OFFICE OF THE MAYOR
CITY OF CHICAGO
LORI E. LIGHTFOOT MAYOR
December 14, 2022
TO THE HONORABLE, THE CITY COUNCIL OF THE CITY OF CHICAGO
Ladies and Gentlemen:
At the request ofthe Commissioner of Planning and Development, I transmit herewith ordinance authorizing the execution of a TIF redevelopment agreement with mITUB for the renovation ofthe property located at 240 North Ashland Avenue.
Your favorable consideration ofthis ordinance will be appreciated.
ORDINANCE
WHEREAS, the City of Chicago (the "City") is a home rule unit of government under Section 6(a), Article VII ofthe 1970 Constitution ofthe State of Illinois; and
WHEREAS, pursuant to an ordinance adopted by the City Council (the "City Council") of the City on June 10, 1998, and published at pages 70368-70499 ofthe Journal of Proceedings of the City Council (the "Journal") of such date, which ordinance was amended on May 12, 2010 and published at pages 89655-89664 of the Journal of such date, a certain redevelopment plan and project (the "Plan") for the Kinzie Industrial Corridor redevelopment project area (the "Area") was approved pursuant to the Illinois Tax Increment Allocation Redevelopment Act, as amended (65 ILCS 5/11-74.4-1 et seg.) (the "Act"); and
WHEREAS, pursuant to an ordinance adopted by the City Council on June 10, 1998, and published at pages 70500-70512 of the Journal of such date, the Area was designated as a redevelopment project area pursuant to the Act; and
WHEREAS, pursuant to an ordinance adopted by the City Council on June 10, 1998, and published at pages 70512-70520 ofthe Journal of such date, (the "TIF Ordinance"), tax increment allocation financing was adopted pursuant to the Act as a means of financing certain Area redevelopment project costs (as defined in the Act) incurred pursuant to the Plan; and
WHEREAS, pursuant to Section 5/11-74.4-8(b) of the Act and the TIF Ordinance, incremental taxes ("Incremental Taxes") are deposited from time to time in the "Kinzie Industrial Redevelopment Project Area Special Tax Allocation Fund" (the "TIF Fund") established pursuant to the TIF Ordinance; and
WHEREAS, mHUB Support Corporation, an Illinois not-for-profit corporation ("Owner") intends to acquire the property located within the Area at 240 North Ashland Avenue in Chicago (the "Property"), and together with mHUB, an Illinois not-for-profit corporation ("Tenant" and collectively with Owner, the "Developer") shall complete rehabilitation of an approximately 80,000 square foot facility into laboratory, office and meeting spaces, with an updated facade and renovated clock tower (collectively, the Project"); and
WHEREAS, the Developer proposes to undertake the Project in accordance with the Plan and pursuant to the terms and conditions of a proposed redevelopment agreement to be executed by the Developer and the City to be financed in part by a portion of Incremental Taxes, if any, deposited in the TIF Fund pursuant to Section 5/11-74.4-8(b) ofthe Act; and
WHEREAS, pursuant to Resolution 22-CDC-64 adopted by the Community Development Commission of the City of Chicago (the "Commission") on November 8, 2022, the Commission has recommended that the Developer be designated as the developer for the Project (as defined in such resolution), and that the City's Department of Planning and Development ("DPD") be authorized to negotiate, execute and deliver on behalf of the City a redevelopment agreement with the Developer for the Project; now, therefore,
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF CHICAGO:
|1010|
SECTION 1. The above recitals are incorporated herein and made a part hereof.
SECTION 2. The Developer is hereby designated as the developer for the Project pursuant to Section 5/11 -74.4-4 of the Act.
SECTION 3. The Commissioner of DPD (the "Commissioner") or a designee of the Commissioner are each hereby authorized, with the approval of the City's Corporation Counsel as to form and legality, to negotiate, execute and deliver a redevelopment agreement between the Developer and the City in substantially the form attached hereto as Exhibit A and made a part hereof (the "Redevelopment Agreement"), and such other supporting documents as may be necessary to carry out and comply with the provisions of the Redevelopment Agreement, with such changes, deletions and insertions as shall be approved by the persons executing the Redevelopment Agreement.
SECTION 4. The City Council hereby finds that the City is authorized to pay $17,550,000 ("City Funds") from Incremental Taxes deposited in the general account of the TIF Fund (the "General Account") to the Developer to finance a portion of the eligible costs included within the Project. The proceeds of the City Funds are hereby appropriated for the purposes set forth in this Section 4.
SECTION 5. Pursuant to the TIF Ordinance, the City has created the TIF Fund. The Chief Financial Officer (or his or her designee) ofthe City is hereby directed to maintain the TIF Fund as a segregated interest-bearing account, separate and apart from the City's Corporate Fund or any other fund of the City. Pursuant to the TIF Ordinance, all Incremental Taxes received by the City for the Area shall be deposited into the TIF Fund. The City shall use the funds in the TIF Fund to make payments pursuant to the terms of the Redevelopment Agreement.
SECTION 6. The Mayor, the Chief Financial Officer, the City Comptroller, the City Clerk and the other officers of the City are authorized to execute and deliver on behalf of the City such other documents, agreements and certificates and to do such other things consistent with the terms of this ordinance as such officers and employees shall deem necessary or appropriate in order to effectuate the intent and purposes of this ordinance.
SECTION 7. If any provision of this ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such provision shall not affect any of the other provisions of this ordinance.
SECTION 8. This ordinance shall be in full force and effect immediately upon its passage and approval.
|1010|
Exhibit A to the Ordinance Form of Redevelopment Agreement
[see attached]
|1010|
This agreement was prepared by and
after recording return to:
Ann Kaplan-Perkins, Esq.
City of Chicago Department of Law
121 North LaSalle Street, Room 600
Chicago, IL 60602
MHUB REDEVELOPMENT AGREEMENT
This mHUB Redevelopment Agreement (this "Agreement" or "RDA") is made as of this _
day of , 20_, by and between the City of Chicago, an Illinois municipal corporation (the "City"),
through its Department of Planning and Development ("DPD"), and mHUB Support Corporation, an Illinois not-for-profit corporation ("Owner"), and mHUB, an Illinois not-for-profit corporation ("Tenant"). (Tenant and Owner are referred to collectively as the "Developer".)
RECITALS
Constitutional Authority: As a home rule unit of government under Section 6(a), Article VII of the 1970 Constitution of the State of Illinois (the "State"), the City has the power to regulate for the protection of the public health, safety, morals and welfare of its inhabitants, and pursuant thereto, has the power to encourage private development in order to enhance the local tax base, create employment opportunities and to enter into contractual agreements with private parties in order to achieve these goals.
Statutory Authority: The City is authorized under the provisions of the Tax Increment Allocation Redevelopment Act, 65 ILCS 5/11-74.4-1 et seq., as amended from time to time (the "Act"), to finance projects that eradicate blighted conditions and conservation area factors through the use of tax increment allocation financing for redevelopment projects.
