Share to Facebook Share to Twitter Bookmark and Share
This record contains private information, which has been redacted from public viewing.
Record #: O2019-2817   
Type: Ordinance Status: Passed
Intro date: 4/10/2019 Current Controlling Legislative Body: Committee on Housing and Real Estate
Final action: 6/12/2019
Title: Sale of vacant City-owned library at 2724 W Cermak Rd to Latinos Progresando
Sponsors: Emanuel, Rahm
Topic: PROPERTY - Sale
Attachments: 1. O2019-2817.pdf
OFFICE OF THE MAYOR
CI TY OF CHICAGO
RAIIM EMANUEL
MAYOR
April 10, 2019










TO THE HONORABLE, THE CITY COUNCIL OF THE CITY OF CHICAGO


Ladies and Gentlemen:

At the request of the Commissioner of Planning and Development, I transmit herewith ordinances authorizing the sale of City-owned property.

Your favorable consideration of these ordinances will be appreciated.

Mayor


Very truly yours,
ORDINANCE

WHEREAS, the City of Chicago (the "City") is a home rule unit of government by virtue of the provisions of the Constitution of the State of Illinois of 1970, and as such, may exercise any power and perform any function pertaining to its government and affairs; and

WHEREAS, the Developer desires to purchase from the City, for One Dollar ($1.00), the property commonly known as 2724 W Cermak Road, Chicago, Illinois, which is improved with an approximately 9,330 sq. ft., 2-story vacant former Chicago Public Library building (the "Building") and legally described on Exhibit A, attached hereto (the "Property"); and

WHEREAS, the appraised fair market value of the Property is Two Hundred Fifty Thousand Dollars ($250,000); and

WHEREAS, the Developer proposes to completely renovate the entire building, with the first floor to include a lobby, office space and administrative space for Latinos Progresando's immigration services, the second floor to include more office space for the Marshall Square Resource Network and community meeting space, and with the basement floor to include space for two tenants, Esperanza Health Center and Lincoln Park Zoo (the "Project"); and

WHEREAS, by Resolution No. 19-010-021, adopted by the Plan Commission ofthe City of Chicago (the "Plan Commission") on February 21, 2019, the Plan Commission recommended the sale of the Property; and

WHEREAS, public notices advertising the proposed sale appeared in the Sun-Times on February 6, 2019; now therefore,

BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO:

SECTION 1. The foregoing recitals are hereby adopted as the findings ofthe City Council.

SECTION 2. The sale ofthe Property to the Developer in the amount of One Dollar ($1.00) is hereby approved. This approval is expressly conditioned upon the City entering into a redevelopment agreement with the Developer substantially in the form attached hereto as Exhibit B and made a part hereof (the "Redevelopment Agreement"). The Commissioner of the City's Department of Planning and Development, or any successor department thereto ("Commissioner"), or a designee of the Commissioner, is each hereby authorized, with the approval of the City's Corporation Counsel as to form and legality, to negotiate, execute and deliver the Redevelopment Agreement, and such other supporting documents as may be necessary or appropriate to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement.

SECTION 3. The Mayor or his proxy is authorized to execute, and the City Clerk or Deputy City Clerk is authorized to attest, a quitclaim deed conveying the Property to the Developer, or to a

land trust of which the Developer is the sole beneficiary, or to an entity of which the Developer is the sole owner and the controlling party, subject to those covenants, conditions and restrictions set forth in the Redevelopment Agreement.

SECTION 4. If any provision of this ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such provision shall not affect any of the other provisions of this ordinance.

SECTION 5. All ordinances, resolutions, motions or orders in conflict with this ordinance are hereby repealed to the extent of such conflict.

SECTION 6. This ordinance shall take effect immediately upon its passage and approval.
EXHIBIT A

LEGAL DESCRIPTION OF PROPERTY (Subject to Title Commitment and Final Survey)

LOT 19 IN MCMAHON'S SUBDIVISION OF THE WEST '/2 OF THE WEST Vi OF THE SOUTHEAST lA OF SECTION 24-39-13, IN COOK COUNTY, ILLINOIS.


PINs: 16-24-422-037-0000


Commonly known as 2724 W Cermak Road, Chicago, Illinois 60608-3510
EXHIBIT B
REDEVELOPMENT AGREEMENT (Attached)
This Document Prepared by and After Recording Return To:

City of Chicago Department of Law Real Estate Division 121 North LaSalle Street Room 600
Chicago, Illinois 60602 (312)744-0200


AGREEMENT FOR THE SALE AND REDEVELOPMENT OF LAND



(The Above Space For Recorder's Use Only)


This AGREEMENT FOR THE SALE AND REDEVELOPMENT OF LAND, as
may be amended from time to time ("Agreement"), is made on or as of the day of
, 20_ (the "Effective Date"), by and among the CITY OF CHICAGO,
an Illinois municipal corporation and home rule unit of government ("City"), acting by and through its Department of Planning and Development (together with any successor department thereto, the "Department" or "DPD"), having its principal offices at City Hall, 121 North LaSalle Street, Chicago, Illinois 60602, and LATINOS PROGRESANDO, an Illinois not-for-profit corporation ("LP"), located at 3047 W. Cermak Road, Chicago, Illinois 60623, (the "Developer").

RECITALS

WHEREAS, LP desires to purchase from the City, for One Dollar ($1.00), the property commonly known as 2724 W. Cermak, Chicago, Illinois, which is improved with the approximately 9,330 sq. ft., vacant former Chicago Public Library facility (the "Building") and legally described on Exhibit A, attached hereto (the "Property"), for the purpose of LP's redeveloping the Property as herein provided; and

WHEREAS, the appraised fair market value of the Property is Two Hundred Fifty Thousand Dollars and 00/100 ($250,000.00); and

WHEREAS, LP provided to the City a Phase I Environmental Site Assessment for the Property in accordance with ASTM E-l 527-13 ("Phase I ESA"), dated April 17, 2014,

|1010|
performed by Pioneer Environmental Services, LLC (Pioneer). LP must provide to the City a reliance letter naming the City as an authorized user, or provide an Updated Phase I ESA, within 180 days prior to closing; and

WHEREAS, the Phase I ESA did not identify any recognized environmental conditions in connection with the Property, therefore the Developer does not need to obtain a Phase II Environmental Site Assessment ("Phase II ESA"); and

WHEREAS, LP obtained and provided to the City a Hazardous Materials Survey, (the "HMS") consisting of a Lead Based Paint Inspection Report ("LBP"), dated February 28, 2019, an Asbestos Containing Material Survey ("ACM") dated February 20, 2019, arid Hazardous Materials Assessment ("HMA") dated March 5, 2019, all performed by Pekron Consulting, Inc. (Pekron); and

WHEREAS, the HMS identified hazardous materials in the Buildirig or otherwise in connection with the Property, therefore the Developer must generate a Hazardous Materials Operations and Management Plan and/or an Abatement Plan, and LP must comply with such plans in accordance therewith prior to occupancy of the Property; and

WHEREAS, the City Council, pursuant to an ordinance adopted on May , 2019 (the
- "Ordinance Date"), and published at pages through in the Journal of the
Proceedings of the City Council of such date, authorized the sale of the Property to LP for One Dollar ($1.00), subject to the execution, delivery and recording of this Agreement, and in consideration of LP's fulfillment of its obligations under this Agreement, including the obligations (i) to undertake and complete a complete renovation of the Building (the "Project"), and (ii) to operate offices and administrative space for Latinos Progresando's immigration services and other community services organizations on the Property, each as further described in Exhibit B attached hereto; and

WHEREAS, the Ordinance authorized the Mayor or his proxy to execute, and .the City Clerk or Deputy City Clerk to attest, a quitclaim deed conveying the Property to LP, or to a land trust of which1 LP is the sole beneficiary, or to an entity of which LP is the sole owner and the controlling party, subject to those covenants, conditions and restrictions set forth in this Agreement; and

WHEREAS, LP represents and warrants that LP is the sole owner and the controlling party of LP.

NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree as follows:







|1010|
SECTION 1. INCORPORATION OF RECITALS.

The recitals set forth above constitute an integral part of this Agreement and are incorporated herein by this reference with the same force and effect as if set forth herein as agreements of the parties.

SECTION 2. PURCHASE PRICE / EARNEST MONEY / PERFORMANCE DEPOSIT.
Purchase Price. Subject to the terms, covenants and conditions of this Agreement, the City agrees to sell the Property to LP, and LP agrees to purchase the Property from the City, for One Dollar ($1.00) (the "Purchase Price") to be paid by cashier's check or certified check, to be paid on the Closing Date (defined in Section 3).
Earnest Money. [Intentionally omitted.]
Performance Deposit. [Intentionally omitted.]


SECTION 3. CLOSING.

The closing of this Agreement and the closing of the transfer of the Property from the City to LP (together, the "Closing", which occurs on the "Closing Date") shall take place concurrently, and at the downtown offices of Greater Illinois Title Company, 120 North LaSalle Street, Chicago, Illinois 60602, or such other reputable title company as may be selected by the Developer (the "Title Company"). In no event shall the Closing occur: (1) until and unless the conditions precedent set forth in Section 8 are all satisfied, unless the Department, in its . sole discretion, waives one or more of such conditions; and (2) any later than ninety (90) days
following the Ordinance Date (i.e., May , 2019) (the "Outside Closing Date"), unless, at the
Developer's request, the Department, in its sole discretion, extends the Outside Closing Date. At the Closing, the City shall deliver to LP (a) the Deed (as defined below); (b) all necessary state, county and municipal real estate transfer declarations; and (c) possession of the Property.

SECTION 4. CONVEYANCE OF TITLE.

4.1 Form of Deed. The City shall convey the Property to LP by quitclaim deed ("Deed"), subject to the terms of this Agreement and, without limiting the quitclaim nature ofthe Deed, to the following:
standard exceptions in an ALTA title insurance policy;
general real estate taxes and any special assessments or other taxes;
all easements, encroachments, covenants and restrictions of record and not shown of record;
such other title defects that may exist; and
any and all exceptions caused by the acts of the Developer or its agents.




|1010|
Recording Costs. The Developer shall at its expense record, or cause the Title Company to record, the Deed, this Agreement, and any other documents incident to the conveyance of the Property to LP.
Escrow. If the Developer requires conveyance through escrow, the Developer shall pay all escrow fees.

SECTION 5. TITLE, SURVEY AND REAL ESTATE TAXES.
Title Commitment and Insurance. Not less than 30 days before the Closing Date, the Developer shall order a current title commitment for the Property issued by the Title Company. The Developer shall pay the cost of, and shall be responsible for, obtaining on the Closing Date, any title insurance, extended coverage and any endorsements it deems necessary. The City agrees to provide the Title Company with a completed ALTA owner's statement, and other transfer documents typically required by the Title Company and typically provided by the City (but expressly excluding, however, "gap" undertakings, title indemnities and similar liabilities) at or prior to the Closing. Promptly following the Closing, the Developer shall deliver to the City a copy of the owner's policy of title insurance that it obtains with respect to the Property.
Survey. The Developer will be responsible for obtaining, at Developer's expense, any survey for the Property, as it deems necessary.
Real Estate Taxes. The City shall use reasonable efforts to obtain the waiver or release of any delinquent real estate taxes or tax liens on the Property prior to the Closing Date, to the extent such taxes or tax liens can be waived or released through the submission of an abatement letter to the Cook County Treasurer, a motion to vacate a tax sale, or a petition for exemption. If, after using such reasonable efforts, the City is unable to obtain the waiver or release of any such tax liens or is unable to cause the Title Company to insure over such tax liens, or if the Property is encumbered with any other exceptions that would adversely affect the use and insurability of the Property for the development of the Project, the Developer shall have the option to do one of the following: (1) accept title to the Property subject to the exceptions, without reduction in the Purchase Price; or (2) terminate this Agreement by delivery of written notice to the City, in which event this Agreement shall be null and void, and except as otherwise specifically provided herein, neither party shall have any further right, duty or obligation hereunder. If the Developer elects not to terminate this Agreement as aforesaid, LP agrees to accept title subject to all exceptions.

