Share to Facebook Share to Twitter Bookmark and Share
This record contains private information, which has been redacted from public viewing.
Record #: SO2016-4593   
Type: Ordinance Status: Passed
Intro date: 5/18/2016 Current Controlling Legislative Body: Committee on Finance
Final action: 6/22/2016
Title: Redevelopment agreement with Chicago Neighborhood Initiatives, Inc. and issuance of City Note for extension of individual roadway in vicinity of E 107th St and S Doty Ave for Whole Foods distribution facility
Sponsors: Emanuel, Rahm
Topic: AGREEMENTS - Redevelopment
Attachments: 1. SO2016-4593.pdf, 2. O2016-4593.pdf
SUBSTITUTE

AN ORDINANCE OF THE CITY OF CHICAGO, ILLINOIS DESIGNATING CHICAGO NEIGHBORHOOD INITIATIVES, INC., AS DEVELOPER
AND AUTHORIZING A REDEVELOPMENT AGREEMENT AND
ISSUANCE OF CITY NOTE ORDINANCE
WHEREAS, pursuant to an ordinance adopted by the City Council ("City Council") of the City of Chicago (the "City") on June 20, 2009, a certain redevelopment plan and project (the "Redevelopment Plan") for the North Pullman TIF Redevelopment Project Area (the "Redevelopment Area") was approved pursuant to the Illinois Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4-1 et seg., as amended (the "Act"); and

WHEREAS, pursuant to an ordinance adopted by the City Council on June 30, 2009, the Redevelopment Area was designated as a redevelopment project area pursuant to the Act; and
WHEREAS, pursuant to an ordinance (the "TIF Ordinance") adopted by the City Council on June 30, 2009 tax increment allocation financing was adopted pursuant to the Act as a means of financing certain redevelopment project costs (as defined in the Act) incurred pursuant to the Redevelopment Plan; and

WHEREAS, Chicago Neighborhood Initiatives, Inc., an Illinois not-for-profit corporation (the "Developer"), plans to either obtain a right-of-entry to or acquire certain property within the Redevelopment Area in the vicinity of 107th Street and Doty Avenue (the "Property"). The Developer plans to commence and complete demolition, site grading, utility installation and extension of the industrial roadway (the "Project") in order to prepare the Property to sell to Ryan Companies US, Inc., a Minnesota corporation, for future construction of an approximately 140,000 square foot facility to be leased by Whole Foods Market, Inc., a Texas corporation, for use as a warehouse and distribution facility; and

WHEREAS, the Developer has proposed to undertake the Project in accordance with the Redevelopment Plan and pursuant to the terms and conditions of a proposed redevelopment agreement to be executed by the Developer and the City, to be financed in part by the issuance of a Note (as defined below); and

WHEREAS, pursuant to Resolution 16-CDC-12 adopted by the Community Development Commission of the City of Chicago (the "Commission") on April 12, 2016, the Commission recommended that the Developer be designated as the developer for the Project, and authorized the City's Department of Planning and Development ("DPD") to negotiate, execute and deliver a redevelopment agreement with the Developer for the Project, to be financed in part by ad valorem taxes which, pursuant to the TIF Ordinance and Section 5/11-74.4-8(b) of the Act, are allocated to and when collected are paid to the Treasurer of the City of Chicago for deposit by the Treasurer into the North Pullman Redevelopment Project Area Special Tax Allocation Fund established to pay redevelopment project costs (as such term is|1010|
defined in the Act) and obligations incurred in the payment thereof (such ad valorem taxes so allocated, collected, paid and deposited pursuant to the Act are known generally as "Increment," Increment from the North Pullman Redevelopment Area shall be known herein as "North Pullman Increment," and the not to exceed $8,400,000 in principal amount of cash contribution and tax-exempt note secured by Increment for the Project shall be known herein and in the proposed redevelopment agreement as the "City Funds"); and

WHEREAS, pursuant to Section 5/11-74.4-4(q) of the Act, the City can use Increment from one redevelopment project area for eligible redevelopment project costs in another redevelopment project area that is either contiguous to, or is separated only by a public right of way from, the redevelopment project area from which the Increment is received so long as the applicable redevelopment plans permit such use (the "Transfer Rights"); and

WHEREAS, to induce certain redevelopment pursuant to the Act, in accordance with the provisions ofthe Act, pursuant to ordinances adopted on January 16, 2002, the City Council: (1) approved and adopted a redevelopment plan (the "Roseland/Michigan Redevelopment Plan") for the Roseland/Michigan Avenue Redevelopment Project Area (the "Roseland/Michigan Redevelopment Area") of the City; (2) designated the Roseland/Michigan Redevelopment Area as a "redevelopment project area" pursuant to the Act; and (3) adopted tax increment allocation financing for the Roseland/Michigan Redevelopment Area; and

WHEREAS, the North Pullman Redevelopment Area is either contiguous to, or is separated only by a public right of way from, the Roseland/Michigan Redevelopment Area; and

WHEREAS, the Roseland/Michigan Redevelopment Plan permits the exercise of Transfer Rights with respect to Increment from the Roseland/Michigan Redevelopment Area ("Roseland/Michigan Increment") and the North Pullman Redevelopment Plan permits the receipt of Increment pursuant to Transfer Rights; and

WHEREAS, it is anticipated that the City may, in its discretion, exercise its Transfer Rights pursuant to the Act and the Roseland/Michigan and North Pullman Redevelopment Plans to use Roseland/Michigan Increment in an amount up to $500,000 as part of (and not in addition to) the City Funds; and
WHEREAS, in consideration of redevelopment project costs for the Project incurred or to be incurred by or on behalf of the Developer, the City agrees to issue, and the Developer agrees to acquire, according to certain terms and conditions, the City Note (as defined below) as a tax increment revenue obligation; and

BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO:

SECTION 1. The above recitals are incorporated herein and made a part hereof.

SECTION 2. Developer is hereby designated as the developer for the Project pursuant to Section 5/11-74.4-4 of the Act.

SECTION 3. The Commissioner of DPD (the "Commissioner") or a designee of the Commissioner are each hereby authorized, with the approval of the City's Corporation Counsel as to form and legality, to negotiate, execute and deliver a redevelopment agreement between Developer and the City in substantially the form attached hereto as Exhibit A and made a part hereof (the "Redevelopment Agreement"), and such other supporting documents as may be|1010|
necessary or appropriate to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement and supporting documents. The City shall exercise its Transfer Rights pursuant to the Act and applicable redevelopment plans to use Increment as part of (and not in addition to) the City Funds and to pay debt service on the City Note.
SECTION 4. The City Council hereby finds that the City is authorized to issue its tax increment allocation revenue obligations in an aggregate amount not to exceed $8,400,000 for the purpose of paying a portion ofthe eligible costs included within the Project.

SECTION 5. There shall be borrowed for and on behalf of the City an aggregate amount not to exceed $7,400,000 for the payment of a portion of the eligible costs included within the Project and the notes of the City shall be issued up to said amount and shall be designated as Tax Increment Allocation Revenue Note (Chicago Neighborhood Initiatives, Inc. (Whole Foods Warehouse and Distribution Facility) Redevelopment Project), Tax Exempt Series A, Registered No. R-1 for a principal amount not to exceed $7,400,000 (the "City Note"), and

The City Note shall be dated the date of delivery thereof, and shall also bear the date of authentication, shall be in fully registered form, shall be in the denomination of the outstanding principal amount thereof and shall become due and payable as provided therein. The proceeds of the City Note are hereby appropriated for the purposes set forth in this Ordinance.

The City Note shall bear interest at the rate as calculated in the Redevelopment Agreement but not to exceed 6.125% per annum computed on the basis of a 360 day year of twelve 30-day months, with the exact rate to be determined by an Authorized Officer (as hereinafter defined). Interest on the City Note shall not be subject to federal income taxes.

The City Note shall mature as set forth in the Redevelopment Agreement.

The City Note shall be subject to such further terms as are set forth in the Redevelopment Agreement and this Ordinance, subject to such changes and additions as are set forth in Bond Orders of the City executed by the Comptroller and filed with the City Clerk at the time of issuance of the City Note. The provisions of the respective Bond Orders shall be subject to the parameters set forth in the Redevelopment Agreement and this Ordinance.

The principal of and interest on the City Note shall be paid by check or draft of the Comptroller of the City, as registrar and paying agent (the "Registrar") (or, at the City's sole election, by wire transfer of funds), payable in lawful money of the United States of America to the person in whose name the City Note is registered at the close of business on the 15th day of the month immediately prior to the applicable payment date; provided, that the final installment of the principal and accrued but unpaid interest of the City Note shall be payable in lawful money of the United States of America at the principal office of the Registrar or as otherwise directed by the City.

The seal of the City shall be affixed to or a facsimile thereof printed on the City Note, and the City Note shall be signed by the manual or facsimile signature of the Mayor of the City and attested by the manual or facsimile signature of the City Clerk of the City, and in case any officer whose signature shall appear on the City Note shall cease to be such officer before the delivery of the . City Note, such signature shall nevertheless be valid and sufficient for all purposes, the same as if such officer had remained in office until delivery.

|1010|
The City Note shall have thereon a certificate of authentication substantially in the form hereinafter set forth duly executed by the Registrar, as authenticating agent of the City for such Note, and showing the date of authentication. The City Note shall not be valid or obligatory for any purpose or be entitled to any security or benefit under this Ordinance unless and until such certificate of authentication shall have been duly executed by the Registrar by manual signature, and such certificate of authentication upon the City Note shall be conclusive evidence that the Note has been authenticated and delivered under this Ordinance.

SECTION 6. The City shall cause books (the "Register") for the registration of the City Note as provided in this Ordinance to be kept at the principal office of the Registrar, which is hereby constituted and appointed the registrar of the City for the City Note. The Registrar shall maintain a list of the names and addresses of the registered owner(s) from time to time of the City Note, and upon transfer (to the extent such transfer is permitted under the Redevelopment Agreement) shall add the name and address of the new registered owner and eliminate the name and address of the transferor. The City is authorized to prepare, and the Registrar shall keep custody of, multiple City Note blanks executed by the City for use in the transfer of the City Note.

Upon surrender for transfer of the City Note authorized under this Ordinance at the principal office of the Registrar, duly endorsed by, or accompanied by: (i) a written instrument or instruments of transfer in form satisfactory to the Registrar; (ii) an investment representation in form satisfactory to the City and duly executed by the registered owner or his attorney duly authorized in writing, (iii) the written consent of the City evidenced by the signature of the Commissioner (or his or her designee) on the instrument of transfer, and (iv) any deliveries required under this Ordinance or the Redevelopment Agreement, the City shall execute and the Registrar shall authenticate, date and deliver in the name of any such authorized transferee or transferees, a new fully registered City Note of the same maturity, of authorized denomination, for a like aggregate principal amount. The execution by the City of a fully registered City Note shall constitute full and due authorization of the City Note and the Registrar shall thereby be authorized to authenticate, date and deliver the City Note, provided, however, that the principal amount of the City Note authenticated by the Registrar shall not exceed the authorized principal amount of the City Note less previous retirements. The Registrar shall not be required to transfer or exchange the City Note during the period beginning at the close of business on the fifteenth day of the month immediately prior to the maturity date of the City Note nor to transfer or exchange the City Note after notice calling the City Note for redemption has been made, nor during a period of five (5) days next preceding mailing of a notice for redemption of principal of the City Note. No beneficial interests in the City Note shall be assigned, except in accordance with the procedures for transferring the City Note described above.

The person or entity in whose name the City Note shall be registered shall be deemed and regarded as the absolute owner thereof for all purposes, and payment ofthe principal ofthe City Note shall be made only to the order of the registered owner thereof or his legal representative. All such payments shall be valid and effectual to satisfy and discharge the liability upon the City Note to the extent of the sum or sums so paid.

No service charge shall be made for any transfer of the City Note, but the City or the Registrar may require payment of a sum sufficient to cover any tax or other governmental charge that may be imposed in connection with any transfer of the Notes.

SECTION 7. Subject to the limitations set forth herein, the principal of the City Note shall be subject to determination, redemption and prepayment as provided in the form of the City|1010|
Note attached to the Redevelopment Agreement as Exhibit M, and as provided in the Redevelopment Agreement. As directed by the Commissioner, the Registrar shall proceed with redemptions or prepayment without further notice or direction from the City.
SECTION 8. The City Note shall be prepared in substantially the form attached hereto as Exhibit B, with such additions or modifications at the time of issuance as shall be determined to be necessary by the person duly approved and serving as the Chief Financial Officer of the City, or if no such person has been appointed, the City Comptroller (the "Authorized Officer").

SECTION 9. Pursuant to the Redevelopment Agreement, Developer has agreed to perform redevelopment work on the Property necessary for the Project. The eligible Redevelopment Project costs of such acquisition, construction and redevelopment up to the amount not to exceed $7,400,000, shall be financed from proceeds of the City Note. The principal amount outstanding of the City Note shall be the amount of principal indicated in the City Note on its date of issuance, or the sum of advances made pursuant to a form of certificate of expenditure (the "Certificate of Expenditure") executed by the Commissioner (or his or her designee) and authenticated by the Registrar, in accordance with the Redevelopment Agreement, minus any principal amount paid on the City Note and other reductions in principal as provided in the Redevelopment Agreement. A Certificate of Expenditure shall not be valid or obligatory under this Ordinance unless or until authenticated by the Registrar by manual signature. The City shall not execute Certificates of Expenditure that total in excess of $7,400,000. Upon execution of a Certificate of Expenditure, the Registrar shall promptly send the Certificate of Expenditure to the Registered Owner and retain a copy with the Register. The Certificate of Expenditure for the City Note shall be in substantially the form attached hereto as Exhibit C.

SECTION 10. The Registrar shall note on the payment schedule attached to the City Note the amount of any payment of principal or interest on the City Note, including the amount of any redemption, and the amount of any reduction in principal pursuant to the Redevelopment Agreement.
SECTION 11. The City Note hereby authorized shall be executed as provided in this Ordinance and the Redevelopment Agreement and thereupon be deposited with the Commissioner, and by said Commissioner delivered to Developer.

SECTION 12. (a) Special Tax Allocation Fund. Pursuant to the TIF Ordinance, the City has created a special fund, designated as the North Pullman Redevelopment Project Area Special Tax Allocation Fund (the "North Pullman TIF Fund").

The Comptroller of the City is hereby directed to maintain the North Pullman TIF Fund as a segregated interest-bearing account, separate and apart from the General Fund or any other fund of the City, with a bank which is insured by the Federal Deposit Insurance Corporation or its successor. Pursuant to the TIF Ordinance, all incremental ad valorem taxes received by the City for the Redevelopment Area are to be deposited into the North Pullman TIF Fund.

(b) Debt Service Account. There is hereby created within the North Pullman TIF Fund a special account to be known as the "Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account " The City shall promptly designate and deposit into the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account the incremental taxes defined as the "Available
|1010|
Incremental Taxes" in the Redevelopment Agreement which have been deposited into the North Pullman TIF Fund after the execution and delivery of the Redevelopment Agreement.

(c) Pledge of Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account. The City hereby assigns, pledges and dedicates the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account, together with all amounts on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account: (i) to the payment of the City Note, subject to the provisions and limitations of the Redevelopment Agreement. Upon deposit, the moneys on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account may be invested as hereinafter provided. Interest and income on any such investment shall be deposited in the North Pullman TIF Fund. All moneys on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account shall be used to pay the principal of and interest on the City Note, at maturity or upon payment or redemption prior to maturity, each in accordance with its respective terms, which payments from the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account are hereby authorized and appropriated by the City. Upon payment of all amounts due under the City Note in accordance with their respective terms (or the termination of the City's obligation to make such payments), the amounts on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account shall be deposited in the North Pullman TIF Fund of the City and the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account shall be closed.

SECTION 13. The City Note is a special limited obligation of the City, and is payable solely from amounts on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account (or such other funds in the North Pullman TIF Fund as the City, in its sole discretion, may determine), and shall be a valid claim of the registered owner thereof only against said sources. The City Note shall not be deemed to constitute an indebtedness or a loan against the general taxing powers or credit of the City, within the meaning of any constitutional or statutory provision. The registered owners of the City Note shall not have the right to compel any exercise of the taxing power of the City, the State of Illinois or any political subdivision thereof to pay the principal of or interest on the City Note.

SECTION 14. Moneys on deposit in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account may be invested as allowed under Section 2-32-520 of the Municipal Code of the City of Chicago (the "Municipal Code"). Each such investment shall mature on a date prior to the date on which said amounts are needed to pay the principal of or interest on the City Note.

SECTION 15. The City Note is not a "private activity bond" as defined in Section 141(a) of the Internal Revenue Code of 1986, as amended (the "Code"). In support of such conclusion, the City certifies, represents and covenants as follows."
No direct or indirect payments are to be made on the City Note with respect to any private business use by any person other than a state or local governmental unit.
None of the proceeds of the City Note is to be used, directly or indirectly, to make or finance loans to persons other than a state or local governmental unit.
|1010|
SECTION 16. The City certifies and covenants as follows with respect to the requirements of Section 148(f) of the Code, relating to the rebate of "excess arbitrage profits" (the "Rebate Requirement") to the United States:
Unless an applicable exception to the Rebate Requirement is available to the City, the City will meet the Rebate Requirement.
Relating to applicable exceptions, the Comptroller is hereby authorized to make such elections under the Code as such officer shall deem reasonable and in the best interests of the City. If such election may result in a "penalty in lieu of rebate" as provided in the Code, and such penalty is incurred (the "Penalty"), then the City shall pay such Penalty.
The officers of the City shall cause to be established at such time and in such manner as they may deem necessary or appropriate hereunder, a rebate fund, and such officers shall further, not less frequently than annually, cause to be transferred to the rebate fund the amount determined to be the accrued liability under the Rebate Requirement or the Penalty. Said officers shall cause to be paid to the United States, from time to time as required, amounts sufficient to meet the Rebate Requirement or to pay the Penalty.
Interest earnings in the Chicago Neighborhood Initiatives (Whole Foods Warehouse and Distribution Facility) Debt Service Account are hereby authorized to be transferred, without further order or direction from the Comptroller, from time to time as required, to the rebate fund for the purposes herein provided; and other funds of the City are also hereby authorized to be used to meet the Rebate Requirement or to pay the Penalty, but only if necessary after application of investment earnings as aforesaid and only if appropriated by the City Council.
SECTION 17. The City covenants that it: (i) will take those actions which are necessary to be taken (and avoid those actions which it is necessary to avoid taking) so that interest on the City Note will not be or become included in gross income for federal income tax purposes under existing law including, without limitation, the Code; (ii) will take those actions reasonably within its power to take which are necessary to be taken (and avoid taking those actions which are reasonably within its power to avoid taking and which it is necessary to avoid) so that interest on the City Note will not be or become included in gross income for federal income tax purposes under the federal income tax laws as in effect from time to time; and (iii) will take no action in the investment of any fund or account of the City which would result in making interest on the City Note subject to federal income taxes by reason of causing the City Note to be an "arbitrage bond" within the meaning of Section 148 of the Code. In furtherance of the foregoing provisions, but without limiting their generality, the City agrees: (a) through its officers, to make such further specific covenants, certifications and representations as shall be truthful, and assurances as may be necessary or advisable; (b) to comply with all representations, covenants and assurances contained in certificates or agreements as may be prepared by counsel approving the City Note; (c) to consult with such counsel and to comply with such advice as may be given; (d) to file such forms, statements and supporting documents as may be required and in a timely manner; and (e) if deemed necessary or advisable by its officers, to employ and pay fiscal agents, financial advisors, attorneys and other persons to assist the City in such compliance.
SECTION 18. The City recognizes that Section 149(a) of the Code requires that the City Note to be issued and to remain in fully registered form in order that interest thereon is exempt from federal income taxation under laws in force at the time the City Note is delivered. In this|1010|
connection, the City agrees that it will not take any action to permit the City Note to be issued in, or converted into, bearer or coupon form.

SECTION 19. The provisions of this Ordinance shall constitute a contract between the City and the registered owner(s) of the City Note. All covenants relating to the City Note are enforceable by the registered owner(s) of the City Note.
SECTION 20. The Mayor, the Comptroller, the City Clerk, the Commissioner (or his or her designee) and the other officers of the City are authorized to execute and deliver on behalf of the City such other documents, agreements and certificates and to do such other things consistent with the terms of this Ordinance as such officers and employees shall deem necessary or appropriate in order to effectuate the intent and purposes of this Ordinance.

SECTION 21. If any provision of this Ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such provision shall not affect any of the other provisions of this Ordinance.

SECTION 22. All ordinances, resolutions, motions or orders in conflict with this Ordinance are hereby repealed to the extent of such conflict. No provision of the Municipal Code or violation of any provision of the Municipal Code shall be deemed to impair the validity of this ordinance or the instruments authorized by this ordinance or to impair the security for or payment of the instruments authorized by this ordinance; provided further, however, that the foregoing shall not be deemed to affect the availability of any other remedy or penalty for violation of any provision of the Municipal Code.

SECTION 23. This Ordinance shall be in full force and effect immediately upon its passage.
























|1010|
Attachments:
Exhibit A: Chicago Neighborhood Initiatives, Inc. Redevelopment Agreement (Whole Foods Warehouse and Distribution Facility)

Exhibit B: Form of Series A, Note R-1 (the "City Note")

Exhibit C: Certificate of Expenditure form for the City Note










































|10 10|
Exhibit A to the Ordinance

Chicago Neighborhood Initiatives, Inc. Redevelopment Agreement (Whole Foods Warehouse and Distribution Facility)


(See attached)













































10

This agreement was prepared by and after recording return tcr Keith A. May
City of Chicago Law Department 121 North LaSalle Street, Room 600 Chicago, IL 60602







This space reserved for Recorder's use only



NORTH PULLMAN REDEVELOPMENT PROJECT AREA
CHICAGO NEIGHBORHOOD INITIATIVES, INC. REDEVELOPMENT AGREEMENT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

This Chicago Neighborhood Initiatives, Inc. Redevelopment Agreement (the
"Agreement") is made as of this day of , 2016, between the City of Chicago,
an Illinois municipal corporation (the "City"), through its Department of Planning and Development ("DPD"), and Chicago Neighborhood Initiatives, Inc., an Illinois not-for-profit corporation (the "Developer"). Ryan Companies US, Inc., a Minnesota corporation ("Vertical Developer"), is signing a limited joinder hereto with respect to Section 18.27 hereof. The City, the Developer, and the Vertical Developer (but only with respect to Section 18.27 hereof) shall be known herein as the "Parties." i
RECITALS:
Constitutional Authority: As a home rule unit of government under Section 6(a), Article VII of the 1970 Constitution of the State of Illinois (the "State"), the City has the power to regulate for the protection of the public health, safety, morals, and welfare of its inhabitants and, pursuant thereto, has the power to encourage private development in order to enhance the local tax base and create employment opportunities, and to enter into contractual agreements with private parties in order to achieve these goals.
Statutory Authority: The City is authorized under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4-1 et seq., as amended from time-to-time (the "Act"), to finance projects that eradicate blighted conditions through the use of tax increment allocation financing for redevelopment projects.
City Council Authority: To induce certain redevelopment pursuant to the Act, in accordance with the provisions of the Act, pursuant to ordinances adopted on June 30, 2009, and published at pages 65068 through 65179 of the Journal of Proceedings of the City Council (the "Journal") for such date (the "North Pullman TIF Ordinances"), the City Council of the City (the "City Council"): (1) approved and adopted a redevelopment plan (the "North Pullman Redevelopment Plan") for the North Pullman Redevelopment Project Area (the "North Pullman|1010|
Redevelopment Area") of the City; (2) designated the North Pullman Redevelopment Area as a "redevelopment project area" pursuant to the Act; and (3) adopted tax increment allocation financing for the North Pullman Redevelopment Area (the "North Pullman TIF Adoption Ordinance"). The North Pullman Area is legally described in Exhibit A. The Roseland/Michigan Redevelopment Project Area (the "Roseland/Michigan Redevelopment Area") of the City is directly adjacent to the North Pullman Redevelopment Area.
The Project: The Developer will obtain a right of entry to or acquire from North Pullman 111th, Inc., a wholly-owned subsidiary of U.S. Bank, certain property located within the North Pullman Redevelopment Area in the vicinity of 107th Street and Doty Avenue, as legally described on Exhibit B (the "Property"), together with certain adjacent property on which the Developer will extend an industrial roadway, as legally described on Exhibit B-1 (the "Roadway Extension Parcel"). Within the time frames set forth in Section 3.01, the Developer shall: (i) commence and complete demolition, site grading, utility installation and extension of the industrial roadway on the Roadway Extension Parcel, and (ii) purchase the Property and the Roadway Extension Parcel from North Pullman 111th, Inc. (the "Acquisition") and (iii) convey title to the Property to Ryan Companies US, Inc. (the "Vertical Developer") for construction of an approximately 140,000 square foot LEED Certified facility to be leased by Whole Foods Market, Inc., a Texas corporation ("Whole Foods"), for use as a warehouse and distribution facility, together with an easement in the Roadway Extension Parcel for the benefit of the Vertical Developer and its tenants of the Property (the Acquisition, site preparation and work, including construction of the roadway extension, and conveyance of the Property shall be known herein as the "Project"). However, no costs associated with the construction of the roadway that are not directly related to environmental remediation thereof shall be reimbursed by the City unless permitted by the Act. The Parties acknowledge that the Project expressly excludes construction of such warehouse and distribution facility itself, which work is to be performed by the Vertical Developer as set forth in Section 18.27. After conveyance of the Property to the Vertical Developer, the Vertical Developer will be the owner of the Property and all improvements constructed thereon. The City approached Whole Foods seeking agreement by Whole Foods to locate a warehouse and distribution center at the Property. It is anticipated that Whole Foods will maintain at least 80 full-time equivalent employees at the Property upon issuance of the Certificate of Completion (as defined herein). The Project PINs consist of unsubdivided land, and include land that is not part of the Property. The Developer will apply for a subdivision to create the Property as a separate legal lot of record and tax parcel. The completion of the Project and the leasing of the Property to Whole Foods would not reasonably be anticipated without the financing contemplated in this Agreement.
Redevelopment Plan: The Project will be carried out in accordance with the North Pullman Redevelopment Plan and Planned Development No. 1167, as amended (the "PD").
City Financing and Assistance: Subject to Developer fulfilling those obligations under this Agreement that are the applicable conditions precedent to obligate the City to do so, the City will grant the Developer Incremental Taxes as defined in Schedule A in an amount of $1,000,000 and issue the City Note in a principal amount not to exceed $7,400,000 (collectively, the "City Funds"). The Developer, and not the Vertical Developer or Whole Foods, will be the sole recipient of the City Funds.
NOW, THEREFORE, in consideration of the premises and of the mutual covenants and agreements contained in this Agreement, and for other good and valuable consideration, the
|1010|
receipt and sufficiency of which are hereby acknowledged, the parties hereto hereby agree as follows:
AGREEMENT:

ARTICLE ONE: INCORPORATION OF RECITALS

The recitals stated above are an integral part of this Agreement and are hereby incorporated into this Agreement by reference and made a part of this Agreement.
ARTICLE TWO: DEFINITIONS
The definitions stated in Schedule A and those definitions stated in the recitals and preamble are hereby incorporated into this Agreement by reference and made a part of this Agreement.
ARTICLE THREE: THE PROJECT
The Project. Developer will commence and complete construction of the Project no later than December 30, 2016, subject to: (a) Section 18.17 (Force Majeure); (b) applicable Change Orders, if any, issued under Section 3.04; (c) the receipt of all applicable permits and Project approvals; and (d) issuance of a "No Further Remediation" letter, which shall not be required to be completed by December 30, 2016, but which shall be diligently pursued to completion.
Scope Drawings and Plans and Specifications. Developer has delivered the Scope Drawings and Plans and Specifications to DPD, and DPD has approved them. Subsequent proposed changes to the Scope Drawings or Plans and Specifications within the scope of Section 3.04 will be submitted to DPD as a Change Order under Section 3.04. The Scope Drawings and Plans and Specifications will at all times conform to the Redevelopment Plan as in effect on the date of this Agreement, and to all applicable Federal, State and local laws, ordinances and regulations. Developer will submit all necessary documents to the City's Department of Buildings, Department of Transportation, and to such other City departments or governmental authorities as may be necessary to acquire building permits and other required approvals for the Project.
Project Budget. Developer has furnished to DPD, and DPD has approved, a Project Budget which is Exhibit D-1, showing total costs for the Project in an amount not less than $8,142,176. The Note Issuance Costs are estimated to be a total of $1,003,101. The Project Costs and the Note Issuance Costs, together, are estimated to exceed $8,400,000. The Developer hereby certifies to the City that: (a) it has Lender Financing and/or Equity, along with the City Funds, in an aggregate amount sufficient to pay for all Project costs and Note Issuance Costs; and (b) the Project Budget is true, correct and complete in all material respects. Developer will promptly deliver to DPD copies of any Change Orders with respect to the Project Budget as provided in Section 3.04.
Change Orders.
(a) Except as provided in subparagraph (b) below, all Change Orders (and documentation substantiating the need and identifying the source of funding therefor) relating to changes to the Project must be submitted by Developer to DPD concurrently with the progress|1010|
reports described in Section 3.07; provided, however, that any Change Orders relating to any of the following must be submitted by Developer to DPD for DPD's prior written approval: (i) a reduction by more than five percent (5%) in the square footage of the Project from the square footage approved by DPD under Section 3.02, or (ii) a change in the primary use of the Project, or (iii) a delay in the Project completion date by more than 30 days, or (iv) change orders resulting in an aggregate increase to the Project Budget of 10% or more. Developer will not authorize or permit the performance of any work relating to any Change Order requiring DPD's prior written approval or the furnishing of materials in connection therewith prior to the receipt by Developer of DPD's written approval. The Construction Contract, and each contract between the General Contractor and any subcontractor, will contain a provision to this effect or for compliance with this Agreement generally. An approved Change Order will not be deemed to imply any obligation on the part of the City to increase the amount of City Funds or to provide any other additional assistance to Developer.
(b) Notwithstanding anything to the contrary in this Section 3.04, Change Orders other than those stated in subsection (a) above do not require DPD's prior written approval as stated in this Section 3.04, but DPD must be notified in writing of all such Change Orders within 10 Business Days after the execution of such change order, and Developer, in connection with such notice, must identify to DPD the source of funding therefor in the progress reports described in Section 3.07.
DPD Approval. Any approval granted by DPD under this Agreement of the Scope Drawings, Plans and Specifications and the Change Orders is for the purposes of this Agreement only, and any such approval does not affect or constitute any approval required by any other City department or under any City ordinance, code, regulation, or any other governmental approval, nor does any such approval by DPD under this Agreement constitute approval of the utility, quality, structural soundness, safety, habitability, merchantability or investment quality of the Project. Developer will not make any verbal or written representation to anyone to the contrary. Developer shall not undertake construction of the Project unless Developer has obtained all necessary permits and approvals (including but not limited to DPD's approval of the Scope Drawings and Plans and Specifications) and proof of the General Contractor's and each subcontractor's bonding as required under this Agreement.
Other Approvals. Any DPD approval under this Agreement will have no effect upon, nor will it operate as a waiver of, Developer's obligations to comply with the provisions of Section 5.03 (Other Governmental Approvals).
Progress Reports and Survey Updates. After the Closing Date, on or before the 15th day of each reporting month, Developer will provide DPD with written quarterly construction progress reports detailing the status of the Project, including a revised completion date, if necessary (with any delay in completion date of more than 30 days being considered a Change Order, requiring DPD's written approval under Section 3.04). Developer must also deliver to the City written monthly progress reports detailing compliance with the requirements of Section 8.08 (Prevailing Wage), Section 10.02 (City Resident Construction Worker Employment Requirement) and Section 10.03 (Developer's MBEAA/BE Commitment) (collectively, the "City Requirements"). If the reports reflect a shortfall in compliance with the requirements of Sections 8.08, 10.02 and 10.03, then there must also be included a written plan from Developer acceptable to DPD to address and cure such shortfall.
Inspecting Agent or Architect. An independent agent or architect, if-any (other than Developer's architect), will also act as the inspecting agent or architect for DPD for the|1010|
Project, and any fees and expenses connected with its work or incurred by such independent agent or architect will be solely for Developer's account and will be promptly paid by Developer. The inspecting agent or architect shall perform periodic inspections with respect to the Project, providing certifications with respect thereto to DPD, prior to requests for disbursement for costs related to the Project.
Barricades. Prior to commencing any construction requiring barricades, Developer will install a construction barricade of a type and appearance satisfactory to the City and constructed in compliance with all applicable Federal, State or City laws, ordinances, rules and regulations. DPD retains the right to approve the maintenance, appearance, color scheme, painting, nature, type, content, and design of all barricades (other than the name and logo of Developer or the Project).
Signs and Public Relations. If requested by DPD, Developer will erect in a conspicuous location on the Property during the Project a. sign of size and style approved by the City, indicating that financing has been provided by the City. The City reserves the right to include the name, photograph, artistic rendering of the Project and any other pertinent information regarding Developer and the Project in the City's promotional literature and communications.
3.11 Reserved.
3.12 Reserved.
3.13 Accessibility for Disabled Persons. Developer acknowledges that it is in the public interest to design, construct and maintain the Project in a manner which promotes, enables, and maximizes universal access throughout the Project. Plans for all buildings on the Property and improvements on the Property will be reviewed and approved by the Mayor's Office for People with Disabilities ("MOPD") to ensure compliance with all applicable laws and regulations related to access for persons with disabilities and to promote the highest standard of accessibility.

ARTICLE FOUR: FINANCING
4.01 (a) Total Project Cost and Sources of Funds. The total cost of the Project is estimated to be approximately $8,142,176 to be applied in the manner set forth in the Project Budget.
Lender Financing/City Note Net Proceeds
(to be deposited into Construction Escrow) $ 6,396,899.00*

Equity (Property sale proceeds;
subject to Section 4.06) $ 745,277.00

City Funds - Construction Phase Assistance
(to be deposited into Construction Escrow) $ 1,000,000.00
ESTIMATED TOTAL $ 8,142,176.00


|1010|
*Note: Developer reserves the right to use Lender Financing to initially pay for all or any portion of the Project costs, and Developer shall not be required to deposit Lender Financing proceeds into the Construction Escrow.

(b) Note Issuance Costs; Debt Service Reserve Fund; and Source of Funds. The total Note Issuance Costs and Debt Service Reserve Fund are estimated to be $1,003,101. Such costs shall be funded from the proceeds of the sale of the City Note in accordance with Section 4.04.
Developer Funds. Equity, Lender Financing and City Funds shall be used to pay all Project costs, including but not limited to Redevelopment Project Costs and costs of TIF-Funded Improvements.
City Funds.