Citv Council Authority: To induce redevelopment pursuant to the Act, the City Council of the City (the "City Council") adopted the following ordinances: (1) on June 10, 1998,
|1010|
"An Ordinance of the City of Chicago, Illinois Approving a Redevelopment Plan for the Kinzie Industrial Corridor Redevelopment Project Area" (as amended by an ordinance adopted by City Council on May 12, 2010, the "Plan Adoption Ordinance"); (2) on June 10, 1998, "An Ordinance of the City of Chicago, Illinois Designating the Kinzie Industrial Corridor Redevelopment Project Area as a Redevelopment Project Area Pursuant to the Tax Increment Allocation Redevelopment Act"; (3) on June 10, 1998, "An Ordinance of the City of Chicago, Illinois Adopting Tax Increment Allocation Financing for the Kinzie Industrial Corridor Redevelopment Project Area" (the "TIF Adoption Ordinance") (items(1)-(3) collectively referred to herein as the "TIF Ordinances"). The redevelopment project area referred to above (the "Redevelopment Area") is legally described in Exhibit A hereto.
The Project: Owner intends to purchase (the "Acquisition") certain property located within the Redevelopment Area at 240 North Ashland Avenue, Chicago, Illinois 60607 and legally described on Exhibit B hereto (the "Property"). Within the time frames set forth in Section 3.01 hereof, Developer shall commence and complete rehabilitation of an approximately 80,000 square foot facility into laboratory, office and meeting spaces (the "Facility").
Owner shall lease the Facility to Tenant, pursuant to a lease (as amended from time to time, the "Lease").
The Facility and related improvements (including but not limited to those TIF-Funded Improvements as defined below and set forth on Exhibit C) are collectively referred to herein as the "Project." The completion of the Project would not reasonably be anticipated without the financing contemplated in this Agreement.
Redevelopment Plan: The Project will be carried out in accordance with this Agreement and the Kinzie Industrial Corridor Redevelopment Plan and Project (the "Redevelopment Plan") included in the Plan Adoption Ordinance and published on June 10,1998 at pages 70368-70499 ofthe Journal of Proceedings ofthe City Council for that date, as amended.
Citv Financing: The City agrees to use, in the amounts set forth in Section 4.03 hereof, Incremental Taxes (as defined below), to pay for or reimburse Developer for the costs of TIF-Funded Improvements pursuant to the terms and conditions of this Agreement.
Now, therefore, in consideration of the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:
SECTION 1. RECITALS, HEADINGS AND EXHIBITS
The foregoing recitals are hereby incorporated into this Agreement by reference. The paragraph and section headings contained in this Agreement, including without limitation those set forth in the following table of contents, are for convenience only and are not intended to limit, vary, define or expand the content thereof. Developer agrees to comply with the requirements set forth in the following exhibits which are attached to and made a part of this Agreement. All
|1010|
provisions listed in the Exhibits have the same force and effect as if they had been listed in the body of this Agreement.
Table of Contents List of Exhibits
1. Recitals, Headings and Exhibits 2. Definitions 3. The Project 4. Financing 5. Conditions Precedent 6. Agreements with Contractors 7. Completion of Construction or Rehabilitation 8. Covenants/RepresentationsAA/arranties of Developer 9. Covenants/Representations/Warranties of the City 10. Developer's Employment Obligations 11. Environmental Matters 12. Insurance 13. Indemnification 14. Maintaining Records/Right to Inspect 15. Defaults and Remedies 16. Mortgaging ofthe Project 17. Notice 18. Miscellaneous A *Redevelopment Area B *Property C *TIF-Funded Improvements D [intentionally omitted] E Construction Contract F [intentionally omitted] G *Permitted Liens H-1 *Project Budget H-2 *MBEA/VBE Budget I Approved Prior Expenditures J Opinion of Developer's Counsel K , *Preliminary TIF Projection - Real Estate Taxes L Form of Payment Bond (An asterisk (*) indicates which exhibits are to be recorded.)
SECTION 2. DEFINITIONS
For purposes of this Agreement, in addition to the terms defined in the foregoing recitals, the following terms shall have the meanings set forth below:
"Act" shall have the meaning set forth in the Recitals hereof.
"Acquisition" shall have the meaning set forth in the Recitals hereof.
"Affiliate" shall mean any person or entity directly or indirectly controlling, controlled by or under common control with Developer.
"Annual Compliance Report" shall mean a signed report from Developer to the City (a) itemizing each of Developer's obligations under the RDA during the preceding calendar year, (b) certifying Developer's compliance or noncompliance with such obligations, (c) attaching evidence (whether or not previously submitted to the City) of such compliance or noncompliance and (d) certifying that Developer is not in default with respect to any provision ofthe RDA, the agreements evidencing the Lender Financing, if any, or any related agreements; provided, that the obligations to be covered by the Annual Compliance Report shall include the following: (1) compliance with the Operating Covenant (Section 8.06); (2) compliance with the Jobs Covenant (Section 8.06); (3) delivery of Financial Statements and unaudited financial statements (Section 8.13); (4) delivery of updated insurance certificates, if applicable (Section 8.14), (5) delivery of evidence of
|1010|
payment of Non-Governmental Charges, if applicable (Section 8.15); (6)) notification of a Capital Event (Section 8.20); (7) delivery of evidence that Chicago Sustainable Development Policy has been satisfied (Section 8.23); and (8) compliance with all other executory provisions ofthe RDA.
"Available Project Funds" shall have the meaning set forth for such term in Section 4.07
hereof.
"Bond(s)" shall have the meaning set forth for such term in Section 8.05 hereof.
"Bond Ordinance" shall mean the City ordinance authorizing the issuance of Bonds.
"Bridge Lender" shall mean and/or such other lender as may
make a Bridge Loan to Developer in connection with the Project.
"Bridge Loan" shall mean the loan or loans from Bridge Lender to Developer in connection
with the Project in the aggregate principal amount of $ .
"Capital Event" shall mean during the NMTC Compliance Period any arms-length sale, transfer or refinancing of the Project or any part thereof, including any New Mortgage, except for (i) refinancing of construction loan Lender Financing to a permanent loan of the same or lesser amount; (ii) refinancing to a lower interest rate; or (iii) enforcement of the Lender Financing or deed in lieu thereof. Notwithstanding the foregoing in no event shall a Permitted Transfer be considered a Capital Event.
"Certificate" shall mean the Certificate of Completion of Construction described in Section 7.01 hereof.
"Change Order" shall mean any amendment or modification to the Scope Drawings, Plans and Specifications or the Project Budget as described in Section 3.03, Section 3.04 and Section 3.05, respectively.
"Citv Contract" shall have the meaning set forth in Section 8.01(1) hereof.
"Citv Council" shall have the meaning set forth in the Recitals hereof.
"Citv Funds" shall mean the funds described in Section 4.03(b) hereof.
"Closing Date" shall mean the date of execution and delivery of this Agreement by all parties hereto, which shall be deemed to be the date appearing in the first paragraph, of this Agreement.
"Collateral Assignment" shall mean a collateral assignment of the right to receive payment of City Funds, such collateral assignment to be made by Developer to secure a bridge loan and in form and substance acceptable to the City in its sole discretion.
|1010|
"Contaminant" means any of those materials set forth in 415 ILCS 5/3.165, as amended from time to time, that are subject to regulation under any Environmental Law.