SECTION 6. BUILDING PERMITS AND OTHER GOVERNMENTAL APPROVALS.

The Developer shall apply for and obtain all necessary building permits and other approvals, (collectively, the "Governmental Approvals") necessary for the Project, prior to the Closing Date, unless the Department, in its sole discretion, agrees to waive such requirement.




|1010|
SECTION 7. PROJECT BUDGET AND PROOF OF FINANCING.
The total budget for the Project is currently estimated to be Two Million One Hundred Forty Two Thousand Seven Hundred Nine and 00/100 Dollars ($2,142,709.00) (the "Preliminary Project Budget"). Not less than fourteen (14) days prior to the Closing Date, the Developer shall submit to the Department for approval: (1) a final budget for the Project which is materially consistent with the Preliminary Project Budget (the "Final Project Budget"); and (2) evidence of availability of eighty percent (80%) of funds necessary to complete the Project, provided that no more than fifteen percent (15%) of that eighty percent (80%) shall be in the form of written pledges, and as shall otherwise be acceptable to the Department, in its sole discretion (the "Proof of Financing").

SECTION 8. CONDITIONS TO THE CITY'S OBLIGATION TO CLOSE.
The obligations of the City under this Agreement are contingent upon each of the following being satisfied at least seven (7) days prior to the Closing Date, or by such other date as may be specified, unless waived or extended in writing by the Commissioner of the Department (the "Commissioner"):
Final Governmental Approvals. Developer shall have delivered to the City evidence of its receipt of all Governmental Approvals necessary to construct the Project.
Budget and Proof of Financing. The City shall have approved the Developer's Final Project Budget and Proof of Financing as described in Section 7.
Simultaneous Loan Closing. On the date of the Closing, the Developer shall simultaneously close the financing necessary for the acquisition and construction of the Project, and be in a position to immediately commence construction of the Project.
Insurance. The Developer shall provide evidence of insurance reasonably acceptable to the City. The City shall be named as an additional insured on any liability insurance policies ($1M per occurrence and $2M aggregate) and as a loss payee (subject to the rights of any permitted mortgagee) on any property insurance policies from the; Closing Date through the date the City issues the Certificate of Completion (as defined in Section 12). With respect to property insurance, the City will accept an ACORD 28 form. With respect to liability insurance, the City will accept an ACORD 25 form, together with a copy of the endorsement that is added to the Developer's policy showing the City as an additional insured.
Legal Opinion. The Developer shall have delivered to the City a legal opinion stating, in part, that LP has been duly organized and that LP is duly authorized to enter into this Agreement. Such opinion shall be in a form and substance reasonably acceptable to the City's Corporation Counsel.
Due Diligence. The Developer shall have delivered to the City due diligence searches in LP's name (UCC, State and federal tax lien, pending litigation and judgments in Cook County and the U.S. District Court for the Northern District of Illinois, and bankruptcy) showing no unacceptable liens, litigation, judgments or filings, as reasonably determined by the


|1010|
City's Corporation Counsel. Litigation searches must be provided with the LP separately named as the plaintiff and with LP separately named as defendant.
Organization and Authority Documents. The Developer shall have delivered to the City: (a) certified articles of incorporation or organization, as applicable, including all amendments thereto, of LP, as furnished and certified by the Secretary of State of the State of Illinois; (b) a Certificate of Good Standing dated no more than thirty (30) days prior to the Closing Date, issued by the Secretary of State of the State of Illinois, as to the good standing of the Developer; and (c) resolutions and such other organizational documents as the City may reasonably request.
Subordination Agreement. On the Closing Date, and prior to recording any mortgage approved pursuant to Section 8.2, the Developer shall, at the City's request, deliver to the City a subordination agreement substantially in the form attached hereto as Exhibit C attached hereto (the "Subordination Agreement"), in which the construction lender agrees to subordinate the lien of its mortgage to the covenants running with the land.
MBE/WBE and Local Hiring Compliance Plan!

At least fourteen (14) days prior to the Closing Date, the Developer and the Developer's general contractor and all major subcontractors shall meet with staff from the Department of Housing's monitoring section regarding compliance with the MBE/WBE and local hiring requirements set forth in this Agreement pursuant to Section 22 below. During said meeting, the Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under Section 22 below, the sufficiency of which shall be approved by the City's monitoring staff.
shall also have approved the Developer's compliance plan in accordance with Section 22.
Leases. Prior to the Closing Date, the Developer shall provide to the City, proof of leases between Developer and the prospective tenants in the building, including Marshall Square Resource Network (if applicable), Esperanza Health Center and Lincoln Park Zoo.
Representations and Warranties. On the Closing Date, each of the representations and warranties ofthe Developer in this Agreement shall be true and correct.
Other Obligations. On the Closing Date, the Developer shall have performed all of the other obligations required to be performed by the Developer under this Agreement as of the Closing Date.
Reconveyance Deed. Prior to the conveyance ofthe Property to LP, LP shall deliver to the City a special warranty deed for the Property in recordable form naming the City as grantee ("Reconveyance Deed"), for possible recording in accordance with Section 18.3.d. below.


|1010|
8.14 Right to Terminate. If any of the conditions in this Section 8 have not been satisfied to the City's reasonable satisfaction within the time periods provided for herein, the City may, at its option, terminate this Agreement after (a) delivery of written notice to the Developer at any time after the expiration of the applicable time period, stating the condition or conditions that have not been fulfilled, and (b) providing the Developer with forty-five (45) days to fulfill those conditions. If, after receiving notice and an opportunity to cure as described in the preceding sentence, the Developer still has not fulfilled the applicable conditions to the City's reasonable satisfaction, this Agreement shall be null and void and, except as otherwise specifically provided, neither party shall have any further right, duty or obligation hereunder. Any forbearance by the City in exercising its right to terminate this Agreement upon a default \ hereunder shall not be construed as a waiver of such right.

SECTION 9. SITE PLANS AND ARCHITECTURAL DRAWINGS.
Site Plans. The Developer shall perform, or cause to be performed, the work set forth in Section A of Exhibit B.
Relocation of Utilities, Curb Cuts arid Driveways. To the extent necessary to complete the Project, the Developer shall be solely responsible for and shall pay all costs in regard to: (1) the relocation, installation or construction of public or private utilities located on the Property; (2) the relocation, installation and construction of any curb cuts and driveways; (3) the repair or reconstruction of any curbs, vaults, sidewalks or parkways required in connection with the Project; (4) the removal of existing pipes, utility equipment or building foundations located on the Property; and (5) the termination of existing water or other services. Any streetscaping, including any paving of sidewalks, landscaping and lighting provided by the Developer, as part of the Project, must be approved by the City.
Inspection by the City. For the period commencing on the Closing Date and continuing through the date the City issues the Certificate of Completion, any duly authorized representative of the City shall have access to the Property at all reasonable times for the purpose of determining whether the Developer is constructing the Project in accordance with the terms of this Agreement and all applicable federal, state and local statutes, laws, ordinances, codes, rules, regulations, orders and judgments, including, without limitation, Sections 7-28 and 11-4 of the Municipal Code of Chicago relating to waste disposal (collectively, "Laws").
Barricades and Signs. Upon the City's request, the Developer agrees to erect such signs as the City may reasonably require identifying the Property as a City redevelopment project. The Developer may erect signs of its own incorporating such approved identification information upon the execution of this Agreement. Prior to the commencement of any construction activity requiring barricades, the Developer shall install a construction barricade of a type and appearance satisfactory to the City and constructed in compliance with all applicable Laws. The City shall have the right to approve all barricades, the maintenance, appearance, color scheme, painting, nature, type, content and design of all barricades, and all signage.




|1010|
SECTION 10. LIMITED APPLICABILITY.

The approval of the work set forth in Section A of Exhibit B by the Department's Bureau of Economic Development is for the purpose of this Agreement only and does not constitute the approval required by the City's Department of Buildings, any other Department bureau (such as, but not limited to, the Department's Bureau of Zoning), or any other City department; nor does the approval by the Department pursuant to this Agreement constitute an approval of the quality, structural soundness or the safety of any improvements located or to be located on the Property. The approval given by the Department shall be only for the benefit of the Developer and any lienholder authorized by this Agreement.

SECTION 11. COMMENCEMENT AND COMPLETION OF PROJECT.

Subject to the receipt of all necessary Governmental Approvals, the Developer shall commence the work set forth in Section A of Exhibit B no later than thirty (30) days following the Closing Date (the "Outside Construction Commencement Date"), and shall complete such work, as reasonably determined by the Department, no later than eighteen (18) months following the Outside Construction Commencement Date (the "Outside Construction Completion Date").
The Commissioner shall have discretion to extend the Outside Construction Commencement Date, and the Outside Construction Completion Date for good cause shown by issuing a written extension letter. The Developer shall give written notice to the City within five (5) days after it commences construction of the Project. The Project shall be constructed in accordance with all applicable Laws.

SECTION 12. CERTIFICATE OF COMPLETION.

Upon the Developer's satisfaction of the following events: (a) the Developer has completed construction of the Project, and the Developer has complied with MBE/WBE and City Residency requirements for the Project; and (b) fully executed leases with any not-for-profit organization; and (c) Completion of any required environmental remediation work, including but -not limited to asbestos, lead based paint, or hazardous materials abatement, the Developer shall request from the City a certificate of completion (the "Certificate of Completion"). Within forty-five (45) days thereof, the City shall provide the Developer with either:

(i) the Certificate of Completion; or

(ii) a written statement indicating that the City will not provide the Certificate of
Completion. Such written statement will identify whether: (x) the Developer has failed to
complete the Project in compliance with this Agreement; (y) the Developer has failed to (1)
complete construction of the Project, and/or comply with MBE/WBE and City Residency
requirements for the Project, and (2) complete any required environmental remediation work,
including but not limited to hazardous materials abatement; or (z) the Developer is otherwise in
default. In addition, the written statement will identify what measures or acts are necessary, in
the sole reasonable opinion of the Department, for the Developer to take or perform in order to
obtain the Certi ficate of Completion.


|1010|
If the Department requires additional measures or acts to assure compliance, the Developer shall resubmit a written request for the Certificate of Completion upon compliance with the City's response. The Certificate of Completion shall be in recordable form, and shall, upon recording, constitute a conclusive determination of satisfaction and termination of certain of the covenants in this Agreement and the Deed (but excluding those on-going covenants as referenced in Section 17) with respect to the Developer's obligations to construct the Project.

SECTION 13. RESTRICTIONS ON USE.

