 11 of 13
 
F.l.    The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.
 
F.2     If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by the U. S. General Services Administration.
 
F.3     If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent of the City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.
 
NOTE: If the Disclosing Party cannot certify as to any of the items in F.l., F.2. or F.3. above, an explanatory statement must be attached to this EDS.
 
CERTIFICATION
 
(Print or type name of Disclosing Party) (Sign here)
^xiAV^e,^W>^cxS
(Print or type name of person signing) (Print or type title of person signing)
 
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
Enterprise Community Partners, Inc.
 
Signed and sworn to before me on (date) Lp\ \5A \ at ^QUOOXcS  County, jfoaryiafrd (state).
 
Notary Public.
Commission expires:
Page 12 of 13
 
VERONICA KWAFO
<      Notary Public
Baltimore County Maryland
      My Commission Expires Feb 2, 2014
# w i> t « » " » win » n m
 
 
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
 
 
 
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
 
 
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
 
Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
 
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section U.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Parry is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
 
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
 
[ ] Yes      [x] No
 
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
 
 
 
 
 
 
 
 
 
 
 
Page 13 of 13
 
 
EXHIBIT A
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1 .a. List below the full names and titles of all executive officers and all directors of the entity. For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities,
list below the legal titleholder(s).
DIRECTORS Name
Priscilla Almodovar      Trustee
Gregory A. Baer      Trustee
Maria F. Barry      Trustee
Bill Beckmann      Trustee
Raphael Bostic      Trustee
Jospeh E. Brown      Trustee
Raymond R. Christman      Trustee
Richard A.C. Coles      Trustee
Sheila Crowley      Trustee
Adam R. Flatto      Trustee
Lance Fors      Trustee
Dora Leong Gallo      Trustee
Alicia Glen      Trustee
Ronald Grzywinski      Trustee
Enrico (Rick) Lazio      Trustee
Terri L. Ludwig      Trustee
Edward Norton      Trustee
 
 
John M. Reilly      Trustee
Nicholas P. Retsinas      Trustee
Jonathan F. P. Rose      Trustee
Tony M. Salazar      Trustee
Renata Simril      Trustee
Michael Slocum      Trustee
J. Ronald Terwilliger      Trustee
Charles R. Werhane      Trustee
 
OFFICERS
 
Terri Ludwig Faith Thomas
 
 
Michael McNeely
 
 
President and CEO
Senior Vice President and
General Counsel
Senior Vice President and CFO