"Contract" shall have the meaning set forth in Section 10.03 hereof.
"Contractor" shall have the meaning set forth in Section 10.03 hereof.
"Construction Contract" shall mean that certain contract, substantially in the form attached hereto as Exhibit E. to be entered into between Developer and the General Contractor providing for construction of the Project.
"Corporation Counsel" shall mean the City's Department of Law.
"EDS" shall mean the City's Economic Disclosure Statement and Affidavit, on the City's then-current form, whether submitted in paper or via the City's online submission process.
"Employees)" shall have the meaning set forth in Section 10 hereof.
"Environmental Laws" means any Federal, state, or local law, statute, ordinance, code, rule, permit, plan, regulation, license, authorization, order, or injunction which pertains to health, safety, any Hazardous Substance or Other Regulated Material, or the environment (including, but not limited to, ground, air, water or noise pollution or contamination, and underground or above-ground tanks) and shall include, without limitation, the Emergency Planning and Community Right-to-Know Act, 42 U.S.C. § 11001 et seq.; the Toxic Substances Control Act, 15 U.S.C. § 2601 etseq.; the Hazardous Material Transportation Act, 49 U.S.C. § 1801 ef sec/.; the Resource Conservation and Recovery Act ("RCRA"), 42 U.S.C. § 6901 etseq., as amended by the Hazardous and Solid Waste Amendments of 1984; the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 U.S.C. § 9601 et seq. ("CERCLA"), as amended by the Superfund Amendments and Reauthorization Act of 1986 ("SARA"); the Occupational Safety and Health Act, 29 U.S.C. § 651 et seq.; the Federal Water Pollution Control Act, 33 U.S.C. § 1251 et seq.; the Clean Air Act, 42 U.S.C. § 7401 ef seq.; the Illinois Environmental Protection Act, 415 ILCS 5/1 etseq.; the Gasoline Storage Act, 430 ILCS 15/0.01 etseq.; the Sewage and Waste Control Ordinance of the Metropolitan Water Reclamation District of Greater Chicago ("MWRD"); the Municipal Code of the City of Chicago; and any other local, state, or federal environmental statutes, and all rules, regulations, orders, and decrees now or hereafter promulgated under any of the foregoing, as any of the foregoing now exist or may be changed or amended or come into effect in the future.
"Environmental Performance Deposit" means a dollar amount equal to
Dollars ($ ) which has been deposited by the Developer into a third-party escrow
("Environmental Escrow"), as security for the performance of the Developer's obligations under Section 11 of this Agreement.
"Equity" shall mean funds of Developer (other than funds derived from Lender Financing) irrevocably available for the Project, in the amount set forth in Section 4.01 hereof, which amount may be increased pursuant to Section 4.06 (Cost Overruns) or Section 4.03(b).
|1010|
"Escrow" shall mean the construction escrow established pursuant to the Escrow Agreement.
"Escrow Agreement" shall mean the Escrow Agreement establishing a construction escrow, to be entered into as ofthe date hereof by the Title Company, NMTC Investor, Developer, NMTC Lender, and the disbursement agent engaged by the NMTC Lender.
"Event of Default" shall have the meaning set forth in Section 15 hereof.
"Facility" shall have the meaning set forth in the Recitals hereof.
"Financial Interest" shall have the meaning set forth for such term in Section 2-156-010 of the Municipal Code.
"Financial Statements" shall mean complete audited financial statements of Developer prepared by a certified public accountant in accordance with generally accepted accounting principles and practices consistently applied throughout the appropriate periods.
"General Contractor" shall mean the general contractor(s) hired by Developer pursuant to Section 6.01.
"Hazardous Substance" has the meaning set forth in 415 ILCS 5/3.215, as amended from time to time.
"Human Rights Ordinance" shall have the meaning set forth in Section 10 hereof.
"IEPA" shall mean the Illinois Environmental Protection Agency.
"In Balance" shall have the meaning set forth in Section 4.07 hereof.
"Incremental Taxes" shall mean such ad valorem taxes which, pursuant to the TIF Adoption Ordinance and Section 5/11-74.4-8(b) of the Act, are allocated to and when collected are paid to the Treasurer of the City of Chicago for deposit by the Treasurer into the TIF Fund established to pay Redevelopment Project Costs and obligations incurred in the payment thereof.
"Indemnitee" and "Indemnitees" shall have the meanings set forth in Section 13.01 hereof.
"Investment Fund" shall mean a to-be-formed subsidiary of NMTC Investor expected to make a qualified equity investment in NMTC Lender.
"Lease" shall have the meaning set forth in the Recitals hereof.
"Lender Financing" shall mean funds borrowed by Developer from lenders and irrevocably available to pay for Costs of the Project, in the amount set forth in Section 4.01 hereof, including, without limitation the NMTC Loan, the Bridge Loan, and the Senior Loan.
|1010|
"Material Amendment" shall mean an amendment of the Lease the net effect of which is to directly or indirectly do any of the following with respect to the Project: (a) materially reduce, increase, abate or rebate base rent, other amounts deemed rent, operating expense payments, tax payments, tenant improvement allowances or credits, or other monetary amounts payable (or monetary credits) under the Lease, or otherwise confer or take away any material economic benefit, in each case taking into account all direct economic effects under the Lease of the amendment; or (b) shorten the initial term of the Lease, or grant additional early termination rights that, if exercised, would shorten the initial term of the Lease.
"MBE(s)" shall mean a business identified in the Directory of Certified Minority Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a minority-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
"MBEA/VBE Budget" shall mean the budget attached hereto as Exhibit H-2, as described in Section 10.03.
"MBEAA/BE Program" shall have the meaning set forth in Section 10.03 hereof.
"Municipal Code" shall mean the Municipal Code ofthe City of Chicago, as amended from time to time.
"Net NMTC Eguity" shall have the meaning set forth in Section 4.01 hereof. "New Mortgage" shall have the meaning set forth in Article 16 hereof. "NMTC" shall mean the Federal New Markets Tax Credits.
"NMTC Compliance Period" shall mean the earlier of (a) the seventh (7th) anniversary of the Investment Fund's most recent qualified equity investment in NMTC Lender or (b) the termination or repayment ofthe NMTC Loan.
"NMTC Investor" shall mean , or such other investor in NMTCs
generated by the Project as may be engaged by Developer.
"NMTC Lender" shall mean, collectively, one or more community development entities or their respective subsidiaries that make NMTC Loans to Developer for the Project.
"NMTC Loan" shall mean, collectively, those certain loans made by the NMTC Lender to Developer for the Project.
"No Further Remediation Letter" or "NFR Letter" shall mean a final letter issued by IEPA pursuant to the procedures of the SRP and 35 III. Adm. Code § 740.600, following a comprehensive investigation of the Property, development of remediation objectives consistent with future industrial/commercial use, and allowing industrial/commercial future use of the Property.
|1010|
"Non-Governmental Charges" shall mean all non-governmental charges, liens, claims, or encumbrances relating to Developer, the Property or the Project.