The Developer, for itself and its successors and assigns, agrees as follows:
The Developer shall construct the Project in accordance with Section A. of Exhibit B, this Agreement and all applicable Laws.
The Developer shall not, in violation of applicable law, discriminate on the basis of race, color, sex, gender identity, age, religion, disability, national origin, ancestry, sexual orientation, marital status, parental status, military discharge status, or source of income in the sale, lease, rental, use or occupancy of the Property or any part thereof.
The Developer shall use the Property solely for:

Low-cost immigration legal services and free services for immigrant victims of domestic violence, for at least 400 people annually.
Community education on immigration and the legal system. Minimum number of sessions per year is four (4) and the total number of persons educated per year must be at least 100.
Training and professional development workshops for nonprofit staff and small businesses. Minimum number of sessions per year is four (4) and the total number of persons trained per year must be at least 100.
Employment opportunities for neighborhood residents. The Developer must employ 10% of its workforce from residents from in the 60608 and 60632, 60623 and 60609 zip codes.
Other similar or equivalent purposes which are part of Developer's mission, and which uses are reviewed and approved by the City, in writing.
Commencing one (1) year after the City's issuance of the Certificate of Completion, and annually thereafter, the Developer shall submit to the Department:

A notarized affidavit signed by the Chief Executive Officer of the Developer certifying that low-cost immigration and legal services, and free counseling and services to immigrant victims of domestic violence were provided for the given year to a minimum of 400 persons.
A notarized affidavit signed by the Chief Executive Officer of the Developer showing the total number of sessions provided by the Developer for legal and education services to immigrants. Included in


|10 10|
each affidavit must be a flyer advertising each session that shows the date, time and location and total number of participants.
A notarized affidavit signed by the Chief Executive Officer of the Developer showing the total number of sessions provided by the Developer for training and professional development workshops for nonprofit staff and small businesses. Included in each affidavit must be a flyer advertising each session that shows the date, time and location and registration forms listing the names and total number of participants.
A notarized affidavit signed by the Chief Executive Officer of the Developer showing a list of persons employed by the Developer including the name and address and title of each person employed

Each affidavit and the property tax documentation must be submitted to the Department within thirty (30) days following the completion of each applicable one (1) year period.

SECTION 14. PROHIBITION AGAINST TRANSFER OF PROPERTY.

14.1 Restriction on Transfer Prior to Issuance of Certificate of Completion. Prior to the City's issuance of the Certificate of Completion, Developer may not, without the prior written consent of the Department, which consent shall be in the Department's sole and absolute discretion: (a) merge, liquidate or consolidate; (b) directly or indirectly sell, transfer, convey, lease (except for leases executed by the Developer in its ordinary course of business) or otherwise dispose of all or substantially all of its assets or all or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) or any interest therein or the Developer's controlling interests therein (including, without limitation, a transfer by assignment of any beneficial interest under a land trust); (c) directly or indirectly assign this Agreement; or (d) enter into any transaction outside the ordinary course of its business. The Developer acknowledges and agrees that the Department may withhold its consent under (a) through (d) above if, among other reasons, the proposed purchaser, transferee or assignee (or any of such entity's principal officers, members or directors) is in violation of any Laws, or if the Developer fails to submit sufficient evidence of the financial responsibility, business background and reputation of the proposed purchaser, transferee or assignee. In the event of a proposed sale, transfer, conveyance, lease or other disposition of all or any portion of the Property, the Developer shall provide the City copies of any and all sales contracts, legal descriptions, descriptions of intended use, certifications from the proposed purchaser, transferee or assignee, as applicable, regarding this Agreement, and such other information as the City may reasonably request. The proposed purchaser, transferee or assignee must be qualified to do business with the City (including but not limited to the City's anti-scofflaw requirement). If the City consents to any of the transactions described in this Section 14.1, then the Developer shall pay the City fifty percent (50%) of the "Net Sales Proceeds" (as defined below), except that in the event that construction of the Project has not commenced, the Developer shall pay the City one hundred percent (100%) ofthe "Net Sales Proceeds".

"Net Sales Proceeds" equals:



10

the greater of (a) the price at which the Developer sells, transfers, leases, conveys or otherwise disposes of the Property or the Developer's interest therein and (b) the fair market value of the Property, valued with improvements, as of a date not more than six (6) months prior to the transaction (i.e., merger, sale, lease, etc.) closing date, as determined by an appraiser selected by the City and paid for by the Developer,

minus
the sum of the Developer's closing costs and commissions, and the dollar amount of any existing mortgage that was approved by the Department in accordance with Sections 7 and 8.2.

14.2 Transfer of Property Within Twenty (20) Years Following the Date of the Certificate of Completion. During the period following the date of the Certificate of Completion and prior to the date that is twenty (20) years after the date of the Certificate of Completion, the Developer may not, without the prior written consent of the Department, which consent shall be in the Department's sole and absolute discretion, directly or indirectly sell, transfer, convey, lease (except for leases executed by the Developer in its ordinary course of business) or otherwise dispose of all or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto, except fixtures or equipment which are worn out or no longer useful in conduct of Developer's operations, provided that such worn out fixtures or equipment are replaced with updated equipment and fixtures essential to the conduct of Developer's operations) or any interest therein or the Developer's controlling interests therein (including, without limitation, a transfer by assignment of any beneficial interest under a land trust). The Developer acknowledges and agrees that the Department may withhold its consent under this Section 14.2 if, among other reasons, the proposed purchaser, transferee or assignee (or any of such entity's principal officers, members or directors) is in violation of any Laws, or if the Developer fails to submit sufficient evidence of the financial responsibility, business background and reputation of the proposed purchaser, transferee or assignee. In the event of a proposed sale, transfer, conveyance, lease or other disposition of all or any portion of the Property, the Developer shall provide the City copies of any and all sales contracts, legal descriptions, descriptions of intended use, proposed operating agreement(s),. certifications from the proposed purchaser, transferee or assignee, as applicable, regarding this Agreement and such other information as the City may reasonably request. The proposed purchaser, transferee or assignee must be qualified to do business with the City (including but not limited to anti-scofflaw requirement).

If the City consents to a sale, transfer, conveyance, lease or other disposition of the Property following the date of the Certificate of Completion, but prior to the date that is twenty (20) years after the date of the Certificate of Completion, such consent shall be conditioned upon the Developer's paying the City a percentage of the Net .Sales Proceeds in accordance with the following chart:

Time elapsed from the date Percentage of Net Sales Proceeds to
ofthe Certificate of Completion be paid to the City



11

1 One (1) day through year five (5)
Year six (6) through year ten (10)
Year eleven (11) through year fifteen (15)
Year sixteen (16) through year twenty (20)
After twenty (20) years have elapsed
100%
75%
50%
25%
0%.

14.3 Transfer of Property More than Twenty (20) Years Following the Date of the Certificate of Completion. Upon the expiration of twenty (20) years following the date of the Certificate of Completion, the City's consent shall not be required for any sale, transfer, conveyance, lease or other disposition of all or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) or any interest therein or the Developer's controlling interests therein.

SECTION 15. LIMITATION UPON ENCUMBRANCE OF PROPERTY.

Prior to the issuance of the Certificate of Completion, the Developer shall not, without the Department's prior written consent, engage in any financing or other transaction which creates a financial encumbrance or lien on the Property, except for the purposes of obtaining: (a) funds necessary to acquire the Property; (b) funds related to the Proof of Financing or otherwise necessary to construct the Project in substantial accordance with the Final Project Budget; and (c) after construction, funds necessary to own, maintain and operate the Property in accordance with the requirements of this Agreement. After the issuance of the Certificate of Completion, no City consent shall be required for any type of financing or other transaction which creates a financial encumbrance or lien on the Property.

SECTION 16. MORTGAGEES NOT OBLIGATED TO CONSTRUCT

Notwithstanding any other provision of this Agreement or of the Deed, the holder of any mortgage authorized by this Agreement (or any affiliate of such holder) shall not itself be obligated to construct or complete the Project, or to guarantee such construction or completion, but shall be bound by the other covenants running with the land specified in Section 17 and, at Closing, at the City's request, shall execute a Subordination Agreement (as defined in Section 8.8). If any such mortgagee or its affiliate succeeds to the Developer's interest in the Property prior to the issuance of the Certificate of Completion, whether by foreclosure, deed-in-lieu of foreclosure or otherwise, and thereafter transfers its interest in the Property to another party (that is not also a mortgagee), such transferee shall be obligated to complete the Project, and shall also be bound by the other covenants running with the land specified in Section 17. If and to the extent transfer by a mortgagee (or its affiliate) requires consent by the City, the City shall not unreasonably withhold or delay such consent. Such request for consent may include proposed use restrictions appropriate to the transferee to be substituted for those in Section 13.3, which shall be subject to written approval of the City in its reasonable discretion, which may include the approval of City Council.

SECTION 17. COVENANTS RUNNING WITH THE LAND.

The parties agree, and the Deed shall so expressly provide, that the covenants provided in


12

Section 11 (Commencement and Completion of Project), Section 13 (Restrictions on Use), and Section 14 (Prohibition Against Transfer of Property) and Section 15 (Limitation Upon Encumbrance of Property) will be covenants running with the Property, binding on the Developer and its successors and assigns (subject to the limitations set forth in Section 16 above as to any permitted mortgagee) to the fullest extent permitted by law and equity for the benefit and in favor of the City, and shall be enforceable by the City. The covenants provided in Section 11, and Section 13.1 shall terminate upon the City's issuance of the Certificate of Completion. The covenants contained in Section 13.2 and Section 21.5 shall remain in effect without limitation as to time. The covenants contained in Section 13.3, Section 13.4, Section 14 and Section 15 shall terminate twenty (20) years after the date on which the City issues the Certificate of Completion, unless terminated in writing at an earlier date in the sole discretion of the Commissioner.

SECTION 18. PERFORMANCE AND BREACH.
Time ofthe Essence. Time is of the essence in the Developer's performance of its obligations under this Agreement.
Permitted Delays. The Developer shall not be considered in breach of its obligations under this Agreement in the event of a delay due to unforeseeable causes beyond the Developer's control and without the Developer's fault or negligence, including but not limited to, acts of God, acts of the public enemy, acts of the United States government, fires, floods, epidemics, quarantine restrictions, strikes, embargoes, material shortages, and unusually severe weather or delays of contractors or subcontractors due to such causes. The time for the performance of the obligations shall be extended only for the period of the delay and only if the Developer requests it in writing of the City within thirty (30) days after the beginning of any such delay.
Breach.

Generally. Except as provided in Section 18.3.b„ if the Developer defaults in performing its obligations under this Agreement, the City shall deliver written notice of such default, after which the Developer shall have a 45-day cure period to remedy such default. If the default is not capable of being cured within the 45-day period, then provided the Developer has commenced to cure the default and is diligently proceeding to cure the default within the 45-day period, and thereafter diligently prosecutes such cure through to completion, then the 45-day period shall be extended for the length of time that is reasonably necessary to cure the default. If the default is not cured in the time period provided for herein, the City may institute such proceedings at law or in equity as may be necessary or desirable to cure and remedy the default, including but not limited to, proceedings to compel specific performance.
Event of Default. The occurrence of any one or more of the following shall constitute an "Event of Default" after written notice from the City (if required):

1'. The Developer fails to perform any obligation of the Developer under this Agreement, which default is not cured pursuant to Section 18.3.a.; or


13

The Developer makes or furnishes a warranty, representation, statement or certification to the City (whether in this Agreement, an Economic Disclosure Form, or another document) which is not true and correct, which default is not cured pursuant to Section 18.3.a.;or
A petition is filed by or against the Developer under the Federal Bankruptcy Code or any similar state or federal law, whether now or hereafter existing, which is not vacated, stayed or set aside within sixty (60) days after filing; or
Except as excused by Section 18.2 above, the Developer abandons or substantially suspends the construction work for a period of time greater than 60 days (no notice or cure period shall apply); or
The Developer fails to timely submit the documentation required by Section 13.4 (no notice or cure period shall apply); or
The Developer fails to comply with the operating covenant set forth in Section 13.3 (30-day cure period shall apply); or
Unless being contested in good faith by the Developer, the Developer fails to timely pay real estate taxes or assessments affecting the Property or suffers or permits any levy or attachment, material suppliers' or mechanics' lien, or any other lien or encumbrance unauthorized by this Agreement to attach to the Property, which default is not cured pursuant to Section 18.3.a.; or
The Developer makes an assignment, pledge, unpermitted financing, encumbrance, transfer or other disposition in violation of this Agreement (no notice or cure period shall apply); or
The Developer's financial condition or operations adversely change to such an extent that would materially and adversely affect the Developer's ability to complete the Project, which default is not cured pursuant to Section 18.3.a.; or
The Developer fails to perform, keep or observe any of the other covenants, promises, agreements, or obligations under this Agreement, including but not limited to, the covenants set forth in Sections 13 and 17 herein, or any other written agreement entered into with the City with respect to this Project, which default is not cured pursuant to Section 18.3.a.; or
Failure to close by the Outside Closing Date, unless the Department in its sole discretion extends the Outside Closing Date in accordance with Section 3 of this Agreement (no notice or cure period shall apply); or
Failure to commence or complete construction in accordance with the timeframes set forth in Section 11 of this Agreement; or
Failure to (a) timely apply to the Board of Review for Cook County, Illinois, for an exemption from real estate property taxes, or (b) timely pay real estate property taxes, which default is not cured pursuant to Section 18.3.a.