Uses of City Funds. City Funds may only be used to reimburse the Developer for costs of the Acquisition and of TIF-Funded Improvements that constitute Redevelopment Project Costs. Exhibit E sets forth, by line item, the TIF-Funded Improvements for the Project, and the maximum amount of costs that may be paid by or reimbursed from City Funds for each line item therein (subject to Sections 4.03(b) and 4.03(d)), contingent upon receipt by the City of documentation in form and substance satisfactory to DPD evidencing such cost and its eligibility as a Redevelopment Project Cost. The foregoing notwithstanding, DPD may consent to transfers of costs and expenses from one line item to another. Developer will submit a Requisition Form in the form of Exhibit N (the "Requisition Form") to request payment of City Funds from the Construction Escrow. The Developer shall submit the Requisition Form for the initial payment request no later than 45 days prior to Closing.
Sources of City Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03 and Section 5 hereof, the City hereby agrees to provide City funds from the sources and in the amounts described directly below (the "City Funds") to pay for or reimburse the Developer for the costs of the TIF-Funded Improvements, in the manner described herein:

Source of City Funds Maximum Amount
(Construction Phase Assistance, City Note,
Note Issuance Costs and Reserve Account) $8,400,000

The City hereby agrees to issue the City Note to Developer on the Closing Date. The principal amount of the City Note shall be in an amount equal to $7,400,000; provided, however, that payments under the City Note are subject to the amount of Incremental Taxes deposited into the applicable TIF Fund being sufficient for such payments; and further provided, however, that the City has received written acknowledgement from the Phase IB Noteholder of its understanding and acceptance of the City Note structure related to this Project, as set forth in Exhibit G. If the amount of Incremental Taxes is insufficient to make any anticipated payment of City Funds, then: (1) the City will not be in default under this Agreement, and (2) unpaid payments (or portions thereof) will be paid as provided in this Section 4.03 as promptly as funds become available for their payment.
|1010|
(c) Construction Phase Assistance. An amount equal to $1,000,000 in City
Funds (the "Construction Phase Assistance") will be deposited into the Construction
Escrow (defined below) on the Closing Date as follows: $500,000 in existing Incremental
Taxes from the North Pullman TIF Special Tax Allocation Fund and $500,000 in existing
Incremental Taxes from the Roseland/Michigan TIF Special Tax Allocation Fund. The
Construction Phase Assistance will be paid to the Developer pursuant to the terms of the
Escrow Agreement, subject to City certification of sufficient costs related to TIF-Funded
Improvements incurred by the Developer related to the Project.
The City Funds will be reduced on a dollar-for-dollar basis if the final Project cost (as evidenced by the final owner's sworn statement for the Project submitted pursuant to Section 7.01) is less than $8,142,176. Any such reduction in the City Note shall occur through the operation of the redemption provisions set forth in the City Note.
The Developer acknowledges and agrees that the City's obligation to pay Construction Phase Assistance, up to a maximum of $1,000,000, is contingent upon the fulfillment of the conditions set forth above in this Section 4.03 and upon satisfaction of all applicable terms and conditions of this Agreement, including without limitation, compliance with the covenants in Section 8 (Covenants/Representations/ Warranties of the Developer). In the event that such conditions are not fulfilled, the amount of Equity to be contributed pursuant to Section 4.01 hereof shall be increased, as necessary, to complete the Project.
Construction Escrow. On the Closing Date, Developer will enter into the Escrow Agreement with the City and the Title Company, substantially in the form of Exhibit H-1, creating the "Construction Escrow." The Construction Phase Assistance and the City Note Net Proceeds will each be deposited into the Construction Escrow. Funds on deposit in the Construction Escrow will be used to pay for or reimburse Developer for the costs of TIF-Funded Improvements associated with the Project; provided, however, that the City Note Net Proceeds shall be disbursed prior to the Construction Phase Assistance. Disbursements of funds from the Construction Escrow shall be made through the funding of draw requests upon the approval of a Requisition Form submitted by Developer under the terms of the Escrow Agreement and this Agreement. In the event of any conflict between the terms of this Agreement and the terms of the Escrow Agreement concerning the Project (including the dispersal of funds for the Project through the Escrow), the terms of this Agreement shall control. All costs associated with the Construction Escrow shall be the responsibility of the Developer.
Reserve Escrow. Upon the sale of the City Note, the City and Developer will deposit or cause to be deposited not to exceed 10% of the par amount of the City Note into on escrow account (the "Reserve Escrow") held by a financial institution selected by the Developer and acceptable to the City (the "Bank Trustee"). The Reserve Escrow will be available to cure payment shortfalls in the event there are insufficient Available Incremental Taxes to make any scheduled payment for the City Note. Funds shall be held in the Reserve Escrow until the City Note has been paid in full or at maturity according to its terms and shall be applied to the final payment of the City Note. The Developer shall provide the Reserve Escrow agreement to the City for review and approval. All costs associated with the Reserve Escrow shall be the responsibility of the Developer.
|1010|
The City shall enter into the Reserve Escrow with a financial institution selected by Developer and acceptable to the City under which there shall be created a Debt Service Reserve Fund (as defined in such agreement). There shall be deposited into the Debt Service Reserve Fund proceeds from the sale of the City Note in an amount necessary to fund any required reserve for the City Note in an amount not in excess of 10% of the principal amount of the City Note. Amounts on deposit in the Reserve Escrow shall be available to pay debt service owed on the City Note in the event there are insufficient Available Incremental Taxes to pay such debt service and shall be replenished upon receipt of Available Incremental Taxes after payment of debt service owed on City Note.

4.04 Issuance of the City Note. On the Closing Date, the City will issue the City Note to the Developer with the following terms and conditions:
Principal. The Developer expects to sell the City Note to an investor in a transaction on the Note Sale Date for targeted City Note Net Proceeds, up to $6,453,329. The City Note Net Proceeds shall be deposited in the Construction Escrow.
City Note Interest Rate. When issued, the annual interest rate for the City Note will be equal to the median value of the Baa (municipal market data) G.O. Bond rate (20 year) as published by Thompson-Reuters Municipal Market Data ("MMD") for 15 business days prior to the date of issuance of the City Note plus 250 basis points, but in no event exceeding six and one-eighth percent (6.125%).
Term. The City Note will have the same maturity date as the current termination date of the North Pullman Redevelopment Area, with no future extension of the term allowed.
Payments of Principal and Interest.

Interest on the City Note will begin to accrue at the date of issuance. Amortization of principal will be over the term of the City Note. Upon issuance, the City will issue an amortization schedule for the City Note and make payments annually on March 1st of each year, beginning in 2017.
Except as may be otherwise provided in this Agreement, Available Incremental Taxes only will be used to pay the principal of and interest on the City Note and on unpaid interest, if any. In the ordinance authorizing the issuance of the City Note, the City established an account denominated the: "Chicago Neighborhood Initiatives, Inc. (Whole Foods Warehouse and Distribution Facility) Debt Service Account" within the North Pullman Redevelopment Project Area Special Tax Allocation Fund (the "CNI Debt Service Account"). All Available Incremental Taxes will be deposited into the CNI Debt Service Account and payments of principal and interest on the City Note will be made therefrom, first to interest due under the City Note; next to scheduled principal payments on the City Note.
After the principal and interest on the City Note have been paid in full or the term of the City Note has expired, and the City Note has been canceled according to its terms, then the CNI Debt Service Account will be closed and all subsequent Available Incremental Taxes will be deposited by the City in the North Pullman Redevelopment Project Area Special Tax Allocation Fund.
|1010|
If the amount of Available Incremental Taxes pledged under this Agreement is insufficient to make any scheduled payment on the City Note, then: (A) the City will not be in default under this Agreement or the City Note, provided that, to the extent available, the City shall draw on the Reserve Escrow to make up any shortfall, and (B) due but unpaid scheduled payments (or portions thereof) on the City Note will be paid as provided in this Section 4.04 and, if necessary, the Reserve Escrow will be replenished, promptly as funds become available for their payment. Interest per annum at the rate set when the City Note is issued will accrue on any principal or interest payments which are unpaid because of insufficient Available Incremental Taxes.
Prepayment of the City Note by the City. The City may prepay the City Note in whole or in part at any time without premium or penalty, subject to the following conditions:

City Note Lock-Out Period. The City will not prepay the City Note for a 5-year (60 month) period beginning with the first whole month after the date of issuance of the City Note, (the "Lock-Out Period"), unless the Lock-Out Period restriction is formally waived by the City Note registered holder(s) and except from any unexpended proceeds in the Construction Escrow as described in the City Note.
City May Prepay. Upon expiration or formal waiver of the Lock-Out Period, the City may prepay the then current balance of the City Note without any restrictions or conditions, together with any accrued interest.
Sale or Transfer of the City Note. After the issuance, the City Note may be sold or assigned in accordance with the provisions of Section 18.29 and the City Note.
No Cessation of City Note Payments. Notwithstanding anything to the contrary contained in this Agreement, after a Qualified Transfer, if an Event of Default occurs, the City will, notwithstanding such Event of Default, continue to make payments with respect to the City Note.
[Intentionally omitted]
The City Note shall have a parity first lien with the Phase IB Note (subject to the City's receipt of the written acknowledgment from the Phase IB Noteholder referenced in Section 4.03(b) of this Agreement) on the Available Incremental Taxes attributable to the Property and area-wide from the North Pullman Redevelopment Area. The City Note shall have a first lien on the Available Incremental Taxes attributable to the Roseland/Michigan Redevelopment Area.
4.05 Treatment of Prior Expenditures/Administration Fee.

(a) Prior Expenditures. Only those expenditures made by Developer with respect to the Project prior to the Closing Date, evidenced by documentation satisfactory to DPD and approved by DPD as satisfying costs covered in the Project Budget, will be considered previously contributed Equity or Lender Financing, if any, hereunder (the "Prior Expenditure(s)"). Prior Expenditures made for items other than TIF-Funded Improvements will not be reimbursed to Developer but will reduce the amount of Equity and/or Lender Financing, if any, required to be contributed by Developer under Section 4.01.|10 10|
(b) TIF District Administration Fee. The City may annually allocate an amount not to exceed five (5%) of the Incremental Taxes, exclusive of Incremental Taxes attributable to the Property, (the "City Fee") for payment of costs incurred by the City for the administration and monitoring of the North Pullman Redevelopment Area and the Roseland/Michigan Redevelopment Area, including the Project. The foregoing fee shall be in addition to and shall not be deducted from or considered a part of the City Funds, and, to the extent Incremental Taxes are disbursed to the Developer, the City shall have the right to receive the City Fee only after payment to Developer of such Incremental Taxes.
Cost Overruns. If the aggregate cost of the TIF-Funded Improvements exceeds City Funds available under Section 4.03, the City will not be responsible for such excess costs, and the Developer will hold the City harmless from any and all costs and expenses of completing the TIF-Funded Improvements in excess of City Funds and from any and all costs and expenses of completing the Project in excess of the Project Budget.
Conditional Grant. The $1,000,000 of Construction Phase Assistance being provided hereunder is being granted on a conditional basis, subject to the Developer's compliance with the provisions of this Agreement.
Preconditions of Disbursement and Certification of Expenditure. Prior to each disbursement City Funds from the Escrow Account and Certification of Expenditure hereunder, Developer shall submit a Requisition Form, along with documentation regarding the applicable expenditures to DPD, which shall be satisfactory to DPD in its sole discretion. Disbursements shall occur on a monthly basis. Delivery by Developer to DPD of any request for disbursement of City Funds hereunder shall, in addition to the items therein expressly set forth, constitute a certification to the City, as of the date of such request for disbursement, that:

the representations and warranties contained in this Agreement are true and correct and Developer is in compliance with all covenants contained herein (including but not limited to Sections 8.08, 10.02 and 10.03 hereof);
Developer has received no notice and has no knowledge of any lien or claim of lien either filed or threatened against the Property or the Project except for the Permitted Liens;
no Event of Default or condition or event which, with the giving of notice or passage time or both, would constitute an Event of Default exists or has occurred; and
The City shall have the right, in its discretion, to require Developer to submit further documentation as the City may require in order to verify that the matters certified to above are true and correct, and any disbursement by the City shall be subject to the City's review and approval of such documentation and its satisfaction that such certifications are true and correct; provided, however, that nothing in this sentence shall be deemed to prevent the City from relying on such certifications by Developer. In addition, Developer shall have satisfied all other preconditions of disbursement of City Funds for each disbursement, including not limited to the requirements set forth in the TIF Ordinances and this Agreement.
Retainage. Ten (10%) of the City Funds will not be disbursed from the Escrow Account until the City issues the Certificate of Completion to the Developer, which retainage is partial security for satisfaction of the requirements in Sections 8.08 (Prevailing Wage), 10.02 (City Resident Construction Worker Employment Requirement) and 10.03 (Developer's

10

MBE/WBE Commitment), and for satisfaction of Sections 4.03(d) and 7.01(b) (final certification of Project costs).

4.10 [Intentionally omitted]

ARTICLE FIVE: CONDITIONS PRECEDENT TO CLOSING
The following conditions precedent to closing must be complied with to the City's satisfaction within the time periods set forth below or, if no time period is specified, prior to the Closing Date:
Project Budget. Developer will have submitted to DPD, and DPD will have approved, the Project Budget stated in Exhibit D-1, in accordance with the provisions of Section 3.03. This condition precedent has been satisfied prior to the date hereof.
Scope Drawings and Plans and Specifications. Developer will have submitted to DPD, and DPD will have approved, the Scope Drawings and Plans and Specifications in accordance with the provisions of Section 3.02. This condition precedent has been satisfied prior to the date hereof.
Other Governmental Approvals. Not less than 5 Business Days prior to the Closing Date, Developer will have secured or applied for or provided DPD with an application time schedule for all other necessary approvals and permits required by any Federal, State, or local statute, ordinance, rule or regulation to begin or continue construction of the Project, and will submit evidence thereof to DPD.
Financing.

Developer will have furnished evidence acceptable to the City that Developer has Equity and/or Lender Financing, if any, at least in the amounts stated in Section 4.01, along with City Funds, to complete the Project and satisfy its obligations under this Agreement. If a portion of such financing consists of Lender Financing, Developer will have furnished evidence as ofthe Closing Date that the proceeds thereof are available to be drawn upon by Developer as needed and are sufficient (along with the Equity and other financing sources, if any, stated in Section 4.01) to complete the Project.
Prior to the Closing Date, Developer will deliver to DPD a copy of the construction escrow agreement, if any, entered into by Developer regarding Developer's Lender Financing, if any. Such construction escrow agreement must provide that the City will receive copies of all construction draw request materials submitted by Developer after the date of this Agreement.
Any financing liens against the Property or the Project in existence at the Closing Date will be subordinated to certain encumbrances of the City stated in this Agreement under a subordination agreement, in the form of Exhibit O, executed on or prior to the Closing Date, which is to be recorded, at the expense of Developer, in the Office of the Recorder of Deeds of Cook County.
Title. On the Closing Date, Developer will furnish the City with a copy of the Title Policy for the Property, showing North Pullman 111th, Inc. or Developer (if the Developer will acquire the Property at or before the Closing Date) as the named insured. The Title Policy will
11

be dated as of the Closing Date and will contain only those title exceptions listed as Permitted Liens on Exhibit I and will evidence the recording of this Agreement under the provisions of Section 8.15. The Title Policy will also contain the following endorsements as required by Corporation Counsel: an owner's comprehensive endorsement and satisfactory endorsements regarding location, access, and survey. On or prior to the Closing Date, Developer will provide to DPD documentation related to the Property and copies of all easements and encumbrances of record with respect to the Property not addressed, to DPD's satisfaction, by the Title Policy and any endorsements thereto.
Evidence of Clear Title. Not less than 5 Business Days prior to the Closing Date, Developer, at its own expense, will have provided the City with current searches under Developer's name as follows:
Secretary of State (IL) , UCC search
Secretary of State (IL) Federal tax lien search
Cook County Recorder UCC search
Cook County Recorder Fixtures search
Cook County Recorder Federal tax lien search
Cook County Recorder State tax lien search
Cook County Recorder Memoranda of judgments search
U.S. District Court (N:D. IL) Pending suits and judgments
Clerk of Circuit Court, Cook County Pending suits and judgments

showing no liens against Developer, the Property or any fixtures now or hereafter affixed thereto, except for the Permitted Liens.
Surveys. If requested by DPD, not less than 5 Business Days prior to the Closing Date, Developer will have furnished the City with 3 copies of the Survey.
Insurance. Developer, at its own expense, will have insured the Property as required under Article Twelve. At least 5 Business Days prior to the Closing Date, certificates required under Article Twelve evidencing the required coverages will have been delivered to DPD.
Opinion of Developer's Counsel, (a) On the Closing Date, Developer will furnish the City with an opinion of counsel, substantially in the form of Exhibit J, with such changes as may be required by or acceptable to Corporation Counsel. If Developer has engaged special counsel in connection with the Project, and such special counsel is unwilling or unable to give some of the opinions stated in Exhibit J, such opinions shall be obtained by Developer from its general corporate counsel.

(b) On the Closing Date, the City has received from [ ], special counsel, an
opinion regarding the tax-exempt status and enforceability of the City Note, in form and substance acceptable to Corporation Counsel.
Evidence of Prior Expenditures. Not less than 20 Business Days prior to the Closing Date, Developer will have provided evidence satisfactory to DPD of the Prior Expenditures as provided in Section 4.05. Such evidence of Prior Expenditures may be updated to the Closing Date by Developer.


12

Financial Statements. Not less than 30 days prior to the Closing Date, Developer will have provided Financial Statements to DPD for its 2013 and 2014 fiscal years, if available, and its most recently publicly available unaudited interim Financial Statements, in each case together with any opinions and management letters prepared by auditors.
Reserved.
Environmental Reports. Not less than 30 days prior to the Closing Date, Developer will provide DPD with copies of all environmental reports or audits, if any, obtained by Developer with respect to the Property, together with any notices addressed to Developer from any agency regarding environmental issues at the Property. Prior to the Closing Date, Developer will have provided the City with a letter from the environmental engineer(s) who completed such report(s) or audit(s), authorizing the City to rely on such report(s) or audit(s).
Entity Documents; Economic Disclosure Statement.

Entity Documents. Developer will provide a copy of its current Articles of Incorporation, with all amendments, containing the original certification ofthe Secretary of State of its state of organization; certificates of good standing from the Secretary of State of Illinois and all other states, if any, in which Developer is registered to do business; its bylaws; a secretary's certificate in such form and substance as the Corporation Counsel may require; and such other organizational documentation as the City may request.
Economic Disclosure Statement. Developer will provide the City an EDS, in the City's then current form, dated as of the Closing Date, which is incorporated by reference and Developer further will provide any other affidavits or certifications as may be required by Federal, State or local law in the award of public contracts, all of which affidavits or certifications are incorporated by reference. Notwithstanding acceptance by the City of the EDS, failure of the EDS to include all information required under the Municipal Code renders this Agreement voidable at the option of the City. Developer and any other parties required by this Section 5.14 to complete an EDS must promptly update their EDS(s) on file with the City whenever any information or response provided in the EDS(s) is no longer complete and accurate, including changes in ownership and changes in disclosures and information pertaining to ineligibility to do business with the City under Chapter 1-23 of the Municipal Code, as such is required under Sec. 2-154-020, and failure to promptly provide the updated EDS(s) to the City will constitute an event of default under this Agreement.
Litigation. Developer has provided to Corporation Counsel and DPD in writing, a description of all pending or threatened litigation or administrative proceedings: (a) involving Developer's property located in the City, (b) that Developer is otherwise required to publicly disclose or that may affect the ability of Developer to perform its duties and obligations under this Agreement, or (c) involving the City or involving the payment of franchise, income, sales or other taxes by such party to the State of Illinois or the City. In each case, the description shall specify the amount of each claim, an estimate of probable liability, the amount of any reserves taken in connection therewith, and whether (and to what extent) such potential liability is covered by insurance.
5.16 Right of Entry. Developer has provided the City with a certified copy of the right of
entry between North Pullman 111th, Inc. and the Developer, allowing Developer to perform the
work on the Property.

13

Purchase and Sale Agreement. Developer has provided the City with a certified copy of the purchase contract whereby Developer will purchase the Property from North Pullman 111th, Inc. and convey the Property to the Vertical Developer.
Whole Foods Lease. Developer has provided the City with a certified copy of the lease of the Property to Whole Foods (the "Whole Foods Lease").
ARTICLE SIX: AGREEMENTS WITH CONTRACTORS
Bid Requirement for General Contractor and Subcontractors.

DPD acknowledges that Developer may act as general contractor for all or a portion of the Project. To the extent Developer elects to engage a third party to provide general contractor or construction oversight services, the Developer's selection of such third party shall be subject to the City's approval (the "General Contractor"). Developer must solicit, or must cause the General Contractor to solicit, bids from qualified contractors eligible to do business with the City.
For the TIF-Funded Improvements related to hard costs and soft costs, Developer must select or cause the General Contractor to select the subcontractor submitting the lowest responsible and responsive bid who can complete the Project (or phase thereof) in a timely and good and workmanlike manner; provided, however, that Developer may consider a bidder's ability to meet the unique challenges of the Project in evaluating the "lowest responsible and responsive bid" rather than the lowest bid. If the General Contractor selects any subcontractor submitting other than the lowest responsible and responsive bid for the TIF-Funded Improvements, the difference between the lowest responsible and responsive bid and the bid selected may not be paid out of City Funds.
Developer must submit copies of the Construction Contract to DPD as required under Section 6.02 below. Photocopies of all subcontracts entered or to be entered into in connection with the TIF-Funded Improvements related to hard costs and soft costs must be provided to DPD within 20 Business Days of the execution thereof. Developer must ensure that the General Contractor will not (and must cause the General Contractor to ensure that the subcontractors will not) begin work on the Project (or any phase thereof) until the applicable Plans and Specifications for that phase have been approved by DPD and all requisite permits have been obtained.
Construction Contract. Prior to the execution thereof, Developer must deliver to DPD a copy of the proposed Construction Contract with the General Contractor selected to work on the TIF-Funded Improvements under Section 6.01 above, for DPD's prior written approval. Within 10 Business Days after execution of such contract by Developer, the General Contractor and any other parties thereto, Developer must deliver to DPD and Corporation Counsel a certified copy of such contract together with any modifications, amendments or supplements thereto.
Performance and Payment Bonds. Prior to commencement of construction of any work in the public way, if any, Developer will require that the General Contractor and any applicable subcontractor(s) be bonded (as to such work in the public way) for their respective payment and performance by sureties having an AA rating or better using the form of payment and performance bond form attached as Exhibit L. The City will be named as obligee or co-obligee on such bond.
14

Employment Opportunity. Developer will contractually obligate and cause the General Contractor to agree and contractually obligate each subcontractor to agree to the provisions of Article Ten. The Parties acknowledge that the contracting, hiring and testing requirements for the MBEAA/BE and City Residency obligations in Article Ten are applied by the City's monitoring staff on an aggregate basis, and that it shall not be an event of default under this Agreement, nor shall the payment of the City resident hiring shortfall amount be required, if the Developer or, as applicable, the General Contractor do not impose such obligations on each subcontractor, or if any one subcontractor does not satisfy such obligations, so long as such obligations are satisfied on an aggregate basis.
Other Provisions. In addition to the requirements of this Article Six, the Construction Contract and each contract with any subcontractor working on the Project must contain provisions required under Section 3.04 (Change Orders), Section 8.08 (Prevailing Wage), Section 10.01(e) (Employment Opportunity), Section 10.02 (City Resident Construction Worker Employment Requirement), Section 10.03 (Developer's MBEAA/BE Commitment), Article Twelve (Insurance) and Section 14.01 (Books and Records).
ARTICLE SEVEN: COMPLETION OF CONSTRUCTION
Certificate of Completion of Construction. DPD will issue to Developer a certificate of completion of construction in recordable form (the "Certificate of Completion") certifying that Developer has fulfilled its obligation to complete the Project pursuant to Section 8.02 hereof upon completion of the construction of the Project in compliance with the terms and conditions of this Agreement, and upon Developer's written request, including:

a final owner's sworn statement for the Project;
evidence that the Total Project Cost is equal to, or in excess of, $8,142,176;
evidence,that the Developer has incurred TIF-eligible costs in an equal amount to, or greater than, the total maximum amount of $8,400,000;

evidence that the Developer has acquired the Property and conveyed it to the Vertical Developer (or its designee);
evidence that Whole Foods has entered into a lease with the Vertical Developer (or its designee) and the Vertical Developer (or its designee) has accepted the Property; and
DPD will respond to Developer's written request for a Certificate of Completion within 45 days by issuing either a Certificate of Completion or a written statement detailing the ways in which the Project does not conform to this Agreement or has not been satisfactorily completed and the measures which must be taken by Developer in order to obtain the Certificate of Completion. Developer may resubmit a written request for a Certificate of Completion upon completion of such measures, and the City will respond within 45 days in the same way as the procedure for the initial request. Such process may repeat until the City issues a Certificate of Completion.
Effect of Issuance of Certificate of Completion; Continuing Obligations.
(a) The Certificate of Completion relates only to the construction of the Project, and upon its issuance, the City will certify that the terms of the Agreement specifically related to
15

Developer's obligation to complete such activities have been satisfied. After the issuance of a Certificate of Completion, however, all executory terms and conditions of this Agreement and all representations and covenants contained herein will continue to remain in full force and effect throughout the Term of the Agreement as to the parties described in the following paragraph, and the issuance of the Certificate of Completion must not be construed as a waiver by the City of any of its rights and remedies under such executory terms.

(b) Those covenants specifically described at Section 8.02 as covenants that run with the land comprising the Property are the only covenants in this Agreement intended to be binding throughout the Term of the Agreement upon any transferee of the Developer holding title to the Property or any portion thereof, regardless of whether or to what extent that owner is also an assignee of Developer as described in this paragraph and regardless of whether or not a Certificate of Completion has been issued. Unless a Certificate of Completion has been issued, those covenants specifically described at Section 8.02 (Covenant to Redevelop) as covenants that run with the land comprising the Property are the only other covenants in this Agreement intended to be binding throughout the Term of the Agreement upon any transferee of the Developer holding title to the Property or any portion thereof, regardless of whether or to what extent that owner is also an assignee of Developer as described in this paragraph. The other executory terms of this Agreement that remain after the issuance of a Certificate of Completion, specifically Sections 8.17, will be binding only upon [the Developer] or a permitted assignee of [the Developer].
Failure to Complete. If Developer fails to complete the Project in accordance with the terms of this Agreement, then the City has, but shall not be limited to, any of the following rights and remedies, subject to the opinion of special counsel that such rights and remedies will not jeopardize the tax-exempt status of the City Note:

the right to terminate this Agreement and cease all disbursement of City Funds not yet disbursed under this Agreement other than principal and interest due under the City Note;
the right (but not the obligation) to complete those TIF-Funded Improvements that are public improvements and to pay for the costs of TIF-Funded Improvements (including interest costs) out of City Funds or other City monies. In the event that the aggregate cost of completing the TIF-Funded Improvements exceeds the amount of City Funds available pursuant to Section 4.01, Developer shall reimburse the City for all reasonable costs and expenses incurred by the City in completing such TIF-Funded Improvements in excess of the available City Funds;
the right to seek reimbursement ofthe Construction Phase Assistance; and
the right to redeem the City Note from amounts on deposit in the City Note Proceeds Subaccount of the Construction Escrow.
Notice of Expiration or Termination. Upon the expiration of the Term of the Agreement, DPD will provide Developer, at Developer's written request, with a written notice in recordable form stating that the Term of the Agreement has expired.





16

ARTICLE EIGHT: REPRESENTATIONS, WARRANTIES AND COVENANTS OF DEVELOPER.
8.01 General. Developer represents, warrants, and covenants, as of the date of this Agreement and as of the date of each disbursement of City Funds hereunder, that:
Developer is an Illinois not-for-profit corporation, duly organized, validly existing, qualified to do business in Illinois, and licensed to do business in any other state where, due to the nature of its activities or properties, such qualification or license is required;
Developer has the right, power and authority to enter into, execute, deliver and perform this Agreement;
the execution, delivery and performance by Developer of this Agreement has been duly authorized by all necessary corporate action, and does not and will not violate its Articles of Incorporation as amended and supplemented, its bylaws, any applicable provision of law, or constitute a breach of, default under or require any consent under any agreement, instrument or document to which Developer is now a party or by which Developer or any of its assets is now or may become bound;
Developer has acquired an easement to the Property (and improvements located thereon) free and clear of all liens (except for the Permitted Liens or Lender Financing, if any, as disclosed in the Project Budget, and those liens otherwise bonded or insured over in accordance with the terms of this Agreement).
Developer is now, and for the Term of the Agreement, will remain solvent and able to pay its debts as they mature;
there are no actions or proceedings by or before any court, governmental commission, board, bureau or any other administrative agency pending or, to Developer's actual knowledge threatened or affecting Developer which would impair its ability to perform under this Agreement;
Developer has and will maintain all government permits, certificates and consents (including, without limitation, appropriate environmental approvals) necessary to construct and complete the Project;
Developer is not in default with respect to any indenture, loan agreement, mortgage, deed, note or any other agreement or instrument related to the borrowing of money to which Developer is a party or by which Developer or any of its assets is bound beyond applicable notice and cure periods;
(i) the Financial Statements are, and when hereafter required to be submitted will
be, complete, correct in all material respects and accurately present the assets, liabilities,
results of operations and financial condition of Developer; and there has been no material
adverse change in the assets, liabilities, results of operations or financial condition of Developer
since the date of Developer's most recent Financial Statements;
(j) prior to the issuance of a Certificate of Completion, if it would adversely affect Developer's ability to perform its obligations under this Agreement, Developer will not do any of the following without the prior written consent of DPD: (1) be a party to any merger, liquidation
17

or consolidation; (2) sell, transfer, convey, lease or otherwise dispose (directly or indirectly) of all or substantially all of its assets or any portion of the Property or the Project (including but not limited to any fixtures or equipment now or hereafter attached thereto) except in the ordinary course of business, and except with respect to the sale of the Property to the Vertical Developer; (3) enter into any transaction outside the ordinary course of Developer's business; (4) assume, guarantee, endorse, or otherwise become liable in connection with the obligations of any other person or entity to the extent that such action would have an adverse effect on Developer's ability to perform its obligations under this Agreement; or (5) enter into any transaction that would cause a material and detrimental change to Developer's financial condition.

(k) Developer has not incurred and, prior to the issuance of a Certificate of Completion, will not, without the prior written consent of the Commissioner of DPD, allow the existence of any liens against the Property other than the Permitted Liens; or incur any indebtedness secured or to be secured by the Property or the Project or any fixtures now or hereafter attached thereto;

(I) Developer has not made or caused to be made, directly or indirectly, any payment, gratuity or offer of employment in connection with the Agreement or any contract paid from the City treasury or under City ordinance, for services to any City agency ("City Contract") as an inducement for the City to enter into the Agreement or any City Contract with Developer in violation of Chapter 2-156-120 ofthe Municipal Code ofthe City, as amended; and

(m) neither Developer nor any Affiliate thereof is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons Lists, the Unverified List, the Entity List and the Debarred List. For purposes of this subparagraph (m) only, the term "affiliate," when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.

(n) Developer understands that (i) the City Funds are limited obligations of the City, payable solely from moneys on deposit in the TIF Fund; (ii) the City Funds do not constitute indebtedness of the City within the meaning of any constitutional or statutory provision or limitation; (iii) Developer will have no right to compel the exercise of any taxing power of the City for payment of the City Funds; and (iv) the City Funds do not and will not represent or constitute a general obligation or a pledge of the faith and credit of the City, the State of Illinois or any political subdivision thereof;

(o) Developer has sufficient knowledge and experience in financial and business matters, including municipal projects and revenues of the kind represented by the City Funds, and has been supplied with access to information to be able to evaluate the risks associated with the receipt of City Funds;

18

(p) Developer understands that there is no assurance as to the amount or timing of receipt of City Funds, and that the amounts of City Funds actually received by such party may be less than the maximum amounts set forth in Section 4.03(b);

(q) Developer understands it may not sell, assign, pledge or otherwise transfer its interest in this Agreement or City Funds in whole or in part except in accordance with the terms of Section 18.15 and Section 18.29 of this Agreement, and, to the fullest extent permitted by law, agrees to indemnify the City for any losses, claims, damages or expenses relating to or based upon any sale, assignment, pledge or transfer of City Funds in violation of this Agreement; and
(r) Developer acknowledges that with respect to City Funds, the City has no obligation to provide any continuing disclosure to the Electronic Municipal Market Access System maintained by the Municipal Securities Rulemaking Board, to any holder of a note relating to City Funds or any other person under Rule 15c2-12 of the Commission promulgated under the Securities Exchange Act of 1934 or otherwise, and shall have no liability with respect thereto.
Covenant to Redevelop. Upon DPD's approval of the Scope Drawings and Plans and Specifications, and the Project Budget as provided in Sections 3.02 and 3.03, and Developer's receipt of all required building permits and governmental approvals, Developer will redevelop the Property and the Project in compliance with this Agreement and all exhibits attached hereto, the TIF Ordinances, the Scope Drawings, the Plans and Specifications, the Project Budget and all amendments thereto, and all Federal, State and local laws, ordinances, rules, regulations, executive orders and codes applicable to the Property, the Project and/or Developer. The covenants set forth in this Section 8.02 will run with the land comprising the Property (as defined herein) and will be binding upon any transferee, until fulfilled as evidenced by the issuance of a Certificate of Completion.
Redevelopment Plan. Developer represents that the Project is and will be in compliance with all applicable terms of the Redevelopment Plan, as in effect on the date of this Agreement.
Use of City Funds. City Funds disbursed to Developer will be used by Developer solely to reimburse Developer for its payment for the TIF-Funded Improvements as provided in this Agreement.
Other Bonds. At the request of the City, Developer will agree to any reasonable amendments to this Agreement that are necessary or desirable in order for the City to issue (in its sole and absolute discretion) any Bonds in connection with the Redevelopment Area, the proceeds of which may be used to reimburse the City for expenditures made in connection with or provided a source of funds for the payment for the TIF-Funded Improvements (the "Bonds"); provided, however, that any such amendments will not have a material adverse effect on Developer or the Project. Developer will, at Developer's expense, cooperate and provide reasonable assistance in connection with the marketing of any such Bonds, including but not limited to providing written descriptions of the Project, making representations, providing information regarding its financial condition (but not including proprietary sales and operating information), and assisting the City in its preparation of an offering statement with respect thereto. Developer will not have any liability with respect to any disclosures made in connection with any such issuance that are actionable under applicable securities laws unless such

19

disclosures are based on factual information provided by Developer that is determined to be false and misleading.
Employment Opportunity.

Developer covenants and agrees to abide by, and contractually obligate and use reasonable efforts to contractually obligate, and, as applicable, to cause the General Contractor to contractually obligate, each subcontractor to abide by the terms set forth in Section 8.08 (Prevailing Wage) and Article Ten (Developer's Employment Obligations). Developer will submit a plan to DPD describing its compliance program prior to the Closing Date.
Developer will deliver to the City written quarterly progress reports detailing compliance with the requirements of Sections 8.08, (Prevailing Wage) 10.02 (City Resident Construction Worker Employment Requirement) and 10.03 (Developer's MBEAA/BE Commitment) of this Agreement. If any such reports indicate a shortfall in compliance, Developer will also deliver a plan to DPD which will outline, to DPD's satisfaction, the manner in which Developer will correct any shortfall.
Employment Profile. Developer will submit, and contractually obligate and cause the General Contractor to submit and contractually obligate any subcontractor to submit, to DPD, from time to time, statements of its employment profile upon DPD's request.
Prevailing Wage. Developer covenants and agrees to pay, and to contractually obligate and cause the General Contractor to pay and to contractually cause each subcontractor to pay, the prevailing wage rate as ascertained by the State Department of Labor (the "Labor Department"), to all of their respective employees working on constructing the Project or otherwise completing the TIF-Funded Improvements. All such contracts will list the specified rates to be paid to all laborers, workers and mechanics for each craft or type of worker or mechanic employed under such contract, or alternatively Developer will provide applicable schedules evidencing wage rates paid. If the Labor Department revises such prevailing wage rates, the revised rates will apply to all such contracts. Upon the City's request, Developer will provide the City with copies of all such contracts entered into by Developer or the General Contractor to evidence compliance with this Section 8.08.
Arms-Length Transactions. Unless DPD shall have given its prior written consent with respect thereto, no Affiliate of Developer may receive any portion of City Funds, directly or indirectly, in payment for work done, services provided or materials supplied in connection with any TIF-Funded Improvement. Developer will provide information with respect to any entity to receive City Funds directly or indirectly (whether through payment to an Affiliate by Developer and reimbursement to Developer for such costs using City Funds, or otherwise), upon DPD's request, prior to any such disbursement.
Financial Statements. * Developer will obtain and provide to DPD Financial Statements for 2014 and 2015, if available, and each year thereafter for the Term of the Agreement.
Insurance. Solely at its own expense, Developer will comply with all applicable provisions of Article Twelve (Insurance) hereof.



20

Non-Governmental Charges.

Payment of Non-Governmental Charges. Except for the Permitted Liens, and subject to subsection (b) below, Developer agrees to pay or cause to be paid when due any Non-Governmental Charges assessed or imposed upon the Property or the Project or the or any fixtures that are or may become attached thereto and which are owned by Developer, which creates, may create, or appears to create a lien upon all or any portion of the Property; provided however, that if such Non-Governmental Charges may be paid in installments, Developer may pay the same together with'any accrued interest thereon in installments as they become due and before any fine, penalty, interest, or cost may be added thereto for nonpayment. Developer will furnish to DPD, within thirty (30) days of DPD's request, official receipts from the appropriate entity, or other evidence satisfactory to DPD, evidencing payment of the Non-Governmental Charges in question.
Right to Contest. Developer will have the right, before any delinquency occurs:

to contest or object in good faith to the amount or validity of any Non-Governmental Charges by appropriate legal proceedings properly and diligently instituted and prosecuted, in such manner as shall stay the collection of the contested Non-Governmental Charges, prevent the imposition of a lien or remove such lien, or prevent the transfer or forfeiture of the Property (so long as no such contest or objection shall be deemed or construed to relieve, modify or extend Developer's covenants to pay any such Non-Governmental Charges at the time and in the manner provided in this Section 8.12); or
at DPD's sole option, to furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD will require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such transfer or forfeiture of the Property or any portion thereof or any fixtures that are or may be attached thereto, during the pendency of such contest, adequate to pay fully any such contested Non-Governmental Charges and all interest and penalties upon the adverse determination of such contest.
Developer's Liabilities. Developer will not enter into any transaction that would materially and adversely affect its ability to: (i) perform its obligations under this Agreement or (ii) repay any material liabilities or perform any material obligations of Developer to any other person or entity. Developer will immediately notify DPD of any and all events or actions which may materially affect Developer's ability to carry on its business operations or perform its obligations under this Agreement or under any other documents and agreements.
Compliance with Laws.