"Other Regulated Material" means any Waste, Contaminant, or any other material, not otherwise specifically listed or designated as a Hazardous Substance, that (a) is or contains: petroleum, including crude oil or any fraction thereof, motor fuel, jet fuel, natural gas, natural gas liquids, liquefied natural gas, or synthetic gas usable for fuel or mixtures of natural gas and such synthetic gas, asbestos, radon, any polychlorinated biphenyl, urea, formaldehyde foam insulation, explosive or radioactive material, materials known to contain per- and polyfluoroalkyl substances, i.e. PFAS, or (b) is a hazard to the environment or to the health or safety of persons.
"Permitted Liens" shall mean those liens and encumbrances against the Property and/or the Project set forth on Exhibit G hereto.
"Permitted Mortgage" shall have the meaning set forth in Article 16 hereof.
"Permitted Transfer" shall mean transfer of the Project from Owner to Tenant or an affiliate thereof, or in connection with a financing related to the end of NMTC Compliance Period of the Project.
"Phase I ESA" shall mean a Phase I environmental site assessment of the Property in accordance with ASTM E-1527-13 (as most recently updated at the time of assessment).
"Phase II ESA" shall mean a Phase II environmental site assessment of the Property in accordance with ASTM E-1903-19 (as most recently updated at the time of assessment).
"Plans and Specifications" shall mean final construction documents containing a site plan and working drawings and specifications for the Project, as submitted to the City as the basis for obtaining building permits for the Project.
"Prior Expenditure(s)" shall have the meaning set forth in Section 4.05(a) hereof.
"Project" shall have the meaning set forth in the Recitals hereof.
"Project Budget" shall mean the budget attached hereto as Exhibit H-1, showing the total cost of the Project by line item, furnished by Developer to DPD, in accordance with Section 3.03 hereof.
"Property" shall have the meaning set forth in the Recitals hereof.
"RAP" shall mean the Remedial Action Plan document required by the IEPA under the SRP in order to receive a No Further Remediation Letter.
"RAP Approval Letter" shall mean written approval from the IEPA of the RAP.
"RACR" shall mean the Remedial Action Completion Report required by the IEPA in order to receive a No Further Remediation Letter under the SRP.
|1010|
"Redevelopment Area" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Plan" shall have the meaning set forth in the Recitals hereof.
"Redevelopment Project Costs" shall mean redevelopment project costs as defined in Section 5/11-74.4-3(q) of the Act that are included in the budget set forth in the Redevelopment Plan or otherwise referenced in the Redevelopment Plan.
"Remediation Work" means all investigation, sampling, monitoring, testing, reporting, removal, response, disposal, storage, remediation, treatment and other activities taken to obtain a No Further Remediation Letter in accordance with: the terms and conditions of the RAP Approval Letter issued by the IEPA, the SRP Documents (as defined below), all requirements of the IEPA, and all applicable federal, state and local laws, ordinances and regulations , including, without limitation, all applicable Environmental Laws.
"Scope Drawings" shall mean preliminary construction documents containing a site plan and preliminary drawings and specifications for the Project.
"Senior Lender" shall mean and/or such other lender as may
make a Senior Loan to Developer in connection with the Project.
"Senior Loan" shall mean the loan or loans from Senior Lender to Developer in connection
with the Project in the aggregate principal amount of $ .
"SRP" shall mean the Illinois Site Remediation Program codified at 35 III. Adm. Code Part 740 et seq., as amended or supplemented from time to time.
"Environmental Documents" means all documents submitted to the IEPA under the SRP, as amended or supplemented from time to time, including, without limitation, the Comprehensive Site Investigation and Remediation Objectives Report, the RAP, and the RACR and any and all correspondence, data and other information prepared by any party pursuant to Section 11 or related to activities required or referenced in Section 11.
"Survey" shall mean a plat of survey in the most recently revised form of ALTA/ACSM land title survey of the Property, meeting the 2011 Minimum Standard Detail Requirements for ALTA/ACSM Land Title Surveys, effective February 23, 2011, dated within 75 days prior to the Closing Date, acceptable in form and content to the City and the Title Company, prepared by a surveyor registered in the State of Illinois, certified to the City and the Title Company, and indicating whether the Property is in a flood hazard area as identified by the United States Federal Emergency Management Agency (and updates thereof to reflect improvements to the Property in connection with the construction of the Facility and related improvements as required by the City or lender(s) providing Lender Financing).
"Term of the Agreement" shall mean the period of time commencing on the Closing Date and ending on the 20th anniversary of the Closing Date.
|10 10|
"TIF Adoption Ordinance" shall have the meaning set forth in the Recitals hereof.
"TIF District Administration Fee" shall mean the fee described in Section 4.05(c) hereof.
"TIF Fund" shall mean the special tax allocation fund created by the City in connection with the Redevelopment Area into which the Incremental Taxes will be deposited.
"TIF-Funded Improvements" shall mean those improvements of the Project which (i) qualify as Redevelopment Project Costs, (ii) are eligible costs under the Redevelopment Plan and (iii) the City has agreed to pay for out of the City Funds, subject to the terms of this Agreement. Exhibit C lists the TIF-Funded Improvements for the Project.
"TIF Ordinances" shall have the meaning set forth in the Recitals hereof.
"Title Company" shall mean [ ].
"Title Policy" shall mean a title insurance policy in the most recently revised ALTA or equivalent form, showing Developer as the insured, noting the recording ofthis Agreement as an encumbrance against the Property, and a subordination agreement in favor of the City with respect to previously recorded liens against the Property related to Lender Financing, if any, issued by the Title Company.
"WARN Act" shall mean the Worker Adjustment and Retraining Notification Act (29 U.S.C. Section 2101 et seq.).
"Waste" means those materials defined in the Illinois Environmental Protection Act, 415 ILCS 5/1 et seq. as waste and identified subcategories thereof, including but not limited to, construction or demolition debris, garbage, household waste, industrial process waste, landfill waste, landscape waste, municipal waste, pollution control waste, potentially infectious medical waste, refuse, or special waste.
"WBE(s)" shall mean a business identified in the Directory of Certified Women Business Enterprises published by the City's Department of Procurement Services, or otherwise certified by the City's Department of Procurement Services as a women-owned business enterprise, related to the Procurement Program or the Construction Program, as applicable.
SECTION 3. THE PROJECT
The Project. With respect to the Facility, Developer shall, pursuant to the Plans and Specifications and subject to the provisions of Section 8.17 hereof: (i) commence rehabilitation
no later than [ ' , 2023]; and (ii) complete rehabilitation and conduct business
operations therein no later than [ , 20 ].
Scope Drawings and Plans and Specifications. Developer has delivered the Scope Drawings and Plans and Specifications to DPD and DPD has approved same. After such initial approval, subsequent proposed changes to the Scope Drawings or Plans and Specifications shall be submitted to DPD as a Change Order pursuant to Section 3.04 hereof. The Scope Drawings
10
and Plans and Specifications shall at all times conform to the Redevelopment Plan and all applicable federal, state and local laws, ordinances and regulations. Developer shall submit all necessary documents to the City's Building Department, Department of Transportation and such other City departments or governmental authorities as may be necessary to acquire building permits and other required approvals for the Project.