14

Prior to Conveyance. Prior to Closing, if an Event of Default occurs and is continuing, and the default is not cured in the time period provided herein, the City may terminate this Agreement, and institute any action or proceeding at law or in equity against the Developer.
After Conveyance. If an Event of Default occurs after the Closing but prior to the issuance of the Certificate of Completion, and the default is not cured in the time period provided for in this Section 18.3, the City may terminate this Agreement and exercise any and all remedies available to it at law or in equity, including, without limitation, the right to re-enter and take possession of the Property, terminate the estate conveyed to LP, and direct the Title Company to record the Reconveyance Deed for the purpose of revesting title to the Property in the City (the "Right of Reverter"); provided, however, the City's Right of Reverter shall be limited by, and shall not defeat, render invalid, or limit in any way, the lien of any mortgage authorized by this Agreement. If the Reconveyance Deed is recorded by the Title Company, the Developer shall be responsible for all real estate taxes and assessments which accrued during the period the Property was owned by LP, and shall cause the release of all liens or encumbrances placed on the Property during the period of time the Property was owned by LP. The Developer will cooperate with the City and Title Company to ensure that if the Title Company records the Reconveyance Deed, such recording is effective for purposes of transferring title to the Property to the City, subject only to those title exceptions that were on title as ofthe date and time that the City conveyed the Property to LP and except for any mortgage authorized by this Agreement.

Notwithstanding the foregoing to the contrary, prior to its exercise of its Right of Reverter, the City shall provide written notice to the Developer of its intent to exercise its Right of Reverter, and the Developer shall have an additional ninety (90) days to cure the applicable Event of Default.

Following the revesting in the City of title to the Property as provided in this Section 18.3.d., the City shall employ its best efforts to convey the Property (subject to all existing encumbrances) to a qualified and financially responsible party (reasonably acceptable to the first mortgagee) for the fair market value of the Property. Such purchaser is subject to the covenants that run with the Property, as specified in Section
12-
If the City sells the Property as provided for in this Section 18.3.d., the proceeds from the sale shall be utilized to reimburse the City for:
the fair market value of the Property, which fair market value shall equal the appraised fair market value of the Property as of a date not more than six (6) months prior to the sales date; and
costs and expenses incurred by the City (including, without limitation, salaries of personnel) in connection with the recapture, management and resale of the Property; and


15

all unpaid taxes, assessments, and water and sewer charges assessed against the Property; and:
any payments made (including, without limitation, reasonable attorneys' fees and court costs) to discharge or prevent from attaching or being made any subsequent encumbrances or liens due to obligations, defaults or acts of the Developer; and
any expenditures made or obligations incurred by the City with respect to construction or maintenance of the Project; and
6. any other amounts owed to the City by the Developer.
LP shall be entitled to receive any remaining proceeds.
Notwithstanding anything contained herein to the contrary, the City's Right of Reverter shall terminate on the date on which the City issues the Certificate of Completion. Following the issuance of the Certificate of Completion, the Developer may request in writing the return ofthe Reconveyance Deed, and the City shall return the Reconveyance Deed to LP promptly following its receipt of such request.
After Issuance of Certificate of Completion. If an Event of Default occurs after the Issuance of the Certificate of Completion, but prior to the date that is twenty (20) years after the date of issuance of the Certificate of Completion, and the default is not cured in the time period provided for in this Section 18.3, the Developer shall pay upon written demand by the City an amount equal to the fair market value of the Property4n excess of the costs of the Project, which fair market value shall equal the appraised fair market value of the Property as if the site or structure was vacant, as of a date not more than six (6) months prior to the Event of Default.
Waiver and Estoppel. Any delay by the City in instituting or prosecuting any actions or proceedings or otherwise asserting its rights shall not operate as a waiver of such rights or operate to deprive the City of or limit such rights in any way. No waiver made by the City with respect to any specific default by the Developer shall be construed, considered or treated as a waiver of the rights of the City with respect to any other defaults of the Developer.

SECTION 19. CONFLICT OF INTEREST; CITY'S REPRESENTATIVES NOT INDIVIDUALLY LIABLE.

The Developer warrants that no agent, official, or employee of the City shall have any personal interest, direct or indirect, in this Agreement or the Property, nor shall any such agent, official or employee participate in any decision relating to this Agreement which affects his or her personal interests or the interests of any entity or association in which he or she is directly or indirectly interested. No agent, official, or employee of the City shall be personally liable to the


16

Developer or any successor in interest in the event of any default or breach by the City or for any amount which may become due to the Developer or successor or on any obligation under the terms of this Agreement.

SECTION 20. INDEMNIFICATION.

LP agrees to indemnify, defend and hold the City harmless from and against any losses, costs, damages, liabilities, claims, suits, actions, causes of action and expenses (including, without limitation, reasonable attorneys' fees and court costs) (collectively "Losses") suffered or incurred by the City arising from or in connection with: (1) an Event of Default that has occurred; (2) the failure of the Developer or any of Developer's contractors, subcontractors or agents to pay contractors, subcontractors or material suppliers in connection with the construction of the Project; (3) the failure of the Developer to redress any misrepresentations or omissions in this Agreement or any other agreement relating hereto; and (4) any actions, including but not limited to, conducting environmental tests on the Property as set forth in Section 21 herein, resulting from any activity undertaken by the Developer on the Property prior to or after the conveyance of said Property to LP by the City; provided, however, the Developer shall have no obligation to indemnify the City for Losses (i) to the extent such Losses are caused by the City or its agents, or (ii) to the extent such Losses were not suffered or incurred by the City in connection with any of items (1) through (4) set forth in the first sentence of this Section 21 and arose after the City has re-acquired the Property from LP. This indemnification shall survive any termination of this Agreement (regardless of the reason for such termination).

SECTION 21. ENVIRONMENTAL MATTERS.

21.1 Definitions. For purposes of this Agreement, the following terms shall have the following meanings:

"Environmental Laws" means any and all Laws relating to the regulation and protection of human health, safety, the environment and natural resources now or hereafter in effect, as amended or supplemented from time to time, including, without limitation, the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. § 9601 et seq., the Resource Conservation and Recovery Act, 42 U.S.C. § 6901 et seq., the Hazardous Materials Transportation Act, 49 U.S.C. § 5101 et seq., the Federal Water Pollution Control Act, 33 U.S.C. § 1251 et seq., the Clean Air Act, 42 U.S.C. § 7401 et seq., the Toxic Substances Control Act, 15 U.S.C. § 2601 el seq., the Federal Insecticide, Fungicide, and Rodenticide Act, 7 U.S.C. § 136 et seq., the Occupational Safety and Health Act, 29 U.S.C. § 651 et seq., any and all regulations promulgated under such Laws, and all analogous state and local counterparts or equivalents of such Laws, including, without limitation, the Illinois Environmental Protection Act, 415 ILCS 5/1 et seq., and the common law, including, without limitation, trespass and nuisance.

"Environmental Remediation Work" shall mean preparing and following a Hazardous Materials Operations and Management Plan and/or an Abatement Plan, or performing abatement, for all asbestos, lead based paint, or other hazardous materials, according to all applicable Laws, including, without limitation, all applicable Environmental Laws.


17

"AS IS" Sale. THE CITY MAKES NO COVENANT, REPRESENTATION OR WARRANTY, EXPRESS OR IMPLIED, OF ANY KIND, AS TO THE STRUCTURAL, PHYSICAL OR ENVIRONMENTAL CONDITION OF THE PROPERTY OR THE SUITABILITY OF THE PROPERTY FOR ANY PURPOSE WHATSOEVER. THE DEVELOPER ACKNOWLEDGES THAT IT HAS HAD ADEQUATE OPPORTUNITY TO INSPECT AND EVALUATE THE STRUCTURAL, PHYSICAL AND ENVIRONMENTAL CONDITION AND RISKS OF THE PROPERTY AND ACCEPTS THE RISK THAT ANY. INSPECTION MAY NOT DISCLOSE ALL MATERIAL MATTERS AFFECTING THE PROPERTY. LP AGREES TO ACCEPT THE PROPERTY IN ITS "AS IS," "WHERE IS" AND "WITH ALL FAULTS" CONDITION AT CLOSING WITHOUT ANY COVENANT, REPRESENTATION OR WARRANTY, EXPRESS OR IMPLIED, OF ANY KIND, AS TO THE STRUCTURAL, PHYSICAL OR ENVIRONMENTAL CONDITION OF THE PROPERTY OR THE SUITABILITY OF THE PROPERTY FOR ANY PURPOSE WHATSOEVER. THE DEVELOPER ACKNOWLEDGES THAT IT IS RELYING SOLELY UPON ITS OWN INSPECTION AND OTHER DUE DILIGENCE ACTIVITIES AND NOT UPON ANY INFORMATION (INCLUDING, WITHOUT LIMITATION, ENVIRONMENTAL STUDIES OR REPORTS OF ANY KIND) PROVIDED BY OR ON BEHALF OF THE CITY OR ITS AGENTS OR EMPLOYEES WITH RESPECT THERETO. THE DEVELOPER AGREES THAT IT IS ITS SOLE RESPONSIBILITY AND OBLIGATION TO PERFORM AT ITS EXPENSE ANY ENVIRONMENTAL REMEDIATION WORK (AS DEFINED BELOW) AND TAKE SUCH OTHER ACTION AS IS NECESSARY TO PUT THE PROPERTY IN A CONDITION WHICH IS SUITABLE FOR ITS INTENDED USE.
Right of Entry. Pursuant to the Developer's request, the City previously granted the Developer the right, at its sole cost and expense, to enter the Property pursuant one or more right of entry agreements to inspect the same, perform surveys, environmental assessments, soil and any other due diligence it deems necessary or desirable to satisfy itself as to the condition of the Property. The Developer acknowledges that it is satisfied with the condition of the Property. The Developer agrees to deliver to the City a copy of each report prepared by or for the Developer regarding the environmental condition of the Property.
Environmental Remediation. Based on the HMS of the building on the Property, ACM, LBP, and other hazardous materials are present in the building. All renovation work must be performed in accordance with Illinois Department of Public Health, Chicago Department of Public Health and Occupational Safety and Health Administration (OSHA) requirements, along with all other applicable regulations.

A Hazardous Materials Operations and Management Plan and/or an Abatement Plan addressing any ACM, LBP, or other hazardous materials that will be handled or disturbed must be prepared. The City, acting through its Department of Fleet and Facility Management, and any successor department thereto ("2FM") shall have the right to review and approve the management and/or abatement plan.