Representation. To Developer's knowledge, after diligent inquiry, the Property and the Project are in compliance with all applicable Federal, State and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the Property and the Project. Upon the City's request, Developer will provide evidence reasonably satisfactory to the City of such current compliance.
Covenant. Developer covenants that, the Property and the Project will be operated and managed in compliance with all applicable Federal, State and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the
21

Property or the Project, including the following Municipal Code Sections: 7-28-390, 7-28-440, 11-4-1410, 11-4-1420, 11-4-1450, 11-4-1500, 11-4-1530, 11-4-1550 or 11-4-1560, whether or not in performance of this Agreement. Upon the City's request, Developer will provide evidence to the City of its compliance with this covenant.
8.15 Recording and Filing. Developer will cause this Agreement, certain exhibits (as
specified by Corporation Counsel) and all amendments and supplements hereto to be recorded
and filed on the date hereof in the conveyance and real property records of Cook County, Illinois
against the Property. Such recordings shall be recorded prior to any mortgage made in
connection with Lender Financing, if any. Developer will pay all fees and charges incurred in
connection with any such recording. Upon recording, Developer will immediately transmit to the
City an executed original of this Agreement showing the date and recording number of record.
8.16 Real Estate Provisions,
(a) Governmental Charges.
Payment of Governmental Charges. Subject to subsection (ii) below, Developer agrees to pay or cause to be paid when due all Governmental Charges (as defined below) which are assessed or imposed upon Developer, the Property or the Project, or become due and payable, and which create, may create, or appear to create a lien upon Developer or all or any portion of the Property or the Project, provided, however, that this section shall not impose on Developer any obligation to be personally liable on any tax that does not generally impose personal liability (except that the City's rights and remedies attributable to the Construction Phase Assistance shall not be affected). "Governmental Charge" means all Federal, State, county, the City, or other governmental (or any instrumentality, division, agency, body, or department thereof) taxes, levies, assessments, charges, liens, claims or encumbrances relating to Developer, the Property or the Project, including but not limited to real estate taxes.
Right to Contest. Developer has the right before any delinquency occurs to contest or object in good faith to the amount or validity of any Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted in such manner as shall stay the collection of the contested Governmental Charge and prevent the imposition of a lien or the sale or transfer or forfeiture of the Property or the Project. No such contest or objection will be deemed or construed in any way as relieving, modifying or extending Developer's covenants to pay any such Governmental Charge at the time and in the manner provided in this Agreement unless Developer has given prior written notice to DPD of Developer's intent to contest or object to a Governmental Charge and, unless, at DPD's sole option:
(x) .Developer will demonstrate to DPD's satisfaction that legal proceedings instituted by Developer contesting or objecting to a Governmental Charge will conclusively operate to prevent or remove a lien against, or the sale or transfer or forfeiture of, all or any part of the Property or the Project to satisfy such Governmental Charge prior to final determination of such proceedings, and/or;

(y) Developer will furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD may require, or a good and sufficient undertaking as may be required or permitted by law to accomplish
22

a stay of any such sale or transfer or forfeiture of the Property or the Project during the pendency of such contest, adequate to pay fully any such contested Governmental Charge and all interest and penalties upon the adverse determination of such contest.
(b) Developer's Failure To Pay Or Discharge Lien. If Developer fails to pay or contest any Governmental Charge or to obtain discharge of the same, Developer will advise DPD thereof in writing, at which time DPD may, but will not be obligated to, and without waiving or releasing any obligation or liability of Developer under this Agreement, in DPD's sole discretion, make such payment, or any part thereof, or obtain such discharge and take any other action with respect thereto which DPD deems advisable. All sums so paid by DPD, if any, and any expenses, if any, including reasonable attorneys' fees, court costs, expenses and other charges relating thereto, will be promptly disbursed to DPD by Developer. Notwithstanding anything contained herein to the contrary, this paragraph must not be construed to obligate the City to pay any such Governmental Charge. Additionally, if Developer fails to pay any Governmental Charge, the City, in its sole discretion, may require Developer to submit to the City audited Financial Statements at Developer's own expense.
This Agreement will be recorded by Developer against the Property as a memorandum thereof, at Developer's expense, with the Cook County Recorder of Deeds on the Closing Date. These restrictions will be binding upon any owner of the Property, from and after the date hereof, provided however, that the covenants will be released upon the earlier of when the North Pullman Redevelopment Area is no longer in effect, or upon expiration of the Term of Agreement. Developer agrees that any sale, transfer, lease, conveyance, or transfer of title to all or any portion of the Property or the Project from and after the date hereof shall be made explicitly subject to such covenants and restrictions.
Annual Reports, (a) Developer or Vertical Developer, for the ten-year period of time from the Commencement Date through and including the tenth anniversary of the Commencement Date, shall submit to DPD the Annual Compliance Report within 30 days after the end of the calendar year to which the Annual Compliance Report relates. For purposes of this Section 8.17, "Commencement Date" shall mean the date on which the City issues a certificate of occupancy for the Whole Foods Facility.

(b) Beginning with the issuance of the Certificate and continuing throughout the Term of the Agreement, Developer shall cause to be submitted to DPD each calendar year an Annual Report of Incremental Taxes not later than February 1st of the subsequent calendar year. Failure by the Developer to submit the Annual Report of Incremental Taxes before February 15th of a relevant year shall constitute an Event of Default under Section 15.01 hereof, without notice or opportunity to cure pursuant to Section 15.03 hereof. If the Developer defaults in submitting the Annual Report of Incremental Taxes in any year, the City may engage its own financial consultant to prepare the report and the cost thereof shall be reimbursed to the City from City Funds to the extent available for payments on the City Note.
Reserved.
Broker's Fees. Developer has no liability or obligation to pay any fees or commissions to any broker, finder, or agent with respect to any of the transactions contemplated by this Agreement for which the City could become liable or obligated.


23

No Conflict of Interest. Under Section 5/11-74.4-4(n) of the Act, Developer represents, warrants and covenants that to the best of its knowledge, no member, official, or employee of the City, or of any commission or committee exercising authority over the Project, the Redevelopment Area or the Redevelopment Plan, or any consultant hired by the City, (a "City Group Member") owns or controls, has owned or controlled or will own or control any interest, and no such City Group Member will represent any person, as agent or otherwise, who owns or controls, has owned or controlled, or will own or control any interest, direct or indirect, in Developer, the Property, the Property, the Project, or to Developer's actual knowledge, any other property in the Redevelopment Area.
Disclosure of Interest. Developer's counsel has no direct or indirect financial ownership interest in Developer, the Property or any other feature of the Project.
No Business Relationship with City Elected Officials. Developer acknowledges receipt of a copy of Section 2-156-030(b) of the Municipal Code and that Developer has read and understands such provision. Under Section 2-156-030(b) of the Municipal Code of Chicago, it is illegal for any elected official of the City, or any person acting at the direction of such official, to contact, either orally or in writing, any other City official or employee with respect to any matter involving any person with whom the elected official has a "Business Relationship" (as defined in Section 2-156-080(b)(2) of the Municipal Code), or to participate in any discussion of any City Council committee hearing or in any City Council meeting or to vote on any matter involving the person with whom an elected official has a Business Relationship. Violation of Section 2-156-030(b) by any elected official, or any person acting at the direction of such official, with respect to this Agreement, or in connection with the transactions contemplated thereby, will be grounds for termination of this Agreement and the transactions contemplated thereby. Developer hereby represents and warrants that, to the best of its knowledge after due inquiry, no violation of Section 2-156-030(b) has occurred with respect to this Agreement or the transactions contemplated thereby.
Inspector General. It is the duty of Developer and the duty of any bidder, proposer, contractor, subcontractor, and every applicant for certification of eligibility for a City contract or program, and all of Developer's officers, directors, agents, partners, and employees and any such bidder, proposer, contractor, subcontractor or such applicant: (a) to cooperate with the Inspector General in any investigation or hearing undertaken pursuant to Chapter 2-56 of the Municipal Code and (b) to cooperate with the Legislative Inspector General in any investigation undertaken pursuant to Chapter 2-55 of the Municipal Code. Developer represents that it understands and will abide by all provisions of Chapters 2-56 and 2-55 of the Municipal Code and that it will inform subcontractors of this provision and require their compliance.
Prohibition on Certain Contributions - Mayoral Executive Order No. 2011-4. Neither Developer or any person or entity who directly or indirectly has an ownership or beneficial interest in Developer of more than 7.5% ("Owners"), spouses and domestic partners of such Owners, Developer's Subcontractors, any person or entity who directly or indirectly has an ownership or beneficial interest in any Subcontractor of more than 7.5% ("Sub-owners") and spouses and domestic partners of such Sub-owners (Developer and all the other preceding classes of persons and entities are together, the "Identified Parties"), shall make a contribution of any amount to the Mayor of the City of Chicago (the "Mayor") or to his political fundraising committee during: (i) the bid or other solicitation process for this Agreement or Other Agreement, including while this Agreement or Other Agreement is executory, (ii) the term of this Agreement or any Other Agreement between City and Developer, and/or (iii) any period in
24

which an extension of this Agreement or Other Agreement with the City is being sought or negotiated.

Developer represents and warrants that since the date of public advertisement of the specification, request for qualifications, request for proposals or request for information (or any combination of those requests) or, if not competitively procured, from the date the City approached the Developer or the date the Developer approached the City, as applicable, regarding the formulation of this Agreement, no Identified Parties have made a contribution of any amount to the Mayor or to his political fundraising committee.

Developer shall not: (a) coerce, compel or intimidate its employees to make a contribution of any amount to the Mayor or to the Mayor's political fundraising committee; (b) reimburse its employees for a contribution of any amount made to the Mayor or to the Mayor's political fundraising committee; or (c) bundle or solicit others to bundle contributions to the Mayor or to his political fundraising committee.

The Identified Parties must not engage in any conduct whatsoever designed to intentionally violate this provision or Mayoral Executive Order No. 2011-4 or to entice, direct or solicit others to intentionally violate this provision or Mayoral Executive Order No. 2011-4.

Violation of, non-compliance with, misrepresentation with respect to, or breach of any covenant or warranty under this provision or violation of Mayoral Executive Order No. 2011-4 constitutes a breach and default under this Agreement, and under any Other Agreement for which no opportunity to cure will be granted. Such breach and default entitles the City to all remedies (including without limitation termination for default) under this Agreement, under any Other Agreement, at law and in equity. This provision amends any Other Agreement and supersedes any inconsistent provision contained therein.

If applicable, if Developer violates this provision or Mayoral Executive Order No. 2011-4 prior to award of the Agreement resulting from this specification, then DPD may reject Developer's bid.

For purposes of this provision:
"Other Agreement" means any agreement entered into between the Developer and the City that is (i) formed under the authority of MCC Ch. 2-92; (ii) for the purchase, sale or lease of real or personal property; or (iii) for materials, supplies, equipment or services which are approved and/or authorized by the City Council.

"Contribution" means a "political contribution" as defined in MCC Ch. 2-156, as amended.
"Political fundraising committee" means a "political fundraising committee" as defined in MCC Ch. 2-156, as amended.

8.25 Shakman Accord.

(a) The City is subject to the June 24, 2011 "City of Chicago Hiring Plan" (the "City Hiring Plan") entered in Shakman v. Democratic Organization of Cook County, Case No 69 C 2145 (United States District Court for the Northern District of Illinois). Among other things, the

25

City Hiring Plan prohibits the City from hiring persons as governmental employees in non-exempt positions on the basis of political reasons or factors.
Developer is aware that City policy prohibits City employees from directing any individual to apply for a position with Developer, either as an employee or as a subcontractor, and from directing Developer to hire an individual as an employee or as a subcontractor. Accordingly, Developer must follow its own hiring and contracting procedures, without being influenced by City employees. Any and all personnel provided by Developer under this Agreement are employees or subcontractors of Developer, not employees of the City of Chicago. This Agreement is not intended to and does not constitute, create, give rise to, or otherwise recognize an employer-employee relationship of any kind between the City and any personnel provided by Developer.
Developer will not condition, base, or knowingly prejudice or affect any term or aspect of the employment of any personnel provided under this Agreement, or offer employment to any individual to provide services under this Agreement, based upon or because of any political reason or factor, including, without limitation, any individual's political affiliation, membership in a political organization or party, political support or activity, political financial contributions, promises of such political support, activity or financial contributions, or such individual's political sponsorship or recommendation. For purposes of this Agreement, a political organization or party is an identifiable group or entity that has as its primary purpose the support of or opposition to candidates for elected public office. Individual political activities are the activities of individual persons in support of or in opposition to political organizations or parties or candidates for elected public office.
In the event of any communication to Developer by a City employee or City official in violation of paragraph (b) above, or advocating a violation of paragraph (c) above, Developer will, as soon as is reasonably practicable, report such communication to the Hiring Oversight Section of the City's Office of the Inspector General ("IGO Hiring Oversight"), and also to the Commissioner of DPD. Developer will also cooperate with any inquiries by IGO Hiring Oversight or the Shakman Monitor's Office related to this Agreement.

8.26 FOIA and Local Records Act Compliance.
FOIA. Developer acknowledges that the City is subject to the Illinois Freedom of Information Act, 5 ILCS 140/1 et. seq., as amended ("FOIA"). The FOIA requires the City to produce records (very broadly defined in the FOIA) in response to a FOIA request in a very short period of time, unless the records requested are exempt under the FOIA. If Developer receives a request from the City to produce records within the scope of FOIA, that would be otherwise required under this Agreement then Developer covenants to comply with such request within two (2) Business Days of the date of such request. Failure by Developer to timely comply with such request will be a breach of this Agreement.
Exempt Information. Documents that Developer submits to the City under Section 8.20, (Annual Compliance Report) or otherwise during the Term of the Agreement that contain trade secrets and commercial or financial information may be exempt if disclosure would result in competitive harm. However, for documents submitted by Developer to be treated as a trade secret or information that would cause competitive harm, FOIA requires that Developer mark any such documents as "proprietary, privileged or confidential." If Developer marks a document
26

as "proprietary, privileged and confidential", then DPD will evaluate whether such document may be withheld under the FOIA. DPD, in its discretion, will determine whether a document will be exempted from disclosure, and that determination is subject to review by the Illinois Attorney General's Office and/or the courts.

(c) Local Records Act. Developer acknowledges that the City is subject to the Local Records Act, 50 ILCS 205/1 et. seq, as amended (the "Local Records Act"). The Local Records Act provides that public records may only be disposed of as provided in the Local Records Act. If requested by the City, Developer covenants to use its best efforts consistently applied to assist the City in its compliance with the Local Records Act concerning records arising under or in connection with this Agreement and the transactions contemplated in the Agreement.
Employment Plan. The Developer must meet with the Workforce Solutions Unit of DPD to discuss the Project and to formulate an Employment Plan for the Project. In addition, the Developer shall provide in its purchase and sale agreement with the Vertical Developer, a requirement that the Vertical Developer will require through its lease that any subsequent tenant on the Property meet with Workforce Solutions to prepare an Employment Plan.
Continuing Information Agreement. The Developer covenants and agrees as
follows:

(a) For each tax collection year following the date the Certificate is issued pursuant to Section 7.01 hereof, the Developer shall engage a recognized financial consultant to prepare an annual continuing information report (the "Consultant's Report") that sets forth as of its date the following information:
a description of the Redevelopment Area, including all redevelopment agreements relating to the Redevelopment Area;
a description of the Project;
a status update of the Project, including information on construction, occupancy, leasing or sales, as applicable;
a listing of the top ten taxpayers in the Redevelopment Area; and
for the property within the Redevelopment Area from which incremental taxes will be used to pay the City Note(s), by tax codes or PINs, as applicable, for the last five collection years:

the equalized assessed value;
the initial equalized assessed value;
the incremental equalized assessed value;
the composite tax rates;
the available incremental taxes;
the debt service ofthe City Note(s); and
27

(G) the debt service coverage ratio.
The Consultant's Report shall be signed by the consultant and available to the Developer no later than February 1 following each tax collection year. If the Developer fails to obtain the Consultant's report by the date required, DPD may engage its own financial consultant to prepare the report and the cost thereof shall be reimbursed to the City from monies available in the TIF Fund.
Each Consultant's Report shall include in a prominent place the following disclaimer:

"The City's Office of Budget and Management ("OBM") produces five year District Projection Reports for each TIF district in the City for the purpose of evaluating resources and project balances. This information is used by the OBM to determine how much funding has been committed and how much funding is available for potential projects. The reports and the projections including therein are not audited and do not represent a final accounting of funds. The reports are not prepared for investors or as a basis for making investment decisions with respect to any notes, bonds or other debt obligations of the City that are payable from Available Incremental Taxes. Investors in such obligations are cautioned not to rely on any of the information contained in the District Projection Reports."
If any Consultant's Report contains projections, the consultant shall consider the publicly available TIF-wide projections from the OBM and provide an explanation as to the discrepancy, if any, between the consultant's projections and those of OBM. In addition, the consultant shall state in the Consultant's Report all assumptions used in formulating the projections.
(e) The Developer shall cause the following documents to be disseminated through the Electronic Municipal Market Access ("EMMA") system for municipal securities disclosure maintained by the Municipal Securities Rulemaking Board (the "MSRB") or through any other electronic format or system prescribed by the MSRB for purposes of Rule 15c2-12 under the Securities Exchange Act of 1934, as amended:
Within five (5) days of the issuance of the Certificate:

The Redevelopment Agreement, including the specimen of the City Note;
The original feasibility study delivered to DPD; and
On the date of the closing of any third party sale of the City Note or any beneficial interests therein by the Developer: the private placement or limited offering memorandum used by or on behalf of the Developer in connection with the sale.
By February 15 of each year:

All redevelopment agreements with respect to the Redevelopment Area that have been made publicly available by DPD;
Annual financial statements of the Redevelopment Area that have been made publicly available by DPD; and
28

(C) The Consultant's Report.
The Developer shall deliver to DPD each of the documents set forth in subparagraph (e) above on the date such documents are disseminated through EMMA.
The Developer shall be responsible to pay or make provision for all costs and expenses relating to Developer's obligations hereunder, including but not limited to the fees and expenses of the Consultant and the costs of filing with EMMA. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorney's fees, incurred in connection with the enforcement of the provisions of this Agreement. This includes, subject to any limits under applicable law, attorney's fees and legal expenses.

8.29 Survival of Covenants. All warranties, representations, covenants and agreements of Developer contained in this Article Eight and elsewhere in this Agreement are true, accurate and complete at the time of Developer's execution of this Agreement, and will survive the execution, delivery and acceptance by the parties and (except as provided in Article Seven upon the issuance of a Certificate of Completion) will be in effect throughout the Term of the Agreement.
ARTICLE NINE: REPRESENTATIONS, WARRANTIES AND COVENANTS OF CITY
General Covenants. The City represents that it has the authority as a home rule unit of local government to execute and deliver this Agreement and to perform its obligations hereunder.
Survival of Covenants. All warranties, representations, and covenants of the City contained in this Article Nine or elsewhere in this Agreement shall be true, accurate, and complete at the time of the City's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and be in effect throughout the Term of the Agreement.
ARTICLE TEN: DEVELOPER'S EMPLOYMENT OBLIGATIONS
10.01 Employment Opportunity. Developer, on behalf of itself and its successors and assigns, hereby agrees, and will contractually obligate its or their various contractors, subcontractors or any Affiliate of Developer on the Project (collectively, with Developer, such parties are defined herein as the "Employers", and individually defined herein as an "Employer") to agree, that for the Term of this Agreement with respect to Developer and during the period of any other party's provision of services in connection with the construction of the Project:
(a) No Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Chapter 2-160, Section 2-160-010 et seq., Municipal Code, except as otherwise provided by said ordinance and as amended from time-to-time (the "Human Rights Ordinance"). Each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual
29

orientation, military discharge status, marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including without limitation: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Employers, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.
To the greatest extent feasible, each Employer is required to present opportunities for training and employment of low- and moderate-income residents of the City and preferably of the Redevelopment Area; and to provide that contracts for work in connection with the construction of the Project be awarded to business concerns that are located in, or owned in substantial part by persons residing in, the City and preferably in the Redevelopment Area.
Each Employer will comply with all applicable Federal, State and local equal employment and affirmative action statutes, rules and regulations, including but not limited to the City's Human Rights Ordinance and the State Human Rights Act, 775 ILCS 5/1-101 et. seq. (2006 State Bar Edition), as amended, and any subsequent amendments and regulations promulgated thereto.
Each Employer, in order to demonstrate compliance with the terms of this Section, will cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of Federal, State and municipal agencies.
Each Employer will include the foregoing provisions of subparagraphs (a) through (d) in every construction contract entered into in connection with the Project, after the Closing Date, and will require inclusion of these provisions in every subcontract entered into by any subcontractors, after the Closing Date, and every agreement with any Affiliate operating on the Property or at the Project, after the Closing Date, so that each such provision will be binding upon each contractor, subcontractor or Affiliate, as the case may be.
Failure to comply with the employment obligations described in this Section 10.01 will be a basis for the City to pursue remedies under the provisions of Section 15.02 hereof, subject to the cure rights under Section 15.03.
10.02 City Resident Construction Worker Employment Requirement.
(a) Developer agrees for itself and its successors and assigns, and will contractually obligate its General Contractor and will cause the General Contractor to contractually obligate its subcontractors, as applicable, to agree, that during the construction of the Project they will comply with the minimum percentage of total worker hours performed by actual residents of the City as specified in Section 2-92-330 of the Municipal Code of Chicago (at least 50 percent of the total worker hours worked by persons on the site of the Project will be performed by actual residents of the City); provided, however, that in addition to complying with this percentage, Developer, its General Contractor and each subcontractor will be required to make good faith
30

efforts to utilize qualified residents of the City in both unskilled and skilled labor positions. Developer, the General Contractor and each subcontractor will use their respective best efforts to exceed the minimum percentage of hours stated above, and to employ neighborhood residents in connection with the Project.
Developer may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code of Chicago in accordance with standards and procedures developed by the Chief Procurement Officer of the City.
"Actual residents of the City" means persons domiciled within the City. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.
Developer, the General Contractor and each subcontractor will provide for the maintenance of adequate employee residency records to show that actual Chicago residents are employed on the Project. Each Employer will maintain copies of personal documents supportive of every Chicago employee's actual record of residence.
Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) will be submitted to the Commissioner of DPD in triplicate, which will identify clearly the actual residence of every employee on each submitted certified payroll. The first time that an employee's name appears on a payroll, the date that the Employer hired the employee should be written in after the employee's name.
Upon 2 Business Days prior written notice, Developer, the General Contractor and each subcontractor will provide full access to their employment records related to the construction of the Project to the Chief Procurement Officer, the Commissioner of DPD, the Superintendent of the Chicago Police Department, the Inspector General or any duly authorized representative of any of them. Developer, the General Contractor and each subcontractor will maintain all relevant personnel data and records related to the construction of the Project for a period of at least 3 years after final acceptance of the work constituting the Project.
At the direction of DPD, affidavits and other supporting documentation will be required of Developer, the General Contractor and each subcontractor to verify or clarify an employee's actual address when doubt or lack of clarity has arisen.
Good faith efforts on the part of Developer, the General Contractor and each subcontractor to provide utilization of actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) will not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.

(i) When work at the Project is completed, in the event that the City has determined
that Developer has failed to ensure the fulfillment of the requirement of this Article concerning
the worker hours performed by actual residents of the City or failed to report in the manner as
indicated above, the City will thereby be damaged in the failure to provide the benefit of
demonstrable employment to Chicagoans to the degree stipulated in this Article. Therefore, in
such a case of non-compliance, it is agreed that 1/20 of 1 percent (0.0005) of the aggregate
hard construction costs set forth in the Project Budget (the product of .0005 x such aggregate
31

hard construction costs) (as the same will be evidenced by approved contract value for the actual contracts) will be surrendered by Developer to the City in payment for each percentage of shortfall toward the stipulated residency requirement. Failure to report the residency of employees entirely and correctly will result in the surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the certification of payroll data may subject Developer, the General Contractor and/or the subcontractors to prosecution. Any retainage to cover contract performance that may become due to Developer pursuant to Section 2-92-250 of the Municipal Code of Chicago may be withheld by the City pending the Chief Procurement Officer's determination as to whether Developer must surrender damages as provided in this paragraph.
(j) Nothing herein provided will be construed to be a limitation upon the "Notice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order 11246" and "Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement or related documents.
(k) Developer will cause or require the provisions of this Section 10.02 to be included in all construction contracts and subcontracts related to the Project, entered into after the Closing Date.
10.03 Developer's MBEAA/BE Commitment. Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements stated in this section, will contractually obligate the General Contractor to agree that during the construction of the Project:
Consistent with the findings which support, as applicable: (i) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seq., Municipal Code of Chicago (the "Procurement Program"), and (ii) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seq., Municipal Code of Chicago (the "Construction Program", and collectively with the Procurement Program, the "MBEAA/BE Program"), and in reliance upon the provisions of the MBEAA/BE Program to the extent contained in, and as qualified by, the provisions of this Section 10.03, during the course of the Project, at least the following percentages of the MBEAA/BE Budget (as stated in Exhibit D-2) must be expended for contract participation by Minority-Owned Businesses ("MBEs") and by Women-Owned Businesses ("WBEs"):

At least 26 percent by MBEs.
At least six percent by WBEs.
For purposes of this Section 10.03 only:

Developer (and any party to whom a contract is let by Developer in connection with the Project) is deemed a "contractor" and this Agreement (and any contract let by Developer in connection with the Project) is deemed a "contract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670, Municipal Code of Chicago, as applicable.
The term "minority-owned business" or "MBE" shall mean a business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's
32

Department of Procurement Services as a minority-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.

(iii) The term "women-owned business" or "WBE" shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
Consistent with Sections 2-92-440 and 2-92-720, Municipal Code of Chicago, Developer's MBEAA/BE commitment may be achieved in part by Developer's status as an MBE or WBE (but only to the extent of any actual work performed on the Project by Developer) or by a joint venture with one or more MBEs or WBEs (but only to the extent of the lesser of: (i) the MBE or WBE participation in such joint venture or (ii) the amount of any actual work performed on the Project by the MBE or WBE), by Developer utilizing a MBE or a WBE as the General Contractor (but only to the extent of any actual work performed on the Project by the General Contractor), by subcontracting or causing the General Contractor to subcontract a portion of the Project to one or more MBEs or WBEs, or by the purchase of materials or services used in the Project from one or more MBEs or WBEs, or by any combination of the foregoing. Those entities which constitute both a MBE and a WBE shall not be credited more than once with regard to Developer's MBEAA/BE commitment as described in this Section 10.03. In compliance with Section 2-92-730, Municipal Code of Chicago, Developer will not substitute any MBE or WBE General Contractor or subcontractor without the prior written approval of DPD.
Developer must deliver monthly reports to the City's monitoring staff during the Project describing its efforts to achieve compliance with this MBEAA/BE commitment. Such reports will include, inter alia: the name and business address of each MBE and WBE solicited by Developer or the General Contractor to work on the Project, and the responses received from such solicitation; the name and business address of each MBE or WBE actually involved in the Project; a description of the work performed or products or services supplied; the date and amount of such work, product or service; and such other information as may assist the City's monitoring staff in determining Developer's compliance with this MBEAA/BE commitment. Developer will maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with the Project for at least 5 years after completion of the Project, and the City's monitoring staff will have access to all such records maintained by Developer, on 5 Business Days' notice, to allow the City to review Developer's compliance with its commitment to MBEAA/BE participation and the status of any MBE or WBE performing any portion of the Project.
Upon the disqualification of any MBE or WBE General Contractor or subcontractor, if such status was misrepresented by the disqualified party, Developer is obligated to discharge or cause to be discharged the disqualified General Contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (e), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730, Municipal Code of Chicago, as applicable.
Any reduction or waiver of Developer's MBEAA/BE commitment as described in this Section 10.03 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730, Municipal Code of Chicago, as applicable.


33

(g) Prior to the commencement of the Project, Developer shall be required to meet with the City's monitoring staff with regard to Developer's compliance with its obligations under this Section 10.03. The General Contractor and all major subcontractors are required to attend this pre-construction meeting. During said meeting, Developer will demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 10.03, the sufficiency of which will be approved by the City's monitoring staff. During the Project, Developer shall submit the documentation required by this Section 10.03 to the City's monitoring staff, including the following: (i) subcontractor's activity report; (ii) contractor's certification concerning labor standards and prevailing wage requirements; (iii) contractor letter of understanding; (iv) monthly utilization report; (v) authorization for payroll agent; (vi) certified payroll; (vii) evidence that MBEAA/BE contractor associations have been informed of the Project via written notice and hearings; and (viii) evidence of compliance with job creation/job retention requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that Developer is not complying with its obligations under this Section 10.03, will, upon the delivery of written notice to Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to Developer to halt the Project, (2) withhold any further payment of any City Funds to Developer or the General Contractor, or (3) seek any other remedies against Developer available at law or in equity.

ARTICLE ELEVEN: ENVIRONMENTAL MATTERS
11.01 Environmental Matters. Developer hereby represents and warrants to the City that Developer has conducted environmental studies sufficient to conclude that the Project may be constructed, completed and operated in accordance with all Environmental Laws.
Without limiting any other provisions hereof, Developer agrees to indemnify, defend and hold the City harmless from and against any and all losses, liabilities, damages, injuries, costs, expenses or claims of any kind whatsoever including, without limitation, any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any Environmental Laws incurred, suffered by or asserted against the City as a direct or indirect result of any of the following, regardless of whether or not caused by, or within the control of Developer: (i) the presence of any Hazardous Materials on or under, or the escape, seepage, leakage, spillage, emission, discharge or release of any Hazardous Materials from: (A) all or any portion of the Property, or (B) any other real property in which Developer, or any person directly or indirectly controlling, controlled by or under common control with Developer, holds any estate or interest whatsoever (including, without limitation, any property owned by a land trust in which the beneficial interest is owned, in whole or in part, by Developer), or (ii) any liens against the Property permitted or imposed by any Environmental Laws, or any actual or asserted liability or obligation of the City or Developer or any of its Affiliates under any Environmental Laws relating to the Property.

ARTICLE TWELVE: INSURANCE

12.01 Insurance Requirements. Developer's insurance requirements are stated in Schedule B which is hereby incorporated into this Agreement by reference and made a part of this Agreement.




34

ARTICLE THIRTEEN: INDEMNIFICATION

13.01 General Indemnity. Developer agrees to indemnify, pay and hold the City, and its elected and appointed officials, employees, agents and affiliates (individually an "Indemnitee," and collectively the "Indemnitees") harmless from and against, any and all liabilities, obligations, losses, damages (arising out of a third party action against the City), penalties, actions, judgments, suits, claims, costs, expenses and disbursements of any kind or nature whatsoever, (and including, without limitation, the reasonable fees and disbursements of counsel for such Indemnitees in connection with any investigative, administrative or judicial proceeding commenced or threatened, whether or not such Indemnitees shall be designated a party thereto), that may be imposed on, suffered, incurred by or asserted against the Indemnitees by a third party in any manner relating to or arising out of:
Any cost overruns as described in Section 4.06; or
Developer's failure to comply with any of the terms, covenants and conditions contained within this Agreement; or
Developer's or any contractor's failure to pay General Contractors, subcontractors or materialmen in connection with the TIF-Funded Improvements or any other Project improvement; or
the existence of any material misrepresentation or omission in this Agreement, any offering memorandum or information statement or the Redevelopment Plan or any other document related to this Agreement that is the result of information supplied or omitted by Developer or its agents, employees, contractors or persons acting under the control or at the request of Developer or any affiliate of Developer; or
Developer's failure to cure any misrepresentation in this Agreement or any other document or agreement relating hereto; or
any act or omission by Developer or any Affiliate of Developer;
provided, however, that Developer shall have no obligation to an Indemnitee arising from the wanton or willful misconduct of that Indemnitee. To the extent that the preceding sentence may be unenforceable because it is violative of any law or public policy, Developer will contribute the maximum portion that it is permitted to pay and satisfy under applicable law, to the payment and satisfaction of all indemnified liabilities incurred by the Indemnitees or any of them. The provisions of the undertakings and indemnification set out in this Section 13.01 will survive the termination of this Agreement.

ARTICLE FOURTEEN: MAINTAINING RECORDS/RIGHT TO INSPECT

14.01 Books and Records. Developer will keep and maintain separate, complete, accurate and detailed books and records necessary to reflect and fully disclose the total actual costs of the Project and the disposition of all funds from whatever source allocated thereto, and to monitor the Project. All such books, records and other documents, including but not limited to Developer's loan statements, if any, General Contractors' and contractors' sworn statements, general contracts, subcontracts, purchase orders, waivers of lien, paid receipts and invoices, will be available at Developer's offices for inspection, copying, audit and examination by an authorized representative of the City, at Developer's expense. Developer will not pay for
35

salaries or fringe benefits of auditors or examiners. Developer must incorporate this right to inspect, copy, audit and examine all books and records into all contracts entered into by Developer with respect to the Project. The City shall provide three (3) Business Days' prior written notice to Developer in accordance with Section 17. The notice shall indicate the date and time of the inspection. All inspections shall be conducted between the hours of 9:00 a.m. and 5:00 p.m., Monday through Friday.
14.02 Inspection Rights. Upon three (3) Business Days' notice, any authorized representative of the City shall have access to all portions of the Property or the Project during normal business hours for the Term of the Agreement. The City shall provide three (3) Business Days' prior written notice to Developer in accordance with Section 17. The notice shall indicate the date and time of the inspection. All inspections shall be conducted between the hours 9:00 a.m. and 5:00 p.m., Monday through Friday.
ARTICLE FIFTEEN: DEFAULT AND REMEDIES

15.01 Events of Default. Subject to the terms of Section 15.04 below, the occurrence of any one or more of the following events, subject to the provisions of Section 15.03, will constitute an "Event of Default" by Developer hereunder:
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under this Agreement or any related agreement;
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under any other agreement with any person or entity if such failure may have a material adverse effect on Developer's business, property (including the Property or the Project), assets (including the Property or the Project), operations or condition, financial or otherwise;
the making or furnishing by Developer to the City of any representation, warranty, certificate, schedule, report or other communication within or in connection with this Agreement or any related agreement which is untrue or misleading in any material respect;
except as otherwise permitted hereunder, the creation (whether voluntary or involuntary) of, or any attempt by Developer to create, any lien or other encumbrance upon the Property or the Project, including any fixtures now or hereafter attached thereto, other than the Permitted Liens or any Permitted Mortgage, or the making or any attempt to make any levy, seizure or attachment thereof;
the commencement of any proceedings in bankruptcy by or against Developer or Developer's ultimate parent entity, if any, or for the liquidation or reorganization of Developer or Developer's ultimate parent entity, if any, or alleging that Developer or Developer's ultimate parent entity, if any, is insolvent or unable to pay its debts as they mature, or for the readjustment or arrangement of Developer's or Developer's ultimate parent entity's, if any, debts, whether under the United States Bankruptcy Code or under any other state or Federal law, now or hereafter existing for the. relief of debtors, or the commencement of any analogous statutory or non-statutory proceedings involving Developer or Developer's ultimate parent entity, if any; provided, however, that if such commencement of proceedings is involuntary, such action will not constitute an Event of Default unless such proceedings are not dismissed within 60 days after the commencement of such proceedings;
36

the appointment of a receiver or trustee for Developer or Developer's ultimate parent entity, if any, for any substantial part of Developer's or Developer's ultimate parent entity's, if any, assets or the institution of any proceedings for the dissolution, or the full or partial liquidation, or the merger or consolidation, of Developer or Developer's ultimate parent entity, if any; provided, however, that if such appointment or commencement of proceedings is involuntary, such action will not constitute an Event of Default unless such appointment is not revoked or such proceedings are not dismissed within 60 days after the commencement thereof;
the entry of any judgment or order against Developer, not covered by insurance for an amount in excess of $1.0 million which remains unsatisfied or undischarged and in effect for 60 days after such entry without a stay of enforcement or execution;
[reserved];

(i) the dissolution of Developer or Developer's ultimate parent entity, if any;
(j) the institution in any court of a criminal proceeding (other than a misdemeanor) against Developer or any natural person who owns a material interest in Developer, which is not dismissed within 30 days, or the indictment of Developer or any natural person who owns a material interest in Developer, for any crime (other than a misdemeanor);
(k) [reserved]; or
(I) The failure of Developer, or the failure by any party that is a Controlling Person (defined in Section 1-23-010 of the Municipal Code) with respect to Developer, to maintain eligibility to do business with the City in violation of Section 1-23-030 of the Municipal Code; such failure shall render this Agreement voidable or subject to termination, at the option of the Chief Procurement Officer.
For purposes of Section 15.01(j), hereof, a natural person with a material interest in Developer is one owning in excess of seven and a half percent (7.5%) of Developer's or Developer's ultimate parent entity, if any, issued and outstanding ownership shares or interests. For purposes of Section 15.01, "ultimate parent entity" does not mean a person or entity that is a Member of Developer.
15.02 Remedies. Upon the occurrence of an Event of Default, the City may terminate this Agreement and all related agreements, may suspend disbursement of City Funds, and recover the Construction Phase Assistance, provided, however, that, notwithstanding any conflicting provision herein, upon issuance of the City Note, the City's obligation to make payments on the City Note shall be vested without defense to payment (other than insufficiency of Available Incremental Taxes), including as a result of an Event of Default hereunder, and the City's obligation to make payments on the City Note shall survive any termination of this Agreement. Subject to the foregoing, the City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to injunctive relief or the specific performance of the agreements contained herein. To the extent permitted by law, the City may also lien the Property.