Project Budget. Developer has furnished to DPD, and DPD has approved, a Project Budget showing total costs for the Project in an amount not less than Forty Six Million Eight Hundred One Thousand Two Hundred Eleven Dollars ($46,801,211). Developer hereby certifies to the City that (a) the City Funds, together with Lender Financing, Equity and Net NMTC Equity described in Section 4.02 hereof, shall be sufficient to complete the Project. Developer hereby certifies to the City that (a) it has Lender Financing, Equity and Net NMTC Equity in an amount sufficient to pay for all Project costs; and (b) the Project Budget is true, correct and complete in all material respects. Developer shall promptly deliver to DPD certified copies of any Change Orders with respect to the Project Budget for approval pursuant to Section 3.04 hereof.
Change Orders. Except as provided below in this Section 3.04, all Change Orders (and documentation substantiating the need and identifying the source of funding therefor) relating to changes to the Project must be submitted by Developer to DPD concurrently with the progress reports described in Section 3.07 hereof; provided, that any Change Order relating to any of the following must be submitted by Developer to DPD for DPD's prior written approval: (a) a reduction in the gross or net square footage of the Project by five percent (5%) or more (either individually or cumulatively); (b) a change in the use of Facility to a use other than as described in Recital D to this Agreement; (c) a delay in the completion of the Project by six (6) months or more; or (d) Change Orders resulting in an aggregate increase to the Project Budget for the Project of ten percent (10%) or more. Developer shall not authorize or permit the performance of any work relating to any Change Order or the furnishing of materials in connection therewith prior to the receipt by Developer of DPD's written approval (to the extent said City prior approval is required pursuant to the terms of this Agreement). The Construction Contract, and each contract between the General Contractor and any subcontractor, shall contain a provision to this effect. An approved Change Order shall not be deemed to imply any obligation on the part of the City to increase the amount of City Funds which the City has pledged pursuant to this Agreement or provide any other additional assistance to Developer. Notwithstanding anything to the contrary in this Section 3.04, Change Orders other than those set forth above do not require DPD's prior written approval as set forth in this Section 3.04. but DPD shall be notified in writing of all such Change Orders within 10 business days after the execution of such Change Order and Developer, in connection with such notice, shall identify to DPD the source of funding therefor.
DPD Approval. Any approval granted by DPD of the Scope Drawings, Plans and Specifications and the Change Orders is for the purposes of this Agreement only and does not affect or constitute any approval required by any other City department or pursuant to any City ordinance, code, regulation or any other governmental approval, nor does any approval by DPD or the City pursuant to this Agreement constitute approval of the quality, structural soundness or safety ofthe Property or the Project or compliance with Environmental Laws.
Other Approvals. Any DPD approval under this Agreement shall have no effect upon, nor shall it operate as a waiver of, Developer's obligations to comply with the provisions of
11
Section 5.03 (Other Governmental Approvals) hereof or Environmental Laws. Developer shall not commence construction ofthe Project until Developer has obtained all necessary permits and approvals (including but not limited to DPD's approval of the Scope Drawings and Plans and Specifications) and proof of the General Contractor's and each subcontractor's bonding as required hereunder.
Progress Reports and Survey Updates. Developer shall provide DPD with written quarterly written progress reports detailing the status ofthe Project, including a revised completion date, if necessary (with any change in completion date being considered a Change Order, requiring DPD's written approval pursuant to Section 3.04). Developer shall provide three (3) copies of an updated Survey to DPD upon the request of DPD or any lender providing Lender Financing, reflecting improvements made to the Property.
Inspecting Agent or Architect. An independent agent or architect (other than Developer's architect) approved by DPD shall be selected to act as the inspecting agent or architect, at Developer's expense, for the Project. The inspecting agent or architect shall perform periodic inspections with respect to the Project, providing certifications with respect thereto to DPD, prior to requests for disbursement for costs related to the Project hereunder; provided that, to the extent there is any disagreement between DPD's inspecting architect and the NMTC Lender's inspecting architect, DPD agrees to defer to NMTC Lender's inspecting architect. The inspecting agent or architect may be the same one being used in such role by the NMTC Lender or the Senior Lender providing Lender financing, provided that such agent or architect (a) is not also Developer's agent or architect and (b) acknowledges in writing to the City that the City may rely on the findings of such agent or architect.
Barricades. Prior to commencing any construction requiring barricades, Developer shall install a construction barricade of a type and appearance satisfactory to the City and constructed in compliance with all applicable federal, state or City laws, ordinances and regulations. DPD retains the right to approve the maintenance, appearance, color scheme, painting, nature, type, content and design of all barricades.
Signs and Public Relations. Developer shall erect a sign of size and style approved by the City in a conspicuous location on the Property during the Project, indicating that financing has been provided by the City. This sign may also name the other financing sources. The City reserves the right to include the name, photograph, artistic rendering of the Project and other pertinent information regarding Developer, the Property and the Project in the City's promotional literature and communications.
Utility Connections. Developer may connect all on-site water, sanitary, storm and sewer lines constructed on the Property to City utility lines existing on or near the perimeter ofthe Property, provided Developer first complies with all City requirements governing such connections, including the payment of customary fees and costs related thereto.
Permit Fees. In connection with the Project, Developer shall be obligated to pay only those building, permit, engineering, tap on and inspection fees that are assessed on a uniform basis throughout the City of Chicago and are of general applicability within the City of Chicago to other property and/or activities similar to those that occur during the Project.
12
SECTION 4. FINANCING
4.01 Total Project Cost and Sources of Funds. The cost of the Project is estimated to be $46,801,211, to be applied in the manner set forth in the Project Budget. Such costs shall be funded through a NMTC financing structure, including the NMTC Loan, in part, from the following sources:
Equity (subject to Sections 4.03(b) and 4.06) Senior Loan
Estimated City Funds (subject to Section 4.03) Net NMTC Equity State of Illinois Funding
$500,000
$12,682,280 $17,550,000 $ 6,500,000 $ 9,568,931
ESTIMATED TOTAL
Developer Funds. Equity, Net NMTC Equity and/or Lender Financing, including bridge financing for any of the foregoing, shall be used directly or indirectly through a NMTC financing structure to pay all Project costs, including but not limited to Redevelopment Project Costs and costs of TIF-Funded Improvements.
Citv Funds.
Uses of Citv Funds. City Funds may only be used to pay directly or reimburse Developer for costs of TIF-Funded Improvements that constitute Redevelopment Project Costs. Exhibit C sets forth, by line item, the TIF-Funded Improvements forthe Project, and the maximum amount of costs that may be paid by or reimbursed from City Funds for each line item therein (subject to Sections 4.03(b) and 4.05(d)), contingent upon receipt by the City of documentation satisfactory in form and substance to DPD evidencing such cost and its eligibility as a Redevelopment Project Cost.