In the event of an unplanned disturbance to suspected or known ACM and/or LBP, the Licensee must stop work and immediately notify 2FM.


18

The Developer acknowledges and agrees that the City will not issue a Certificate of Completion for the Project or a certificate of occupancy for the Building until the Hazardous Materials Operations and Management Plan, and/or Abatement of any ACM, LBP, or other hazardous materials, is completed and approved by 2FM.

The Developer must abide by the terms and conditions of the Hazardous Materials Operations and Management Plan, if a Hazardous Materials Operations and Management Plan was required. .

21.5 Release and Indemnification. LP on behalf of LP and its officers, directors,
employees, successors, assigns and anyone claiming by, through or under them (LP, and all the
individuals and entities described in the preceding, collectively, the "Developer Parties"), hereby
releases, relinquishes and forever discharges the City, its officers, agents and employees, from
and against any and all Losses which the Developer Parties ever had, now have, or hereafter may
have, whether grounded in tort or contract or otherwise, in any and all courts or other forums, of
whatever kind or nature, whether known or unknown, foreseen or unforeseen, now existing or
occurring after the Closing Date, based upon, arising out of or in any way connected with,
directly or indirectly (i) any environmental contamination, pollution or hazards associated with
the Property or any improvements, facilities or operations located or formerly located thereon,
including, without limitation, any release, emission, discharge, generation, transportation,
treatment, storage or disposal of Hazardous Substance, or threatened release, emission or
discharge of Hazardous Substance; (ii) the structural, physical or environmental condition of the
Property, including, without limitation, the presence or suspected presence of Hazardous
Substance in, on, under or about the Property or the migration of Hazardous Substance from or to
other property; (iii) any violation of, compliance with, enforcement of or liability under any
Environmental Laws, including, without limitation, any governmental or regulatory body
response costs, natural resource damages or Losses arising under CERCLA; and (iv) any
investigation, cleanup, monitoring, remedial, removal or restoration work required by any
federal, state or local governmental agency or political subdivision or other third party in
connection or associated with the Property or any improvements, facilities or operations located
or formerly located thereon (collectively, "Released Claims"); provided, however, the foregoing
release shall not apply to the extent such Losses are proximately caused by the gross negligence
or willful misconduct of the City following the Closing Date. Furthermore, LP shall each
indemnify, defend (through an attorney reasonably acceptable to the City) and hold the City and
its officers, agents and employees harmless from and against any and all Losses which may be
made or asserted by any third parties (including, without limitation, any of the Developer Parties)
arising out of or in any way connected with, directly or indirectly, any of the Released Claims,
except as provided in the immediately preceding sentence for the City's gross negligence or
willful misconduct following the Closing Date.

21.6 Release Runs with the Property. The covenant of release in Section 21.5 above
shall run with the Property, and shall be binding upon all successors and assigns of LP with
respect to the Property, including, without limitation, each and every person, firm, corporation,
limited liability company, trust or other entity owning, leasing, occupying, using or possessing
any portion of the Property under or through LP following the date of the Deed. LP


19

acknowledges and agrees that the 'foregoing covenant of release constitutes a material inducement to the City to enter into this Agreement, and that, but for such release, the City would not have agreed to convey the Property to the Developer. It is expressly agreed and understood by and among LP and the City that, should any future obligation of LP or the Developer Parties arise or be alleged to arise in connection with any environmental, soil or other condition of the Property, LP and any of the Developer Parties shall not assert that those obligations must be satisfied in whole or in part by the City, because Section 21.5 contains a full, complete and final release of all such claims, except as provided in such section for the City's gross negligence or willful misconduct following the Closing Date.

21.7 Survival. This Section 21 shall survive the Closing Date or any termination of this Agreement'(regardless ofthe reason for such termination).

SECTION 22. DEVELOPER'S EMPLOYMENT OBLIGATIONS.

22.1 Employment Opportunity. The Developer agrees, and shall contractually obligate its various contractors, subcontractors and any affiliate of the Developer operating on the Property (collectively, the "Employers" and individually, an "Employer") to agree that, with respect to the provision of services in connection with the construction of the Project on the Property, but not including construction on the Property, or occupation of the Property during the construction'period:

a. Neither the Developer nor any Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Section 2-160-010 et seq. ofthe Municipal Code of Chicago, as amended from time to time (the "Human Rights Ordinance"). The Developer and each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including, without limitation: employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The Developer and each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Developer and each Employer, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.



20

To the greatest extent feasible, the Developer and each Employer shall present opportunities for training and employment of low and moderate income residents of the City, and provide that contracts for work in connection with the construction of the Project be awarded to business concerns which are located in, or owned in substantial part by persons residing in, the City.
The Developer and each Employer shall comply with all federal, state and local equal employment and affirmative action statutes, rules and regulations, including, without limitation, the Human Rights Ordinance, and the Illinois Human Rights Act, 775 ILCS 5/1-101 et seq. (1993), and any subsequent amendments and regulations promulgated thereto.
The Developer, in order to demonstrate compliance with the terms of this Section, shall cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of federal, state and municipal agencies.
The Developer and each Employer shall include the foregoing provisions of subparagraphs (a) through (d) in every contract entered into in connection with the construction of the Project, and shall require inclusion of these provisions in every subcontract entered into by any subcontractors, and every agreement with any affiliate operating on the Property, so that each such provision shall be binding upon each contractor, subcontractor or affiliate, as the case may be.
Failure to comply with the employment obligations described in this Section 22 shall be a basis for the City to pursue remedies under the provisions of Section 18.

22.2 City Resident Employment Requirement.
The Developer agrees, and shall contractually obligate each Employer to agree, that during the construction of the Project, it and each Employer shall comply with the minimum percentage of total worker hours performed by actual residents of the City of Chicago as specified in Section 2-92-330 of the Municipal Code of Chicago (at least fifty percent (50%) of the total worker hours worked by persons on the construction of the Project shall be performed by actual residents of the City of Chicago); provided, however, that in addition to complying with this percentage, the Developer and each Employer shall be required to make good faith efforts to utilize qualified residents of the City of Chicago in both unskilled and skilled labor positions.
The Developer and the Employers may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code of Chicago in accordance with standards and procedures developed by the Purchasing Agent of the City of Chicago.





21

"Actual residents of the City of Chicago" shall mean persons domiciled within the City of Chicago. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.
The Developer and the Employers shall provide for the maintenance of adequate employee residency records to ensure that actual Chicago residents are employed on the construction of the Project. The Developer and the Employers shall maintain copies of personal documents supportive of every Chicago employee's actual record of residence.
Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) shall be submitted to the Commissioner of DPD in triplicate, which shall identify clearly the actual residence of every employee on each submitted certified payroll. The first time that an employee's name appears on a payroll, the date that the company hired the employee should be written in after the employee's name.
The Developer and the Employers shall provide full access to their employment records to the Chief Procurement Officer, the Commissioner of DPD, the Superintendent of the Chicago Police Department, the Inspector General, or any duly authorized representative thereof. The Developer and the Employers shall maintain all relevant personnel data and records for a period of at least three (3) years from and after the issuance of the Certificate of Completion.
At the direction of DPD, the Developer and the Employers shall provide affidavits and other supporting documentation to verify or clarify an employee's actual address when doubt or lack of clarity has arisen.
Good faith efforts on the part of the Developer and the Employers to provide work for actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) shall not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.

i. If the City determines that the Developer or an Employer failed to ensure the
fulfillment of the requirements of this Section concerning the worker hours
performed by actual Chicago residents or failed to report in the manner as
indicated above, the City will thereby be damaged in the failure to provide the
benefit of demonstrable employment to Chicagoans to the degree stipulated in this
Section. If such non-compliance is not remedied in accordance with the breach
and cure provisions of Section 18, the parties agree that 1/20 of 1 percent
(.0005%) of the aggregate hard construction costs set forth in the Project Budget
as applicable, shall be surrendered by the Developer to the City in payment for
each percentage of shortfall toward the stipulated residency requirement. Failure
to report the residency of employees entirely and correctly shall result in the


22

surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the certification of payroll data may subject the Developer and/or the other Employers or employees to prosecution.

j. Nothing herein provided shall be construed to be a limitation upon the "Notice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order 11246" and "Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement.

k. The Developer shall cause or require the provisions of this Section 22.2 to be included in all construction contracts and subcontracts related to the construction of the Project.

22.3 Developer's MBE/WBE Commitment. The Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements set forth herein, shall contractually obligate the general contractor to agree that during the construction of the Project:
Consistent with the findings which support, as applicable, (a) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seq., Municipal Code of Chicago (the "Procurement Program"), and (b) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seq., Municipal Code of Chicago (the "Construction Program," and collectively with the Procurement Program, the "MBE/WBE Program"), and in reliance upon the provisions of the MBE/WBE Program to the extent contained in, and as qualified by, the provisions of this Section 22.3., during the course of the Project, the following percentages of the MBE/WBE Budget, substantially in the City's standard form, shall be expended for contract participation by minority-owned businesses ("MBEs") and by women-owned businesses ("WBEs"): (1) At least 26% by MBEs; and (2) At least 6% by WBEs.
For purposes of this Section 22.3 only:

The Developer (and any party to whom a contract is let by the Developer in connection with the Project) shall be deemed a "contractor" and this Agreement (and any contract let by the Developer in connection with the Project) shall be deemed a "contract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670, Municipal Code of Chicago, as applicable.
The term "minority-owned business" or "MBE" shall mean a. business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a minority-owned business enterprise,


23

related to the Procurement Program or the Construction Program, as applicable. ' 3. The term "women-owned business" or "WBE" shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise, certified by the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.

Consistent with Sections 2-92-440 and 2-92-720, Municipal Code of Chicago, the Developer's MBE/WBE commitment may be achieved in part by the Developer's status as an MBE or WBE (but only to the extent of any actual work performed on the Project by the Developer) or by a joint venture with one or more MBEs or WBEs (but only to the extent of the lesser of (a) the MBE or WBE participation in such joint venture, or (b) the amount of any actual work performed on the Project by the MBE or WBE); by the Developer utilizing a MBE or a WBE as the general contractor (but only to the extent of any actual work performed on the Project by the general contractor); by subcontracting or causing the general contractor to subcontract a portion of the construction of the Project to one or more MBEs or WBEs; by the purchase of materials or services used in the construction of the Project from one or more MBEs or WBEs; or by any combination of the foregoing. Those entities which constitute both a MBE and a WBE shall not be credited more than once with regard to the Developer's MBE/WBE commitment as described in this Section 22.3. In accordance with Section 2-92-730, Municipal Code of Chicago, the Developer shall not substitute any MBE or WBE general contractor or subcontractor without the prior written approval of DPD.

The Developer shall deliver quarterly reports to the City's monitoring staff during construction of the Project describing its efforts to achieve compliance with this MBE/WBE commitment. Such reports shall include, inter alia, the name and business address of each MBE and WBE solicited by the Developer or the general contractor to work on the Project, and the responses received from such solicitation, the name and' business address of each MBE or WBE actually involved in construction of the Project, a description of the work performed or products or services supplied, the date and amount of such work, product or service, and such other information as may assist the City's monitoring staff in determining the Developer's compliance with this MBE/WBE commitment. The Developer shall maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with construction of the Project for at least five years after completion of the Project, and the City's monitoring staff shall have access to all such records maintained by the Developer, on prior notice of at least fifteen (15) business days, to allow the City to review the Developer's compliance with its commitment to MBE/WBE participation and the status of any MBE or WBE performing any portion of construction of the Project.