37

15.03 Curative Period.
In the event Developer fails to perform a monetary covenant which Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default will not be deemed to have occurred unless Developer or a Lender has failed to perform such monetary covenant within 10 days of its receipt of a written notice from the City specifying that it has failed to perform such monetary covenant.
In the event Developer fails to perform a non-monetary covenant which Developer is required to perform under this Agreement, an Event of Default will not be deemed to have occurred unless Developer or Lender has failed to cure such default within 30 days of its receipt of a written notice from the City specifying the nature of the default; provided, however, with respect to those non-monetary defaults which are not capable of being cured within such 30 day period, Developer will not be deemed to have committed an Event of Default under this Agreement if the Developer or a Lender has commenced to cure the alleged default within such 30 day period and thereafter diligently and continuously prosecutes the cure of such default until the same has been cured.

15.04 Reserved.
ARTICLE SIXTEEN: MORTGAGING OF THE PROJECT
16.01 Mortgaging of the Project. Any and all mortgages or deeds of trust in place as of the date hereof with respect to the Property or Project or any portion thereof are listed on Exhibit I hereto (including but not limited to mortgages made prior to or on the date hereof in connection with Lender Financing, if any) and are referred to herein as the "Existing Mortgages." Any mortgage or deed of trust that Developer may hereafter elect to execute and record or execute and permit to be recorded against the Property or Project or any portion thereof without obtaining the prior written consent of the City is referred to herein as a "New Mortgage." Any mortgage or deed of trust that Developer may hereafter elect to execute and record or execute and permit to be recorded against the Property or Project or any portion thereof with the prior written consent of the City is referred to herein as a "Permitted Mortgage." It is hereby agreed by and between the City and Developer as follows:
If a mortgagee or any other party shall succeed to Developer's interest in the Property or any portion thereof by the exercise of remedies under a mortgage or deed of trust (other than an Existing Mortgage or a Permitted Mortgage) whether by foreclosure or deed in lieu of foreclosure, and in conjunction therewith accepts an assignment of Developer's interest hereunder in accordance with Section 18.15 hereof, the City may, but will not be obligated to, attorn to and recognize such party as the successor in interest to Developer for all purposes under this Agreement and, unless so recognized by the City as the successor in interest, such party will be entitled to no rights or benefits under this Agreement, but such party will be bound by those provisions of this Agreement that are covenants expressly running with the land comprising the Property (as defined herein).
Notwithstanding any provision of this Agreement to the contrary, the exercise of the remedies of foreclosure of a mortgage or any sale of Developer's interest in the Property in connection with a foreclosure, whether by judicial proceedings or by virtue of any power of sale contained in the mortgage, or any conveyance of Developer's interest in the Property to the mortgagee or its nominee or designee by virtue of or in lieu of foreclosure or other appropriate
38

proceedings, or any conveyance of Developer's interest in the Property by the mortgagee or its nominee or designee, or any other exercise of remedies under the documents evidencing Lender Financing shall not require the consent or approval of the City or constitute a breach of any provision of or a default under this Agreement.
If any mortgagee or any other party shall succeed to Developer's interest in the Property or any portion thereof by the exercise of remedies under an Existing Mortgage or a Permitted Mortgage, whether by foreclosure or deed in lieu of foreclosure, and in conjunction therewith accepts an assignment of Developer's interest hereunder in accordance with Section 18.15 hereof, then the City hereby agrees to attorn to and recognize such party as the successor in interest to Developer for all purposes under this Agreement so long as such party accepts all of the executory obligations and liabilities of "Developer" hereunder. Notwithstanding any other provision of this Agreement to the contrary, it is understood and agreed that if such party accepts an assignment of Developer's interest under this Agreement, such party will have no liability under this Agreement for any Event of Default of Developer which occurred prior to the time such party succeeded to the interest of Developer under this Agreement, in which case Developer will be solely responsible. However, if such mortgagee under a Permitted Mortgage or an Existing Mortgage does not expressly accept an assignment of Developer's interest hereunder, such party will be entitled to no rights and benefits under this Agreement, and such party will be bound only by those provisions of this Agreement, if any, which are covenants expressly running with the land.
Prior to the issuance by the City to Developer of a Certificate of Completion under Article Seven hereof, no New Mortgage will be executed with respect to the Property or the Project or any portion thereof without the prior written consent of the Commissioner of DPD. A feature of such consent will be that any New Mortgage will subordinate its mortgage lien to the covenants in favor of the City that run with the land. After the issuance of a Certificate of Completion, consent of the Commissioner of DPD is not required for any such New Mortgage.
ARTICLE SEVENTEEN: NOTICES
17.01 Notices. All notices and any other communications under this Agreement will: (A) be in writing; (B) be sent by: (i) telecopier/fax machine, (ii) delivered by hand, (iii) delivered by an overnight courier service which maintains records confirming the receipt of documents by the receiving party, or (iv) registered or certified U.S. Mail, return receipt requested; (c) be given at the following respective addresses:

If to the City: City of Chicago
Department of Planning and Development
Attn: Commissioner
121 North LaSalle Street, Room 1000
Chicago, IL 60602
312/744-4190 (Main No.)
312/744-2271 (Fax)

With Copies To: City of Chicago
Corporation Counsel
Attn: Finance and Economic Development Division 121 North LaSalle Street, Room 600 Chicago, IL 60602

39

312/744-0200 (Main No.) 312/742-0277 (Fax)
If to Developer: Chicago Neighborhood Initiatives, Inc.
10000 E. 111th Street - 10th Floor Chicago, IL 60628 Attn: David Doig

With Copies To: DLA Piper LLP (US)
203 North LaSalle Street 19th Floor
Chicago, IL 60601
Attn: Mariah F. DiGrino, Esq.

If to Vertical Developer:


Attn:

With Copies To:


Attn:


or at such other address or telecopier/fax or telephone number or to the attention of such other person as the party to whom such information pertains may hereafter specify for the purpose in a notice to the other specifically captioned "Notice of Change of Address" and, (D) be effective or deemed delivered or furnished: (i) if given by telecopier/fax, when such communication is confirmed to have been transmitted to the appropriate telecopier/fax number specified in this section, and confirmation is deposited into the U.S. Mail, postage prepaid to the recipient's address shown herein; (ii) if given by hand delivery or overnight courier service, when left at the address ofthe addressee, properly addressed as provided above.
17.02 Developer Requests for City or DPD Approval. Any request under this Agreement for City or DPD approval submitted by Developer will comply with the following requirements:
be in writing and otherwise comply with the requirements of Section 17.01 (Notices);
expressly state the particular document and section thereof relied on by Developer to request City or DPD approval;
if applicable, note in bold type that failure to respond to Developer's request for approval by a certain date will result in the requested approval being deemed to have been given by the City or DPD;
(d) if applicable, state the outside date for the City's or DPD's response; and


40

(e) be supplemented by a delivery receipt or time/date stamped notice or other documentary evidence showing the date of delivery of Developer's request.
ARTICLE EIGHTEEN: ADDITIONAL PROVISIONS
Amendments. This Agreement and the Schedules and Exhibits attached hereto may not be modified or amended except by an agreement in writing signed by the parties; provided, however, that the City in its sole discretion, may amend, modify or supplement the Redevelopment Plan. For purposes of this Agreement, Developer is only obligated to comply with the Redevelopment Plan as in effect on the date of this Agreement. It is agreed that no material amendment or change to this Agreement shall be made or be effective unless ratified or authorized by an ordinance duly adopted by the City Council. The term "material" for the purpose of this Section 18.01 shall be defined as any deviation from the terms of the Agreement which operates to cancel or otherwise reduce any developmental, construction or job-creating obligations of Developer (including those set forth in Sections 10.02 and 10.03 hereof) by more than five percent (5%) or materially changes the Project site or character of the Project or any activities undertaken by Developer affecting the Project site, the Project, or both, or increases any time agreed for performance by Developer by more than 90 days.
Complete Agreement, Construction, Modification. This Agreement, including any exhibits and the other agreements, documents and instruments referred to herein or contemplated hereby, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all previous negotiations, commitments and writings with respect to such subject matter. This Agreement and the Schedules and Exhibits attached hereto may not be contradicted by evidence of prior, contemporaneous, or subsequent verbal agreements ofthe parties. There are no unwritten verbal agreements between the parties.
Limitation of Liability. No member, elected or appointed official or employee or agent of the City shall be individually, collectively or personally liable to Developer or any successor in interest to Developer in the event of any default or breach by the City or for any amount which may become due to Developer or any successor in interest, from the City or on any obligation under the terms of this Agreement.
Further Assurances. Developer agrees to take such actions, including the execution and delivery of such documents, instruments, petitions and certifications as may become necessary or appropriate to carry out the terms, provisions and intent of this Agreement, and to accomplish the transactions contemplated in this Agreement.
Waivers. No party hereto will be deemed to have waived any rights under this Agreement unless such waiver is given in writing and signed by such party. No delay or omission on the part of a party in exercising any right will operate as a waiver of such right or any other right unless pursuant to the specific terms hereof. A waiver by a party of a provision of this Agreement will not prejudice or constitute a waiver of such party's right otherwise to demand strict compliance with that provision or any other provision of this Agreement. No prior waiver by a party, nor any course of dealing between the parties hereto, will constitute a waiver of any of such parties' rights or of any obligations of any other party hereto as to any future transactions.
Remedies Cumulative. The remedies of a party hereunder are cumulative and the exercise of any one or more of the remedies provided for herein must not be construed as a waiver of any other remedies of such party unless specifically so provided herein.
41

Parties in Interest/No Third Party Beneficiaries. The terms and provisions of this Agreement are binding upon and inure to the benefit of, and are enforceable by, the respective successors and permitted assigns of the parties hereto. This Agreement will not run to the benefit of, or be enforceable by, any person or entity other than a party to this Agreement and its successors and permitted assigns. This Agreement should not be deemed to confer upon third parties any remedy, claim, right of reimbursement or other right. Nothing contained in this Agreement, nor any act of the City, Developer or Vertical Developer, will be deemed or construed by any of the parties hereto or by third persons, to create any relationship of third party beneficiary, principal, agent, limited or general partnership, joint venture, or any association or relationship involving the City or Developer.
Titles and Headings. The Article, section and paragraph headings contained herein are for convenience of reference only and are not intended to limit, vary, define or expand the content thereof.
Counterparts. This Agreement may be executed in any number of counterparts and by different parties hereto in separate counterparts, with the same effect as if all parties had signed the same document. All such counterparts shall be deemed an original, must be construed together and will constitute one and the same instrument.
Counterpart Facsimile Execution. For purposes of executing this Agreement, a document signed and transmitted by facsimile machine will be treated as an original document. The signature of any party thereon will be considered as an original signature, and the document transmitted will be considered to have the same binding legal effect as an original signature on an original document. At the request of either party, any facsimile document will be re-executed by other parties in original form. No party hereto may raise the use of a facsimile machine as a defense to the enforcement of this Agreement or any amendment executed in compliance with this section. This section does not supersede the requirements of Article Seventeen: Notices.
Severability. If any provision of this Agreement, or the application thereof, to any person, place or circumstance, is be held by a court of competent jurisdiction to be invalid, unenforceable or void, the remainder of this Agreement and such provisions as applied to other persons, places and circumstances will remain in full force and effect only if, after excluding the portion deemed to be unenforceable, the remaining terms will provide for the consummation of the transactions contemplated hereby in substantially the same manner as originally set forth herein. In such event, the parties will negotiate, in good faith, a substitute, valid and enforceable provision or agreement which most nearly affects the parties' intent in entering into this Agreement.
Conflict. In the event of a conflict between any provisions of this Agreement and the provisions of the TIF Ordinances in effect as of the date of this Agreement, such ordinance(s) will prevail and control.
Governing Law. This Agreement is governed by and construed in accordance with the internal laws of the State, without regard to its conflicts of law principles.
Form of Documents. All documents required by this Agreement to be submitted, delivered or furnished to the City will be in form and content satisfactory to the City.


42

Assignment. Prior to the issuance by the City to Developer of a Certificate of Completion, Developer may not sell, assign or otherwise transfer its interest in this Agreement in whole or in part without the written consent of the City; provided, however, that Developer may assign, on a collateral basis, the right to receive City Funds to a lender providing Lender Financing, if any, which has been identified to the City as of the Closing Date. Any successor in interest to Developer under this Agreement (excluding any Lender that has been assigned only the right to received City Funds on a collateral basis) will certify in writing to the City its agreement to abide by all remaining executory terms of this Agreement, including but not limited to Section 8.25 (Survival of Covenants) hereof, for the Term of the Agreement. Developer hereby consents to the City's assignment or other transfer of this Agreement at any time in whole or in part.
Binding Effect. This Agreement is binding upon Developer, the City and their respective successors and permitted assigns (as provided herein) and will inure to the benefit of Developer, the City and their respective successors and permitted assigns (as provided herein).
Force Majeure. Neither the City nor Developer nor any successor in interest to either of them will be considered in breach of or in default of its obligations under this Agreement in the event of any delay caused by damage or destruction by fire or other casualty, war, acts of terrorism, imposition of martial law, plague or other illness, bank holidays or stock or commodity exchange closures or wire transfer interruptions, capital controls, civil disorders, rebellions or revolutions, strike, shortage of material, power interruptions or blackouts, cyber-attacks, electromagnetic pulse ("EMP") attacks, fuel shortages or rationing, adverse weather conditions such as, by way of illustration and not limitation, severe rain storms or below freezing temperatures of abnormal degree or for an abnormal duration, tornadoes or cyclones, and other events or conditions beyond the reasonable control of the party affected which in fact interferes with the ability of such party to discharge its obligations hereunder, except to the extent that, the non-performing party is at fault in failing to prevent or causing such default or delay; and provided that such default or delay cannot reasonably be circumvented by the non-performing party through the use of alternative sources, work around plans or other means. The individual or entity relying on this section with respect to any such delay will, upon the occurrence of the event causing such delay, immediately give written notice to the other parties to this Agreement. The individual or entity relying on this section with respect to any such delay may rely on .this section only to the extent of the actual number of days of delay affected by any such events described above.
Exhibits and Schedules. All of the exhibits and schedules to this Agreement are incorporated herein by reference. Any exhibits and schedules to this Agreement will be construed to be an integral part of this Agreement to the same extent as if the same has been set forth verbatim herein.
Business Economic Support Act. Under the Business Economic Support Act (30 ILCS 760/1 et seq. (2006 State Bar Edition), as amended), if Developer is required to provide notice under the WARN Act, Developer will, in addition to the notice required under the WARN Act, provide at the same time a copy of the WARN Act notice to the Governor of the State, the Speaker and Minority Leader of the House of Representatives of the State, the President and Minority Leader of the Senate of State, and the Mayor of each municipality where Developer has locations in the State. Failure by Developer to provide such notice as described above may result in the termination of all or a part of the payment or reimbursement obligations of the City set forth herein.

43

Approval. Wherever this Agreement provides for the approval or consent of the City, DPD or the Commissioner, or any matter is to be to the City's, DPD's or the Commissioner's satisfaction, unless specifically stated to the contrary, such approval, consent or satisfaction shall be made, given or determined by the City, DPD or the Commissioner in writing and in the reasonable discretion thereof. The Commissioner or other person designated by the Mayor of the City shall act for the City or DPD in making all approvals, consents and determinations of satisfaction, granting the Certificate of Completion or otherwise administering this Agreement for the City.
Construction of Words. The use of the singular form of any word herein includes the plural, and vice versa. Masculine, feminine and neuter pronouns are fully interchangeable, where the context so requires. The words "herein", "hereof and "hereunder" and other words of similar import refer to this Agreement as a whole and not to any particular Article, Section or other subdivision. The term "include" (in all its forms) means "include, without limitation" unless the context clearly states otherwise. The word "shall" means "has a duty to."
Date of Performance. If any date for performance under this Agreement falls on a Saturday, Sunday or other day which is a holiday under Federal law or under State Law, the date for such performance will be the next succeeding Business Day.
Survival of Agreements. All covenants and agreements ofthe parties contained in this Agreement will survive the Closing Date in accordance with the provisions of this Agreement.
Equitable Relief. In addition to any other available remedy provided for hereunder, at law or in equity, to the extent that a party fails to comply with the terms of this Agreement, any of the other parties hereto shall be entitled to injunctive relief with respect thereto, without the necessity of posting a bond or other security, the damages for such breach hereby being acknowledged as unascertainable.
Venue and Consent to Jurisdiction. If there is a lawsuit under this Agreement, each party hereto agrees to submit to the jurisdiction of the courts of Cook County, the State of Illinois and the United States District Court for the Northern District of Illinois.
Costs and Expenses. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorneys' fees, incurred in connection with the enforcement of the provisions of this Agreement but only if the City is determined to be the prevailing party in an action for enforcement. This includes, subject to any limits under applicable law, reasonable attorneys' fees and legal expenses, whether or not there is a lawsuit, including reasonable attorneys' fees for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals, and any anticipated post-judgment collection services. Developer also will pay any court costs, in addition to all other sums provided by law.
Purchase of Property and Construction of Whole Foods Facility. Upon completion of certain initial work on the Project, the Vertical Developer intends to purchase the Property and construct a warehouse and distribution facility thereon for Whole Foods, including without limitation the installation of environmental barriers (the "Whole Foods Facility") and lease the Whole Foods Facility to Whole Foods. After conveyance of the Property' to the Vertical Developer, the Vertical Developer will be the owner of the Property and all improvements constructed thereon. In the event that the Vertical Developer fails to so purchase the Property
44

for any reason other than a default by the Developer, or to so construct the Whole Foods Facility thereon by March 1, 2018, subject to Force Majeure, such failure shall be considered an Event of Default by Vertical Developer, and Vertical Developer hereby agrees and shall be obligated to reimburse the City $8,400,000 plus interest. Any amounts owed to the City pursuant to this Section 18.27 are being paid as liquidated damages and in no event shall any liquidated damages or amounts received pursuant to this Section 18.27 be made available to pay debt service owed on the City Note.
Reserved.
Restrictions on Transfer. The City Note(s) may only be offered, sold, pledged or otherwise transferred in principal amounts of not less than $100,000 and only to (a) an institutional "accredited investor" within the meaning of rule 501(a) (1), (2), (3) or (7) under the Securities Act of 1933 (the "Securities Act') that delivers to the City an Investor Letter in the form of Exhibit P hereto, or (b) a person (other than a dealer) who the seller reasonably believes is a "qualified institutional buyer" within the meaning of Rule 144A(a)(1) of the Securities Act. Any holder of the City Note(s) is required to notify any purchaser of the City Note(s) of the resale restrictions referred to above. Notwithstanding the forgoing, if any transfer of the City Note(s) is to a dealer meeting the requirements of Section 144A(a)(1)(ii) or (iii), such dealer shall deliver to the City an Investor Letter with the modifications set forth on the Exhibit P.






[The remainder of this page is intentionally left blank and the signature page follows]
























45

IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment Agreement to be signed on or as ofthe day and year first above written.
CHICAGO NEIGHBORHOOD INITIATIVES, INC., an Illinois not-for-profit corporation


By:

David Doig President

CITY OF CHICAGO

By:

David L. Reifman Commissioner,
Department of Planning and Development

Limited Joinder of Ryan Companies US, Inc.

Ryan Companies US, Inc., a Minnesota corporation ("Vertical Developer"), has caused this Limited Joinder hereto to be signed on behalf of itself, and hereby joins solely for the purpose of making those obligations, covenants and promises of performance which are made by and to the extent applicable to Vertical Developer in Section 18.27 hereof.

Ryan Companies US, Inc. a Minnesota corporation

By:
Name:
Title:
















46

STATE OF ILLINOIS )
) SS
COUNTY OF COOK )

I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that David Doig, personally known to me to be the President of Chicago Neighborhood Initiatives, Inc., an Illinois not-for-profit corporation (the "Developer"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by Developer, as his free and voluntary act and as the free and voluntary act of Developer, for the uses and purposes therein set forth.

GIVEN under my hand and official seal this day of , 2016.





Notary Public


My Commission Expires

(SEAL)


























47

STATE OF )
) SS
COUNTY OF )

I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that
personally known to me to be the of Ryan Companies US,
Inc., a Minnesota corporation ("Vertical Developer"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by Vertical Developer, as his/her free and voluntary act and as the free and voluntary act of Vertical Developer, for the uses and purposes therein set forth.

GIVEN under my hand and official seal this day of , 2016.






































48

STATE OF ILLINOIS )
) SS
COUNTY OF COOK )

I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that David L. Reifman, personally known to me to be the Commissioner of the Department of Planning and Development of the City of Chicago (the "City"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he signed, sealed, and delivered said instrument pursuant to the authority given to him by the City, as his free and voluntary act of the City, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this day of , 2016.





Notary Public


My Commission Expires






























49

NORTH PULLMAN REDEVELOPMENT PROJECT AREA
CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)
Redevelopment Agreement
dated as of , 2016
SCHEDULE A
DEFINITIONS
For purposes of this Agreement the following terms shall have the meanings stated forth
below:
"Acquisition" has the meaning defined in Recital D. "Act" has the meaning defined in Recital B.
"Actual Residents of the City" has the meaning defined for such phrase in Section 10.02(c).
"Affiliate(s)" when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any person or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.
"Agreement" has the meaning defined in the Agreement preamble.
"Annual Compliance Report" shall mean a signed report from the Developer or Vertical Developer to the City identifying the number of employees (both full-time and part-time) employed at the Whole Foods Facility; provided, however, that if Developer or Vertical Developer is unable to secure such information but evidences good faith efforts to secure such information in such signed report, such report shall also constitute an Annual Compliance Report for purposes herein.
"Annual Report of Incremental Taxes" means a signed report from a recognized financial consultant approved by the City that sets forth as of its date (i) a description of the Redevelopment Area, (ii) a description of the Project, (iii) a status update of the Project, including information on construction, occupancy, leasing or sales, as applicable; and (iv) a calculation of the Available Incremental Taxes constituting the source of funds for payment on any City Note, showing for the Property or applicable tax codes the current year equalized assessed value, the initial equalized assessed value, the incremental equalized assessed value and the composite tax rates for the last five years.


50

"Available Incremental Taxes" shall mean Incremental Taxes (as defined below) deposited in the TIF Fund attributable to, and payable from, the following in order: (1) the taxes levied on the Property; (2) increment generated area-wide from the Roseland/Michigan Redevelopment Area, adjusted to exclude the City Fee (defined below), which is currently unallocated to other purposes; and (3) if necessary, increment generated area-wide from the North Pullman Redevelopment Area, adjusted to exclude the City Fee (defined below).
"Bonds" has the meaning defined in Section 8.05.
"Bond Ordinance" means the City Ordinance authorizing the issuance of Bonds. "Business Day" means any day other than Saturday, Sunday or a legal holiday in the
State.

"Certificate of Completion" has the meaning defined in Section 7.01.
"Certification of Expenditure" shall mean any Certification of Expenditure referenced in the City Note pursuant to which the principal amount of the City Note will be established.

"Change Order" means any amendment or modification to the Scope Drawings, the Plans and Specifications, or the Project Budget (all as defined below) within the scope of Section 3.03, 3.04 and 3.05.
"Chicago Neighborhood Initiatives" has the meaning defined in the Agreement Preamble.
"City" has the meaning defined in the Agreement preamble. "City Contract" has the meaning defined in Section 8.01(1).
"City Council" means the City Council ofthe City of Chicago as defined in Recital C. "City Fee" has the meaning defined in Section 4.05(b).
"City Funds" means a) with respect to the Construction Phase Assistance, the funds described in Section 4.03(b) hereof and (b) with respect to the City Note, the funds paid to the registered owner of the City Note.

"City Note" shall mean the Tax Increment Allocation Revenue Note (North Pullman Redevelopment Project Area), Tax Exempt Series A, to be in the form attached hereto as Exhibit M, in an initial principal amount of $7,400,000. Interest on the City Note shall accrue upon issuance at the City Note Interest Rate. The City Note shall be tax exempt and shall have a first lien on the Available Incremental Taxes. Upon issuance, the City will issue an amortization schedule for the City Note. The City Note shall be issued on the Closing Date.
"City Note Interest Rate" shall mean an annual interest rate equal to the median value of the Baa (municipal market data) G.O. Bond rate (20 year) as published by Thompson-Reuters Municipal Market Data ("MMD") for 15 business days prior to the date of issuance of the City Note plus 250 basis points, but in no event exceeding six and one-eighth percent (6.125%) per annum.

51

"City Note Net Proceeds" means the par value of the City Note less Note Issuance
Costs.
"City Group Member" has the meaning defined in Section 8.20. "City Requirements" has the meaning defined in Section 3.07.
"Closing Date" means the date of execution and delivery of this Agreement by all parties hereto, which shall be deemed to be the date appearing in the first paragraph of this Agreement.
"Commissioner" or "Commissioner of DPD" means that individual holding the office and exercising the responsibilities of the Commissioner or Acting Commissioner of the City's Department of Planning and Development and any successor City Department.
"Construction Escrow" shall mean the construction escrow established under the terms of the Escrow Agreement.
"Contribution" and "political contribution" each has the meaning defined in Section 8.24.

"Construction Contract" means that certain contract substantially in the form of Exhibit G, to be entered into between Developer and the General Contractor (as defined below) providing for construction of, among other things, the TIF-Funded Improvements. The parties to this Agreement may agree that the Construction Contract may be provided after Closing Date.
"Construction Phase Assistance" has the meaning defined in Section 4.03(c).
"Construction Program" has the meaning defined in Section 10.03(a).
"Corporation Counsel" means the City's Department of Law.
"Developer" has the meaning defined in the Agreement preamble.
"DPD" has the meaning defined in the Agreement preamble.
"EDS" means the City's Economic Disclosure Statement and Affidavit, on the City's then-current form, whether submitted in paper or via the City's online submission process.

"Employer(s)" has the meaning defined in Section 10.01.

"Environmental Laws" means any and all Federal, State or local statutes, laws, regulations, ordinances, codes, rules, orders, licenses, judgments, decrees or requirements relating to public health and safety and the environment now or hereafter in force, as amended and hereafter amended, including but not limited to: (i) the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. Section 9601 et seq.); (ii) any so-called "Superfund" or "Superlien" law; (iii) the Hazardous Materials Transportation Act (49 U.S.C. Section 1802 et seq.); (iv) the Resource Conservation and Recovery Act (42 U.S.C. Section 6902 et seq.); (v) the Clean Air Act (42 U.S.C. Section 7401 et seq.); (vi) the Clean Water Act (33 U.S.C. Section 1251 et seq.); (vii) the Toxic Substances Control Act (15 U.S.C. Section 2601 et seq.); (viii) the Federal Insecticide, Fungicide and Rodenticide Act (7 U.S.C. Section 136 et seq.); (ix) the Illinois Environmental Protection Act (415 ILCS 5/1 et seq.); and (x) the Municipal Code of Chicago (as defined below), and including the following Municipal
52

Code Sections: 7-28-390, 7-28-440, 11-4-1410, 11-4-1420, 11-4-1450, 11-4-1500, 11-4-1530, 11-4-1550 or 11-4-1560.

"Equity" means net proceeds received by Developer from the sale of the Property to the Vertical Developer (defined below) irrevocably available for the Project, in the amount stated in Section 4.01 hereof, which amount may be increased under Section 4.06 (Cost Overruns), and excluding without limitation funds derived from Lender Financing (as defined below).
"Escrow Agreement" shall mean the Escrow Agreement substantially in the form of Exhibit H-1 establishing a construction escrow for the Project, to be entered into as of even date with this Agreement by and among the Title Company (or an affiliate of the Title Company), Developer, the General Contractor and the City. The Escrow Agreement shall provide among other things, that all draw requests from the Escrow must be accompanied by invoices, cancelled checks, lien waivers, owner's sworn statements, contractor sworn statements, MBEAA/BE subcontractor, contract amounts, and certification letters as a prerequisite to disbursements. The Escrow Agreement shall also provide that the City Note Net Proceeds shall be disbursed prior to the Construction Phase Assistance.
"Event of Default" has the meaning defined in Section 15.01.
"Excess Profit" has the meaning defined in Section 4.05(c).
"Existing Mortgages" has the meaning defined in Section 16.01.
"Financial Statements" means the financial statements regularly prepared by Developer, if any, and including, but not limited to, a balance sheet, income statement and cash-flow statement, in accordance with generally accepted accounting principles and practices consistently applied throughout the appropriate periods, for business enterprises operating for profit in the United States of America, and also includes financial statements (both audited and unaudited) prepared by a certified public accountant, together with any audit opinion and management letter issued by Developer's auditor.

"General Contractor" means the general contractor(s) hired by Developer under Section 6.01.

"Governmental Charge" has the meaning defined in Section 8.16(a)(i).
"Hazardous Materials" means any toxic substance, hazardous substance, hazardous material, hazardous chemical or hazardous, toxic or dangerous waste defined or qualifying as such in (or for.the purposes of) any Environmental Law, or any pollutant or contaminant, and shall include, but not be limited to, petroleum (including crude oil), any radioactive material or by-product material, polychlorinated biphenyls and asbestos in any form or condition.

"Human Rights Ordinance" has the meaning defined in Section 10.01(a).

"Incremental Taxes" means such ad valorem taxes which, pursuant to the North Pullman TIF Adoption Ordinance and Section 5/11-74.4-8(b) of the Act, are allocated to, and when collected are paid to, the Treasurer of the City for deposit by the Treasurer into a special tax allocation fund established to pay Redevelopment Project Costs (as defined below) and obligations incurred in the payment thereof, such fund for the purposes of this Agreement being the North Pullman Redevelopment Project Area Special Tax Allocation Fund, and shall also
53

include funds which the City shall transfer into the North Pullman Redevelopment Project Area Special Tax Allocation Fund pursuant to Section 5/11-74.4-4(q) of the Act from the Roseland/Michigan Area (or any other redevelopment project area allowed by law).
"Indemnitee" and "Indemnitees" have the respective meanings defined in Section 13.01.
"Labor Department" has the meaning defined in Section 8.08.
"Lender" means a provider of Lender Financing.
"Lender Financing" means funds borrowed by Developer from lenders, if any, and available to pay for costs of the Project, in the amount stated in Section 4.01.
"MBE(s)" has the meaning defined in Section 10.03(b).
"MBEAA/BE Program" has the meaning defined in Section 10.03(a).
"Minority-Owned Business" has the meaning defined in Section 10.03(b).
"MOPD" has the meaning defined in Section 3.13.
"Municipal Code" means the Municipal Code of the City of Chicago as presently in effect and as hereafter amended from time to time.
"New Mortgage" has the meaning defined in Section 16.01.
"Non-Governmental Charges" means all non-governmental charges, liens, claims, or encumbrances relating to Developer, the Property or the Project.
"North Pullman Redevelopment Project Area Special Tax Allocation 'Fund" means the special tax allocation fund created by the City in connection with the North Pullman Redevelopment Area into which the Incremental Taxes (as defined below) will be deposited.
"North Pullman TIF Adoption Ordinance" has the meaning stated in Recital C.
"Note Issuance Costs" means those note issuance costs and the costs of the Developer's sale or assignment of the City Note to an investor in accordance with Sections 4.04 and 18.29, identified in Exhibit E in an amount not to exceed $1,003,101.
"Note Sale Date" means the date the Developer sells or assigns the City Note to an investor in accordance with the provisions of Sections 4.04 and 18.29.

"Other Agreement" has the meaning defined in Section 8.24.
"Permitted Liens" means those liens and encumbrances against the Property and/or the Project stated in Exhibit I.

"Permitted Mortgage" has the meaning defined in Section 16.01.
"Plan Adoption Ordinance" has the meaning defined in Recital C.


54

"Plans and Specifications" means final construction documents containing a site plan and working drawings and specifications for the Project, as submitted to the City as the basis for obtaining building permits for the Project.
"Political fundraising committee" has the meaning defined in Section 8.24.
"Prior Expenditure(s)" has the meaning defined in Section 4.04.
"Procurement Program" has the meaning defined in Section 10.03(a).
"Project" has the meaning defined in Recital D.
"Project Budget" means the budget stated in Exhibit D-1, showing the total cost of the Project by line item, as furnished by Developer to DPD, in accordance with Section 3.03.
"Property" has the meaning defined in Recital D.
"Redevelopment Area" means the North Pullman Redevelopment Project Area as legally described in Exhibit A, and defined in Recital C.
"Redevelopment Plan" has the meaning defined in Recital E.
"Redevelopment Project Costs" means redevelopment project costs as defined in Section 5/11-74.4-3(q) of the Act that are included in the budget stated in the Redevelopment Plan or otherwise referenced in the Redevelopment Plan.

"Requisition Form" has the meaning defined in Section 4.03(a).
"Reserve Escrow" shall mean an escrow to cure payment shortfalls if there are insufficient Available Incremental Taxes to make payments on the City Note.
"Scope Drawings" means preliminary construction documents containing a site plan and preliminary drawings and specifications for the Project.
"State" means the State of Illinois as defined in Recital A.
"Survey" means a plat of survey in the most recently revised form of ALTA/ACSM land title survey of the Property meeting the 2011 minimum standard detail requirements for ALTA/ACSM Land Title Surveys, effective February 23, 2011, dated within 75 days prior to the Closing Date, acceptable in form and content to the City and the Title Company, prepared by a surveyor registered in the State, certified to the City and the Title Company, and indicating whether the Property is in a flood hazard area as identified by the United States Federal Emergency Management Agency (and any updates thereof to reflect improvements to the Property as required by the City or the lender(s) providing Lender Financing, if any).
"Term of the Agreement" means the period of time commencing on the Closing Date and ending on December 31, 2033 (such date being the last.date ofthe calendar year in which taxes levied in the year that is 23 years after the creation of the North Pullman Redevelopment Area are paid) or such later date as the North Pullman Redevelopment Area expires in accordance with the North Pullman TIF Ordinances.

55

"TIF District Administration Fee" has the meaning described in Section 4.05(b).
"TIF Fund" shall mean the special tax allocation fund created by the City in connection with the Redevelopment Area into which the Incremental Taxes will be deposited.

"TIF-Funded Improvements" means those improvements of the Project and Note Issuance Costs listed in Exhibit E, all of which have been determined by the City prior to the date hereof to be qualified Redevelopment Project Costs and costs that are eligible under the Redevelopment Plan for reimbursement by the City out of the City Funds, subject to the terms of this Agreement.
"TIF Ordinances" has the meaning stated in Recital C.
"Title Company" means Chicago Title Insurance Company or such other title insurance company agreed to by Developer and the City.
"Title Policy" means a title insurance policy in the most recently revised ALTA or equivalent form, showing Developer as the insured, noting the recording of this Agreement as an encumbrance against the Property, and a subordination agreement in favor of the City with respect to previously recorded liens against the Property related to Lender Financing, if any, issued by the Title Company.
"WARN Act" means the Worker Adjustment and Retraining Notification Act (29 U.S.C. Section 2101 et seq.).
"WBE(s)" has the meaning defined in Section 10.03(b).
"Women-Owned Business" has the meaning defined in Section 10.03(b).
























56

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
SCHEDULE B
ARTICLE TWELVE: INSURANCE REQUIREMENTS

12.01 Insurance. Developer will provide and maintain, or cause to be provided and maintained, at Developer's own expense, during the Term of this Agreement, the insurance coverages and requirements specified below, insuring all operations related to the Agreement.
Prior to Execution and Delivery of this Agreement

(i) Workers' Compensation and Employers Liability Insurance
Workers Compensation and Employers Liability Insurance, as prescribed by applicable law covering all employees who are to provide a service under this Agreement in statutorily prescribed limits and Employers Liability coverage with limits of not less than $100,000 each accident or illness.
(ii) Commercial General Liability Insurance (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $1,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations, independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
Construction. Prior to the construction of any portion of the Project, Developer will cause its architects, contractors, sub-contractors, project managers and other parties constructing the Project to procure and maintain the following kinds and amounts of insurance:

(i) Workers Compensation and Employers Liability Insurance
Workers Compensation and Employers Liability Insurance, as prescribed by applicable law covering all employees who are to provide a service under this Agreement in statutorily prescribed limits and Employers Liability coverage with limits of not less than $500,000 each accident or illness.


57

Commercial General Liability Insurance (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $2,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include- the following: All premises and operations, products/completed operations (for a minimum of 2 years following Project completion), explosion, collapse, underground, independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
Automobile Liability Insurance (Primary and Umbrella)
When any motor vehicles (owned, non-owned and hired) are used in connection with work to be performed, Developer must cause each contractor to provide Automobile Liability Insurance with limits of not less than $2,000,000 per occurrence for bodily injury and property damage. The City is to be named as an additional insured on a primary, non-contributory basis.
Railroad Protective Liability Insurance
When any work is to be done adjacent to or on railroad or rail transit property or within 50 feet of railroad or rail transit property, contractor must provide, or cause to be provided with respect to the operations that the contractor performs, Railroad Protective Liability Insurance in the name of railroad or transit entity. The policy must have limits of not less than $2,000,000 per occurrence and $6,000,000 in the aggregate for losses arising out of injuries to or death of all persons, and for damage to or destruction of property, including the loss of use thereof.
All Risk Builders Risk Insurance
When the contractor undertakes any construction, including improvements, betterments, and/or repairs, Developer must cause each contractor to provide, or cause to be provided All Risk Blanket Builders Risk Insurance at replacement cost for materials, supplies, equipment, machinery and fixtures that are or will be part of the Project. Coverages shall include but are not limited to the following: collapse, boiler and machinery if applicable, flood including surface water backup. The City will be named as an additional insured and loss payee.
Professional Liability

When any architects, engineers, construction managers or other professional consultants perform work in connection with this Agreement, Developer must cause such parties to maintain Professional Liability Insurance covering acts, errors, or omissions which shall be maintained with limits of not less than $1,000,000. Coverage must include contractual liability. When policies are renewed or replaced, the policy
58

retroactive date must coincide with, or precede, start of work performed in connection with this Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of 2 years.
Valuable Papers Insurance
When any plans, designs, drawings, specifications and documents are produced or used under this Agreement by Developer's architects, contractors, sub-contractors, project managers and other parties constructing the Project, Developer will cause such parties to maintain Valuable Papers Insurance which must be maintained in an amount to insure against any loss whatsoever, and which must have limits sufficient to pay for the re-creations and reconstruction of such records.
Contractor's Pollution Liability

When any environmental remediation work is performed which may cause a pollution exposure, Developer will cause the party performing such work to maintain contractor's Pollution Liability insurance with limits of not less than $1,000,000 insuring bodily injury, property damage and environmental remediation, cleanup costs and disposal. When policies are renewed, the policy retroactive date must coincide with or precede, start of work on the Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of 1 year. The City is to be named as an additional insured on a primary, non-contributory basis.
Blanket Crime
Developer must provide Crime Insurance or equivalent covering all persons handling funds under this Agreement, against loss by dishonesty, robbery, destruction or disappearance, computer fraud, credit card forgery, and other related crime risks. The policy limit must be written to cover losses in the amount of the maximum monies collected or received and in the possession of Developer at any given time.