Sources of Citv Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03 and Section 5 hereof, the City hereby agrees to provide up to $17,550,000 in City funds from Incremental Taxes (the "City Funds") to reimburse Developer for the costs of the TIF-Funded Improvements, provided, however, that the total amount of City Funds expended for TIF-Funded Improvements shall be an amount not to exceed the lesser of Seventeen Million Dollars Five Hundred Fifty Thousand ($17,550,000) or 37.5% of the actual total Project costs, and provided further, that the $17,550,000 to be derived from Incremental Taxes shall be available to pay costs related to TIF-Funded Improvements and allocated by the City for that purpose only so long as the amount of the Incremental Taxes deposited into the TIF Fund shall be sufficient to pay for such costs. In the event that such conditions are not fulfilled, the amount of Equity to be contributed by Developer pursuant to Section 4.01 hereof shall increase proportionately.
(c) Disbursement of Citv Funds. Subject to the terms and conditions of this Agreement, including but not limited to this Section 4.03, Section 4.08 and Section 5 hereof, the City shall disburse the City Funds upon the issuance by DPD of the Certificate. The City hereby
13
represents to the Developer that except for the Prior TIF Obligations the City has not made and will not make a pledge of Incremental Taxes to any entity, party or person that is senior or superior to the pledge of Incremental Taxes to Developer hereunder.
Treatment of Prior Expenditures and Subsequent Disbursements.
Prior Expenditures. Only those expenditures made by Developer with respect to the Project prior to the Closing Date, evidenced by documentation satisfactory to DPD and approved by DPD as satisfying costs covered in the Project Budget, shall be considered previously contributed Equity hereunder (the "Prior Expenditures"). DPD shall have the right, in its sole discretion, to disallow any such expenditure as a Prior Expenditure. Exhibit I hereto sets forth the prior expenditures approved by DPD [as of the date hereof] as Prior Expenditures. Prior Expenditures made for items other than TIF-Funded Improvements shall not be reimbursed to Developer, but shall reduce the amount of Equity required to be contributed by Developer pursuant to Section 4.01 hereof.
Allocation Among Line Items. Disbursements for expenditures related to TIF-Funded Improvements may be allocated to and charged against the appropriate line only, with transfers of costs and expenses from one line item to another, without the prior written consent of DPD, being prohibited; provided, however, that such transfers among line items, in an amount not to exceed $25,000 or $100,000 in the aggregate, may be made without the prior written consent of DPD.
Cost Overruns. If the aggregate cost ofthe TIF-Funded Improvements exceeds City Funds available pursuant to Section 4.03 hereof, or if the cost of completing the Project exceeds the Project Budget, Developer shall be solely responsible for such excess cost, and shall hold the City harmless from any and all costs and expenses of completing the TIF-Funded Improvements in excess of City Funds and of completing the Project.
Preconditions of Disbursement. Prior to the disbursement of City Funds hereunder, Developer shall submit documentation regarding the applicable expenditures to DPD, which shall be satisfactory to DPD in its sole discretion. Delivery by Developer to DPD of any request for disbursement of City Funds hereunder shall, in addition to the items therein expressly set forth, constitute a certification to the City, as ofthe date of such request for disbursement, that:
the total amount of the disbursement request represents the actual cost of the Acquisition or the actual amount payable to (or paid to) the General Contractor and/or subcontractors who have performed work on the Project, and/or their payees;
all amounts shown as previous payments on the current disbursement request have been paid to the parties entitled to such payment;
Developer has approved all work and materials for the current disbursement request, and such work and materials conform to the Plans and Specifications;
the representations and warranties contained in this Redevelopment Agreement are true and correct and Developer is in compliance with all covenants contained herein;
14
Developer has received no notice and has no knowledge of any liens or claim of lien either filed or threatened against the Property except for the Permitted Liens;
no Event of Default or condition or event which, with the giving of notice or passage of time or both, would constitute an Event of Default exists or has occurred; and
the Project is In Balance. The Project shall be deemed to be in balance ("In Balance") only if the total of the available Project funds equals or exceeds the aggregate of the amount necessary to pay all unpaid Project costs incurred or to be incurred in the completion of the Project. "Available Project Funds" as used herein shall mean: (i) the undisbursed City Funds; (ii) the undisbursed Lender Financing, if any (including any Lender Financing advanced into and available in a controlled account pledged to NMTC Lender); (iii) the undisbursed Equity (including any bridge financing for any ofthe foregoing); and (iv) any other amounts deposited by Developer pursuant to this Agreement. Developer hereby agrees that, if the Project is not In Balance, Developer shall, within 10 days after a written request by the City, deposit with the escrow agent or NMTC Lender (or an account controlled by NMTC Lender) or will make available (in a manner acceptable to the City), cash in an amount that will place the Project In Balance, which deposit shall first be exhausted before any further disbursement of the City Funds shall be made.
The City shall have the right, in its discretion, to require Developer to submit further documentation as the City may require in order to verify that the matters certified to above are true and correct, and any disbursement by the City shall be subject to the City's review and approval of such documentation and its satisfaction that such certifications are true and correct; provided, however, that nothing in this sentence shall be deemed to prevent the City from relying on such certifications by Developer. In addition, Developer shall have satisfied all other preconditions of disbursement of City Funds for each disbursement, including but not limited to requirements set forth in the Bond Ordinance, if any, TIF Bond Ordinance, if any, the Bonds, if any, the TIF Bonds, if any, the TIF Ordinances, this Agreement and/or the Escrow Agreement.
4.07 Conditional Grant. The City Funds being provided hereunder are being granted on a conditional basis, subject to the Developer's compliance with the provisions of this Agreement. If a Capital Event occurs, Developer agrees to pay and remit to the City all City Funds previously disbursed. There shall be no applicable cure period for Capital Events. The City Funds are subject to being reimbursed as provided in Sections 7.03 and 15.02 hereof.
SECTION 5. CONDITIONS PRECEDENT
The following conditions have been complied with to the City's satisfaction on or prior to the Closing Date:
5.01 Project Budget. Developer has submitted to DPD, and DPD has approved, a Project Budget in accordance with the provisions of Section 3.03 hereof.
15
Scope Drawings and Plans and Specifications. Developer has submitted to DPD, and DPD has approved, the Scope Drawings and Plans and Specifications accordance with the provisions of Section 3.02 hereof.
Other Governmental Approvals. Developer has secured all other necessary approvals and permits required by any state, federal, or local statute, ordinance or regulation and has submitted evidence thereof to DPD.
Financing. Developer has furnished proof reasonably acceptable to the City that Developer has Equity, Lender Financing, and Net NMTC Equity (including any bridge financing for any of the foregoing) in the amounts set forth in Section 4.01 hereof to complete the Project and satisfy its obligations under this Agreement. If a portion of such funds consists of Lender Financing, Developer has furnished proof as of the Closing Date that the proceeds thereof are available to be drawn upon by Developer as needed and are sufficient (along with the Equity and other sources set forth in Section 4.01) to complete the Project. Any liens against the Property in existence at the Closing Date have been subordinated to certain encumbrances of the City set forth herein pursuant to a Subordination Agreement, in a form acceptable to the City, executed on or prior to the Closing Date, which is to be recorded, at the expense of Developer, with the Office of the Recorder of Deeds of Cook County.