24

Upon the disqualification of any MBE or WBE general contractor or subcontractor, if such status was misrepresented by the disqualified party, the Developer shall be obligated to discharge or cause to be discharged the disqualified general contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (v), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730, Municipal Code of Chicago, as applicable.
Any reduction or waiver of the Developer's MBE/WBE commitment as described in this Section 22.3 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730, Municipal Code of Chicago, as applicable.
Prior to the commencement of the Project, the Developer shall meet with the City's monitoring staff with regard to the Developer's compliance with its obligations under this Section 22.3. The general contractor and all major subcontractors shall be required to attend this pre-construction meeting. During said meeting, the Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 22.3., the sufficiency of which shall be approved by the City's monitoring staff. During the Project, as applicable, the Developer shall submit the documentation required by this Section 22.3 to the City's monitoring staff, including the following: (a) MBE/WBE utilization plan and record; (b) subcontractor's activity report; (c) contractor's certification concerning labor standards and prevailing wage requirements (if applicable); (d) contractor letter of understanding; (e) monthly utilization report; (f) authorization for payroll agent; (g) certified payroll; (h) evidence that MBE/WBE contractor association's have been informed of the Project via written notice and hearings; and (i) evidence of compliance with job creation requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that the Developer is not complying with its obligations under this Section 22.3, shall, upon the delivery of written notice to the Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to the Developer to halt the Project, (2) withhold any further payment of any city funds to the Developer or the general contractor, or (3) seek any other remedies against the Developer available at law or in equity.

SECTION 23. REPRESENTATIONS AND WARRANTIES.

23.1 Representations and Warranties of the Developer.
To induce the City to execute this Agreement and perform its obligations hereunder, LP hereby represents and warrants to the City that as of the date of this Agreement and as of the Closing Date the following shall be true and correct in all respects:

a. LP is a not-for-profit corporation duly organized, validly existing and in good standing under the laws of the State of Illinois, with full power and authority to acquire,


25

own and redevelop the Property, and the person signing this Agreement on behalf of LP has the authority to do so.
All certifications and statements contained in the Economic Disclosure Statement last submitted to the City by LP (and any legal entity holding an interest in LP) are true, accurate and complete.
LP's execution, delivery and performance of this Agreement and all instruments and agreements contemplated hereby will not, upon the giving of notice or lapse of time, or both, result in a breach or violation of, or constitute a default under, any other agreement to which LP, or any party affiliated with LP, is a party or by which LP or the Property is bound.
To the best of LP's knowledge, no action, litigation, investigation or proceeding of any kind is pending or threatened against LP, or any party affiliated with-LP, and LP knows of no facts which could give rise to any such action, litigation, investigation or proceeding, which could: (a) affect the ability of the LP to perform its obligations hereunder; or (b) materially affect the operation or financial condition of LP.
To the best of LP's knowledge, the Project will not violate: (a) any Laws, including, without limitation, any zoning and building codes and environmental regulations; or (b) any building permit, restriction of record or other agreement affecting the Property.

Representations and Warranties of the City. To induce the Developer to execute this Agreement and perform its obligations hereunder, the City hereby represents and warrants to the Developer that the City has authority under its home rule powers to execute and deliver this Agreement and perform the terms and obligations contained herein, ,and the person signing this Agreement on behalf of the City has the authority to do so.
Survival of Representations and Warranties. Each party agrees that all of its representations and warranties set forth in this Section 23 or elsewhere in this Agreement are true as ofthe date of this Agreement and will be true in all material respects at all times thereafter, except with respect to matters which have been disclosed in writing and approved by the other party.

SECTION 24. PROVISIONS NOT MERGED WITH DEED.

The provisions of this Agreement shall not be merged with the Deed, and the delivery of the Deed shall not be deemed to affect or impair the provisions of this Agreement.

SECTION 25. HEADINGS.

The headings of the various sections of this Agreement have been inserted for convenience of reference only and shall not in any manner be construed as modifying, amending, or affecting in any way the express terms and provisions thereof.


26

SECTION 26. ENTIRE AGREEMENT.

This Agreement constitutes the entire agreement between the parties and supersedes and replaces completely any prior agreements between the parties with respect to the subject matter hereof. This Agreement may not be modified or amended in any manner other than by supplemental written agreement executed by the parties.

SECTION 27. SEVERABILITY.

If any provision of this Agreement, or any paragraph, sentence, clause, phrase or word, or the application thereof is held invalid, the remainder of this Agreement shall be construed as if such invalid part were never included and this Agreement shall be and remain valid and enforceable to the fullest extent permitted by law.

SECTION 28. NOTICES.

Any notice, demand or communication required or permitted to be given hereunder shall be given in writing at the addresses set forth below by any of the following means: (a) personal service; (b) facsimile transmission, provided that there is written confirmation of such communications; (c) overnight courier; or (d) registered or certified first class mail, postage prepaid, return receipt requested:

If to the City: City of Chicago
Department of Planning and Development
121 North LaSalle Street
Room 1000-City Hall
Chicago, Illinois 60602
Attn: Commissioner
Fax: 312-744-5892

With a copy to: City of Chicago
Department of Law 121 North LaSalle Street Room 600
Chicago, Illinois 60602 Attn: Real Estate Division Fax: 312-742-0277

If to LP: Latinos Progresando
3047 West Cermak Road Chicago, Illinois 60623 Attn: Adrienne Lange Fax:

With a copy to: Katten Muchin Rosenman LLP


27

525 West Monroe Street Chicago, IL 60661-693 Attn: Mark C. Simon Fax: 312-902-1061

With a copy to: IFF
333 S. Wabash - Suite 2800
Chicago, Illinois 60604
Attn: Sr. Vice President of Capital Solutions
Email: general@iff.org

Any notice, demand or communication given pursuant to either clause (a) or (b) hereof shall be deemed received upon such personal service or upon dispatch by electronic means, respectively, provided that such electronic dispatch is confirmed as having occurred prior to 5:00 p.m. on a business day. If such dispatch occurred after 5:00 p.m. on a business day or on a non-business day, it shall be deemed to have been given on the next business day. Any notice, demand or communication given pursuant to clause (c) shall be deemed received on the day immediately following deposit with the overnight courier. Any notice, demand or communication sent pursuant to clause (d) shall be deemed received three business days after mailing. The parties, by notice given hereunder, may designate any further or different addresses to which subsequent notices, demands or communications shall be given.

SECTION 29. SUCCESSORS AND ASSIGNS.

Except as otherwise provided in this Agreement, the terms and conditions of this Agreement shall apply to and bind the successors and assigns ofthe parties.

SECTION 30. OTHER ACTS

The parties agree to perform such other acts and to execute, acknowledge and deliver such other instruments, documents and materials as may be reasonably necessary to consummate the transactions contemplated by this Agreement.

SECTION 31. BUSINESS RELATIONSHIPS.

The Developer acknowledges (1) receipt of a copy of Section 2-156-030(b) of the Municipal Code of Chicago, (2) that it has read such provision and understands that pursuant to such Section2-156-030(b) it is illegal for any elected official ofthe City, or any person acting at the direction of such official, to contact, either orally or in writing, any other City official or employee with respect to any matter involving any person with whom the elected City official or employee has a "Business Relationship" (as described in Section 2-156-080 of the Municipal Code of Chicago), or to participate in any discussion in any City Council committee hearing or in any City Council meeting or to vote on any matter involving the person with whom an elected official has a Business Relationship, and (3) notwithstanding anything to the contrary contained in this Agreement, that a violation of Section 2-156-030(b) by an elected official, or any person acting at the direction of such official, with respect to any transaction contemplated by this


28

Agreement shall be grounds for termination of this Agreement and the transactions contemplated hereby. The Developer hereby represents and warrants that no violation of Section 2-156-030(b) has occurred with respect to this Agreement or the transactions contemplated hereby.

SECTION 32. PATRIOT ACT CERTIFICATION.

The Developer represents and warrants that neither LP nor any Affiliate of LP (as defined in the next paragraph) is listed on any ofthe following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List.

As used in the above paragraph, an "Affiliate" shall be deemed to be a person or entity related to LP that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with LP, as applicable, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.

SECTION 33. PROHIBITION ON CERTAIN CONTRIBUTIONS -MAYORAL EXECUTIVE ORDER NO. 2011-4.

Developer agrees that Developer, any person or entity who directly or indirectly has an ownership or beneficial interest in Developer of more than 7.5 percent ("Owners"), spouses and domestic partners of such Owners, Developer's contractors (i.e., any person or entity in direct contractual privity with- Developer regarding the subject matter of this Agreement) ("Contractors"), any person or entity who directly or indirectly has an ownership or beneficial interest in any Contractor of more than 7.5 percent ("Sub-owners") and spouses and domestic partners of such Sub-owners (Developer and all the other preceding classes of persons and entities are together,-the "Identified Parties"), shall not make a contribution of any amount to the Mayor of the City of Chicago (the "Mayor") or to his political fundraising committee (1) after execution of this Agreement by Developer, (2) while this Agreement or any Other Contract is executory, (3) during the term of this Agreement or any Other Contract between Developer and the City, or (4) during any period while an extension of this Agreement or any Other Contract is being sought or negotiated.

Developer represents and warrants that from the later to occur of (1) May 16, 2011, and (2) the date the City approached the Developer or the date the Developer approached the City, as applicable, regarding the formulation of this Agreement, no Identified Parties have made a contribution of any amount to the Mayor or to his political fundraising committee.

Developer agrees that it shall not: (1) coerce, compel or intimidate its employees to make a contribution of any amount to the Mayor or to the Mayor's political fundraising committee; (2)


29

reimburse its employees for a contribution of any amount made to the Mayor or to the Mayor's political fundraising committee; or (3) Bundle or solicit others to bundle contributions to the Mayor or to his political fundraising committee.

Developer agrees that the Identified Parties must not engage in any conduct whatsoever designed to intentionally violate this provision or Mayoral Executive Order No. 2011-4 or to entice, direct or solicit others to intentionally violate this provision or Mayoral Executive Order No. 2011-4.

Developer agrees that a violation of, non-compliance with, misrepresentation with respect to, or breach of any covenant or warranty under this provision or violation of Mayoral Executive Order No. 2011-4 constitutes a breach and default under this Agreement, and under any Other Contract for which no opportunity to cure will be granted, unless the City, in its sole discretion, elects to grant such an opportunity to cure. Such breach and default entitles the City to all remedies (including without limitation termination for default) under this Agreement, under any Other Contract, at law and in equity. This provision amends any Other Contract and supersedes any inconsistent provision contained therein.

If Developer intentionally violates this provision or Mayoral Executive Order No. 2011-4 prior to the closing of this Agreement, the City may elect to decline to close the transaction contemplated by this Agreement.

For purposes of this provision:

"Bundle" means to collect contributions from more than one source, which is then delivered by one person to the Mayor or to his political fundraising committee.

"Other Contract" means any other agreement with the City of Chicago to which Developer is a party that is (1) formed under the authority of chapter 2-92 of the Municipal Code of Chicago; (2) entered into for the purchase or lease of real or personal property; or (3) for materials, supplies, equipment or services which are approved or authorized by the City Council of the City of Chicago.

"Contribution" means a "political contribution" as defined in Chapter 2-156 of the Municipal Code of Chicago, as amended.

Individuals are "Domestic Partners" if they satisfy the following criteria:
they are each other's sole domestic partner, responsible for each other's common welfare; and
neither party is married; and
the partners are not related by blood closer than would bar marriage in the State of Illinois; and
each partner is at least 18 years of age, and the partners are the same sex, and the partners reside at the same residence; and
two of the following four conditions exist for the partners:
a. The partners have been residing together for at least 12 months'.