Other Insurance Required.
Prior to the execution and delivery of this Agreement and during construction of the Project, All Risk Property Insurance in the amount of the full replacement value of the Project. The City is to be named as an additional insured.
Post-construction, throughout the Term of the Agreement, All Risk Property Insurance, including improvements and betterments in the amount of full replacement value of the Project. Coverage extensions shall include business interruption/loss of rents, flood and boiler and machinery, if applicable. The City is to be named as an additional insured.


59

(d) Other Requirements
Developer will furnish the City of Chicago, Department of Planning and Development, City Hall, Room 1000, 121 North LaSalle Street, Chicago, Illinois 60602, original Certificates of Insurance evidencing the required coverage to be in force on the date of this Agreement, and Renewal Certificates of Insurance, or such similar evidence, if the coverages have an expiration or renewal date occurring during the Term of this Agreement. Developer will submit evidence of insurance on the City Insurance Certificate Form or commercial equivalent prior to closing. The receipt of any certificate does not constitute agreement by the City that the insurance requirements in the Agreement have been fully met or that the insurance policies indicated on the certificate are in compliance with all Agreement requirements. The failure of the City to obtain certificates or other insurance evidence from Developer must not be deemed to be a waiver by the City. Developer will advise all insurers of the Agreement provisions regarding insurance. Non-conforming insurance will not relieve Developer of the obligation to provide insurance as specified herein. Nonfulfillment of the insurance conditions may constitute a violation of the Agreement, and the City retains the right to terminate this Agreement until proper evidence of insurance is provided.
The insurance will provide for 60 days prior written notice to be given to the City in the event coverage is substantially changed, canceled, or non-renewed.
Any and all deductibles or self-insured retentions on referenced insurance coverages are borne by Developer.
Developer agrees that insurers must waive rights of subrogation against the City, its employees, elected officials, agents, or representatives.
Developer expressly understands and agrees that any coverages and limits furnished by Developer will in no way limit Developer's liabilities and responsibilities specified within the Agreement documents or by law.
Developer expressly understands and agrees that Developer's insurance is primary and any insurance or self-insurance programs maintained by the City will not contribute with insurance provided by Developer under the Agreement.
The required insurance will not be limited by any limitations expressed in the indemnification language herein or any limitation placed on the indemnity therein given as a matter of law.
Developer will require its general contractor and all subcontractors to provide the insurance required herein or Developer may provide the coverages for the contractor or subcontractors. All contractors and subcontractors will be subject to the same requirements of Developer unless otherwise specified herein.

60

If Developer, contractor or subcontractor desires additional coverages, Developer, contractor and each subcontractor will be responsible for the acquisition and cost of such additional protection.
The City Risk Management Department maintains the right to modify, delete, alter or change these requirements, so long as such action does not, without Developer's written consent, increase such requirements.














































61

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT A
REDEVELOPMENT AREA LEGAL DESCRIPTION A legal description of the Redevelopment Area is attached to this exhibit cover sheet. [NOT ATTACHED FOR PURPOSES OF ORDINANCE]





































62

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)
Redevelopment Agreement
dated as of , 2016
EXHIBIT B
LEGAL DESCRIPTION OF THE PROPERTY
A PARCEL OF LAND IN PART OF THE WEST HALF OF SECTION 14, IN TOWNSHIP 37 NORTH, RANGE 14 EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS, DESCRIBED AS FOLLOWS:

COMMENCING AT THE POINT OF INTERSECTION OF THE EAST LINE OF THE SAID SOUTHEAST QUARTER OF SECTION 15, OR THE WEST LINE OF SAID WEST HALF OF SECTION 14, WITH THE NORTH LINE OF 111TH STREET (BEING A LINE DRAWN PARALLEL WITH AND 50 FEET NORTH OF THE SOUTH LINE OF SAID SECTIONS 14 AND 15); RUNNING THENCE WEST ALONG SAID NORTH LINE, A DISTANCE OF 365.73 FEET TO A POINT ON A CURVE 75.00 FEET EASTERLY AND CONCENTRIC WITH THE EASTERLY LINE OF CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF WAY (30 FEET WIDE, FORMERLY THE PULLMAN RAILROAD); THENCE NORTHEASTERLY ALONG LINES 75.00 FEET EASTERLY AND CONCENTRIC OR PARALLEL WITH SAID EASTERLY LINE FOR THE NEXT FIVE COURSES; (1) THENCE NORTHEASTERLY 279.86 FEET, ALONG THE ARC OF A NON-TANGENT CIRCLE TO THE RIGHT, HAVING A RADIUS OF 626.50 FEET AND WHOSE CHORD BEARS NORTH 29 DEGREES 20 MINUTES 17 SECONDS EAST, 277.54 FEET TO A POINT OF TANGENCY; (2) THENCE NORTH 42 DEGREES 08 MINUTES 06 SECONDS EAST, 61.73 FEET TO A POINT OF CURVATURE; (3) THENCE NORTHEASTERLY 217.98 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE LEFT, HAVING A RADIUS OF 1356.57 FEET AND WHOSE CHORD BEARS NORTH 37 DEGREES 31 MINUTES 54 SECONDS EAST, 217.75 FEET TO A POINT OF COMPOUND CURVATURE; (4) THENCE NORTHEASTERLY 115.05 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE LEFT, HAVING A RADIUS OF 345.04 FEET AND WHOSE CHORD BEARS NORTH 23 DEGREES 22 MINUTES 34 SECONDS EAST, 114.52 FEET TO A POINT OF TANGENCY; (5) THENCE NORTH 13 DEGREES 49 MINUTES 25 SECONDS EAST, 1688.44 FEET TO THE NORTHWEST CORNER OF LOT 5 IN PULLMAN PARK -PHASE 2 RECORDED DECEMBER 6, 2013 AS DOCUMENT 1334039070, ALSO BEING THE POINT OF BEGINNING;

THENCE CONTINUING NORTH 13 DEGREES 49 MINUTES 25 SECONDS EAST, ALONG SAID PARALLEL LINE, 578.86 FEET TO A POINT OF CURVATURE; THENCE NORTHERLY 259.52 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE RIGHT, HAVING A RADIUS OF 2656.00 FEET AND WHOSE CHORD BEARS NORTH 16 DEGREES 37
63

MINUTES 22 SECONDS EAST, 259.42 FEET TO A POINT ON A NON-TANGENT LINE; THENCE SOUTH 68 DEGREES 24 MINUTES 59 SECONDS EAST, 919.31 FEET; TO A POINT ON THE WEST LINE OF PULLMAN PARK - PHASE 1 RECORDED JUNE 19, 2011 AS DOCUMENT 1120029049; THENCE SOUTH 21 DEGREES 35 MINUTES 01 SECONDS WEST, ALONG SAID WEST LINE, 832.00 FEET TO THE NORTHEAST CORNER OF LOT 5 IN PULLMAN PARK - PHASE 2 RECORDED DECEMBER 6, 2013 AS DOCUMENT 1334039070; THENCE NORTH 68 DEGREES 24 MINUTES 59 SECONDS WEST, ALONG THE NORTH LINE OF SAID LOT 5, A DISTANCE OF 818.71 FEET TO THE POINT OF BEGINNING, IN COOK COUNTY, ILLINOIS.











































64

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of 2016
EXHIBIT B-1

LEGAL DESCRIPTION OF THE ROAD EXTENSION PARCEL
A PARCEL OF LAND IN PART OF THE WEST HALF OF SECTION 14, IN TOWNSHIP 37 NORTH, RANGE 14 EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS, DESCRIBED AS FOLLOWS:

COMMENCING AT THE POINT OF INTERSECTION OF THE EAST LINE OF THE SAID SOUTHEAST QUARTER OF SECTION 15, OR THE WEST LINE OF SAID WEST HALF OF SECTION 14, WITH THE NORTH LINE OF 111TH STREET (BEING A LINE DRAWN PARALLEL WITH AND 50 FEET NORTH OF THE SOUTH LINE OF SAID SECTIONS 14 AND 15); RUNNING THENCE WEST ALONG SAID NORTH LINE, A DISTANCE OF 365.73 FEET TO A POINT ON A CURVE 75.00 FEET EASTERLY AND CONCENTRIC WITH THE EASTERLY LINE OF CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF WAY (30 FEET WIDE, FORMERLY THE PULLMAN RAILROAD); THENCE NORTHEASTERLY ALONG LINES 75.00 FEET EASTERLY AND CONCENTRIC OR PARALLEL WITH SAID EASTERLY LINE FOR THE NEXT FIVE COURSES; (1) THENCE NORTHEASTERLY 279.86 FEET, ALONG THE ARC OF A NON-TANGENT CIRCLE TO THE RIGHT, HAVING A RADIUS OF 626.50 FEET AND WHOSE CHORD BEARS NORTH 29 DEGREES 20 MINUTES 17 SECONDS EAST, 277.54 FEET TO A POINT OF TANGENCY; (2) THENCE NORTH 42 DEGREES 08 MINUTES 06 SECONDS EAST, 61.73 FEET TO A POINT OF CURVATURE; (3) THENCE NORTHEASTERLY 217.98 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE LEFT, HAVING A RADIUS OF 1356.57 FEET AND WHOSE CHORD BEARS NORTH 37 DEGREES 31 MINUTES 54 SECONDS.EAST, 217.75 FEET TO A POINT OF COMPOUND CURVATURE; (4) THENCE NORTHEASTERLY 115.05 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE LEFT, HAVING A RADIUS OF 345.04 FEET AND WHOSE CHORD BEARS NORTH 23 DEGREES 22 MINUTES 34 SECONDS EAST, 114.52 FEET TO A POINT OF TANGENCY; (5) THENCE NORTH 13 DEGREES 49 MINUTES 25 SECONDS EAST, 1688.44 FEET TO THE NORTHWEST CORNER OF LOT 5 IN PULLMAN PARK -PHASE 2 RECORDED DECEMBER 6, 2013 AS DOCUMENT 1334039070, ALSO BEING THE POINT OF BEGINNING;

THENCE NORTH 68 DEGREES 24 MINUTES 59 SECONDS WEST, ALONG THE WESTERLY EXTENSION OF THE NORTH LINE OF SAID LOT 5, A DISTANCE OF 69.64 FEET TO A POINT ON A LINE 6.00 FEET EASTERLY AND CONCENTRIC WITH THE EASTERLY LINE OF SAID CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF
65

WAY; THENCE NORTH 13 DEGREES 49 MINUTES 25 SECONDS EAST, ALONG SAID PARALLEL LINE, 569.45 FEET TO A POINT OF CURVATURE; THENCE NORTHERLY 268.87 FEET, ALONG THE ARC OF A TANGENT CIRCLE TO THE RIGHT BEING 6.00 FEET SOUTHEASTERLY OF AND CONCENTRIC WITH THE EASTERLY LINE OF SAID CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF WAY, HAVING A RADIUS OF 2725.00 FEET AND WHOSE CHORD BEARS NORTH 16 DEGREES 39 MINUTES 00 SECONDS EAST, 268.76 FEET TO A POINT ON A NON-TANGENT LINE; THENCE SOUTH 68 DEGREES 24 MINUTES 59 SECONDS EAST, 69.05 FEET TO A POINT ON A CURVE THAT IS 75.00 FEET EASTERLY AND CONCENTRIC WITH THE EASTERLY LINE OF SAID CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF WAY; THENCE SOUTHERLY 259.52 FEET, ALONG SAID CONCENTRIC CURVE BEING THE ARC OF A TANGENT CIRCLE TO THE LEFT, HAVING A RADIUS OF 2656.00 FEET AND WHOSE CHORD BEARS SOUTH 16 DEGREES 37 MINUTES 22 SECONDS WEST, 259.42 FEET TO A POINT OF TANGENCY; THENCE SOUTH 13 DEGREES 49 MINUTES 25 SECONDS WEST, ALONG A LINE 75.00 FEET EASTERLY AND PARALLEL WITH THE EASTERLY LINE OF SAID CHICAGO, ROCK ISLAND AND PACIFIC RAILROAD RIGHT OF WAY, 578.86 FEET TO THE POINT OF BEGINNING, IN COOK COUNTY, ILLINOIS.

































66

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016

EXHIBIT C RESERVED







































67

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT D-1 PROJECT BUDGET

Land Acquisition
Hard Costs
Miscellaneous Hard Costs Pad Construction Site Prep- Earthwork Construction Management Hard Cost Contingency Total Hard Costs

$560,939 $630,053
$2,617,442 $200,000 $344,971
$4,353,405

Soft Costs/Fees
Architecture and Engineering
Legal, Title, Closing Costs
Environmental Consulting
Geotech/Soils/Testing
Insurance
Appraisal
Utility Consulting
Entitlement- site planning
IEPA Fees
TIF Consulting
Financing Costs
Developer Fee
Permits
Contingency
Total Soft Costs

$125,000 $450,000 $150,000 $110,000 $55,000 $5,000 $25,000 $10,000 $10,000 $25,000 $150,000 $233,470 $85,000 $140,000 $1,573,470

Total Project Budget








68

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016

EXHIBIT D-2

CONSTRUCTION (MBEAA/BE) BUDGET

Hard Costs $2,468,259 Soft Costs $125,000 MBEA/VBE Project Budget $2,593,259

MBE Total at 26% $674,247 WBE Total at 6% $155,596

































69

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT E
SCHEDULE OF TIF-FUNDED IMPROVEMENTS
Total Acquisition
Hard Costs
Miscellaneous Hard Costs Pad Construction Site Prep- Earthwork Construction Management Hard Cost Contingency Total Hard Costs

$560,939 $455,053
$2,617,442 $200,000 $344,971
$4,178,405

Soft Costs/Fees Architecture and Engineering Legal, Title, Closing Costs Environmental Consulting Geotech/Soils/Testing Insurance Appraisal
Entitlement- site planning IEPA Fees Financing Costs Permits Contingency Total Soft Costs
Amount
$125,000 $400,000 $150,000 $110,000 $55,000 $5,000 $10,000 $10,000 $45,000 $85,000 $140,000 $1,135,000

Note Issuance Costs
Reserve
Costs of Issuance Total Issuance Costs
Amount
$740,000 $263,101 $1,003,101

Total TIF Funded Improvements*

*Notwithstanding the total of TIF-Funded Improvements or the amount of TIF-eligible costs, the assistance to be provided by the City shall not exceed $8,400,000.



70

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)
Redevelopment Agreement
dated as of 2016
EXHIBIT F
RESERVED









































71

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)
Redevelopment Agreement
dated as of , 2016
EXHIBIT G
ACKNOWLEDGEMENT OF PHASE 1B NOTEHOLDER
A form of the Phase 1B Noteholder's acknowledgement is attached to this exhibit cover
sheet.


[NOT ATTACHED FOR PURPOSES OF ORDINANCE]



































72

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT H
ESCROW AGREEMENT
A form of Escrow Agreement is attached to this exhibit cover sheet.
[NOT ATTACHED FOR PURPOSES OF ORDINANCE]





































73

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of 2016
EXHIBIT I
PERMITTED LIENS
Liens or encumbrances against the Property (and related improvements):
Those matters set forth as Schedule B title exceptions in the owner's title insurance policy issued by the Title Company as ofthe Closing Date, but only so long as applicable title endorsements issued in conjunction therewith on the date hereof, if any, continue to remain in full force and effect;

Other:
































74

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT J
FORM OF OPINION OF DEVELOPER'S COUNSEL
[To be retyped on Developer's Counsel's letterhead]
2016
City of Chicago City Hall, Room 600 121 North LaSalle Street Chicago, Illinois 60602

Attention: Corporation Counsel

Ladies and Gentlemen:

We have acted as special counsel to Chicago Neighborhood Initiatives, Inc., an Illinois not-for-profit company ("Developer"), in connection with a certain North Pullman Redevelopment Project Area, Chicago Neighborhood Initiatives, Inc. Redevelopment Agreement (Whole Foods Warehouse and Distribution Center) (the "Agreement") of even date herewith, by and between Developer and the City of Chicago, a municipal corporation (the "City"), with a limited joinder by Ryan Companies US, Inc., a Minnesota corporation. The Agreement relates to the provision of tax increment financing assistance to Developer from the City for Developer's redevelopment of certain property located in the vicinity of 111th Street and Ellis Avenue (the "Property") located in the North Pullman Redevelopment Project Area (the "Project"). In that capacity, we have examined, among other things, the Agreement.
In rendering this opinion, we also have examined the original or certified, conformed or photostatic copies of: Judgment searches and other due diligence searches for Illinois with respect to Developer performed by Corporation Service Company and delivered to the
Corporation Counsel on (the "Searches"); Developer's Illinois Not-for-Profit
Articles of Incorporation certified by the Illinois Secretary of State (the "Illinois Secretary") on
; Bylaws of Developer (amended and restated effective July 1, 2010) (the
"Bylaws"); Developer's Certificate of Good Standing in the State of Illinois certified by the Illinois
Secretary on ; the certificate of Developer attached hereto as Exhibit A and
referred to herein (the "Certificate"); records of corporate proceedings of Developer relating to the Project and the Agreement; and such legal matters as we have deemed necessary or relevant for purposes of issuing the opinions hereinafter expressed (collectively the "Documents").


75

In all such examinations, and for the purposes of this opinion, we have assumed: (i) the genuineness of all signatures (other than those of Developer) on the Agreement and Documents; (ii) the authenticity and completeness of documents submitted to us as originals; (iii) the authenticity, completeness and conformity to the originals of all documents submitted to us as certified, conformed or photostatic copies; (iv) that all natural persons who executed the Agreement individually or in a representative capacity were legally competent at the time of execution; (v) that all material terms and conditions of the relationship between Developer and any other parties to the Agreement are correctly and completely reflected in the Agreement; and (vi) that the execution and delivery of the Agreement and other documents reviewed by us, and the entry into and performance of the transactions contemplated by the Agreement by all parties other than Developer have been duly authorized by all necessary action and that the Agreement and other documents that we have reviewed have constituted the valid and binding obligations of all parties thereto other than Developer and are enforceable against such parties in accordance with their respective terms.

Based upon the foregoing, and subject to the assumptions, qualifications and limitations set forth herein, it is our opinion that:
Developer is a not-for-profit company duly formed, legally existing and in good standing under the laws of Illinois and has full corporate power and authority to undertake the Project and to carry on its business as presently conducted on the Property.
The Agreement (a) has been properly authorized, executed and delivered by or on behalf of Developer, (b) constitutes the legal, valid and binding obligation of Developer, and (c) is enforceable against Developer in accordance with its terms.
Developer has all requisite corporate power, right, and authority to execute and deliver the Agreement and to perform its obligations thereunder. Such execution, delivery and undertaking of performance will not conflict with, or result in a violation of, Developer's Articles of Incorporation or Bylaws. Based solely on the Certificate, such execution, delivery and undertaking of performance (provided Developer performs in accordance with the terms and conditions of the Agreement) will not result in a material breach or other violation of any of the terms, conditions or provisions of any agreement, instrument or document to which Developer is a party or by which Developer or its properties are bound, or any law, regulation, order, writ, injunction or decree of any court or governmental or regulatory authority. Such execution and delivery, to our knowledge (based on the Certificate and without further investigation), will not: (a) result in the creation of any lien, charge or encumbrance on any property, other than the Property, or assets of Developer, (b) result in a violation of any of the terms, conditions or provisions of any order, writ, injunction or decree entered against Developer by any court, governmental or regulatory authority, (c) constitute grounds for the acceleration of the maturity of any agreements or other instruments to-which Developer is a party or by which any of the property of Developer may be bound, or (d) conflict with, constitute an event of default under, or result in a violation of the provisions of any agreement or other instrument of which we have knowledge to which Developer is a party, or by which the properties or assets of Developer are bound.
No authorizations, approvals or consents of, or filings or registrations with, or the giving of notice to, any person or any governmental or regulatory authority or agency of the State of Illinois or any political subdivision thereof are necessary for the execution and

76

delivery of the Agreement by Developer or for the validity or enforceability thereof against Developer that have not already been obtained or effected.
A federal or state court sitting in the State of Illinois and applying the choice of law provisions of the State of Illinois would enforce the choice of law provisions contained in the Agreement and apply the law of the State of Illinois to the transactions evidenced thereby.
To our knowledge, relying solely on the Searches and the Certificate, and except as set forth in the Searches (copies of which have been delivered to the City), and without further investigation, there are no judgments, or legal, administrative or other governmental proceedings pending or threatened before any court or governmental agency against Developer that would materially and adversely affect its ability to perform its obligations under the Agreement.
To our knowledge, relying solely on the Certificate, without further investigation, there is no default by Developer with respect to any indenture, loan agreement, mortgage, deed of trust, note or any other agreement or instrument to which Developer is a party or by which Developer is bound, a default under which would have a material adverse effect on Developer or its business except as disclosed in the Certificate.
To our knowledge, relying solely on the Certificate, without further investigation, as of the date of this opinion, there are no options, rights or commitments to acquire or transfer any ownership interests of Developer except as permitted under the Agreement or except as provided in the Developer's Bylaws.
To our knowledge, relying solely on the Certificate and the Searches, and except as set forth in the Searches, and without further investigation, Developer is not in default with respect to any order, writ, injunction or decree of any court, government or regulatory authority, or in default of or under any law, order, regulation or demand of any governmental agency or instrumentality, a default under which would have a material adverse effect on Developer or its business.
The opinions set forth above are subject to the following qualifications:
Wherever we indicate that our opinion with respect to the existence or absence of facts is based on our knowledge, our opinion is based solely on (A) the actual knowledge of the attorneys currently with the firm who have represented Developer in connection with the transactions contemplated by the Agreement and of any other attorneys presently in our firm whom we have determined are likely, in the course of representing said party, to have knowledge of the matters covered by this opinion, (B) the representations and warranties of Developer contained in the Agreement, and (C) the Certificate as issued by Developer, and we have not undertaken any independent investigation (and we have not made or caused to be made any review of any court file or indices except as described above with respect to the Searches) and no inference as to our knowledge should be drawn from our representation of Developer or otherwise. However, we know of no facts which lead us to believe such factual matters set forth in the Certificate are untrue or inaccurate;
Your ability to enforce the Agreement may be limited by applicable bankruptcy, reorganization, insolvency, moratorium, fraudulent conveyance or transfer and other
77

similar laws now or hereafter in effect relating to or affecting creditors' rights generally, and their interpretation by courts of appropriate jurisdiction;
Enforcement of your rights and remedies may be limited by general principles of equity, regardless of whether such enforcement is considered in a proceeding in equity or at law, and the availability of equitable remedies or equitable defenses would be subject to the discretion of the court requested to grant such remedies or allow such defenses; and further, in this regard, we have assumed that you will exercise your rights and remedies under the Agreement in good faith and in circumstances and a manner which are commercially reasonable;
Certain provisions of the Agreement may be rendered unenforceable or limited by applicable laws and judicial decisions;
If, and to the extent, the Agreement is construed to provide for the payment of interest on interest, such provisions may be unenforceable under Bowman v. Neeley, 137 III. 443 (1891) and other cases to the same effect;

We express no opinion with respect to provisions in the Agreement which purport to (A) confer, waive or consent to the jurisdiction of any court, (B) provide for service of process except in accordance with applicable law, (C) waive any right granted by statutory or common law, or (D) require indemnification or contribution for liabilities under the provisions of any Federal or state securities law or in respect to the negligent or wrongful conduct of the indemnified party or its representatives or agents; and
We call your attention to the fact that although we represent Developer as special counsel in connection with the subject transaction, we do not represent Developer generally, and our engagement has been limited to the specific matters as to which we have been consulted.
This opinion is limited to the laws of the United States (except as set forth below) and the laws of the State of Illinois and political subdivisions (as to matters set forth in Paragraphs 3 and 4 only) thereof in effect on the date hereof as they presently apply. We shall have no continuing obligations to inform you of changes in law or fact subsequent to the date hereof or of facts of which we become aware after the date hereof.
We express no opinion as to matters of title or priority or perfection of liens or security interests with regard to real and personal property. We understand that, with respect to all real and personal property security interests intended to be created by the Agreement and the priority of the liens thereof, you will rely on a title insurance policy provided to Developer and other searches as you deem adequate, and, accordingly, we express no opinion to such matters.
We have not reviewed and do not opine as to: (i) compliance by the Project with applicable health, fire, safety, building, environmental, subdivision laws, ordinances, codes, rules or regulations, (ii) ERISA laws, rules and regulations, or (iii) Federal or state taxation, banking, securities, USA Patriot Act or other anti-terrorist or "blue sky" laws, rules or regulations.
This opinion is limited to the matters set forth herein. This opinion is provided to you as a legal opinion only and not as a guaranty or warranty of the matter discussed herein or the documents referred to herein. No opinion may be inferred or implied beyond the matters
78

expressly contained herein, and no portion of this opinion may be quoted or in any other way published without the express written consent of the undersigned. This opinion is rendered solely for your benefit and no other person or entity shall be entitled to rely on any matter set forth herein without the express written consent of the undersigned.
Very truly yours,















































79

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT K
RESERVED









































80

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT L
FORM OF PAYMENT AND PERFORMANCE BOND A form of payment and performance bond is attached to this exhibit cover [NOT ATTACHED FOR PURPOSES OF ORDINANCE]





































81

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT M FORM OF NOTE
INVESTMENT IN THIS NOTE INVOLVES A HIGH DEGREE OF RISK. IT IS SUITABLE ONLY FOR PERSONS WHO ARE ABLE TO BEAR THE ECONOMIC RISKS OF THIS INVESTMENT, INCLUDING TOTAL LOSS. NO ASSURANCE CAN BE PROVIDED THAT THE HOLDER OF THIS NOTE WILL NOT LOSE ITS ENTIRE INVESTMENT IN THIS NOTE. SEE "NOTEHOLDER RISKS" ATTACHED TO THIS NOTE.

THIS NOTE IS SUITABLE ONLY FOR PERSONS WHO HAVE NO NEED FOR LIQUIDITY. THIS NOTE MAY ONLY BE TRANSFERRED IN THE MANNER AND SUBJECT TO THE LIMITATIONS PROVIDED IN THE REDEVELOPMENT AGREEMENT.

THE CITY DOES NOT ENDORSE PROJECTIONS OF ANY KIND FROM ANY SOURCE AS TO THE SUFFICIENCY OF ALLOCATED AVAILABLE INCREMENTAL TAXES TO PAY PRINCIPAL OF AND INTEREST ON THIS NOTE. INVESTORS WHO RELY ON SUCH PROJECTIONS DO SO AT THEIR OWN RISK.

PRINCIPAL OF AND INTEREST ON THIS NOTE ARE PAYABLE SOLELY FROM ALLOCATED AVAILABLE INCREMENTAL TAXES ON DEPOSIT IN THE
[ ] ACCOUNT, AS DEFINED IN THE HEREINAFTER DEFINED
REDEVELOPMENT AGREEMENT. THE HOLDER OF THIS NOTE ACCEPTS THE RISK THAT THE AMOUNT OF ALLOCATED AVAILABLE INCREMENTAL TAXES MAY NOT BE SUFFICIENT TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE.

REGISTERED


MAXIMUM AMOUNT
NO. R-1 $7,400,000

UNITED STATES OF AMERICA STATE OF ILLINOIS COUNTY OF COOK CITY OF CHICAGO TAX INCREMENT ALLOCATION REVENUE NOTE (NORTH PULLMAN REDEVELOPMENT PROJECT AREA) TAXABLE SERIES A

Registered Owner: Chicago Neighborhood Initiatives, Inc.

82

Interest Rate: per annum
Maturity Date: , [the same maturity date as the current termination date of the
North Pullman Redevelopment Area, with no future extension of the term allowed]
KNOW ALL PERSONS BY THESE PRESENTS, that the City of Chicago, Cook County, Illinois (the "City"), hereby acknowledges itself to owe and for value received promises to pay to the Registered Owner identified above, or registered assigns as hereinafter provided, on or before the Maturity Date identified above, but solely from the sources hereinafter identified, the principal amount of this Note, in accordance with the ordinance hereinafter referred to, in the
principal amount of $ and to pay the Registered Owner interest on that amount at the
Interest Rate per year specified above from the date of the advance. Interest shall be computed on the basis of a 360-day year of twelve 30-day months. Principal of and interest on this Note, payable solely from the Available Incremental Taxes (as defined in the hereinafter defined Redevelopment Agreement), is due March 1 of each year until the earlier of Maturity or until this Note is paid in full. Payments shall first be applied to interest. A principal amortization schedule is an exhibit to this Note.
The principal of and interest on this Note are payable in lawful money of the United States of America, and shall be made to the Registered Owner hereof as shown on the registration books of the City maintained by the Comptroller of the City, as registrar and paying agent (the "Registrar"), at the close of business on the fifteenth day of the month immediately prior to the applicable payment, maturity or redemption date, and shall be paid by check or draft of the Registrar, payable in lawful money of the United States of America, mailed to the address of such Registered Owner as it appears on such registration books or at such other address furnished in writing by such Registered Owner to the Registrar; provided, that the final installment of principal and accrued but unpaid interest will be payable solely upon presentation of this Note at the principal office of the Registrar in Chicago, Illinois or as otherwise directed by the City.
This Note is issued by the City in the principal amount of $ for the
purpose of paying the costs of certain eligible redevelopment project costs incurred by Chicago Neighborhood Initiatives, Inc. (the "Project"), which were [acquired], [constructed] and [installed]
in connection with the development of an approximately [ acre/ square foot]
site/building in the Redevelopment Project Area (the "Project Area") in the
City, all in accordance with the Constitution and the laws of the State of Illinois, and particularly the Tax Increment Allocation Redevelopment Act (65 ILCS 5/11-74.4-1 et seg.) (the "TIF Act") ,
83

the Local Government Debt Reform Act (30 ILCS 350/1 et secj.) and an Ordinance adopted by
the City Council of the City on , (the "Ordinance"), in all respects as by law
required.
The City has assigned and pledged certain rights, title and interest of the City in and to certain incremental ad valorem tax revenues from the Project Area which the City is entitled to receive pursuant to the TIF Act and the Ordinance, in order to pay the principal of and interest of this Note. Reference is hereby made to the aforesaid Ordinance and the Redevelopment Agreement for a description, among others, with respect to the determination, custody and application of said revenues, the nature and extent of such security with respect to this Note and the terms and conditions under which this Note is issued and secured. THIS NOTE IS A SPECIAL LIMITED OBLIGATION OF THE CITY, AND PRINCIPAL OF AND INTEREST ON THIS NOTE ARE PAYABLE SOLELY FROM ALLOCATED AVAILABLE INCREMENTAL
TAXES ON DEPOSIT IN THE ACCOUNT OF THE TIF FUND (AS DEFINED
IN THE REDEVELOPMENT AGREEMENT) AFTER PAYMENT OF ALL OBLIGATIONS HAVING A PRIORITY OVER THIS NOTE, IF ANY. THE HOLDER OF THIS NOTE ACCEPTS THE RISK THAT THE AMOUNT OF ALLOCATED AVAILABLE INCREMENTAL TAXES MAY NOT BE SUFFICIENT TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE. THIS NOTE SHALL NOT BE DEEMED TO CONSTITUTE AN INDEBTEDNESS OR A LOAN AGAINST THE GENERAL TAXING POWERS OR CREDIT OF THE CITY WITHIN THE MEANING OF ANY CONSTITUTIONAL OR STATUTORY PROVISION. THE REGISTERED OWNER OF THIS NOTE SHALL NOT HAVE THE RIGHT TO COMPEL ANY EXERCISE OF THE TAXING POWER OF THE CITY, THE STATE OF ILLINOIS OR ANY POLITICAL SUBDIVISION THEREOF TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE. This Note shall be subject to partial redemption from unexpended proceeds in the Construction
Escrow on or after , as more fully described in the Redevelopment Agreement. The
principal of this Note also is subject to redemption on any date after 60 months following issuance of this Note, as a whole or in part, at a redemption price of 100% of the principal amount thereof being redeemed. There shall be no prepayment penalty. Notice of any such redemption shall be sent by registered or certified mail not less than five (5) days nor more than sixty (60) days prior to the date fixed for redemption to the registered owner of this Note at the address shown on the registration books of the City maintained by the Registrar or at such other address as is furnished in writing by such Registered Owner to the Registrar.



84

This Note is issued in fully registered form in the denomination of its outstanding principal amount. This Note may not be exchanged for a like aggregate principal amount of notes or other denominations.
THIS NOTE MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT TO (I) AN INSTITUTIONAL "ACCREDITED INVESTOR" WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) or (7) UNDER THE SECURITIES ACT OF 1933 (THE "SECURITIES ACT") THAT DELIVERS TO THE CITY AN INVESTOR LETTER IN THE FORM OF EXHIBIT P TO THE REDEVELOPMENT AGREEMENT REFERENCED BELOW, OR (II) A PERSON (OTHER THAN A DEALER) WHOM THE SELLER REASONABLY BELIEVES IS A "QUALIFIED INSTITUTIONAL BUYER" WITHIN THE MEANING OF RULE 144A(a)(1) UNDER THE SECURITIES ACT. ANY HOLDER OF THIS NOTE IS REQUIRED TO NOTIFY ANY POTENTIAL PURCHASER OF THIS NOTE OF THE RESALE RESTRICTIONS REFERRED TO ABOVE. This Note is transferable by the Registered Owner hereof in person or by its attorney duly authorized in writing at the principal office of the Registrar in Chicago, Illinois, but only in the manner and subject to the limitations provided in the Ordinance, and upon surrender and cancellation of this Note. Upon such transfer, a new Note of authorized denomination of the same maturity and for the same aggregate principal amount will be issued to the transferee in exchange herefor. The Registrar shall not be required to transfer this Note during the period beginning at the close of business on the fifteenth day of the month immediately prior to the maturity date of this Note nor to transfer this Note after notice calling this Note or a portion hereof for redemption has been mailed, nor during a period of five (5) days next preceding mailing of a notice of redemption of this Note. Such transfer shall be in accordance with the form at the end of this Note.
This Note hereby authorized shall be executed and delivered as the Ordinance and the Redevelopment Agreement provide.
Pursuant to the Redevelopment Agreement dated as of [ , ] between the
City and the Developer (the "Redevelopment Agreement"), the Developer has agreed to [acquire] and [construct] the Project and shall be reimbursed from amounts on deposit in the Construction Escrow under the Act for certain eligible redevelopment project costs for the [construction of certain facilities] related to the Project on behalf of the City.
The City shall be obligated to make payments under this Note if an Event of Default (as defined in the Redevelopment Agreement), or condition or event that with notice or the passage of time or both would constitute an Event of Default, has occurred. Such rights shall survive any transfer of this Note.
85

The City and the Registrar may deem and treat the Registered Owner hereof as the absolute owner hereof for the purpose of receiving payment of or on account of principal hereof and for all other purposes and neither the City nor the Registrar shall be affected by any notice to the contrary, unless transferred in accordance with the provisions hereof.
This Note may be transferred only in the manner and subject to the limitations provided in Section 18.29 ofthe Redevelopment Agreement.
It is hereby certified and recited that all conditions, acts and things required by law to exist, to happen, or to be done or performed precedent to and in the issuance of this Note did exist, have happened, have been done and have been performed in regular and due form and time as required by law; that the issuance of this Note, together with all other obligations of the City, does not exceed or violate any constitutional or statutory limitation applicable to the City.
This Note shall not be valid or become obligatory for any purpose until the certificate of authentication hereon shall have been signed by the Registrar.


[THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]






























86

IN WITNESS WHEREOF, the City of Chicago, Cook County, Illinois, by its City Council,
has caused its official seal to be imprinted by facsimile hereon or hereunto affixed, and has
caused this Note to be signed by the duly authorized signature of the Mayor and attested by the
duly authorized signature of the City Clerk of the City, all as of , .