Acguisition and Title. On the Closing Date, Developer has furnished the City with a copy of the Title Policy for the Property, certified by the Title Company, showing Owner as the named insured. The Title Policy is dated as of the Closing Date and contains only those title exceptions listed as Permitted Liens on Exhibit G hereto and evidences the recording of this Agreement pursuant to the provisions of Section 8.18 hereof. The Title Policy also contains such endorsements as shall be required by Corporation Counsel, including but not limited to an owner's comprehensive endorsement and satisfactory endorsements regarding zoning (3.1 with parking), contiguity, location, access and survey. Developer has provided to DPD, on or prior to the Closing Date, documentation related to the purchase ofthe Property and certified copies of all easements and encumbrances of record with respect to the Property not addressed, to DPD's satisfaction, by the Title Policy and any endorsements thereto.
Evidence of Clean Title. Developer, at its own expense, has provided the City with searches as indicated in the chart below under Developer's name showing no liens against Developer, the Property or any fixtures now or hereafter affixed thereto, except for the Permitted Liens:
Jurisdiction Searches
Secretary of State UCC, Federal tax
Cook County Recorder UCC, Fixtures, Federal tax, State tax, Memoranda of judgments
U.S. District Court Pending suits and judgments
Clerk of Circuit Court, Cook County Pending suits and judgments
5.07 Surveys. Developer has furnished the City with three (3) copies ofthe Survey.
16
Insurance. Developer, at its own expense, has insured the Property in accordance with Section 12 hereof, and has delivered certificates required pursuant to Section 12 hereof evidencing the required coverages to DPD.
Opinion of Developer's Counsel. On the Closing Date, Developer has furnished the City with an opinion of counsel, substantially in the form attached hereto as Exhibit J, with such changes as required by or acceptable to Corporation Counsel. If Developer has engaged special counsel in connection with the Project, and such special counsel is unwilling or unable to give some ofthe opinions set forth in Exhibit J hereto, such opinions were obtained by Developer from its general corporate counsel.
Lease. Prior to the Closing Date, Developer must have provided the City with a copy of the Lease, and any other lease associated with the Project then in existence.
5.11 Evidence of Prior Expenditures. Developer has provided evidence satisfactory to DPD in its sole discretion of the Prior Expenditures in accordance with the provisions of Section 4.05(a) hereof.
Financial Statements. Developer has provided Financial Statements to DPD for its most recent fiscal year, and audited or unaudited interim financial statements.
Documentation; Employment Plan. The Developer has provided documentation to DPD, satisfactory in form and substance to DPD, with respect to current employment matters in connection with the construction or rehabilitation work on the Project, including the reports described in Section 8.07.
Environmental. Developer has provided DPD with copies ofthe Phase I ESA and Phase II ESA described in Section 11.01. Developer has provided the City with a letter from the environmental engineer(s) who completed such ESAs, authorizing the City to rely on such ESAs.
Corporate Documents; Economic Disclosure Statement. Each of Owner and Tenant has provided a copy of its Articles or Certificate of Incorporation containing the original certification of the Secretary of State of its state of incorporation; certificates of good standing from the Secretary of State of its state of incorporation and all other states in which Owner and Tenantare qualified to do business; a secretary's certificate in such form and substance as the Corporation Counsel may require; its by-laws; and such other corporate documentation as the City has requested.
Each of Owner and Tenant has provided to the City an EDS, dated as of the Closing Date, which is incorporated by reference, and Developer further will provide any other affidavits or certifications as may be required by federal, state or local law in the award of public contracts, all of which affidavits or certifications are incorporated by reference. Notwithstanding acceptance by the City of the EDS, failure of the EDS to include all information required under the Municipal Code renders this Agreement voidable at the option of the City. Developer and any other parties required by this Section 5.15 to complete an EDS must promptly update their EDS(s) on file with the City whenever any information or response provided in the EDS(s) is no longer complete and
17
accurate, including changes in ownership and changes in disclosures and information pertaining to ineligibility to do business with the City under Chapter 1-23 of the Municipal Code, as such is required under Sec. 2-154-020, and failure to promptly provide the updated EDS(s) to the City will constitute an event of default under this Agreement.
5.16 Litigation. Developer has provided to Corporation Counsel and DPD, a description of all pending or threatened litigation or administrative proceedings involving Developer, specifying, in each case, the amount of each claim, an estimate of probable liability, the amount of any reserves taken in connection therewith and whether (and to what extent) such potential liability is covered by insurance.
SECTION 6. AGREEMENTS WITH CONTRACTORS
6.01 Bid Reguirement for General Contractor and Subcontractors, (a) Except as set forth in Section 6.01(b) below, prior to entering into an agreement with a General Contractor or any subcontractor for construction of the Project, Developer shall solicit, or shall cause the General Contractor to solicit, bids from qualified contractors eligible to do business with, and having an office located in, the City of Chicago, and shall submit all bids received to DPD for its inspection and written approval, (i) For the TIF-Funded Improvements, Developer shall select the General Contractor (or shall cause the General Contractor to select the subcontractor) submitting the lowest responsible bid who can complete the Project in a timely manner. If Developer selects a General Contractor (or the General Contractor selects any subcontractor) submitting other than the lowest responsible bid for the TIF-Funded Improvements, the difference between the lowest responsible bid and the bid selected may not be paid out of City Funds, (ii) For Project work other than the TIF-Funded Improvements, if Developer selects a General Contractor (or the General Contractor selects any subcontractor) who has not submitted the lowest responsible bid, the difference between the lowest responsible bid and the higher bid selected shall be subtracted from the actual total Project costs for purposes of the calculation of the amount of City Funds to be contributed to the Project pursuant to Section 4.03(b) hereof. Developer shall submit copies of the Construction Contract to DPD in accordance with Section 6.02 below. Photocopies of all subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DPD within five (5) business days of the execution thereof. Developer shall ensure that the General Contractor shall not (and shall cause the General Contractor to ensure that the subcontractors shall not) begin work on the Project until the Plans and Specifications have been approved by DPD and all requisite permits have been obtained.
(b) If, prior to entering into an agreement with a General Contractor for construction of the Project, Developer does not solicit bids pursuant to Section 6.01(a) hereof, then the fee of the General Contractor proposed to be paid out of City Funds shall not exceed 7.5% of the total amount of the Construction Contract. Except as explicitly stated in this paragraph, all other provisions of Section 6.01(a) shall apply, including but not limited to the requirement that the General Contractor shall solicit competitive bids from all subcontractors.
6.02 Construction Contract. Prior to the execution thereof, Developer shall deliver to DPD a copy of the proposed Construction Contract with the General Contractor selected to handle the
18
Project in accordance with Section 6.01 above, for DPD's prior written approval, which shall be granted or denied within ten (10) business days after delivery thereof. Within ten (10) business days after execution of such contract by Developer, the General Contractor and any other parties thereto, Developer shall deliver to DPD and Corporation Counsel a certified copy of such contract together with any modifications, amendments or supplements thereto.