30

The partners have common or joint ownership of a residence.
The partners have at least two of the following arrangements:

joint ownership of a motor vehicle;
a joint credit account;
a joint checking account; and
a lease for a residence identifying both domestic partners as tenants.
d. Each partner identifies the other partner as a primary beneficiary in
a will.

"Political fundraising committee" means a "political fundraising committee" as defined in Chapter 2-156 of the Municipal Code of Chicago, as amended.

SECTION 34. FAILURE TO MAINTAIN ELIGIBILITY TO DO BUSINESS WITH THE CITY.

Failure by Developer or any controlling person (as defined in Section 1-23-010 ofthe Municipal Code of Chicago) thereof to maintain eligibility to do business with the City of Chicago as required by Section 1-23-030 ofthe Municipal Code of Chicago shall be grounds for termination of the Agreement and the transactions contemplated thereby. Developer shall at all times comply with Section 2-154-020 of the Municipal Code of Chicago.

SECTION 35. INSPECTOR GENERAL AND LEGISLATIVE INSPECTOR GENERAL.

It is the duty of every officer, employee, department, agency, contractor, subcontractor, developer and licensee of the City, and every applicant for certification of eligibility for a City contract or program, to cooperate with the City's Legislative Inspector General and with the City's Inspector General in any investigation or hearing undertaken pursuant to Chapters 2-55 and 2-56, respectively, of the Municipal Code of Chicago. The Developer understands and will abide by all provisions of Chapters 2-55 and 2-56 of the Municipal Code of Chicago.

SECTION 36. 2014 CITY HIRING PLAN.
The City is subject to the June 16, 2014 "City of Chicago Hiring Plan" (as amended, the "2014 City Hiring Plan") entered in Shakman v. Democratic Organization of Cook County, Case No 69 C 2145 (United States District Court for the Northern District of Illinois). Among other things, the 2014 City Hiring Plan prohibits the City from hiring persons as governmental employees in non-exempt positions on the basis of political reasons or factors.
The Developer is aware that City policy prohibits City employees from directing any individual to apply for a position with the Developer, either as an employee or as a subcontractor, and from directing the Developer to hire an individual as an employee or as a subcontractor. Accordingly, the Developer, must follow its own hiring and contracting procedures, without being influenced by City employees. Any and allpersonnel provided by the Developer under this Agreement are employees or subcontractors of the Developer, not employees of the City of Chicago. This Agreement is not intended to and does not constitute,


31

create, give rise to, or otherwise recognize an employer-employee relationship of any kind between the City and any personnel provided by the Developer.
The Developer will not condition, base, or knowingly prejudice or affect any term or aspect to the employment of any personnel provided under this Agreement, or offer employment to any individual to provide services under this Agreement, based upon or because of any political reason or factor, including, without limitation, any individual's political affiliation, membership in a political organization or party, political support or activity, political financial contributions, promises of such political support, activity or financial contributions, or such individual's political sponsorship or recommendation. For purposes of this Agreement, a political organization or party is an identifiable group or entity that has as its primary purpose the support of or opposition to candidates for elected public office. Individual political activities are the activities of individual persons in support of or in opposition to political organizations or parties or candidates for elected public office.
In the event of any communication to the Developer by a City employee or City official in violation of subparagraph (ii) above, or advocating a violation of subparagraph (iii) above, the Developer will, as soon as is reasonably practicable, report such communication to the Hiring Oversight Section of the City's Office of the Inspector General (the "OIG"), and also to the head of the relevant City department utilizing services provided under this Agreement. The Developer will also cooperate with any inquiries by the OIG.

SECTION 37. COUNTERPARTS. This Agreement may be executed in any number of counterparts, each.of which shall be deemed an original and all of which, taken together, shall constitute a single, integrated instrument.

SECTION 38. DATE OF PERFORMANCE. If the final date of any time period set forth herein falls on a Saturday, Sunday or legal holiday under the laws of Illinois or the United States of America, then such time period shall be automatically extended to the next business day.

SECTION 39. GOVERNING LAW. This Agreement shall be governed by and construed in accordance with the laws of the State of Illinois, without regard to its choice of laws principles.




[SIGNATURES APPEAR ON THE FOLLOWING PAGEJ












32

IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on or as of the date first above written.

CITY OF CHICAGO,
an Illinois municipal corporation and home rule unit of government


By:
David L. Reifman Commissioner
Department of Planning and Development



LATINOS PROGRESANDO,
an Illinois not-for-profit corporation


By:_ Name: Its:





























33
STATE OF ILLINOIS

COUNTY OF COOK



I, the undersigned, a Notary Public in and for said County, in the State aforesaid, do hereby certify that David L. Reifman, Commissioner of the Department of Planning and Development of the City of Chicago, an Illinois municipal corporation, and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and being first duly sworn by me acknowledged that as said Commissioner, he signed and delivered the instrument pursuant to authority given by the City of Chicago, as his free and voluntary act and as the free and voluntary act and deed of the City, for the uses and purposes therein set forth.

GIVEN under my notarial seal this



NOTARY PUBLIC































34

STATE OF ILLINOIS )
) SS.
COUNTY OF COOK )




I, the undersigned, a Notary Public in and for said County, in the State aforesaid, do
hereby certify that , personally known to me to be the
of Latinos Progresando, an Illinois not-for-profit corporation, and personally
known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and, being first duly sworn by me, acknowledged that s/he signed and delivered the foregoing instrument pursuant to authority given by said corporation, as her/his free and voluntary act and as the free and voluntary act and deed of said corporation, for the uses and purposes therein set forth.

GIVEN under my notarial seal this day of , 20 .



NOTARY PUBLIC































35

EXHIBIT A TO REDEVELOPMENT AGREEMENT

LEGAL DESCRIPTION OF PROPERTY


LOT 19 IN MCMAHON'S SUBDIVISION OF THE WEST 54 OF THE WEST l/2 OF THE SOUTHEAST lA OF SECTION 24-39-13, IN COOK COUNTY, ILLINOIS.


PINs: 16-24-422-037-0000


Commonly known as 2724 W Cermak Road, Chicago, Illinois 60608-3510







































36

EXHIBIT B TO REDEVELOPMENT AGREEMENT NARRATIVE DESCRIPTION AND PROJECT REQUIREMENTS

The Developer's organization Latinos Progresando currently provides immigration and legal support services, as well as related community services, to the broader Pilsen and Little Village communities.

The Developer will substantially renovate the existing structure to house office space for their organization and to provide space for other non-profits, as well as meeting and conference space.

The scope of work includes the complete rehabilitation of the exterior and interior space. The first floor will include a lobby, office space, administrative space for Latinos Progresando's immigration services. The mezzanine and second floors will include more office space for the Marshall Square Resource Network and community meeting space.

The basement will be renovated to provide space for two tenants that are partnering with the Developer to provide community services on site.
/
The 1st tenant is Esperanza Health Center, which will provide behavioral and mental health services.

The 2nd tenant is the Lincoln Park Zoo. they have partnered with neighborhood organizations in the past and wish to have a physical presence in the community. This will serve as their first satellite location


























37

EXHIBIT C TO REDEVELOPMENT AGREEMENT FORM OF SUBORDINATION AGREEMENT
[Attached]
















































38

This instrument prepared by and after recording please return to:

City of Chicago
Department of Law, Real Estate Division 121 North LaSalle Street, Room 600 Chicago, Illinois 60602




[UNDER LENDER REVIEW]
REDEVELOPMENT SUBORDINATION AGREEMENT
This Redevelopment Subordination Agreement ("Agreement") is executed and delivered
as of , 20 , by [Insert name of Lender], a
[Insert type of entity and state of formation]
("Lender"), in favor of the City of Chicago, an Illinois municipal corporation (the "City").

WITNESSETH:

WHEREAS, Latinos Progresando, an Illinois not-for-profit corporation (the "Developer"), and the City, acting by and through its Department of Planning and Development, have entered into that certain Agreement for the Sale and Redevelopment of Land dated as of
, 20 , and recorded with the Office of the Recorder of Deeds of Cook
County, Illinois, on , 20 , as Document No. ("Redevelopment
Agreement"), pursuant to which the City has agreed to sell and the Developer has agreed to purchase the real property legally described on Exhibit A attached hereto (the "Property"); and

WHEREAS, pursuant to the terms of the Redevelopment Agreement, the Developer has agreed to complete a renovation of the building located on the Property (the "Project") and to thereafter conduct' its operations in such building, as more specifically described in the Redevelopment Agreement; and

WHEREAS, as part of obtaining financing for the Project, the Developer and the Lender
have entered into that certain Loan Agreement dated as of , 20 (the "Loan
Agreement"), pursuant to which the Lender has agreed to provide a loan in the principal amount
of up to Dollars ($ ) (the "Loan"), which
Loan is evidenced by a Promissory Note (the "Note") in said amount to be executed and delivered by the Developer to the Lender, and the repayment of the Loan is secured by certain liens and encumbrances on the Property pursuant to the Loan Agreement (all such agreements being referred to herein collectively as the "Loan Documents"); and



39

WHEREAS, pursuant to the Redevelopment Agreement, the Developer has agreed to be bound by certain covenants expressly running with the Property, as set forth in Sections 11, 13, 14 and 15 ofthe Redevelopment Agreement (the "City Encumbrances"); and

WHEREAS, the Redevelopment Agreement requires that the Lender agree to subordinate its liens under the Loan Documents to the City Encumbrances.

NOW, THEREFORE, for good and valuable consideration, the receipt, adequacy and sufficiency of which are hereby acknowledged, the Lender hereby agrees as follows:
Subordination. All rights, interests and claims of the Lender in the Property pursuant to the Loan Documents are and shall be subject and subordinate to the City Encumbrances. Nothing herein, however, shall be deemed to limit any of the Lender's other rights or other priorities under the Loan Documents, including, without limitation, the Lender's rights to receive, and the Developer's obligation to make, payments and prepayments of principal and interest on the Note or to exercise the Lender's rights pursuant to the Loan Documents except as provided herein.
Notice of Default. The Lender shall use reasonable efforts to give to the City (a) copies of any notices of default which it may give to the Developer with respect to the Project pursuant to the Loan Documents, and (b) copies of waivers, if any, of the Developer's default in connection therewith. Neither the Developer nor any other third party is an intended beneficiary of this Section 2. Failure of the Lender to deliver such notices or waivers shall in no instance alter the rights or remedies of the Lender under the Loan Documents.
Waivers. No waiver shall be deemed to be made by the City of any of its rights hereunder unless the same shall be in writing, and each waiver, if any, shall be a waiver only with respect to the specific instance involved and shall in no way impair the rights of the City in any other respect at any other time.
Governing Law; Binding Effect. This Agreement shall be interpreted, and the rights and liabilities of the parties hereto determined, in accordance with the internal laws and decisions of the State of Illinois, without regard to its conflict of laws principles, and shall be binding upon and inure to the benefit of the respective successors and assigns of the City and the Lender.
Section Titles; Plurals. The section titles contained in this Agreement are and shall be without substantive meaning or content of any kind whatsoever and are not a part of the agreement between the parties hereto. The singular form of any word used in this Agreement shall include the plural form.
Notices. Any notice required hereunder shall be in writing and addressed to the parties as set forth below by any of the following means: (a) personal service; (b) overnight courier; or (c) registered or certified first class mail, postage prepaid, return receipt requested:



40

City of Chicago
Department of Planning and Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attn: Commissioner

City of Chicago
Department of Law
121 North LaSalle Street, Room 600
Chicago, Illinois 60602'
Attn: Real Estate and Land Use Division

If to the Lender:


Attn:

Any notice given pursuant to clause (a) hereof shall be deemed received upon such personal service. Any notice given pursuant to clause (b) shall be deemed received on the day immediately following deposit with the overnight courier. Any notice given pursuant to clause (c) shall be deemed received three (3) business days after mailing. The parties, by notice given hereunder, may designate any further or different addresses to which subsequent notices, demands or communications shall be given.