Mayor



(SEAL) Attest:
Registrar and Paying Agent Comptroller of the City of Chicago, Cook County, Illinois

City Clerk

CERTIFICATE OF
AUTHENTICATION

This Note is described in the within mentioned Ordinance and is the Tax Increment Allocation Revenue Note (North Pullman Redevelopment Project Area), Taxable Series A, of the City of Chicago, Cook County, Illinois.


Comptroller Date:

[The following "Noteholder Risks" constitutes an integral part of this Note.]

NOTEHOLDER RISKS

The purchase of or investment in the Note involves certain risks. Each prospective holder or purchaser of the Note, or any interest therein, should make an independent evaluation of the financial and business risks associated with holding or having an investment interest in the Note. Certain of these risks are set forth below. The following summary is not intended to be complete and does not purport to identify all possible risks that should be considered by prospective holders of the Note or any interests therein. Capitalized terms used herein have the meanings set forth in the Note.

All prospective holders of the Note are urged to consult with their financial adviser and legal counsel before acquiring the Note or any interest therein.

Loss of Investment

Investment in the Note involves a high degree of risk. It is suitable only for persons who are able to bear the economic risks of the investment, including total loss. No assurance can be provided that prospective holders of the Note will not lose their entire investment in the Note.

Lack of Liquidity

The Note is suitable only for persons who have no need for liquidity. The transferability of the Note is restricted. The Note may only be transferred in the manner and subject to the limitations provided in the Redevelopment Agreement. Investors in the Note must be prepared to hold the Note until the maturity of the Note.

Reliance on Projections

The City does not endorse projections of any kind from any source as to the sufficiency of Available Incremental Taxes to pay principal of and interest on the Note. Investors who rely on any such projections do so at their own risk.

The City's Office of Budget and Management ("OBM") produces five-year projection reports for each TIF district in the City for the purpose of evaluating resources and project balances ("District Projection Reports"). This information, which is currently publicly available, is used by the OBM to determine how much funding has been committed and how much funding is available for potential projects. The District Projection Reports and the projections included therein are not audited and do not represent a final accounting of funds. The District Projection Reports are not prepared for investors or as a basis for making investment decisions with respect to any notes, bonds or other debt obligations of the City that are payable from Incremental Taxes, including the Note. Prospective investors in the Note are cautioned not to rely on any of the information contained in the District Projection Reports.

Limited Obligations

THE NOTE IS A SPECIAL LIMITED OBLIGATION OF THE CITY PAYABLE SOLELY FROM THE ALLOCATED AVAILABLE INCREMENTAL TAXES AFTER PAYMENT OF ALL OBLIGATIONS HAVING A PRIORITY OVER THE NOTE, IF ANY, AND SHALL BE A VALID
88

CLAIM ONLY AGAINST SAID SOURCES. THE NOTE DOES NOT CONSTITUTE AN INDEBTEDNESS OR A LOAN AGAINST THE GENERAL TAXING POWERS OR CREDIT OF THE- CITY, WITHIN THE MEANING OF ANY CONSTITUTIONAL OR STATUTORY PROVISION. THE NOTEHOLDER HAS NO RIGHT TO COMPEL ANY EXERCISE OF THE TAXING POWER OF THE CITY, THE STATE OF ILLINOIS OR ANY POLITICAL SUBDIVISION THEREOF TO PAY THE PRINCIPAL OF OR INTEREST ON THE NOTE.

There can be no assurance that Available Incremental Taxes will be sufficient for payment of amounts due and owing on the Note.

Limited Information

The Note was issued to the Developer under the Redevelopment Agreement as part of a commercial transaction negotiated by the Developer and the City. [The Developer] engaged a [consultant] to deliver a [feasibility report][projection report] to the City in connection with the Project, which included certain information about the Project Area, the Project and historical and projected Available Incremental Taxes. The report contained information as ofits date only, and neither the Developer nor any other party have any obligation to update the report as of any subsequent date.
The City is under no continuing obligation to provide to any holder or prospective holder of the Note, or to post to the Electronic Municipal Market Access System of the Municipal Securities Rulemaking Board or any other website, any current or updated information with respect to the Project Area, the Project, the historical and projected Available Incremental Taxes or the Note. The City does not prepare or have readily available any current or updated information about the Project Area, the Project or the Available Incremental Taxes.

Unavailability of City Funds

The City is not obligated to pay principal of or interest on the Note in any year in which there are inadequate Available Incremental Taxes. The City is obligated to pay the amount of any unpaid principal or accrued interest in any subsequent year but only to the extent of the availability of Available Incremental Taxes for those subsequent years. If, on the maturity date of the Note, any outstanding unpaid principal or interest on the Note exists for any reason, including without limitation the inadequacy of Available Incremental Taxes, such outstanding principal and/or interest will be forgiven in full and the City will have no further obligation to pay such outstanding amount. In such event, there would be no further payments of principal or interest in respect ofthe Note.

Risk of Failure to Maintain Levels of Assessed Valuation

There can be no assurance that the equalized assessed value of the Project property will remain the same throughout the term of the Note. Furthermore, the successful petition or application of any owner for the reduction of the assessed value of the Project property or any other properties in the Project Area may cause the equalized assessed value of the Property to be less than the originally projected equalized assessed value. If any time during the term of the Note the actual equalized assessed value is less than what was projected, the generation of Available Incremental Taxes for payment on the Note is likely to be significantly impaired.



89

Risk of Change in Incremental Taxes

Prospective holders of the Note should carefully consider, among other factors, the risks associated with the ultimate generation of Available Incremental Taxes in the Project Area. These risks include, but are not limited to, the following:
Property tax rates are calculated by the Cook County Clerk for numerous funds of a number of taxing districts that tax all or part of the property in the Project Area. A reduction in the tax levies by the affected taxing districts may have an adverse effect on the Available Incremental Taxes.
Further changes may be made in the real property tax system by the State of Illinois or Cook County. Such changes could include various property tax rollbacks, abatements, exemptions, changes in the ratio of assessment, or relief measures, limitations on the amount or percent of increase in tax levies by taxing districts, or other measures that would limit the tax levy amount that could be extended to the property within the Project Area and, consequently, the projected Available Incremental Taxes generated. For example, if Illinois adopted practices used in other states, the property tax system could be changed so that schools would be financed from a source other than property taxes. This type of change could have a significant adverse effect upon Available Incremental Taxes.
Cook County's methodology and procedures used to assess the value of property may be altered resulting in a potentially reduced or altered valuation in a particular year or succession of years.

FUTURE LEGISLATION, REGULATIONS, GOVERNMENTAL OR JUDICIAL INTERPRETATION OF REGULATIONS OR LEGISLATION OR PRACTICES AND PROCEDURES RELATED TO PROPERTY TAX ASSESSMENT, LEVY, COLLECTIONS OR DISTRIBUTION COULD HAVE A MATERIAL EFFECT ON THE CALCULATION OR AVAILABILITY OF INCREMENTAL TAXES COLLECTED OR DISTRIBUTED AND THEREFORE A MATERIAL EFFECT ON THE AMOUNT OF AVAILABLE INCREMENTAL TAXES FOR PAYMENT OF PRINCIPAL OF AND INTEREST ON THE NOTE.

Changes in Multiplier and Tax Rate

The equalization factor annually determined by the Illinois Department of Revenue for properties located within Cook County (commonly referred to as the "multiplier") may vary substantially in future years. A decrease in the multiplier would reduce the equalized assessed value of the taxable real property in the Project Area and, therefore, the Available Incremental Taxes available to pay principal of and interest on the Note. The future tax rates of the units of local government levying taxes in the Project Area either individually or on a composite basis, may differ from their historical levels. Any decrease in the composite tax rate of the governmental units would decrease the amount of Available Incremental Taxes available to pay principal of and interest on the Note. Any decrease in the composite tax rate of the governmental units could occur in future years as a result of various factors, including, but not limited to, one or more of the following: (a) reduced governmental costs; (b) constitutional or statutory spending or tax rate limitations; or (c) governmental reorganization or consolidation.




90

Economic Risks Affecting Incremental Taxes

Changing economic circumstances or events in the Project Area may result in reductions in Available Incremental Taxes available to pay principal of and interest on the Note. Relocations of major property owners to sites outside the Project Area or sales of major properties to tax-exempt entities could reduce the assessed valuation of the real properties in the Project Area. Substantial damage to or destruction of improvements within the Project Area could cause a material decline in assessed valuation and impair the ability of the taxpayers in the Project Area to pay their respective portions of real estate taxes. Similarly, there can be no assurance that the improvements in the Project Area will be sufficiently insured under fire and extended coverage insurance policies. Even if such insurance is sufficient, the proceeds thereof will not be assigned as security for the payment of real estate taxes or to secure payment of the Note. In addition, any insurance proceeds may not be sufficient to repair or rebuild said improvements. The restoration of such improvements may be delayed by other factors, or the terms of then-applicable mortgage financing could require the application of insurance proceeds to the reduction of mortgage balances. Any of the foregoing circumstances could result in the assessed valuation of property in the Project Area remaining depressed for an unknown period of time and decrease the amount of Available Incremental Taxes available to pay principal of and interest on the Note.

Results of operation of properties within the Project Area depend, in part, on sales, leases, rental rates and occupancy levels, which may be adversely affected by competition, suitability of the properties located in the Project Area, local unemployment, availability of transportation, neighborhood changes, crime levels in the Project Area, vandalism, rising operating costs and similar factors. Poor operating results of properties within the Project Area may cause delinquencies in the payment of real estate taxes, reduce assessed valuations and increase the risk of foreclosures. Successful petitions by taxpayers to reduce their assessed valuations could adversely affect Available Incremental Taxes available for payment of principal of and interest on the Note.

Failure to Sell or Lease Property

At the time of Note issuance, the redevelopment plan called for the Developer [to sell/lease to commercial or industrial enterprises/retailers prior to/in connection with] completion of the Project. The slowdown, stoppage or failure of the Developer to complete the Project and to successfully sell/lease the Project could delay or reduce the amount of Available Incremental Taxes generated in the Project Area. Such delay or reduction could lead to a default in payments of the principal of and interest on the Note.

Reliance on Primary Taxpayers

If one or only a few property owners within the Project Area are responsible for generating a substantial amount of the Incremental Taxes, the generation of Available Incremental Taxes could be significantly adversely affected if such owner or owners and/or their tenants discontinue or curtail their businesses or terminate or default on their leases, and substitutes or replacements cannot be made on a timely basis.

Force Majeure Conditions
Riots, civil disturbances, vandalism, fires, and natural disasters or other "Acts of God" affecting the conditions and viability of the Project Area may reduce or eliminate the receipt of
91

Incremental Taxes which would result in the reduction or elimination of Available Incremental Taxes to pay principal of and interest on the Note.

Contiguous Project Areas

The Project Area is, or may become, contiguous with other redevelopment areas designated by the City pursuant to the TIF Act. The TIF Act allows the City to expend Incremental Taxes collected from the Project Area which are in excess of the amounts required in each year to pay and secure obligations issued and project costs incurred with respect to the Project Area to pay for costs eligible for payment under the TIF Act which are incurred in such contiguous areas. In the event Incremental Taxes from the Project Area in excess of Available Incremental Taxes, along with the amounts required to (i) pay principal and interest coming due on the Note in any year, and (ii) be deposited in other funds and accounts maintained under the Redevelopment Agreement, are allocated to a contiguous project redevelopment area, such excess Incremental Taxes will not be available to remedy any future failure to pay principal of and interest on the Note.

Risk of Delay in Payment

The failure of current or future owners of real property in the Project Area to remit property taxes to Cook County when due or the failure of Cook County to timely remit Incremental Taxes to the City could result in insufficient Available Incremental Taxes being available to pay principal of or interest on the Note when due.

Delays in Exercising Remedies

The enforceability of the Note is subject to applicable bankruptcy laws, equitable principles affecting the enforcement of creditors' rights generally and of liens securing such rights, and the police powers of the State of Illinois and its political subdivisions. Because of delays inherent in obtaining judicial remedies, it should not be assumed that these remedies could be accomplished rapidly.

Remedies available to the Noteholder may be limited by a variety of factors and may be inadequate to assure the timely payment of principal of and interest on the Note, or to preserve the tax-exempt status of the Note. The Note is not subject to acceleration due to payment default. Lack of remedies may entail risks of delay, limitation, or modification of the rights of the Noteholder. Judicial remedies, such as foreclosure and enforcement of covenants, are subject to exercise of judicial discretion.

Risk of Transferee Becoming a Debtor in Bankruptcy

If a transferee of the Note were to become a debtor under the United States Bankruptcy Code or applicable state laws, a creditor or trustee in bankruptcy of the transferee might argue that the sale of the Note by the transferee constituted a fraudulent conveyance or a pledge of the Note rather than a sale. If such positions were accepted by a court, then delays in principal and interest payments to the Noteholder could occur or reductions in the amounts of such payments could result. Additionally, if the transfer of the Note is re-characterized as a pledge, then a tax lien, governmental lien or other lien created by operation of law on the property of the transferee could have priority over the holder's interest in the Note.


92

Loss of Tax Exemption

Interest on the Note could become includible in gross income for federal income tax purposes retroactive to the date of issuance of the Note as a result of a failure of the City to comply with certain provisions of the Internal Revenue Code of 1986, as amended (the "Code"). An event of taxability does not trigger a mandatory redemption of the Note, and the Note will remain outstanding to maturity or until redeemed.
THE ABOVE IS NOT INTENDED TO BE A COMPREHENSIVE DISCUSSION OF ALL POTENTIAL RISKS ASSOCIATED WITH THE NOTE.
*****









































93

PRINCIPAL PAYMENT RECORD
DATE OF PAYMENT PRINCIPAL PAYMENT PRINCIPAL BALANCE DUE


















































94

" (ASSIGNMENT)
FOR VALUE RECEIVED, the undersigned sells, assigns and transfers unto [NAME OF ASSIGNEE] the within Note and does hereby irrevocably constitute and appoint
attorney to transfer the said Note on the books kept for
registration thereof with full power of substitution in the premises.


Dated:
Registered Owner

NOTICE: The signature to this assignment must correspond with the name of the Registered Owner as it appears upon the face of the Note in every particular, without alteration or enlargement or any change whatever.

Signature Guaranteed:
Notice: Signature(s) must be guaranteed by a member of the New York Stock Exchange or a commercial bank or trust company.

Consented to by:

CITY OF CHICAGO
DEPARTMENT OF PLANNING AND DEVELOPMENT
BY:
ITS:

CITY OF CHICAGO DEPARTMENT OF FINANCE

BY:

ITS:











95

CERTIFICATION OF EXPENDITURE
(Closing Date)
To: Registered Owner
Re: City of Chicago, Cook County, Illinois (the "City")
$ Tax Increment Allocation Revenue Note
( Redevelopment Project, [Taxable] Series [A])
(the "Redevelopment Note")
This Certification is submitted to you, Registered Owner of the Redevelopment Note, pursuant to the Ordinance of the City authorizing the execution of the Redevelopment Note
adopted by the City Council of the City on , (the AOrdinance"). All terms
used herein shall have the same meaning as when used in the Ordinance.

The City hereby certifies that $ is advanced as principal under the
Redevelopment Note as of the date hereof. Such amount has been properly incurred, is a proper charge made or to be made in connection with the redevelopment project costs defined in the. Ordinance and has not been the basis of any previous principal advance. As of the date
hereof, the outstanding principal balance under the Redevelopment Note is $
, including the amount of this Certificate and less payment made on the Redevelopment
Note.

IN WITNESS WHEREOF, the City has caused this Certification to be signed on its behalf as of (Closing Date).

CITY OF CHICAGO


By:
Commissioner
Department of Planning and Development


AUTHENTICATED BY:



REGISTRAR











96

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT N
CITY FUNDS REQUISITION FORM
A form of the City Funds Requisition Form is attached to this exhibit cover sheet.







































97

REQUISITION FORM

STATE OF ILLINOIS )
) SS
COUNTY OF COOK )

The affiant, Chicago Neighborhood Initiatives, Inc. ("Developer"), hereby certifies that with respect to that certain Chicago Neighborhood Initiatives, Inc. Redevelopment Agreement
between Developer and the City of Chicago dated as of , 2016 (the
"Redevelopment Agreement"):
Expenditures for the Project, in the total amount of $ , have
been made:
This paragraph B sets forth and is a true and complete statement of all costs of
TIF-Funded Improvements for the Project reimbursed by the City to date:
$
Developer requests reimbursement for "the following cost of TIF-Funded
Improvements: $
None of the costs referenced in paragraph C above have been previously reimbursed by the City.
Developer hereby certifies to the City that, as of the date hereof:

Except as described in the attached certificate, the representations and warranties contained in the Redevelopment Agreement are true and correct and Developer is in compliance with all applicable covenants contained herein.
No event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default, exists or has occurred.
All capitalized terms which are not defined herein have the meanings given such terms in the Redevelopment Agreement.
Chicago Neighborhood Initiatives, Inc., an Illinois not-for-profit corporation

By:
Printed
Name:
Title:

Subscribed and sworn before me this
day of .


My commission expires:


98

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement
dated as of , 2016
EXHIBIT O
FORM OF SUBORDINATION AGREEMENT
This document prepared by and after recording return to:
Keith A. May, Esq.
City of Chicago
Department of Law
121 North LaSalle Street, Room 600
Chicago, IL 60602


SUBORDINATION AGREEMENT

This Subordination Agreement ("Agreement") is made and entered into as of the
day of , between the City of Chicago by and through its Department of
Planning and Development (the "City"), [Name Lender], a [national banking association] (the "Lender").


WITNESSETH:

WHEREAS, [Describe Project - use language form Recitals of Redevelopment
agreement] the an Illinois [limited liability company] (the
"Developer"), has purchased certain property located within the
Redevelopment Project Area at , Chicago, Illinois and legally
described on the Exhibit hereto (the "Property"), in order to located on the
Property through the following activities: (the "Project"); and

WHEREAS, [describe financing and security documents - leave blanks as necessary if you do not have financing documents - see example below] as part of obtaining financing for the
Project, Developer and ¦ ("Borrower"), have entered into a certain Construction Loan
Agreement dated as of with the Lender pursuant to which the Lender has agreed
to make a loan to the Borrower in an amount not to exceed $ (the "Loan"), which Loan
is evidenced by a Mortgage Note and executed by the Borrower in favor of the Lender (the "Note"), and the repayment of the Loan is secured by, among other things, certain liens and encumbrances on the Property and other property of the Borrower pursuant to the following: (i)
Mortgage dated and recorded as document number
made by the Borrower to the Lender; and (ii) Assignment of Leases and Rents recorded
as document number made by the Borrower to the Lender (all such
agreements referred to above and otherwise relating to the Loan referred to herein collectively as the "Loan Documents");
99

WHEREAS, Developer desires to enter into a certain Redevelopment Agreement dated the date hereof with the City in order to obtain additional financing for the Project (the "Redevelopment Agreement," referred to herein along with various other agreements and documents related thereto as the "City Agreements");

WHEREAS, pursuant to the Redevelopment Agreement, Developer will agree to be bound by certain covenants expressly running with the Property, as set forth in Sections [8.02, 8.06 and 8.19] of the Redevelopment Agreement (the "City Encumbrances");

WHEREAS, the City has agreed to enter into the Redevelopment Agreement with Developer as of the date hereof, subject, among other things, to (a) the execution by Developer of the Redevelopment Agreement and the recording thereof as an encumbrance against the Property; and (b) the agreement by the Lender to subordinate their respective liens under the Loan Documents to the City Encumbrances; and

NOW, THEREFORE, for good and valuable consideration, the receipt, adequacy and sufficiency of which are hereby acknowledged, the Lender and the City agree as hereinafter set forth:
Subordination. All rights, interests and claims of the Lender in the Property pursuant to the Loan Documents are and shall be subject and subordinate to the City Encumbrances. In all other respects, the Redevelopment Agreement shall be subject and subordinate to the Loan Documents. Nothing herein, however, shall be deemed to limit the Lender's right to receive, and Developer's ability to make, payments and prepayments of principal and interest on the Note, or to exercise its rights pursuant to the Loan Documents except as provided herein.
Notice of Default. The Lender shall use reasonable efforts to give to the City, and the City shall use reasonable efforts to give to the Lender, (a) copies of any notices of default which it may give to Developer with respect to the Project pursuant to the Loan Documents or the City Agreements, respectively, and (b) copies of waivers, if any, of Developer's default in connection therewith. Under no circumstances shall Developer or any third party be entitled to rely upon the agreement provided for herein.
Waivers. No waiver shall be deemed to be made by the City or the Lender of any of their respective rights hereunder, unless the same shall be in writing, and each waiver, if any, shall be a waiver only with respect to the specific instance involved and shall in no way impair the rights of the City or the Lender in any other respect at any other time.
Governing Law; Binding Effect. This Agreement shall be interpreted, and the rights and liabilities of the parties hereto determined, in accordance with the internal laws and decisions of the State of Illinois, without regard to its conflict of laws principles, and shall be binding upon and inure to the benefit of the respective successors and assigns of the City and the Lender.
Section Titles; Plurals. The section titles contained in this Agreement are and shall be without substantive meaning or content of any kind whatsoever and are not a part of the agreement between the parties hereto. The singular form of any word used in this Agreement shall include the plural form.


100

6. Notices. Any notice required hereunder shall be in writing and addressed to the party to be notified as follows:

If to the City: City of Chicago Department of Planning and Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner If to Developer:


Attention:
With Copies To: City of Chicago Department of Law 121 North LaSalle Street, Room 600 Chicago, Illinois 60602 Attention: Finance and Economic Development Division With Copies To:


Attention:

or to such other address as either party may designate for itself by notice. Notice shall be deemed to have been duly given (i) if delivered personally or otherwise actually received, (ii) if sent by overnight delivery Service, (iii) if mailed by first class United States mail, postage prepaid, registered or certified, with return receipt requested, or (iv) if sent by facsimile with facsimile confirmation of receipt (with duplicate notice sent by United States mail as provided above). Notice mailed as provided in clause (iii) above shall be effective upon the expiration of three (3) business days after its deposit in the United States mail. Notice given in any other manner described in this paragraph shall be effective upon receipt by the addressee thereof; provided, however, that if any notice is tendered to an addressee and delivery thereof is refused by such addressee, such notice shall be effective upon such tender.

7. Counterparts. This Agreement may be executed in two or more counterparts, each of which shall constitute an original and all of which, when taken together, shall constitute one instrument.


















101

IN WITNESS WHEREOF, this Subordination Agreement has been signed as of the date first written above.
[LENDER], [a national banking association] By:
Its:
CITY OF CHICAGO By:
Its: Commissioner,
Department of Planning and Development



ACKNOWLEDGED AND AGREED TOTHIS
DAY OF

[Developer], a


By: Its:




Exhibit to Subordination Agreement - Legal Description












102

STATE OF ILLINOIS COUNTY OF COOK
)
) SS
)

I, the undersigned, a notary public in and for the County and State aforesaid, DO
HEREBY CERTIFY THAT , personally known to me to be the
Commissioner of the Department of Planning and Development of the City of Chicago, Illinois (the "City") and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that as such Commissioner, (s)he signed and delivered the said instrument pursuant to authority, as his/her free and voluntary act, and as the free and voluntary act and deed of said City, for the uses and purposes therein set forth.

GIVEN under my hand and notarial seal this day of , .


Notary Public My Commission Expires
(SEAL)
STATE OF ILLINOIS )
) SS
COUNTY OF COOK )


I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY THAT , personally known to me to be
the of [Lender], a , and personally known to
me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed and delivered said instrument, pursuant to the authority given to him/her by Lender, as his/her free and voluntary act and as the free and voluntary act of the Lender, for the uses and purposes therein set forth.

GIVEN under my hand and notarial seal this day of , .



Notary Public My Commission Expires
(SEAL)




103

NORTH PULLMAN REDEVELOPMENT PROJECT AREA

CHICAGO NEIGHBORHOOD INITIATIVES INC. REDEVELOPMENT PROJECT (WHOLE FOODS WAREHOUSE AND DISTRIBUTION FACILITY)

Redevelopment Agreement dated as of . 2016
EXHIBIT P INVESTOR LETTER A form of the Investor Letter is attached to this exhibit cover sheet.







































104

INVESTOR LETTER

, 20_

City of Chicago
Department of Planning and Development 121 N. LaSalle Street, Suite 1000 Chicago, Illinois 60602 Attention: Commissioner

Re: $[ ] City of Chicago, Illinois Tax Increment Allocation Revenue Note
([ ] Redevelopment Project) [Taxable] Series [ ] issued to
[ ]
Ladies and Gentlemen:

The undersigned (the "Investor") is the acquirer of the above-described note (the "Note"). The undersigned acknowledges that the Note was issued by the City of Chicago (the "City") for the purpose of paying the costs of certain eligible redevelopment project costs incurred by
[ ] (the "Developer") which were incurred in connection with the development of
an approximately [ ] square foot [ ] (the "Project") in the
[ ] Redevelopment Project Area (the "Redevelopment Area") in the City of
Chicago.

The undersigned acknowledges that the Note was issued pursuant to an ordinance
adopted by the City Council of the City on , 20 (the "Project Ordinance") and
the [ _\ Redevelopment Agreement dated as of , 20
and recorded on , 20 as Document Number in the Office of
the Cook County Recorder of Deeds (the "Agreement") by and between the City and the Developer.

In connection with the acquisition ofthe Note by the Investor, the Investor hereby makes the following representations upon which the City may rely:

1. The Investor is a [ : ] duly formed, validly existing and in good
standing under the laws of the State of [ ] and has authority to acquire the Note
and to execute this letter and any other instruments and documents required to be executed by the Investor in connection with the acquisition of the Note.

[2. The Investor is an institutional "accredited investor" within the meaning of Rule 501(a)(1), (2), (3) or (7) of the Securities and Exchange Commission (the "Commission") promulgated under the Securities Act of 1933, as amended (the "Securities Act") or a "qualified institutional buyer" within the meaning of Rule 144A of the Commission promulgated under the Securities Act. ]
If the Investor is a broker or dealer and is purchasing the Note with a view toward any distribution, sale or resale of the Note or any beneficial interest therein, replace paragraph 2 with the following:

[2. The Investor is a "dealer" meeting the requirements of Rule 144A(a)(1)(ii) or (iii) of the Commission promulgated under the Securities Act.]

105

3. The Investor has sufficient knowledge and experience in financial and business matters, including the acquisition and ownership of notes issued by municipalities, to be able to evaluate the merits and risks of its investment in the Note, and the Investor is able to bear any economic risk associated with its investment in the Note.
[4. The Investor is acquiring the Note for its own account and not with a view toward any distribution, sale or resale of the Note. The Investor intends to hold the Note for an indefinite period of time. The Investor understands that it may need to bear the risks of this investment for an indefinite time, since any sale of the Note prior to maturity may not be possible.2]

2 If the Investor is a broker or dealer and is purchasing the Note with a view toward any distribution, sale or resale ofthe Note or any beneficial interest therein, replace paragraph 4 with the following:
[4. The Investor (i) has not solicited offers for, or offered or sold, and will not solicit offers for, or offer and sell the Note or any beneficial interest therein except to persons who it reasonably believes are "qualified institutional buyers" within the meaning of Rule 144A(a)(1) of the Commission promulgated under the Securities Act; (ii) has not solicited offers for, or offered or sold, and will not solicit offers for, or offer or sell Notes by, any form of general solicitation or general advertising or in any manner involving a public offering; and (iii) shall inform each prospective purchaser of the Note or any beneficial interest therein of the restrictions on resale of the Note or beneficial interests therein under the Agreement.]


[ If the Investor is a "dealer" meeting the requirements of Section 144A(a)(1) (ii), replace paragraph 4 with the following:
The Investor (i) has not solicited offers for, or offered or sold, and will not solicit offers for, or offer and sell the Note or any beneficial interest therein, except to persons who it reasonably believes are "qualified institutional buyers" within the meaning of Rule 144A(a)(1) under the Securities Act; (ii) has not solicited offers for, or offered or sold, and will not solicit offers for, or offer or sell Notes by, any form of general solicitation or general advertising or in any manner involving a public offering; and (iii) shall inform each prospective purchaser of the Note or any beneficial interest therein of the restrictions on resale of the Note or beneficial interests therein under the Agreement]
The Investor understands that the Note is not registered under the Securities Act and that such registration is not legally required as of the date hereof; and the Investor further understands that the Note (a) is not being registered or otherwise qualified for sale under the "Blue Sky" laws and regulations of any state, (b) will not be listed in any stock or other securities exchange, (c) will not carry a rating from any rating service, and (d) will be delivered in a form which is not to be readily marketable.
The Investor understands that (a) the Note is a limited obligation of the City, payable
solely from moneys on deposit in the [ ] Account (as defined in the Project
Ordinance); (b) the Note does not constitute an indebtedness of the City within the meaning of any constitutional or statutory provision or limitation; (c) no holder of the Note will have the right to compel the exercise of any taxing power of the City for payment of the principal of, or interest premium, if any, on the Note; and (d) the Note does not and will not represent or constitute a general obligation or a pledge of the faith and credit of the City, the State of Illinois or any political subdivision thereof.

106

The Investor has read and considered the risk factors set forth in "Noteholder Risks" attached hereto.
The Investor has not relied upon the City for any information in connection with its acquisition of the Note. The Investor has either been supplied with or been given access to information, including financial statements and other financial information, to which a reasonable investor would attach significance in making investment decisions, and the Investor has had the opportunity to ask questions and receive answers from knowledgeable individuals concerning the Developer, the Project and the Note. The Investor is in possession of all the information and material necessary to evaluate the merits and risks of the acquisition of the Note.
The Investor has been furnished with and has examined the Agreement and other documents, certificates and the legal opinions delivered in connection with the issuance of the Note. The Investor acknowledges that neither the City nor the Developer has prepared an offering document with respect to the Note. The Investor has made its own inquiry and analysis with respect to the Note and material factors affecting the payment of the Note.
The Investor acknowledges that with respect to the Notes, the City has no obligation to provide any continuing disclosure to the Electronic Municipal Market Access System maintained by the Municipal Securities Rulemaking Board, any holder of the Note or any other person under Rule 15c2-12 ofthe Commission promulgated under the Securities Exchange Act of 1934 or otherwise, and shall have no liability with respect thereto.
The Investor understands that the City, the Developer, their respective counsel and Bond Counsel will rely upon the accuracy and truthfulness ofthe representations and warranties contained herein and hereby consents to such reliance.


Very truly yours,



a[
By: _ Name:_ Title:











107

NOTEHOLDER RISKS

The purchase of or investment in the Note involves certain risks. Each prospective holder or purchaser of the Note, or any interest therein, should make an independent evaluation of the financial and business risks associated with holding or having an investment interest in the Note. Certain of these risks are set forth below. The following summary is not intended to be complete and does not purport to identify all possible risks that should be considered by prospective holders of the Note or any interests therein. Capitalized terms used herein have the meanings set forth in the Note.
All prospective holders of the Note are urged to consult with their financial adviser and legal counsel before acquiring the Note or any interest therein.

Loss of Investment

Investment in the Note involves a high degree of risk. It is suitable only for persons who are able to bear the economic risks of the investment, including total loss. No assurance can be provided that prospective holders of the Note will not lose their entire investment in the Note.

Lack of Liquidity

The Note is suitable only for persons who have no need for liquidity. The transferability of the Note is restricted. The Note may only be transferred in the manner and subject to the limitations provided in the Redevelopment Agreement. Investors in the Note must be prepared to hold the Note until the maturity of the Note.

Reliance on Projections

The City does not endorse projections of any kind from any source as to the sufficiency of available incremental taxes to pay principal and interest on the Note. Investor who rely on any such projections do so at their own risk.

The City's Office of Budget and Management ("OBM") produces five-year District Projection Reports for each TIF district in the City for the purpose of evaluating resources and project balances. This information, which is currently publicly available, is used by the OBM to determine how much funding has been committed and how much funding is available for potential projects. The reports and the projections including therein are not audited and do not represent a final accounting of funds. The reports are not prepared for investors or as a basis for making investment decisions with respect to any notes, bonds or other debt obligations of the City that are payable from available incremental taxes, including the Note. Prospective investors in Note are cautioned not to rely on any of the information contained in the District Projection Reports.

Limited Obligations

THE NOTE IS A SPECIAL LIMITED OBLIGATION OF THE CITY PAYABLE SOLELY FROM THE AVAILABLE INCREMENTAL TAXES, AND SHALL BE A VALID CLAIM ONLY AGAINST SAID SOURCES. THE NOTE DOES NOT CONSTITUTE AN INDEBTEDNESS OR A LOAN AGAINST THE GENERAL TAXING POWERS OR CREDIT OF THE CITY, WITHIN THE MEANING OF ANY CONSTITUTIONAL OR STATUTORY PROVISION. THE
108

NOTEHOLDER HAS NO RIGHT TO COMPEL ANY EXERCISE OF THE TAXING POWER OF THE CITY, THE STATE OF ILLINOIS OR ANY POLITICAL SUBDIVISION THEREOF TO PAY THE PRINCIPAL OR INTEREST OF THE NOTE.

There can be no assurance that Available Incremental Taxes will be sufficient for payment of amounts due and owing on the Note.

Limited Information

The Note was issued to the Developer under the Redevelopment Agreement as part of a commercial transaction negotiated by the Developer and the City. [The Developer] engaged a [consultant] to deliver a [feasibility report][projection report] to the City in connection with the Project, which included certain information about the Project Area, the Project and historical and projected Available Incremental Taxes.] The report contained information as of its date only, and neither the Developer nor any other party have any obligation to update the report as of any subsequent date.

The City is under no continuing obligation to provide to any holder or prospective holder of the Note, or to post to EMMA or any website, any current or updated information with respect to the Project Area, the Project, the historical and projected Available Incremental Taxes or the Note. The City does not prepare or have readily available any current or updated information about the Project Area, the Project or the Available Incremental Taxes.

Unavailability of City Funds

The City is not obligated to pay principal of or interest on the Note in any year in which there are inadequate Available Incremental Taxes. The City is obligated to pay the amount of any unpaid principal or accrued interest in any subsequent year but only to the extent of the Available Incremental Taxes for those subsequent years. If, on the maturity date of the Note, any outstanding unpaid principal or interest on the Note exists for any reason, including without limitation the inadequacy of Available Incremental Taxes, such outstanding principal and/or interest will be forgiven in full and the City will have no further obligation to pay such outstanding amount. In such event, there would be no further payments of principal or interest in respect of the Note.

Risk of Failure to Maintain Levels of Assessed Valuation

There can be no assurance that the equalized assessed value of the Project property will remain the same throughput the term of the Note. Furthermore, the successful petition or application of any owner for the reduction of the assessed value of the Project property may cause the equalized assessed value of the Project Area to be less than the originally projected equalized assessed value of the property. If any time during the term of the Note the actual equalized assessed value is less than what was projected, the generation of Available Incremental Taxes for payment on the Note is likely to be significantly impaired.

Risk of Change in Available Incremental Taxes

Prospective holders of the Note should carefully consider, among other factors, the risks associated with the ultimate generation of Available Incremental Taxes in the Project Area. These risks include, but are not limited to, the following:

109

Property tax rates are calculated by the County Clerk for numerous funds of a number of taxing districts that tax all or part of the property in the Project Area. A reduction in the tax levies by the affected taxing districts may have an adverse effect on the Available Incremental Taxes.
Further changes may be made in the real property tax system by the State of Illinois or Cook County. Such changes could include various property tax rollbacks, abatements, exemptions, changes in the ratio of assessment, or relief measures, limitations on the amount or percent of increase in tax levies by taxing districts, or other measures that would limit the tax levy amount that could be extended to the property within the Project Area and, consequently, the projected Available Incremental Taxes generated. For example, if Illinois adopted practices used in other states, the property tax system could be changed so that schools would be financed from a source other than property taxes. This type of change could have a significant adverse effect upon Available Incremental Taxes.
Cook County's methodology and procedures used to assess the value of property may be altered resulting in a potentially reduced or altered valuation in a particular year or succession of years.
Failure by Cook County to remit property taxes to the City on a timely basis could result in insufficient Available Incremental Taxes being available to pay principal of or interest on the Note when due.

FUTURE LEGISLATION, REGULATIONS, GOVERNMENTAL OR JUDICIAL INTERPRETATION OF REGULATIONS OR LEGISLATION OR PRACTICES AND PROCEDURES RELATED TO PROPERTY TAX ASSESSMENT, LEVY, COLLECTIONS OR DISTRIBUTION COULD HAVE A MATERIAL EFFECT ON THE CALCULATION OR AVAILABILITY OF AVAILABLE INCREMENTAL TAXES COLLECTED OR DISTRIBUTED.

Changes in Multiplier and Tax Rate

The equalization factor annually determined by the Illinois Department of Revenue for properties located within Cook County (commonly referred to as the "multiplier") may vary substantially in future years. A decrease in the multiplier would reduce the equalized assessed value of the taxable real property in the Project Area and, therefore, the Available Incremental Taxes available to pay debt service on the Note. The future tax rates of the units of local government levying taxes in the Project Area either individually or on a composite basis, may differ from their historical levels. Any decrease in the composite tax rate of the governmental units would decrease the amount of Available Incremental Taxes available to pay debt service on the Note. Any decrease in the composite tax rate of the governmental units could occur in future years as a result of various factors, including, but not limited to, one or more of the following: (a) reduced governmental costs; (b) constitutional or statutory spending or tax rate limitations; or (c) governmental reorganization or consolidation.