IN WITNESS WHEREOF, Lender has executed this Redevelopment Subordination Agreement as of the date first written above.


[Lender]

By:
Name: Its:


Attachment: Exhibit A (legal description, PIN and address)












41

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT

SECTION I - GENERAL INFORMATION
Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable:



Check ONE ofthe following three boxes:

Indicate whether the Disclosing Party submitting this EDS is:
[y] the Applicant
OR
[ ] a legal entity currently holding, or anticipated to hold within six months after City action on
the contract, transaction or other undertaking to which this EDS pertains (referred to below as the
"Matter"), a direct or indirect interest in excess of 7.5% in the Applicant. State the Applicant's legal
name:
OR
[ ] a legal entity with a direct or indirect right of control of the Applicant (see Section 11(B)(1)) State the legal name of the entity in which the Disclosing Party holds a right of control:
Business address of the Disclosing Party: 'ZoL\1 W. Cecrvi«.fc-
Telephone: TO~SHT-~1yyrg.orj
Name of contact person: <_
Federal Employer Identification No. (if you have one): .,
Brief description of the Matter to which this EDS pertains. (Include project number and location of property, if applicable):
Which City agency or department is requesting this EDS? "Pe^h PUniqi i/t^ %-V)ev<;lvueW^~
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:

Specification # and Contract #
Ver.2017-1 Paget of 14


SECTION n - DISCLOSURE OF OWNERSHIP INTERESTS

A. NATURE OF THE DISCLOSING PARTY

1. Indicate the nature of the Disclosing Party:
[ ] Person [ ] Limited liability company
[ ] Publicly registered business corporation [ ] Limited liability partnership
[ ] Privately held business corporation [ ] Joint venture
[ ] Sole proprietorship [>C] Not-for-profit corporation
[ ] General partnership (Is the not-for-profit corporation also a 501 (c)(3))?
[ ] Limited partnership fcl Yes [ ] No
[ ] Trust [ ] Other (please specify)
For legal entities, the state (or foreign country) of incorporation or organization, if applicable:
For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?

[ ] Yes [ ] No [y] Organized in Illinois

B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:

1. List below the full names and titles, if applicable, of: (i) all executive officers and all directors of the entity; (ii) for not-for-profit corporations, all members, if any, which are legal entities (if there are no such members, write "no members which are legal entities"); (iii) for trusts, estates or other similar entities, the trustee, executor, administrator, or similarly situated party; (iv) for general or limited partnerships, limited liability companies, limited liability partnerships or joint ventures, each general partner, managing member, manager or any other person or legal entity that directly or indirectly controls the day-to-day management of the Applicant.

NOTE: Each legal entity listed below must submit an EDS on its own behalf.

Name - Title





2. Please provide the following information concerning each person or legal entity having a direct or indirect, current or prospective (i.e. within 6 months after City action) beneficial interest (including ownership) in excess of 7.5% of the Applicant. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture, interest of a member or manager in a


Page 2 of 14

limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None."
NOTE: Each legal entity listed below may be required to submit an EDS on its own behalf.
Name Business Address Percentage Interest in the Applicant

N one.



SECTION III - INCOME OR COMPENSATION TO, OR OWNERSHIP BY, CITY ELECTED OFFICIALS

Has the Disclosing Party provided any income or compensation to any City elected official during the
12-month period preceding the date of this EDS? [ ] Yes [><] No

Does the Disclosing Party reasonably expect to provide any income or compensation to any City
elected official during the 12-month period following the date of this EDS? [ ] Yes [yt] No

If "yes" to either of the above, please identify below the name(s) of such City elected official(s) and describe such income or compensation:

N /A
Does any City elected official or, to the best of the Disclosing Party's knowledge after reasonable
inquiry, any City elected official's spouse or domestic partner, have a financial interest (as defined in
Chapter 2-156 ofthe Municipal Code of Chicago ("MCC")) in the Disclosing Party?
[ ] Yes [ ] No

If "yes," please identify below the name(s) of such City elected official(s) and/or spouse(s)/domestic partner(s) and describe the financial interest(s).

N/A
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES

The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist (as defined in MCC Chapter 2-156), accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll. If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.

Page 3 of 14

Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:
to be retained) lobbyist, etc.) "hourly rate" or "t.b.d." is
not an acceptable response.




(Add sheets if necessary)
[ ] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
COURT-ORDERED CHILD SUPPORT COMPLIANCE

Under MCC Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.

Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?

[ ] Yes [ ] No M No person directly or indirectly owns 10% or more of the Disclosing Party.

If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?

[ ] Yes [ ] No
FURTHER CERTIFICATIONS

[This paragraph 1 applies only if the Matter is a contract being handled by the City's Department of Procurement Services.] In the 5-year period preceding the date of this EDS, neither the Disclosing Party nor any Affiliated Entity [see definition in (5) below] has engaged, in connection with the performance of any public contract, the services of an integrity monitor, independent private sector inspector general, or integrity compliance consultant (i.e., an individual or entity with legal, auditing, investigative, or other similar skills, designated by a public agency to help the agency monitor the activity of specified agency vendors as well as help the vendors reform their business practices so they can be considered for agency contracts in the future, or continue with a contract in progress).
The Disclosing Party and its Affiliated Entities are not delinquent in the payment of any fine, fee, tax or other source of indebtedness owed to the City of Chicago, including, but not limited to, water and sewer charges, license fees, parking tickets, property taxes and sales taxes, nor is the Disclosing Party delinquent in the payment of any tax administered by the Illinois Department of Revenue.


Page 4 of 14

The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section 11(B)(1) of this EDS:

are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government; '¦
have not, during the 5 years before the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in subparagraph (b) above;
have not, during the 5 years before the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
have not, during the 5 years before the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The Disclosing Party understands and shall comply with the applicable requirements of MCC Chapters 2-56 (Inspector General) and 2-156 (Governmental Ethics).
Certifications (5), (6) and (7) concern:

the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity). Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity. With respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it,; or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").

Page 5 of 14

Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor, nor any Agents have, during the 5 years before the date of this EDS, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the 5 years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee ofthe City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in subparagraph (a) or (b) above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions referenced in MCC Subsection 2-92-320(a)(4)(Contracts Requiring a Base Wage); (a)(5)(Debarment Regulations); or (a)(6)(Minimum Wage Ordinance).

Neither the Disclosing Party, nor any Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on a Sanctions List maintained by the United States Department of Commerce, State, or Treasury, or any successor federal agency.
[FOR APPLICANT ONLY] (i) Neither the Applicant nor any "controlling person" [see MCC Chapter 1-23, Article I for applicability and defined terms] of the Applicant is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any "sister agency"; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If MCC Chapter 1-23, Article I applies to the Applicant, that Article's permanent compliance timeframe supersedes 5-year compliance timeframes in this Section V.
[FOR APPLICANT ONLY] The Applicant and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed as having an active exclusion by the U.S. EPA on the federal System for Award Management ("SAM").
[FOR APPLICANT ONLY] The Applicant will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in Certifications (2) and (9) above and will not, without the prior written consent of the City, use any such.
Ver.2017-1 Page 6 of 14



/
contractor/subcontractor that does not provide such certifications or that the Applicant has reason to believe has not provided or cannot provide truthful certifications.

11. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below:





If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

12. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a .complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none").
_____ ^ ———-


13. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $25 per recipient, or (iii) a political contribution otherwise duly reported as required by law (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient.




C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is [x] is not
a "financial institution" as defined in MCC Section 2-32-455(b).
If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in MCC Chapter 2-32. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in MCC Chapter 2-32. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."

Page 7 of 14

If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in MCC Section 2-32-455(b)) is a predatory lender within the meaning of MCC Chapter 2-32, explain here (attach additional pages if necessary):




If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.

D. CERTIFICATION REGARDING FINANCIAL INTEREST IN CITY BUSINESS

Any words or terms defined in MCC Chapter 2-156 have the same meanings if used in this Part D.
In accordance with MCC Section 2-156-110: To the best of the Disclosing Party's knowledge after reasonable inquiry, does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?

[ ] Yes M No

NOTE: If you checked "Yes" to Item D(l), proceed to Items D(2) and D(3). If you checked "No" to Item D(l), skip Items D(2) and D(3) and proceed to Part E.
Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.

Does the Matter involve a City Property Sale?

[ ¦] Yes [ ] No
If you checked "Yes" to Item D(l), provide the names and business addresses of the City officials or employees having such financial interest and identify the nature of the financial interest:

Name Business Address Nature of Financial Interest






4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.

Page 8 of 14

E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS

Please check either (1) or (2) below. If the Disclosing Party checks (2), the Disclosing Party must disclose below or in an attachment to this EDS all information required by (2). Failure to comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.

>C 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.

2. The Disclosing Party verifies that, as a result of conducting the search in step (1) above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:






SECTION VI - CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS

NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.

A. CERTIFICATION REGARDING LOBBYING

1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995, as amended, who have made lobbying contacts on behalf ofthe Disclosing Party with respect to the Matter: (Add sheets if necessary):





(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995, as amended, have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)

2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay
any person or entity listed in paragraph A(l) above for his or her lobbying activities or to pay any
person or entity to influence or attempt to influence an officer or employee of any agency, as defined
by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee
Ver.2017-1 Page 9 of 14

of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A(l) and A(2) above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities," as that term is defined in the Lobbying Disclosure Act of 1995, as amended.
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A(l) through A(4) above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.

B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY

If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.

Is the Disclosing Party the Applicant?
W Yes [ ] No

If "Yes," answer the three questions below:
Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[ ] Yes [ ] No
Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes [ ] No [>] Reports not required
Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes [yj No

If you checked "No" to question (1) or (2) above, please provide an explanation:




Page 10 of 14

SECTION VII - FURTHER ACKNOWLEDGMENTS AND CERTIFICATION

The Disclosing Party understands and agrees that:
The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics Ordinance, MCC Chapter 2-156, imposes certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text of this ordinance and a training program is available on line at www.citvofchicago.org/Ethics . and may also be obtained from the City's Board of Ethics, 740 N. Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with this ordinance.
If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other City transactions. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble , damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided in, and appended to, this EDS may be made publicly available on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to MCC Chapter 1-23, Article I (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by MCC Chapter 1-23 and Section 2-154-020.








Page 11 of 14
CERTIFICATION

Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS, and Appendices A and B (if applicable), on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS, and Appendices A and B (if applicable), are true, accurate and complete as of the date furnished to the City.




(Print or type name of person signing)


(Print or type title of person signing)


Signed and sworn to before me on



at j. County, \j[ iKlpi j

Commission expires: __













Page 12 of 14

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A

FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS

This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5%. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.

Under MCC Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.

"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B.l.a., if the Disclosing Party is a corporation; all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5% ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.

Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?

[ ] Yes [yC] No

If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.

Nl (A







Page 13 of 14

CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX B

BUILDING CODE SCOFFLAW/PROBLEM LANDLORD CERTIFICATION

This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5% (an "Owner"). It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Pursuant to MCC Section 2-154-010, is the Applicant or any Owner identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?

[ ] Yes fee] No
If the Applicant is a legal entity publicly traded on any exchange, is any officer or director of the Applicant identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
i
[ ] Yes [ ] No [x] The Applicant is not publicly traded on any exchange.
If yes to (1) or (2) above, please identify below the name of each person or legal entity identified as a building code scofflaw or problem landlord and the address of each building or buildings to which the pertinent code violations apply.

























Page 14 of 14