Economic Risks Affecting Available Incremental Taxes

Changing economic circumstances or events in the Project Area may result in reductions in Available Incremental Taxes available to pay debt service on the Note. Relocations of major property owners to sites outside the Project Area or sales of major properties to tax-exempt entities could reduce the assessed valuation of the Project Area. Substantial damage to or destruction of improvements within the Project Area could cause a material decline in assessed
110

valuation and impair the ability of the taxpayers in the Project Area to pay their respective portions of real estate taxes. There can be no assurance that the improvements in the Project Area are or will be insured under fire and extended coverage insurance policies, and, even if such insurance exists, the proceeds thereof will not be assigned as security for the payment of real estate taxes or to secure payment of the Note. In addition, any insurance proceeds may not be sufficient to repair or rebuild the improvements. The restoration of the improvements may be delayed by other factors, or the terms of then-applicable mortgage financing could require the application of insurance proceeds to the reduction of mortgage balances. Any of the foregoing circumstances could result in the assessed valuation of property in the Project Area remaining depressed for an unknown period of time and decrease the amount of Available Incremental Taxes available to pay debt service on The Note.

Results of operation of properties within the Project Area depend, in part, on sales, leases, rental rates and occupancy levels, which may be adversely affected by competition, suitability of the properties located in the Project Area in its local market, local unemployment, availability of transportation, neighborhood changes, crime levels in the Project Area, vandalism, rising operating costs and similar factors. Poor operating results of properties within the Project Area may cause delinquencies in the payment of real estate taxes, reduce assessed valuations and increase the risk of foreclosures. Successful petitions by taxpayers to reduce their assessed valuations could adversely affect available incremental Taxes available for payment of the Note.

Failure to Sell or Lease Property

At the time the Note was issued, the redevelopment plan called for the Developer [to sell/lease to commercial or industrial enterprises/retailers] prior to completion of the Project. The slowdown, stoppage or failure of the Developer to complete the Project and to successfully sell/lease the Project could delay or reduce the amount of Available Incremental Taxes generated in the Project Area. Such delay or reduction could lead to a default in payments of the principal of, and interest on, the Note.

Reliance on Primary Taxpayers

If one or only a few property owners within the Project Area are responsible for generating a substantial amount of the Available Incremental Taxes, the generation of Available Incremental Taxes could be significantly adversely affected if such owner or owners and/or their tenants discontinue or curtail their businesses, terminate or default on their leases and substitutes or replacements cannot be found or located on a timely basis.

Force Majeure Conditions

Riots, civil disturbances, vandalism, fires, and natural disasters or other "Acts of God" affecting the conditions and viability of the Project Area may reduce or eliminate the receipt of Available Incremental Property.

Contiguous Project Areas

The Project Area is contagious with other redevelopment areas designated by the City pursuant to the TIF Act and may become contiguous with others. The TIF Act allows the City to expend incremental taxes collected from the Project Area which are in excess of the amounts required in each year to pay and secure obligations issued and project costs incurred with
111

respect to the Project Area to pay for costs eligible for payment under the TIF Act which are incurred in such contiguous areas. In the event Incremental Taxes from the Project Area in excess of Available Incremental Taxes and the amounts required to (i) pay principal and interest coming due on the Note in any year and (ii) be deposited in other funds and accounts maintained under the Redevelopment Agreement are allocated to a contiguous project redevelopment area, such excess incremental taxes will not be available to remedy any future failure to pay principal of and interest on the Note.

Risk of Delay in Payment of Available Incremental Taxes

The failure of current or future owners of property in the Project Area to remit property taxes to the City when due or the failure of the City to timely remit Available Incremental Taxes to the Noteholder could result in insufficient Available Incremental Taxes being available to pay principal of or interest on the Note when due.

Delays in Exercising Remedies

The enforceability of the Note is subject to applicable bankruptcy laws, equitable principles affecting the enforcement of creditors' rights generally and of liens securing such rights, and the police powers of the State of Illinois and its political subdivisions. Because of delays inherent in obtaining judicial remedies, it should not be assumed that these remedies could be accomplished rapidly.
Remedies available to holder of the Note may be limited by a variety of factors and may be inadequate to assure the timely payment of principal of and interest on the Note, or to preserve the tax-exempt status of The Note. The Note is not subject to acceleration due to payment default. Lack of remedies may entail risks of delay, limitation, or modification of the rights of the holders of the Note. Judicial remedies, such as foreclosure and enforcement of covenants, are subject to exercise of judicial discretion.

Risk of Transferee Becoming a Debtor in Bankruptcy

If a transferee of the Note were to become a debtor under the United States Bankruptcy Code or applicable state laws, a creditor or trustee in bankruptcy of the transferee might argue that the sale of the Note by the transferee constituted a fraudulent conveyance or a pledge of the Note rather than a sale. If such positions were accepted by a court, then delays in principal and interest payments to holder the Note could occur or reductions in the amounts of such payments could result. Additionally, if the transfer of the Note is re-characterized as a pledge, then a tax lien, governmental lien or other lien created by operation of law on the property ofthe transferee could have priority over the holder's interest in the Note.

Loss of Tax Exemption

Interest on the Note could become includible in gross income for federal income tax purposes retroactive to the date of issuance of the Note as a result of a failure of the City to comply with certain provisions of the Internal Revenue Code of 1986, as amended (the "Code"). An event of taxability does not trigger a mandatory redemption of the Note, and the Note will remain outstanding to maturity or until redeemed.
THE ABOVE IS NOT INTENDED TO BE A COMPREHENSIVE DISCUSSION OF ALL POTENTIAL RISKS ASSOCIATED WITH THE NOTE.
112

Exhibit B to the Ordinance

Form of Series A, Note R-1 (the "City Note")


(See attached)














































11

FORM OF NOTE

INVESTMENT IN THIS NOTE INVOLVES A HIGH DEGREE OF RISK. IT IS SUITABLE ONLY FOR PERSONS WHO ARE ABLE TO BEAR THE ECONOMIC RISKS OF THIS INVESTMENT, INCLUDING TOTAL LOSS. NO ASSURANCE CAN BE PROVIDED THAT THE HOLDER OF THIS NOTE WILL NOT LOSE ITS ENTIRE INVESTMENT IN THIS NOTE. SEE "NOTEHOLDER RISKS" ATTACHED TO THIS NOTE.

THIS NOTE IS SUITABLE ONLY FOR PERSONS WHO HAVE NO NEED FOR LIQUIDITY. THIS NOTE MAY ONLY BE TRANSFERRED IN THE MANNER AND SUBJECT TO THE LIMITATIONS PROVIDED IN THE REDEVELOPMENT AGREEMENT.

THE CITY DOES NOT ENDORSE PROJECTIONS OF ANY KIND FROM ANY SOURCE AS TO THE SUFFICIENCY OF ALLOCATED AVAILABLE INCREMENTAL TAXES TO PAY PRINCIPAL OF AND INTEREST ON THIS NOTE. INVESTORS WHO RELY ON SUCH PROJECTIONS DO SO AT THEIR OWN RISK.

PRINCIPAL OF AND INTEREST ON THIS NOTE ARE PAYABLE SOLELY FROM ALLOCATED AVAILABLE INCREMENTAL TAXES ON DEPOSIT IN THE
[ ] ACCOUNT, AS DEFINED IN THE HEREINAFTER DEFINED
REDEVELOPMENT AGREEMENT. THE HOLDER OF THIS NOTE ACCEPTS THE RISK THAT THE AMOUNT OF ALLOCATED AVAILABLE INCREMENTAL TAXES MAY NOT BE SUFFICIENT TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE.

REGISTERED


MAXIMUM AMOUNT
NO. R-1 $7,400,000

UNITED STATES OF AMERICA STATE OF ILLINOIS COUNTY OF COOK CITY OF CHICAGO TAX INCREMENT ALLOCATION REVENUE NOTE (NORTH PULLMAN REDEVELOPMENT PROJECT AREA). TAX-EXEMPT SERIES A

Registered Owner: Chicago Neighborhood Initiatives, Inc.

Interest Rate: per annum

Maturity Date: , [the same maturity date as the current termination date of the
North Pullman Redevelopment Area, with no future extension of the term allowed]
KNOW ALL PERSONS BY THESE PRESENTS, that the City of Chicago, Cook County, Illinois (the "City"), hereby acknowledges itself to owe and for value received promises to pay to the Registered Owner identified above, or registered assigns as hereinafter provided, on or

before the Maturity Date identified above, but solely from the sources hereinafter identified, the principal amount of this Note, in accordance with the ordinance hereinafter referred to, in the
principal amount of $ and to pay the Registered Owner interest on that amount at the
Interest Rate per year specified above from the date of the advance. Interest shall be computed on the basis of a 360-day year of twelve 30-day months. Principal of and interest on this Note, payable solely from the Available Incremental Taxes (as defined in the hereinafter defined Redevelopment Agreement), is due March 1 of each year until the earlier of Maturity or until this Note is paid in full. Payments shall first be applied to interest. A principal amortization schedule is an exhibit to this Note.
The principal of and interest on this Note are payable in lawful money of the United States of America, and shall be made to the Registered Owner hereof as shown on the registration books of the City maintained by the Comptroller of the City, as registrar and paying agent (the "Registrar"), at the close of business on the fifteenth day of the month immediately prior to the applicable payment, maturity or redemption date, and shall be paid by check or draft of the Registrar, payable in lawful money of the United States of America, mailed to the address of such Registered Owner as it appears on such registration books or at such other address furnished in writing by such Registered Owner to the Registrar; provided, that the final installment of principal and accrued but unpaid interest will be payable solely upon presentation of this Note at the principal office of the Registrar in Chicago, Illinois or as otherwise directed by the City.
This Note is issued by the City in the principal amount of $ for the
purpose of paying the costs of certain eligible redevelopment project costs incurred by Chicago Neighborhood Initiatives, Inc. (the "Project"), which were [acquired], [constructed] and [installed]
in connection with the development of an approximately [ acre/ square foot]
site/building in the Redevelopment Project Area (the "Project Area") in the
City, all in accordance with the Constitution and the laws of the State of Illinois, and particularly the Tax Increment Allocation Redevelopment Act (65 ILCS 5/11-74.4-1 et seg.) (the "TIF Act") , the Local Government Debt Reform Act (30 ILCS 350/1 et seg.) and an Ordinance adopted by
the City Council of the City on , (the "Ordinance"), in all respects as by law
required.
The City has assigned and pledged certain rights, title and interest of the City in and to certain incremental ad valorem tax revenues from the Project Area which the City is entitled to receive pursuant to the TIF Act and the Ordinance, in order to pay the principal of and interest of this Note. Reference is hereby made to the aforesaid Ordinance and the Redevelopment

Agreement for a description, among others, with respect to the determination, custody and application of said revenues, the nature and extent of such security with respect to this Note and the terms and conditions under which this Note is issued and secured. THIS NOTE IS A SPECIAL LIMITED OBLIGATION OF THE CITY, AND PRINCIPAL OF AND INTEREST ON THIS NOTE ARE PAYABLE SOLELY FROM ALLOCATED AVAILABLE INCREMENTAL
TAXES ON DEPOSIT IN THE ACCOUNT OF THE TIF FUND (AS DEFINED
IN THE REDEVELOPMENT AGREEMENT) AFTER PAYMENT OF ALL OBLIGATIONS HAVING A PRIORITY OVER THIS NOTE, IF ANY. THE HOLDER OF THIS NOTE ACCEPTS THE RISK THAT THE AMOUNT OF ALLOCATED AVAILABLE INCREMENTAL TAXES MAY NOT BE SUFFICIENT TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE. THIS NOTE SHALL NOT BE DEEMED TO CONSTITUTE AN INDEBTEDNESS OR A LOAN AGAINST THE GENERAL TAXING POWERS OR CREDIT OF THE CITY WITHIN THE MEANING OF ANY CONSTITUTIONAL OR STATUTORY PROVISION. THE REGISTERED OWNER OF THIS NOTE SHALL NOT HAVE THE RIGHT TO COMPEL ANY EXERCISE OF THE TAXING POWER OF THE CITY, THE STATE OF ILLINOIS OR ANY POLITICAL SUBDIVISION THEREOF TO PAY THE PRINCIPAL OF OR INTEREST ON THIS NOTE. This Note shall be subject to partial redemption from unexpended proceeds in the Construction
Escrow on or after , as more fully described in the Redevelopment Agreement. The
principal of this Note also is subject to redemption on any date after 60 months following issuance of this Note, as a whole or in part, at a redemption price of 100% of the principal amount thereof being redeemed. There shall be no prepayment penalty. Notice of any such redemption shall be sent by registered or certified mail not less than five (5) days nor more than sixty (60) days prior to the date fixed for redemption to the registered owner of this Note at the address shown on the registration books of the City maintained by the Registrar or at such other address as is furnished in writing by such Registered Owner to the Registrar.
This Note is issued in fully registered form in the denomination of its outstanding principal amount. This Note may not be exchanged for a like aggregate principal amount of notes or other denominations.
THIS NOTE MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT TO (I) AN INSTITUTIONAL "ACCREDITED INVESTOR" WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) or (7) UNDER THE SECURITIES ACT OF 1933 (THE "SECURITIES ACT") THAT DELIVERS TO THE CITY AN INVESTOR LETTER IN THE FORM OF EXHIBIT P TO THE REDEVELOPMENT AGREEMENT REFERENCED BELOW, OR (II) A PERSON (OTHER THAN A DEALER) WHOM THE SELLER REASONABLY

BELIEVES IS A "QUALIFIED INSTITUTIONAL BUYER" WITHIN THE MEANING OF RULE 144A(a)(1) UNDER THE SECURITIES ACT. ANY HOLDER OF THIS NOTE IS REQUIRED TO NOTIFY ANY POTENTIAL PURCHASER OF THIS NOTE OF THE RESALE RESTRICTIONS REFERRED TO ABOVE. This Note is transferable by the Registered Owner hereof in person or by its attorney duly authorized in writing at the principal office of the Registrar in Chicago, Illinois, but only in the manner and subject to the limitations provided in the Ordinance, and upon surrender and cancellation of this Note. Upon such transfer, a new Note of authorized denomination of the same maturity and for the same aggregate principal amount will be issued to the transferee in exchange herefor. The Registrar shall not be required to transfer this Note during the period beginning at the close of business on the fifteenth day of the month immediately prior to the maturity date of this Note nor to transfer this Note after notice calling this Note or a portion hereof for redemption has been mailed, nor during a period of five (5) days next preceding mailing of a notice of redemption of this Note. Such transfer shall be in accordance with the form at the end of this Note.
This Note hereby authorized shall be executed and delivered as the Ordinance and the Redevelopment Agreement provide.
Pursuant to the Redevelopment Agreement dated as of [ , ] between the
City and the Developer (the "Redevelopment Agreement"), the Developer has agreed to [acquire] and [construct] the Project and shall be reimbursed from amounts on deposit in the Construction Escrow under the Act for certain eligible redevelopment project costs for the [construction of certain facilities] related to the Project on behalf of the City.
The City shall be obligated to make payments under this Note if an Event of Default (as defined in the Redevelopment Agreement), or condition or event that with notice or the passage of time or both would constitute an Event of Default, has occurred. Such rights shall survive any transfer of this Note.
The City and the Registrar may deem and treat the Registered Owner hereof as the absolute owner hereof for the purpose of receiving payment of or on account of principal hereof and for all other purposes and neither the City nor the Registrar shall be affected by any notice to the contrary, unless transferred in accordance with the provisions hereof.
This Note may be transferred only in the manner and subject to the limitations provided in Section 18.28 ofthe Redevelopment Agreement.
It is hereby certified and recited that all conditions, acts and things required by law to exist, to happen, or to be done or performed precedent to and in the issuance of this Note did exist, have happened, have been done and have been performed in regular and due form and

time as required by law; that the issuance of this Note, together with all other obligations of the City, does not exceed or violate any constitutional or statutory limitation applicable to the City.
This Note shall not be valid or become obligatory for any purpose until the certificate of authentication hereon shall have been signed by the Registrar.


[THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]
IN WITNESS WHEREOF, the City of Chicago, Cook County, Illinois, by its City Council,
has caused its official seal to be imprinted by facsimile hereon or hereunto affixed, and has
caused this Note to be signed by the duly authorized signature of the Mayor and attested by the
duly authorized signature of the City Clerk ofthe City, all as of , .


Mayor
(SEAL) Attest:

City Clerk

CERTIFICATE OF
AUTHENTICATION





Registrar and Paying Agent Comptroller of the City of Chicago, Cook County, Illinois


This Note is described in the within mentioned Ordinance and is the Tax Increment Allocation Revenue Note (North Pullman Redevelopment Project Area), Tax-Exempt Series A, of the City of Chicago, Cook County, Illinois.


Comptroller Date:
[The following "Noteholder Risks" constitutes an integral part of this Note.]

NOTEHOLDER RISKS

The purchase of or investment in the Note involves certain risks. Each prospective holder or purchaser of the Note, or any interest therein, should make an independent evaluation of the financial and business risks associated with holding or having an investment interest in the Note. Certain of these risks are set forth below. The following summary is not intended to be complete and does not purport to identify all possible risks that should be considered by prospective holders of the Note or any interests therein. Capitalized terms used herein have the meanings set forth in the Note.

All prospective holders of the Note are urged to consult with their financial adviser and legal counsel before acquiring the Note or any interest therein.

Loss of Investment
Investment in the Note involves a high degree of risk. It is suitable only for persons who are able to bear the economic risks of the investment, including total loss. No assurance can be provided that prospective holders of the Note will not lose their entire investment in the Note.

Lack of Liquidity

The Note is suitable only for persons who have no need for liquidity. The transferability of the Note is restricted. The Note may only be transferred in the manner and subject to the limitations provided in the Redevelopment Agreement. Investors in the Note must be prepared to hold the Note until the maturity of the Note.

Reliance on Projections

The City does not endorse projections of any kind from any source as to the sufficiency of Available Incremental Taxes to pay principal of and interest on the Note. Investors who rely on any such projections do so at their own risk.

The City's Office of Budget and Management ("OBM") produces five-year projection reports for each TIF district in the City for the purpose of evaluating resources and project balances ("District Projection Reports"). This information, which is currently publicly available, is used by the OBM to determine how much funding has been committed and how much funding is available for potential projects. The District Projection Reports and the projections included therein are not audited and do not represent a final accounting of funds. The District Projection Reports are not prepared for investors or as a basis for making investment decisions with respect to any notes, bonds or other debt obligations of the City that are payable from Incremental Taxes, including the Note. Prospective investors in the Note are cautioned not to rely on any of the information contained in the District Projection Reports.

Limited Obligations

THE NOTE IS A SPECIAL LIMITED OBLIGATION OF THE CITY PAYABLE SOLELY FROM THE ALLOCATED AVAILABLE INCREMENTAL TAXES AFTER PAYMENT OF ALL OBLIGATIONS HAVING A PRIORITY OVER THE NOTE, IF ANY, AND SHALL BE A VALID

CLAIM ONLY AGAINST SAID SOURCES. THE NOTE DOES NOT CONSTITUTE AN INDEBTEDNESS OR A LOAN AGAINST THE GENERAL TAXING POWERS OR CREDIT OF THE CITY, WITHIN THE MEANING OF ANY CONSTITUTIONAL OR STATUTORY PROVISION. THE NOTEHOLDER HAS NO RIGHT TO COMPEL ANY EXERCISE OF THE TAXING POWER OF THE CITY, THE STATE OF ILLINOIS OR ANY POLITICAL SUBDIVISION THEREOF TO PAY THE PRINCIPAL OF OR INTEREST ON THE NOTE.
There can be no assurance that Available Incremental Taxes will be sufficient for payment of amounts due and owing on the Note.

Limited Information

The Note was issued to the Developer under the Redevelopment Agreement as part of a commercial transaction negotiated by the Developer and the City. [The Developer] engaged a [consultant] to deliver a [feasibility report][projection report] to the City in connection with the Project, which included certain information about the Project Area, the Project and historical and projected Available Incremental Taxes. The report contained information as of its date only, and neither the Developer nor any other party have any obligation to update the report as of any subsequent date.
The City is under no continuing obligation to provide to any holder or prospective holder of the Note, or to post to the Electronic Municipal Market Access System of the Municipal Securities Rulemaking Board or any other website, any current or updated information with respect to the Project Area, the Project, the historical and projected Available Incremental Taxes or the Note. The City does not prepare or have readily available any current or updated information about the Project Area, the Project or the Available Incremental Taxes.

Unavailability of City Funds

The City is not obligated to pay principal of or interest on the Note in any year in which there are inadequate Available Incremental Taxes. The City is obligated to pay the amount of any unpaid principal or accrued interest in any subsequent year but only to the extent of the availability of Available Incremental Taxes for those subsequent years. If, on the maturity date of the Note, any outstanding unpaid principal or interest on the Note exists for any reason, including without limitation the inadequacy of Available Incremental Taxes, such outstanding principal and/or interest will be forgiven in full and the City will have no further obligation to pay such outstanding amount. In such event, there would be no further payments of principal or interest in respect ofthe Note.

Risk of Failure to Maintain Levels of Assessed Valuation

There can be no assurance that the equalized assessed value of the Project property will remain the same throughout the term of the Note. Furthermore, the successful petition or application of any owner for the reduction of the assessed value of the Project property or any other properties in the Project Area may cause the equalized assessed value ofthe Property to be less than the originally projected equalized assessed value. If any time during the term of the Note the actual equalized assessed value is less than what was projected, the generation of Available Incremental Taxes for payment on the Note is likely to be significantly impaired.

Risk of Change in Incremental Taxes

Prospective holders of the Note should carefully consider, among other factors, the risks associated with the ultimate generation of Available Incremental Taxes in the Project Area. These risks include, but are not limited to, the following:
Property tax rates are calculated by the Cook County Clerk for numerous funds of a number of taxing districts that tax all or part of the property in the Project Area. A reduction in the tax levies by the affected taxing districts may have an adverse effect on the Available Incremental Taxes.
Further changes may be made in the real property tax system by the State of Illinois or Cook County. Such changes could include various property tax rollbacks, abatements, exemptions, changes in the ratio of assessment, or relief measures, limitations on the amount or percent of increase in tax levies by taxing districts, or other measures that would limit the tax levy amount that could be extended to the property within the Project Area and, consequently, the projected Available Incremental Taxes generated. For example, if Illinois adopted practices used in other states, the property tax system could be changed so that schools would be financed from a source other than property taxes. This type of change could have a significant adverse effect upon Available Incremental Taxes.
Cook County's methodology and procedures used to assess the value of property may be altered resulting in a potentially reduced or altered valuation in a particular year or succession of years.

FUTURE LEGISLATION, REGULATIONS, GOVERNMENTAL OR JUDICIAL INTERPRETATION OF REGULATIONS OR LEGISLATION OR PRACTICES AND PROCEDURES RELATED TO PROPERTY TAX ASSESSMENT, LEVY, COLLECTIONS OR DISTRIBUTION COULD HAVE A MATERIAL EFFECT ON THE CALCULATION OR AVAILABILITY OF INCREMENTAL TAXES COLLECTED OR DISTRIBUTED AND THEREFORE A MATERIAL EFFECT ON THE AMOUNT OF AVAILABLE INCREMENTAL TAXES FOR PAYMENT OF PRINCIPAL OF AND INTEREST ON THE NOTE.

Changes in Multiplier and Tax Rate

The equalization factor annually determined by the Illinois Department of Revenue for properties located within Cook County (commonly referred to as the "multiplier") may vary substantially in future years. A decrease in the multiplier would reduce the equalized assessed value of the taxable real property in the Project Area and, therefore, the Available Incremental Taxes available to pay principal of and interest on the Note. The future tax rates of the units of local government levying taxes in the Project Area either individually or on a composite basis, may differ from their historical levels. Any decrease in the composite tax rate of the governmental units would decrease the amount of Available Incremental Taxes available to pay principal of and interest on the Note. Any decrease in the composite tax rate, of the governmental units could occur in future years as a result of various factors, including, but not limited to, one or more of the following: (a) reduced governmental costs; (b) constitutional or statutory spending or tax rate limitations; or (c) governmental reorganization or consolidation.

Economic Risks Affecting Incremental Taxes

Changing economic circumstances or events in the Project Area may result in reductions in Available Incremental Taxes available to pay principal of and interest on the Note. Relocations of major property owners to sites outside the Project Area or sales of major properties to tax-exempt entities could reduce the assessed valuation of the'real properties in the Project Area. Substantial damage to or destruction of improvements within the Project Area could cause a material decline in assessed valuation and impair the ability of the taxpayers in the Project Area to pay their respective portions of real estate taxes. Similarly, there can be no assurance that the improvements in the Project Area will be sufficiently insured under fire and extended coverage insurance policies. Even if such- insurance is sufficient, the proceeds thereof will not be assigned as security for the payment of real estate taxes or to secure payment of the Note. In addition, any insurance proceeds may not be sufficient to repair or rebuild said improvements. The restoration of such improvements may be delayed by other factors, or the terms of then-applicable mortgage financing could require the application of insurance proceeds to the reduction of mortgage balances. Any of the foregoing circumstances could result in the assessed valuation of property in the Project Area remaining depressed for an unknown period of time and decrease the amount of Available Incremental Taxes available to pay principal of and interest on the Note.

Results of operation of properties within the Project Area depend, in part, on sales, leases, rental rates and occupancy levels, which may be adversely affected by competition, suitability of the properties located in the Project Area, local unemployment, availability of transportation, neighborhood changes, crime levels in the Project Area, vandalism, rising operating costs and similar factors. Poor operating results of properties within the Project Area may cause delinquencies in the payment of real estate taxes, reduce assessed valuations and increase the risk of foreclosures. Successful petitions by taxpayers to reduce their assessed valuations could adversely affect Available Incremental Taxes available for payment of principal of and interest on the Note.

Failure to Sell or Lease Property

At the time of Note issuance, the redevelopment plan called for the Developer [to sell/lease to commercial or industrial enterprises/retailers prior to/in connection with] completion of the Project. The slowdown, stoppage or failure of the Developer to complete the Project and to successfully sell/lease the Project could delay or reduce the amount of Available Incremental Taxes generated in the Project Area. Such delay or reduction could lead to a default in payments ofthe principal of and interest on the Note.

Reliance on Primary Taxpayers

If one or only a few property owners within the Project Area are responsible for generating a substantial amount of the Incremental Taxes, the generation of Available Incremental Taxes could be significantly adversely affected if such owner or owners and/or their tenants discontinue or curtail their businesses or terminate or default on their leases, and > substitutes or replacements cannot be made on a timely basis.

Force Majeure Conditions
Riots, civil disturbances, vandalism, fires, and natural disasters or other "Acts of God" affecting the conditions and viability of the Project Area may reduce or eliminate the receipt of

Incremental Taxes which would result in the reduction or elimination of Available Incremental Taxes to pay principal of and interest on the Note.

Contiguous Project Areas

The Project Area is, or may become, contiguous with other redevelopment areas designated by the City pursuant to the TIF Act. The TIF Act allows the City to expend Incremental Taxes collected from the Project Area which are in excess of the amounts required in each year to pay and. secure obligations issued and project costs incurred with respect to the Project Area to pay for costs eligible for payment under the TIF Act which are incurred in such contiguous areas. In the event Incremental Taxes from the Project Area in excess of Available Incremental Taxes, along with the amounts required to (i) pay principal and interest coming due on the Note in any year, and (ii) be deposited in other funds and accounts maintained under the Redevelopment Agreement, are allocated to a contiguous project redevelopment area, such excess Incremental Taxes will not be available to remedy any future failure to pay principal of and interest on the Note.

Risk of Delay in Payment

The failure of current or future owners of real property in the Project Area to remit property taxes to Cook County when due or the failure of Cook County to timely remit Incremental Taxes to the City could result in insufficient Available Incremental Taxes being available to pay principal of or interest on the Note when due.

Delays in Exercising Remedies

The enforceability of the Note is subject to applicable bankruptcy laws, equitable principles affecting the enforcement of creditors' rights generally and of liens securing such rights, and the police powers of the State of Illinois and its political subdivisions. Because of delays inherent in obtaining judicial remedies, it should not be assumed that these remedies could be accomplished rapidly.

Remedies available to the Noteholder may be limited by a variety of factors and may be inadequate to assure the timely payment of principal of and interest on the Note, or to preserve the tax-exempt status of the Note. The Note is not subject to acceleration due to payment default. Lack of remedies, may entail risks of delay, limitation, or modification of the rights of the Noteholder. Judicial remedies, such as foreclosure and enforcement of covenants, are subject to exercise of judicial discretion.

Risk of Transferee Becoming a Debtor in Bankruptcy

If a transferee of the Note were to become a debtor under the United States Bankruptcy Code or applicable state laws, a creditor or trustee in bankruptcy of the transferee might argue that the sale of the Note by the transferee constituted a fraudulent conveyance or a pledge of the Note rather than a sale. If such positions were accepted by a court, then delays in principal and interest payments to the Noteholder could occur or reductions in the amounts of such payments could result. Additionally, if the transfer of the Note is re-characterized as a pledge, then a tax lien, governmental lien or other lien created by operation of law on the property ofthe transferee could have priority over the holder's interest in the Note.

Loss of Tax Exemption

Interest on the Note could become includible in gross income for federal income tax purposes retroactive to the date of issuance of the Note as a result of a failure of the City to comply with certain provisions of the Internal Revenue Code of 1986, as amended (the "Code"). An event of taxability does not trigger a mandatory redemption of the Note, and the Note will remain outstanding to maturity or until redeemed.

THE ABOVE IS NOT INTENDED TO BE A COMPREHENSIVE DISCUSSION OF ALL POTENTIAL RISKS ASSOCIATED WITH THE NOTE.
PRINCIPAL PAYMENT RECORD
DATE OF PAYMENT PRINCIPAL PAYMENT PRINCIPAL BALANCE DUE
(ASSIGNMENT)
FOR VALUE RECEIVED, the undersigned sells, assigns and transfers unto [NAME OF ASSIGNEE] the within Note and does hereby irrevocably constitute and appoint
attorney to transfer the said Note on the books kept for
registration thereof with full power of substitution in the premises.


Dated:
Registered Owner

NOTICE: The signature to this assignment must correspond with the name of the Registered Owner as it appears upon the face of the Note in every particular, without alteration or enlargement or any change whatever.

Signature Guaranteed:

Notice: Signature(s) must be guaranteed by a member of the New York Stock Exchange or a commercial bank or trust company.

Consented to by:

CITY OF CHICAGO
DEPARTMENT OF PLANNING AND DEVELOPMENT
BY:
ITS:

CITY OF CHICAGO DEPARTMENT OF FINANCE

BY:

ITS:
Exhibit C to the Ordinance

Certificate of Expenditure form for the City Note


(See attached)














































12

FORM OF CERTIFICATION OF EXPENDITURE
(Closing Date)
To: Registered Owner
Re: City of Chicago, Cook County, Illinois (the "City")
$ Tax Increment Allocation Revenue Note
(North Pullman Redevelopment Project Area, Tax-Exempt Series A) (the "Redevelopment Note")
This Certification is submitted to you, Registered Owner of the Redevelopment Note, pursuant to the Ordinance of the City authorizing the execution of the Redevelopment Note
adopted by the City Council of the City on , (the "Ordinance"). All terms used
herein shall have the same meaning as when used in the Ordinance.

The City hereby certifies that $ is advanced as principal under the
Redevelopment Note as of the date hereof. Such amount has been properly incurred, is a proper charge made or to be made in connection with the redevelopment project costs defined in the Ordinance and has not been the basis of any previous principal advance. As of the date
hereof, the outstanding principal balance under the Redevelopment Note is $ , including
the amount of this Certificate and less payment made on the Redevelopment Note.

IN WITNESS WHEREOF, the City has caused this Certification to be signed on its behalf as of (Closing Date).

CITY OF CHICAGO


By:
Commissioner
Department of Planning and Development


AUTHENTICATED BY:



REGISTRAR
CITY OF CHICAGO ECONOMIC.DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION I - GENERAL INFORMATION
Legal name oT.thc-:D'i|"c1b;§i.nyp:ar.t>; s(i^mittirig;lhis.EDS. Include d/b/a/ if applicable:


• ¦• ¦-, ¦¦ ¦ v- j Check ONE of the following

I ndi ca tc .whether, the Pi^l6^ihg^P'arty^sub.rjlittihg.this;iE•DS is:
jX] the Applicant.
OR ¦¦ ' ' .:; ... ¦
f ] a legalertity)ho;lt!\ti-g;a^ir.ectVor ihdircctjinlcrest in the Applicant. Statc.the'icc'alihahicfof'thc
Applie.aiit.iii wJic^Vlh^.-Disc\lb;sihg- Pa:rty:!h.6la^n;iht^if est:' ¦ ' '•.:. 1 ;j ;> ___
or ' "' ' :." ' "' ' ' ' ¦"" ' ;- ' "
3. [] aTegalcntityAyW^ 1I.B.1.) State the lcgal.na'mc of the cntjty in
w hich the -D t^tldsjngfP^r^bM^a^rigKt of control: . ' -?
V 'v*' ~ : " ~~
Business ;addrcss*bf>the'"Djsclosjn'g Party:. ¦ /pfi.b^ Y?: '' M.jffl?" ,^T~ ; I. ¦ ¦ ¦ • ;
Telephone: 7tf&r.5$frAM<&*$*x: i'¦•.»¦ ¦ ¦ -Email: flftl-a r k^l^ j;^/;^^^/^

. • ' - ^ J :.' ( . 1
Name of contac(;persjbn.: ^fr/^itfA^ ''ffmflxfijjCK H. Fcdcral'Emplpycf^dc'iin

Brief dcspVipiib^.^ other^u^ to
which this EDS pertains'^ if applicabic):
Which Cily agency ocdeparlmchUs r.cqucsting«thi,s'EDS? f\rf{ o/.' /^./^w^'j^ V hf.ilf7- fcoT^ f\V}
ff thc Matter is a Contract being handled by thc'sGily's Department of Procurement Services, please complete thc following:

Specification// >.: ¦ _ _.; and Contract-// _



Page 1 of 13

SECTION II DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY
[ J Person
[ ] Publicly registered business corporation
[ ] Privatcly-held^usiness cbrporation
[ ] Sole proprietorship
'¦[ ];'.Gcn"crai partnership
[] Limited partnership
[ ] Trust
[*] Limited liability company '¦ " 1
[ ] Limited liability partnership
[ ] Joint venture
j>^. Not-rfpr-prbfit corporation
(Is the not-forTprofii corporation.also'a 5.01(c)(3))?
J>I Yes [ ] NO
[ ] Other (please specify)

2. For legal entities, the state (or foreign country) of incorporation or organisation, if applicable:
__z^ :
3. For legal entities not organized in the State of Illinois: Has thc organization registercd"to:do business in the State of Illinois as a foreign entity?

[.JYes []No . []N/A

B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:

1. Lisl below the. fujj names .and titles of all executive officers and all directors of thc.entily. NOTE: For notrfdr-profit ep]r^Qt^n6!tfs.i4also, list .below all-members, if.aiiy, which aFIf the entity is a general partnef|l{jp, linVitcd.partncrshipi Hniitcd liability co.nipahy, liihitcd^bability partnership or joint venture, liist^cjow^^.n^hi^and title of each general/partner. nianagjiigimernbeT, manager or any other person or.entity;-uia^4^r,Q}s.:^ day-lq-day management of the Disclosing Party. NOTE: Each legal tintity listcdiibclow niusirsubni.it' an EDS oh ils own behalf.

Name







2. Please provide the followingvinformation concerning each person or entity haying a-direct or indirect beneficial interest (including ownership) in excess of 7.5'% ofthe Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture.

Page 2 of 13

f^ft CH IC AGO M El G H BOIIHOOD
1 INITIATIVES


2015-20,16 Directory
Board of Directors
Mcrlpo.Jackson, Chair Merlon iac^sbn®cdmgastjiei:... . Senior •'P^5to/;:ghrist:fcommunity Church
Bridget%K6jefe,^]cc,Chair '
hokgiLfe^ • -— p^^r^Q^spin arid Aument
Eva M. Brown.iSedreJaty/
. wa. brown 5>us ba nfecbm
. Vice:'Rrfesjdenrarici Manager. Community Affairs Division
'.-¦v
Timothy Frens,'Treasurer / Tim 'f rflps@plah'temo?an;Com " * Partner^PiaptetMoran
Darryl Jacob's . / rij,nrohs(aainsbera)ac6bs.com
« Parthery'G'ihsb'.erg and Jacobs
Melinda Kelly, '
melihdakeliy@cb,aw6H;» ^cQiB^p;ir^86'eHaJiw'rn Business Association
Steve Kramer-
Si§fj£fgf^|^t. Tax.Creditlnvestments, US Bank Community •Development Corppratibh'l-l - 'i'
Robert McGfiee^', ^ t Robertimrohee'gtijsb'ankrcom _
» "Vice?lj'^TiShC^P'«PWUni^-Aff^^' Citibank
»'.!*>•.""'- fr'r ' '¦ ' ' ;.
Thomas^MC^hpn :i. mcmalionc^bcaiobaLnet

Willard Pay.toh*
Wlnl 500@s'bccilobaljTet:
. ' SenipFPastor, New Birth Church of God In Christ
Arnold Pugh* .„ appMnh.^Kmprite'chvriiSt
• Roselan8.»*ebmmunity representative
Christopher Srnithy rn-pii-h (ahhschlcadb.org
. Roseiaji'dvrepresentative
Daniel Watts r
dv»'atts^orestpaikbaiik,cpm
pfesiderit/COO, Forest Park National Bank and Trust


1000 l-.nsi Hi* Strixl * Chicago. U . Mi.'i2S ? 77,> 341 -21

interest of a member or manager in a limited liability company, or interest of a beneficiary of n trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-1 54-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.

Name Business Address Percentage Interest in the '
Disclosing Party
AiflAJe;' . . . :






SECTION III - BUSINESS RELATIONSHICS WITH CITY ELECTED OFFICIALS

Has the Disclosing Party had a "business relationship,'' as defined in Chapter 2-156 of the Municipal Code, with any City ejected official in the 12 month's before the'date this EDS is signed?

[ ] Yes JX[ No
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):




SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

The Disclosing Party-must disclose the name and^busiii'ess address of-each subcontractor, attorney, lobbyist, accountant; consultanitana'la~hy b thcr>p'erspn'$i'gnft ty\wh,om the Disclosing Party has retained or,e,\pects to retain.in connection witlHhc Matte!r,*."as well as the nature of the relationship, and thc total amount of the fees .paid or estijhat.c%f.o be pajd.YFhe Disclosing Tfarty is not required to disclose employees who are paid solely •through the Disclosing Party's regular payroll.

"Lobbyist" means-any person or entity who undertakes to influence any legislative or administrative action on behalf of any.pcrson or entity other (han:,(l) a nof-for-profil entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any persbni.or*entity any part of whose duties as an employee of anotherincludes undertaking to influence ariy'iegislative or'administrative action.

If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Parly must cither ask lhe City whether disclosure is required or make the disclosure.





Page 3 of 13
Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney. paid or estimated.) NOTE:
to be retained) lobbyist, etc.) "hourly rate" or "t.'b.d." is
not an acceptable response.
fy.Jl ftr'fer 4£M&3j: rj£2L.'&$/(^^J^J^JiAC^-L- CMilo f.VbfctfW , a^t. 0(K\
est, ft S3/odd
TIF (je'ti^m TKivi
mi f.Ai vtkdrMiririn.' e±
(Add sheets if necessary)
( ] Check here if-the Disclosing Party.has.not retained; nor expects to retain, any suchp.ersons or entities. SECTION V -- CERTI^ipATIONS
A. COURTtORDERED CHILD SUPPORT COMPLIANCE
tities that contract with ut the' contract's term.
Under Municipal'^db^Sig-tion''2-9.2-41^substantial'ow|iers of-business e'ntiti the City must remain ihicbiftpiiance wiih;tWeirchild-support obligation's tlirou'gho
Has any person who^duecjly. or indirectly,(owns 10% or more of the Disclosing Party been ,declared in arrearage on any child, support;obligations* by any IIHnoisVcourt of competent jurisdiction?

person in cpmphancenvith chat agreement.'
[ ] Yes [ ]VNo
B. FURTHER CERTIFICATIONS
1. Pursuant to, Municipal '(Code Chapter 'l-:23, Article I ("Article I")(which th~c Applicant^sliould consult for defme'd lenrfs^(c.-g., ."doing business") and legal requirements), if the .Disclosing Party submitting this EDS is the? Applicant and is doing business With the City, then the Disclosing Party certifies as follows: (i).ncither the Applicant lipr any controlling person is currently indicted or charged with, or has admitted g'uiltof;'or has e'ver-been convicted of, or placed under supervision for, any criminal offense invblying.actual/att'cmpled, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dislionesty^df deceit against an officer or empib'yee of the City or any sister agency; and (ii) the Applicant understandS;.andTackiiowledges that cpmp.liarice with Article I is a continuing requirement for doing business with the jC-ity; NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.


Page 4 of 13

2. The Disclosing Party and, if the Disclosing Party is a legal enlily, all of thosepcrsons or entities
identified in Section 11. B. I. of this EDS:
are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from ahy transactions by any federal, stale or local unit of government;
have not, wilhiiv.a':five-year period preceding the dale of this EDS, been convicted of a criminal
offense, adjudged guilty;'or. had a civil judgment rendered against'them in-connection, .with:
obtaining,vatteVnp'tiii^ a,public (federal; state or¦local')>trarisactioh or
contract u'n'deflaVpub'iic. Irarisac'tioni-a'violat'ioh' of federal or .stare'antitrust statutes; fraud-
em^.ezzlc"mch]ti^hcYt\ffp^?ry.; bribery;falsification of destruction'of records; making false
statements; or receiving stolen property;
arc not presentiy iftdicted fyx, or criminally or civilly charged b.y, a ¦governmental entity (federal, state or local).with: committing any of the offerises-set forth in;-clause'B.'2.b. of this Section V;
have.not,:;\vJjthin;a;fiy^year,penod preceding the date .of this !E'D,S, had one or more public transaction's (-fe'dcralKstate-or local) terminated for cause or default; and ¦
" • .-"* ¦
have not, within a five-year period preceding the date of this.EDS/bccn convicted, adjudged
guilty, or founojiiabl^-in acivil proceeding, or "in any criminal-or civil aciion,- including.actions
concerning envirb^ instituted by the City or by mc fcderaLgovc'rnmenl, any
state, or any other unit of local government.
3. The certificatiphs'in subparts 3, 4 and 5 concern:
Mhe Disclosing Party; . -
any "Contracted (rri%hingconnection wit.hjh&Jvi&t^ not limited to all persons;:;oiVlegal entities disclose^lundcr
Section IV, ''pisclosurfe^jSubcontractors andOther Retainedi'Pahics'7);
any "AffiIiat^d*Ei^fj^^veanjn.g a person or entity triati directly or indirectly: controls the
Disclosing P,^rJ.S;c|^p^d by the?. Disclosing Party, or.is, wjtMhe DisclosingjParty, under
common cohjtroj-of another:pcrsqn or entity. Indicia of control include, w'tthp.uj^irnitatipn:
inlcrlbcking;nvan^ of interests among family members, shared facilities
and equipment; cpAnripii^e of employees-; or organization of a. business eritity fpj.lowiiig ;thc
ineligibility df a\b^sj[iifesfrC&tity^p-"dQ Business with federal or state or loca.l;go.yern'h'i.cn\including
lhc City, using substanliaUy the same management, ownership, or principals as (he.ineligible entity);
with respect td'.^o^tracfCiVsj.the term Affiliated Entity means a person or entity that directly or
indirectly controls -thej Con tractor, is controlled by it, or, with thcConiractor, is xtnder- common
control of an other .p.'e.rso.n or .entity;
' any responsible.p'M^ial^fjhe-'Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").


Page 5 of 13

Neither ihe Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before ihe date this EDS is signed, or, with respect to a Contractor, an Affiliated-Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been,convicted or adjudged guilty of bribery or attempting to bribe, a publitVofficcr. or.-employee pftth'e City, thc State of Illinois, or any agency of the federal government'oY^ofany'staf e-.-phldcaj'-gOYCmment in- the United States of America, in that officer's or employee's official capacity; ¦
agreed or colludcd wilh other bidders or prospective bidders, or been a -party-to any such agrcemeiit, or been co'nyi'ctiecl :br\dj\idg'cd guiltyof;agrecmcnt or collusion among, bidders or prospective biddcrs, in" rcstraihr'of freedom of competition-by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described-in a. or b. above that is a matter of record, but have not bccn*prb'sc!duted''f6r;:s;M^h conduct; or
violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).

A. Neither thc- pisclosing-p.afty. Affiliated Entity or Contractor, or any of their cmployees, officials,
agents or.partncrs,/s-liarre^ any unit'of state, or local government as a result of
engaging in or being:conviptcd PL violation of 720 ILCS 5/33E-3: (2) bid-rotating-in'
violation of 720 ILCS-.5/3:3-.fi^.;-o^3);i^"y simjlar offense of any state or of the United States of America that contains tKe^am'e elements as the offense'of bid-rigging or bid-rotating.
Neither th'p DisclcVsiii^ Party nor an&Af&ljated.Entity is listed,on.-any o^thc;following lists maintained by the Qffi^ero'fcrpjreiijgn, Ass^s!Cp^fcft&Vtjbc 'U.S. Department ofthcTreasury or thc Bureau of Industry andfSepuritjfVQf^h,Q^U'Sv;Pehartme'nt of Commerce or their successprs: the Specially Designated Nationals List, thc Denied Persons List, the Unverified List, the Entity List and the Debarred List.
The Disclosing P;frty; Un'ders.ta comply with the.applicabie requirements of Chapters
2-55 (Legislative Inspector General), 2^i.'6-("lnspeclor Genera!) and 2-156 (Governmental Ethics) ofthe
Municipal Code.
If die Disclosing Parly is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:







Page 6 of 13

If thc Idlers "NA," the word "None,".or no response-appears on the lines above, il will be conclusively presumed that ihe Disclosing Party certified to the above statements.

8. To thc best of thcDisclosing Party's knowledge after reasonable inquiry, thc following is a
complete iist.pf all cufrc.i\tcrnj)joyccsiP'f the Disclosing P.arty who were, at any time during the J;-2-
month ;pcr;iod>'pr,ccedin;g4^ amemplpyec, or elected or 'aj>poiiifeofthe Gfty bf'(|hicagbX-iff"ibVe, m.i1|i6^tcw.ith "N/AiV^o r- "'n'phc")''.




y. To the best 'pfftlic 'P.iscibsmg.^ .inquiry, the following is a
complete -list of alfgiftsHh'aiL the DiscIqsiiVg-TaH be given, at any tirite during the
12-month period pr'ece^ an'ejrt'pjoycc. or elected, or appointed,
official, oftthc_Gily,(o:f G^^ ofAhis .statement, a. "giCl!'does not include: (tj anything
made gcncralll^ or- (ii).;f6.pd.prt>drj.nk provided;iji the
course of offic]iai'Cjty:^ 6f.le'ss1tii|n-;S20 per.rec^pt'eht'(if n6:ne, indicate
with "N/A" or "nonc'')?v As:to any gifflisicdbelow, please also lisMhe namc of thc'Gity recipient"




C. CERTIFICATION£)E^STATUS JS^INANCIiAL INSTITUTION
: * ¦' T* ¦ ' *>' *
< ':' i' l.
The Disclosing PaYty'ccrtifi^
¦•• " "f.> - >¦•¦ . "¦ ;'¦ ' J"'~*. - ' •
[ ] is ^'is riot
a ''financial.-jnstitutioh'-'Es^cfthcd. in'Section 2-32;#5/5;(b) of thc Municipal Code.
If the Disclosing Rarty-IS a financial institution>thent.hc Disclosing,Party pledges:
¦ ' '\|99|„• ... .
"We arc not and will not become a predatorylend,cras defined, in Chapter 2-3.2 of the Municipal
Code. We further^lcjty^nhjtt none-bf'bufea^ a predatory
lender as dcfincd'in Ghapft;^ ,Wc;.undeystatid-that becoming a predatory
lender or becoming an affiliate, of :a'.pfj5datb;r-y'lj;n''dcptma.y rcsult'ifi the loss ofthe pfivilcgeof doing business with the City:" ''

If the Disclosing party is unable to makeyius plcd|cjbccauscSection 2-32-4 5 Sfb'ldfihc.^ themcaning of Chapter
2-32 ofthe MunicipaKGcVdei cxplarffrlfe^ if necessary).




Page 7 of 13

If the letters "NA," the word "None," or no response appears on the lines above, il will be conclusively presumed that the Disclosing Party certified to the' above statements.

D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS

Any words or terms .that arc-defincd in Chapter 2-156 of the M unicipal Code have the same meanings when usedUn tliis Part, D.
In accordance with Section 2-156; 110 of the Municipal Code; rj0es any official or employee ofthe City have a'Tinah'ciai interest in his or her own name or in-the- name.of any other person or entity in the Matter?
[]Yes f^No
NOTE: If you checked "Yes" to Item D.l., proceed: to Items D.2. and D.3. If you checked "No" to Item D.l., procccd'tto Part E. ,
Unless sold pursuant to a:process of competitive bidding, or;pthcr^'isc,p;6rmittcd,:no,.Qity elected official or employee shall have a:finahcial'inter.cst in his or licr own name or in thename of any'&thcr plerson:prehtity.iri the purchaserb'f any property tha.t'fi) belongs to ithccC icy, or (ii) is sold for tax'es or assesslnehts, oC(iii)tiis! spld by-virtue of legal process afjllic suifto^the.City,.(cdJ'Iccti.vcly, "City property Sale-",). Compensation for property taken pursuant to"the Cityls eminent domain power does not constitute a financial interest within the meaning of this-Parl.D.

Does the Matter involve a City Property Sale?

[ ] Yes ' [ ] No

3. If you checked "Yes" to Item D 1., "provide the.haines andib'u.sihcss 'addresscs 0f fce City
officials or employ.ees'h'aving such interest and identify the naturc-bf such interest:
" , "' ' ¦ '-
Name Business Address Nature oFlnterest





4. The Disclosing Party further certifies thai no prohibited financial interest in the Matter will be acquired by any City official .or employee.

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check cither 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment lo this EDS all information required by paragraph 2. Failure to
Page-8of 13

comply.with these disclosure requirements may make any contract entered into with thc City in connection with thc Matter voidable by the City.

A 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder'insurance policies during the slavery era (including insurance policies issued to sla.vcholders^iln^r^pro.yidedfcoyerage for damage to or injury or death of their slaves), and the Disclosing Party has'found no such records.

2. The DisclosnigvParty verifics.that, as a result of conducting the search in step 1 above, the
Dj^closing -Party-has .fb'ulhafcpprds of investments or profits from slavery or slaveholder insurance
policies. The Disclosi'rigSP^ that the following constitutes fuirdisclbsure of all such
records, including filenames of any and all slaves or. slaveholders described in those records:






SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS

NOTE: If the^ Matter.isfederally funded, complete this Section VJ. If the .Matter is not federally funded, proceed to Seclipn VU For purposes of this Section VI; tax^credits allocated by the City and proceeds of debt obligations of the City are not federal funding.

A. CERTIFICATION REGARDING LOBBYING

1. List below the n.ames ,of allpersons or entities registered under the federal Lobbying Disclosure Actof?T99.5twhpfhaye)inade lobbying contacts on behalf of the Disclosing Party with respect to the M att^;*(*/^^sheeis ''if necessary):




(If no explanation ,appears or begins on";the lines abo ve, or if the letters "N|V! or if the word "None:" appear, it will be conclusively presumed that the^Disclosing Party, mcans^that NO persons or entities registered under .the Lo'bbying Disclosure Act of 1995 have madc lbbbying contacts on behalf of the Disclosing Party with respect to the Matter.)

2. Thc Disclosing Party has not spent and will not expend any federally, appropriated funds to pay any person or entiiyMi'stcd:in Paragraph A. l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or-employee of any agency, as defined by applicable federal law; a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally, funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13

3'. The Disclosing Parly will submit an updated certification at thc ond of each calendar quarter in which there occurs any event lhat.inaferially affects (he accuracy of (he statements and information set forth in paragraphs A.l. and A.2. above.
The Disclosing"Partyc.e'rtifies lhat either: (i) it is not an organization.described in section 501 (c)(4) of the Internal Revenue of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities". .
If the Disclosing .Party is^He'Applicant, the Disclosing Parly must obtain certifications equal in
form and substancc'Uo^ ."through A .4.above from all-sub'co'ntractprs^b:cfd!rc''tt awards any
subcontract ahd.theTJ.isclb'^ all such subco'ntfactors' certifications fopthc
duration ofthe Matter and must make such certifications promptly available, to thc:G-ity upon request.


B. CIiRTIFICATJ.O.N'REGA*RE> ING E Q UAL EMPLOYMENT OPPORTUNITY -

If the Matter is federally funded, federal regulations require the Applicant and all.proposed
subcontractors to submit the folio wing information with their bids or in writing at, the outset of
negotiations. • "
Is thc Disclosing Party the Applicant?*
[ ] Yes []N.o
If *'Ycs," answer lhcrthfe,e.qucstions below:
Have you 'd^,Vclp;^d^^.o^yic^u'J^avc on file affirmative action programs pursuant to applicable federal regulations'? (S&s '^l0J^0tft6O^,) '•
[ ] Yes [ ]No' >.
Have you filed w'ith the JQintReporting Committee, the Director ofthe Office of Federal Contract CompliaheVProgjams", pr^thc^Equal;EmpIpyment Opportunity Commis'sion all, reports due under the applicableTiling'requirpments?
| 1 Yes .' %t^Q ;:
Have you participated in-any previous.conlracts or subcontracts subject to the equal opportunity clause?
[ J Yes f ] No

If you checked "No" to1 question 1. or.2. above, please provide an explanation:




Page 10 of 13

SECTION VII. -- ACKNOWLEDGMENTS,.CON TRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE

Thc Disclosing Party understands and agrees that:
The certifications,'disclosures, and acknowledgments contained in this EDS will become part of any contract or other, agreement -betwcenVthc Applicant and the City in connection with thc Matter, whether procurement, City assistance, or other City action, and arc material-inducements to the-'City's"execution of any contract or taking other action .with respect to the Matter. The Disclosing Party-understands that it must comply wifh-a'fi statutes, ordinances, and regulations on which this EDS is based.
The City's .Governmental E(hicsr-and Campaign -Financing Ordinances. Chapters 2-156 and 2-164of the Municipal Code",-impose, certain duties and obligations on^pers.oris oiycntities seeking City contracts, work, business, or transactions. The full-'tcxt-'of these ordinances and a training program is.ayailable.pn line at www.citvofchicagoVofg/Eth'ics , and may also be obtained froin the City's Board of Ethics, 740 N.

Sedgwick St., Suite 500,-Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable .ordinances.
If the City deiermines:thaf an^^ in this EDS is false, incomplete or inaccurate,
any contract or other-agreement/ijr^'fcc^nhectipn AV.ith which it is submitted'inay be rescinded'orybe void or
voidable, and thc City-maypursu'ctahy remedies under the contract or agreement (ifnot rescinded tor
void), at law; or in qquiiy,'including terminating the Disclosing Party's participation in the Matter and/or
declining to allow t-Hc'^isclpsing. Party to participate in other transactions with thejCity. Remedies at
law for a false statement of material fact may include incarceration and an award to the City of treble
damages.
It is the City's policy.to;niakejthjs on its^ntcmet-sjtc.'.and/br upon
request. Some or all of the infonnatlon^pfdiyi this EDS~a:nd::any 'attachments t64hi§^E]?'{Jvmay be
made available'to the publicon the Intfc'rnet, imrcsppnsc tp a Freedom of Information Act request, or
otherwise. By comnietjng .and signing this EDS/tlie Disclpsing Party waives and releases-any possible
rights or claims \vhich it may .have agaiifst-the City in connection, with the public release of information
contained in this EDS and alsprauthbriz# thc City to verify the accuracy of any information submitted
in this EDS.
Thc information-provided in this EDS must be kept current. In thc event of changes, the Disclosing Party must supplement this EDS lip to'thc time the City takes action on the Matter. If thc Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as thc contract requires. NOTE: With respect to Matters subject to Article 1 of Chapter 1-23 ofthe Municipal CoddX'im.posihg PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by Chapter 1-23 and Section 2-154:020 ofthe Municipal Code.

Tbe Disclosing Party represents and warrants that:

Page 11 of 13

F. 1. Thc Disclosing Party is not delinquent in thc payment ol" any tax administered by the Illinois Department of Revenue, nor are'-thc Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee. tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets; property taxes or sales taxes.

F.2 If the Disclpsing'Pariy is thc Applicant,.the Disclosi.ng.Party and its Affiliated Entities will not usc,'nor.'pcrmit;thcir;su'bcbntractors to use,-any facility-'listed by the.U.S: E.P.A.on the federal Excluded Parties List System ("EPLS"Tmaintained by:thc U. S^ General Services Administration.

F.3 If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any
contractors/subcontractors hiircd or toj.b.e hired in^conncctioh with the.Matter certifications equal tn
form and substance to those in F. l. and E*2. above .;anti-will not,, without the prior written consent of thc
City, usc.any such^Contractpr/subco^ provide'su'eh certifications or that the
Disclosing Party has reason to believe -has hot provided .or cannot .provide truthful certifications.

NOTE: If the Disclosing-Party cannot certify as.it 6 any ofthe items in F.L, F.2. or F.3. above, an explanatory statement musfbe attached'to tnis'EDS!

CERTIFICATION

Under penalty of perjury, thqjpfersqn signing below: (I) warrants that.he/she is authorized to execute this EDS and-Appendix-A (Uf applicable) onfc^half of thc/pisclosing Party, and (2) warrants that all certifications and s&terneihls cbiitoirted.-in this-EDS and Appendix A (if applicable) are true, accurate and complete as of the date furnished to the City.
Chicago /^m//mmtt>b m /r//) me&, .
(Print or type i^inc^pfsclosinS^Party)

f>fiU ID t>nM-
(Print or type name of person signing)


(Print or type title of person signing)
¦h » OFFICIAL SEAL MARIA 6 McOUGA Msta'v S-A\

Signed and sworn to before mc on (date) f€:J6rua.rat Cook County, t5^Z-, (state). \3'-'" "
^-flltiLtt^J A. Notary Public.

Commission expires: Od7^- / ZZ> ffPage 12 of 13

CITY OF CHICAGO I ECONOMIC: DISCLOSURE .STATEMENT; AND AFFI DAVIT
APPENDIX A I



.FAMILIAL RELATIONSHIPS \VLlH ELE(:!I ED CI I Y OFFICIALS AND DEPARTMENT HEADS

- .f* , -s*- * ¦>¦¦'¦ , ^ ' ¦ * - - * '• .''¦'**
THis App.endixjis ttf Applicant, anil i(b);any\lc;g'al crii|ty,>yhiclrhas/a vdjrecl
owricrsHibjihttr^ ^iltVis hdtjtqijjc
wlii.cK h~as 6"m -"' '?
Uirder«Mijnicipal Codc^Sc must disc|o'sc.;wh
...or any "Applicant domestic .Partner inerebftcurr^
any-clcct^'cityjof^ A ;'familial:relationslii'jp";.ex
signed, the'disclosing .Party? or any Spouse .ofT>oi
thc mayor,:an^^ city treasurer or any city dcpartriieht head as spp^tpri'dp^rftcistic
paitnbr>or'a£anypf^^ or sister, :aunt.o'runclc,
niece br^icbhc^ stepfather
or slcptnodier]lialf-brbthcror half-sisierr £

"Agplicap.l6>^^ if.the
Discibsuig'party.if^ -V •'
partnWship:. JlFgSicra^ the¦©isblpsmg P^rty','if-tK.c0i^ciqsing;ferty is. aijjimilcd'
pa^ajs^ Pisc|pjsing'P.'art^ a
iimtt^iabU
a7.5;pcrecnt^vrim '*flnricipa].bffi .'•
operating office^ ch.ief&hanc^ a legal entity or any person
exercising'sihiilar^uthorily.^ ' ¦' ' :\-; - ' "h
!.v' >* "'•''•
Docs the;Disdosing;Pa^rly;tC;r ajiy^'^^licablp^Pariy" or anjj Spousci.phDprncstic Partncr'rhercpf currently have a 'Tamiliafrcfatipnsi^^
[JYes ^ ' :V ' ¦' J^Nb
"If-yes,-please idcntif^bclbw (l).4jhc name and-titje of such person.,.^) the name.ofthu legal ci) li ly-to. A^hich
such persbiVisrormeb^ and/iitlc/pf the elected' city officiafbr departrncrit licadfto^vhoin such
person has a familial rclatibhship'-and;(4j;ihc precise nature of such familial relationship.










Page 13 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX 13
BUILDING iCODESCOFFLAW/PROBLEM LANDLORD CERTIFICATION

the Applicant
1. . Pursuanf'to.Municjp.al Code/Section 2-154.-010, is thc Applicant or any Owner-identified as a •'bui\di%;c'pdescofllaw or problem landlord pursuant to Section 2-92416 of the Municipal ' Code? " '
f. ]Yes , JX)
If the.-Applicaut ;is a;lc=gal -.entity publicly tradedon any exchange, is any officer .or director, o f the ^^plic^U-iHeKtiirae^ a.s.a*building-Code scofflaw or problem landlord pursuant to-Scciton 2-92-41.6 of the-Municipal Code?
[ ]Ycsl f JNo ^jA^NotApplicable

If yes to (lj/pr (2)-abpy.c, please identify below thc name ofthe^^dri-brjegal entity identificd^^a^wlBjn%xpo4e.scofflaw or problem lan^lprdtand'tile/addressoT





A'Sb^llEEME^.^AT THIS: APPENDIX; S^^ilG^R'iK^OE'D' BY 'REFERENCES! N*i^ THE;ASSOCITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION 1 - GENERAL INFORMATION
Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable:



Check ONE of thc following three boxes:

Indicate whether the Disclosing Party submitting this EDS is:
[j^ the Applicant
OR
[] a legal entity holding a direct or indirect interest in the Applicant. State the legal name of the
Applicant in which the Disclosing Party holds an interest:
OR

3. [] a legal entity with a right of control (see Section II.B. I.) State the legal name of the entity in
which the Disclosing Party holds a right of control:
Business address of the Disclosing Party:
Telephone: 0»i% Fax: &>iZ ^fyl -tfltPD Email: "
Name of contact person: "T~t \^€j^^^U-^
Jj
Federal Employer Identification No. (if you have one): _j|
Brief description of contract, transaction or other undertaking (referred to below as the "Matter") to which this EDS pertains. (Include project number and location of property, if applicable):
fi-bk T19 foiohs T» 3tz_ OSLi c/°*. ^oy&^L TD


G. Which City agency or department is requesting this EDS?
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:

Specification # and Contract #



Page 1 of 13

SECTION II -
- DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY

1. Indicate the nature of the Disclosing Party:
[ ] Person [ ] Limited liability company
[ ] Publicly registered business corporation [ ] Limited liability partnership
^CPrivately held business corporation [ ] Joint venture
[ ] Sole proprietorship [ ] Not-for-profit corporation
[ ] General partnership (Is thc not-for-profit corporation also a 501(c)(3))?
[ ] Limited partnership [ ] Yes [ ] No
[ ] Trust [ ] Other (please specify)


2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable:



3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
L"XYes []No []N/A
B: IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
List below the full names and titles of all executive officers and all directors ofthe entity. NOTE: For not-for-profit corporations, also list below all members, if any, which are legal entities. If there are no such members, write "no members." For trusts, estates or other similar entities, list below the legal titleholder(s).
If the entity is a general partnership, limited partnership, limited liability company, limited liability partnership or joint venture, list below the name and title of each general partner, managing member, manager or any other person or entity that controls the day-to-day management ofthe Disclosing Party. NOTE: Each legal entity listed below must submit an EDS on its own behalf.

Name Title
P/V^vck (> €a*A C^O

~5frimA- H4no>i/vu fC*S[btuT~
rAvOA/VR- Mc-fcl^v pJ/VrtoAJ^ f^CUO^T
Please provide the following information concerning each person or entity having a direct or indirect beneficial interest (including ownership) in excess of 7.5% of the Disclosing Party. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture,

Page 2 of 13

interest of a member or manager in a limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None." NOTE: Pursuant to Section 2-154-030 of the Municipal Code of Chicago ("Municipal Code"), the City may require any such additional information from any applicant which is reasonably intended to achieve full disclosure.

Name Business Address Percentage Interest in the
Disclosing Party







SECTION III - BUSINESS RELATIONSHIPS WITH CITY ELECTED OFFICIALS

Has the Disclosing Party had a "business relationship," as defined in Chapter 2-156 of the Municipal Code, with any City elected official in the 12 months before the date this EDS is signed?
[ ] Yes p^No
If yes, please identify below the name(s) of such City elected official(s) and describe such relationship(s):




SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist, accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature ofthe relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll.

"Lobbyist" means any person or entity who undertakes to influence any legislative or administrative action on behalf of any person or entity other than: (1) a not-for-profit entity, on an unpaid basis, or (2) himself. "Lobbyist" also means any person or entity any part of whose duties as an employee of another includes undertaking to influence any legislative or administrative action.

If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.





Page 3 of 13

Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:
to be retained) lobbyist, etc.) "hourly rate" or "t.b.d." is
not an acceptable response.





(Add sheets if necessary)
jj^ Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
COURT-ORDERED CHILD SUPPORT COMPLIANCE

Under Municipal Code Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.

Has any person who directly or indirectly owns 10% or more ofthe Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?

[JYes ^No [] No person directly or indirectly owns 10% or more of the
Disclosing Party.

If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
[ ] Yes ^ No
FURTHER CERTIFICATIONS

1. Pursuant to Municipal Code Chapter 1-23, Article I ("Article I")(which'the Applicant should consult for defined terms (e.g., "doing business") and legal requirements), if the Disclosing Party submitting this EDS is the Applicant and is doing business with the City, then the Disclosing Party certifies as follows: (i) neither thc Applicant nor any controlling person is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any sister agency; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If Article I applies to the Applicant, the permanent compliance timeframe in Article I supersedes some five-year compliance timeframes in certifications 2 and 3 below.


Page 4 of 13

The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities dentified in Section II.B. 1. of this EDS:

are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
have not, within a five-year period preceding the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in clause B.2.b. of this Section V;
have not, within a five-year period preceding the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
have not, within a five-year period preceding the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The certifications in subparts 3, 4 and 5 concern:

the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity. Indicia of control include, without limitation: interlocking management or. ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity); with respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
• any responsible official of the Disclosing Party, any Contractor or any A ffiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official ofthe Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").


Page 5 of 13

Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor nor any Agents have, during the five years before the date this EDS is signed, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the five years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee ofthe City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in a. or b. above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions of Municipal Code Section 2-92-610 (Living Wage Ordinance).

Neither the Disclosing Party, Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on any ofthe following lists maintained, by the Office of Foreign Assets Control of the U.S. Department of the Treasury or the Bureau of Industry and Security ofthe U.S. Department of Commerce or their successors: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.
The Disclosing Party understands and shall comply with the applicable requirements of Chapters 2-55 (Legislative Inspector General), 2-56 (Inspector General) and 2-156 (Governmental Ethics) of the Municipal Code.
If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:








Page 6 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

8. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the execution date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").




9. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, ofthe City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $20 per recipient (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.



C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is jjfj is not
a "financial institution" as defined in Section 2-32-455(b) of the Municipal Code.
If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in Chapter 2-32 ofthe Municipal Code. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in Chapter 2-32 of the Municipal Code. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."

If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in Section 2-32-455(b) of the Municipal Code) is a predatory lender within the meaning of Chapter 2-32 ofthe Municipal Code, explain here (attach additional pages if necessary):




Page 7 of 13

If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

D. CERTIFICATION REGARDING INTEREST IN CITY BUSINESS

Any words or terms that are defined in Chapter 2-156 of the Municipal Code have the same meanings when used in this Part D.
In accordance with Section 2-156-110 of the Municipal Code: Does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[]Yes )^No
NOTE: If you checked "Yes" to Item D.l., proceed to Items D.2. and D.3. If you checked "No" to Item D.l., proceed to Part E.
Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit ofthe City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.

Does the Matter involve a City Property Sale?

[ ] Yes
3. If you checked "Yes" to Item D.l., provide the names and business addresses of the City officials or employees having such interest and identify the nature of such interest:

Name Business Address Nature of Interest






4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check either 1. or 2. below. If the Disclosing Party checks 2., the Disclosing Party must disclose below or in an attachment to this EDS all information required by paragraph 2. Failure to
Page 8 of 13

comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
)Ct 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.

2. The Disclosing Party verifies that, as a result of conducting the search in step 1 above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that thc following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:






SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS

NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations ofthe City are not federal funding.

A. CERTIFICATION REGARDING LOBBYING

1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995 who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary):




(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995 have made lobbying contacts on behalf ofthe Disclosing Party with respect to the Matter.)

2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in Paragraph A.l. above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
Page 9 of 13

The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects thc accuracy ofthe statements and information set forth in paragraphs A.l. and A.2. above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) ofthe Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) ofthe Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities".
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A.l. through A.4. above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.


B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY

If the Matter is federally funded, federal regulations require thc Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ ] Yes [ ] No
If "Yes," answer the three questions below:
Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[]Ycs []No
Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[]Yes []No
Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[]Yes []No

If you checked "No" to question 1. or 2. above, please provide an explanation:




Page 10 of 13

SECTION VII -- ACKNOWLEDGMENTS, CONTRACT INCORPORATION, COMPLIANCE, PENALTIES, DISCLOSURE

Thc Disclosing Party understands and agrees that:
The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics and Campaign Financing Ordinances, Chapters 2-156 and 2-164 of the Municipal Code, impose certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of these ordinances and a training program is available on line at www.cityofchicago.org/Ethics , and may also be obtained from the City's Board of Ethics, 740 N.

Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with the applicable ordinances.
If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other transactions with the City. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided on this EDS and any attachments to this EDS may be made available to the public on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.

E. The information provided in this EDS must be kept current. In the event of changes, the Disclosing
Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a
contract being handled by the City's Department of Procurement Services, the Disclosing Party must
update this EDS as the contract requires. NOTE: With respect to Matters subject to Article I of
Chapter 1-23 ofthe Municipal Code (imposing PERMANENT INELIGIBILITY for certain specified
offenses), the information provided herein regarding eligibility must be kept current for a longer period,
as required by Chapter 1-23 and Section 2-154-020 ofthe Municipal Code.

The Disclosing Party represents and warrants that:

Page 11 of 13
F. 1. The Disclosing Party is not delinquent in the payment of any tax administered by the Illinois Department of Revenue, nor are the Disclosing Party or its Affiliated Entities delinquent in paying any fine, fee, tax or other charge owed to the City. This includes, but is not limited to, all water charges, sewer charges, license fees, parking tickets, property taxes or sales taxes.

F.2 If the Disclosing Party is the Applicant, the Disclosing Party and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed by the U.S. E.P.A. on the federal Excluded Parties List System ("EPLS") maintained by thc U. S. General Services Administration.

F.3 If the Disclosing Party is the Applicant, the Disclosing Party will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in F.l. and F.2. above and will not, without the prior written consent ofthe City, use any such contractor/subcontractor that does not provide such certifications or that the Disclosing Party has reason to believe has not provided or cannot provide truthful certifications.

NOTE: If the Disclosing Party cannot certify as to any of the items in F.L, F.2. or F.3. above, an explanatory statement must be attached to this EDS.

CERTIFICATION

Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS and Appendix A (if applicable) on behalf ofthe Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS and Appendix A (if applicable) are true, accurate and complete as ofthe date furnished to the City.


(Print or type name of Disclosing Party)


(Print or type name of person signing) (Print or type title of person signing)
at

Signed and sworn to before me on (date) 1^1 RQlfa
tOFFICIAL SEAL
Notary Public.
n . . 03 6b 2y0l7 \ CATHERINELPETERS
Commission expires: L I > notary public-State of Illinois
J MY COMMISSION EXPIRES:03/08/17
Page 12 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A



FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS


This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.

Under Municipal Code Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughtcr-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.

"Applicable Party" means (1) all executive officers ofthe Disclosing Party listed in Section II.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members ofthe Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5 percent ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.

Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?

[ ] Yes
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.










Page 13 of 13

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX B

BUILDING CODE SCOFFLAW/PROBLEM LANDLORD CERTIFICATION

This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5 percent (an "Owner"). It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Pursuant to Municipal Code Section 2-154-010, is the Applicant or any Owner identified as a building code scofflaw or problem landlord pursuant to Section 2-92416 ofthe Municipal Code?
[ ]Yes [X|No
If the Applicant is a legal entity publicly traded on any exchange, is any officer or director of the Applicant identified as a building code scofflaw or problem landlord pursuant to Section 2-92-416 ofthe Municipal Code?
[ ]Yes [ ]No (/] Not Applicable

3. If yes to (1) or (2) above, please identify below thc name of the person or legal entity
identified as a building code scofflaw or problem landlord and the address of the building or buildings to which the pertinent code violations apply.






FILLING OUT THIS APPENDIX B CONSTITUTES ACKNOWLEDGMENT AND AGREEMENT THAT THIS APPENDIX B IS INCORPORATED BY REFERENCE INTO, AND MADE A PART OF, THE ASSOCIATED EDS, AND THAT THE REPRESENTATIONS MADE IN THIS APPENDIX B ARE SUBJECT TO THE CERTIFICATION MADE UNDER PENALTY OF PERJURY ON PAGE 12 OF THE ASSOCIATED EDS.
\3


CHICAGO June 22, 2016
To the President and Members of the City Council:
Your Committee on Finance having had under consideration




A substitute ordinance concerning the authority to approve a Redevelopment Agreement with Chicago Neighborhood Initiatives, Inc.

02016-4593












Having had the same under advisement, begs leave to report and recommend that your Honorable Body pass the Substitute Ordinance Transmitted Herewith

This recommendation was concurred in by
of members of the committee with

Chairman