6.03 Performance and Payment Bonds. Prior to the commencement of any portion of the
Project which includes work on the public way, Developer shall require that the General
Contractor be bonded for its payment by sureties having an AA rating or better using a bond in
the form attached as Exhibit N hereto. The City shall be named as obligee or co-obligee on any
such bonds.
Employment Opportunity. Developer shall contractually obligate and cause the General Contractor and each subcontractor to agree to the provisions of Section 10 hereof.
Other Provisions. In addition to the requirements ofthis Section 6. the Construction Contract and each contract with any subcontractor shall contain provisions required pursuant to Section 3.04 (Change Orders), Section 8.09 (Prevailing Wage), Section 10.01(e) (Employment Opportunity), Section 10.02 (City Resident Employment Requirement), Section 10.03 (MBEAA/BE Requirements, as applicable), Section 11 (Environmental)(as applicable), Section 12 (Insurance) and Section 14.01 (Books and Records) hereof. Photocopies of all contracts or subcontracts entered or to be entered into in connection with the TIF-Funded Improvements shall be provided to DPD within five (5) business days of the execution thereof.
SECTION 7. COMPLETION OF CONSTRUCTION OR REHABILITATION
7.01 Certificate of Completion of Construction or Rehabilitation, (a) Upon completion of the construction of the Project in accordance with the terms of this Agreement and upon Developer's written request, DPD shall issue to Developer a Certificate in recordable form certifying that Developer has fulfilled its obligation to complete the Project in accordance with the terms of this Agreement. DPD shall respond to Developer's written request for a Certificate within forty-five (45) days by issuing either a Certificate or a written statement detailing the ways in which the Project does not conform to this Agreement or has not been satisfactorily completed, and the measures which must be taken by Developer in order to obtain the Certificate. Developer may resubmit a written request for a Certificate upon completion of such measures.
(b) Developer acknowledges and understands that the City will not issue a Certificate until (i) the City's Monitoring and Compliance unit has determined in writing that Developer is in complete compliance with all City requirements (MAA/BE, City residency and prevailing wage) as required in this Agreement; (ii) the Project, including without limitation the facade updates, the clock tower renovation, and all related improvements, has been completed; (iii) the City has received evidence that the Project has complied with the Chicago Sustainable Development Policy; (iv) the City has received evidence that Developer has complied with the environmental requirement of Section 11; (v) the Facility is open for operation and in the process of being marketed for lease to tenants; and (vi) Developer Parties have received a Certificate of Occupancy from the City or other evidence reasonably acceptable to DPD that the Developer Parties have complied with building permit requirements.
19
Effect of Issuance of Certificate; Continuing Obligations. The Certificate relates only to the construction of the Project, and upon its issuance, the City will certify that the terms of the Agreement specifically related to Developer's obligation to complete such activities have been satisfied. After the issuance of a Certificate, however, all executory terms and conditions of this Agreement and all representations and covenants contained herein will continue to remain in full force and effect throughout the Term ofthe Agreement as to the parties described in the following paragraph, and the issuance of the Certificate shall not be construed as a waiver by the City of any of its rights and remedies pursuant to such executory terms.
Those covenants specifically described at Sections 8.02, 8.06, 8.17, and 8.19 as covenants that run with the land are the only covenants in this Agreement intended to be binding upon any transferee of the Property (including an assignee as described in the following sentence) throughout the Term of the Agreement notwithstanding the issuance of a Certificate; provided, that upon the issuance of a Certificate, the covenants set forth in Section 8.02 shall be deemed to have been fulfilled. The other executory terms of this Agreement that remain after the issuance of a Certificate shall be binding only upon Developer or a permitted assignee of Developer who, pursuant to Section 18.15 ofthis Agreement, has contracted to take an assignment of Developer's rights under this Agreement and assume Developer's liabilities hereunder.
Failure to Complete. If Developer fails to complete the Project in accordance with the terms of this Agreement, then the City has, but shall not be limited to, any of the following rights and remedies:
the right to terminate this Agreement and cease all disbursement of City Funds not yet disbursed pursuant hereto;
the right (but not the obligation) to complete those TIF-Funded Improvements that are public improvements and to pay for the costs of TIF-Funded Improvements (including interest costs) out of City Funds or other City monies. In the event that the aggregate cost of completing the TIF-Funded Improvements exceeds the amount of City Funds available pursuant to Section 4.01, Developer shall reimburse the City for all reasonable costs and expenses incurred by the City in completing such TIF-Funded Improvements in excess ofthe available City Funds; and
the right to seek reimbursement of the City Funds from Developer, provided that the City is entitled to rely on an opinion of counsel that such reimbursement will not jeopardize the tax-exempt status of the TIF Bonds, if any.
Notice of Expiration of Term of Agreement. Upon the expiration of the Term of the Agreement, DPD shall provide Developer, at Developer's written reguest, with a written notice in recordable form stating that the Term of the Agreement has expired.
SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES OF DEVELOPER.
8.01 General. Developer represents, warrants and covenants, as of the date of this Agreement and as of the date of each disbursement of City Funds hereunder, that:
20
Owner is an Illinois not-for-profit corporation duly organized, validly existing, qualified to do business in Illinois and licensed to do business in any other state where, due to the nature of its activities or properties such qualification or license is required; Tenant is an Illinois not-for-profit corporation duly organized, validly existing, qualified to do business in Illinois, and licensed to do business in any other state where, due to the nature of its activities or properties, such qualification or license is required; and
Developer has the right, power and authority to enter into, execute, deliver and perform this Agreement;
the execution, delivery and performance by Developer of this Agreement has been duly authorized by all necessary corporate action, and does not and will not violate its respective Articles of Incorporation or bylaws as amended and supplemented, any applicable provision of law, or constitute a breach of, default under or require any consent under any agreement, instrument or document to which Developer is now a party or by which Developer is now or may become bound;
unless otherwise permitted or not prohibited pursuant to or under the terms of this Agreement, Developer shall acquire and shall maintain during the Term good, indefeasible and merchantable fee simple title to the Property (and all improvements thereon) free and clear of all liens (except for the Permitted Liens, Lender Financing as disclosed in the Project Budget and non-governmental charges that Developer is contesting in good faith pursuant to Section 8.15 hereof);
Developer is now and for the Term of the Agreement shall remain solvent and able to pay its debts as they mature;
there are no actions or proceedings by or before any court, governmental commission, board, bureau or any other administrative agency pending, threatened or affecting Developer which would impair its ability to perform under this Agreement;
Developer has and shall maintain all government permits, certificates and consents (including, without limitation, appropriate environmental approvals) necessary to conduct its business and to construct, complete and operate the Project;
Developer is not in default with respect to any indenture, loan agreement, mortgage, deed, note or any other agreement or instrument related to the borrowing of money to which Developer is a party or by which Developer is bound;
(i) the Financial Statements are, and when hereafter required to be submitted will be,
complete, correct in all material respects and accurately present the assets, liabilities, results of
operations and financial condition of Developer, and there has been no material adverse change
in the assets, liabilities, results of operations or financial condition of Developer since the date of
Developer's most recent Financial Statements;
(j) prior to the issuance of a Certificate, Developer shall not do any of the following without the prior written consent of DPD: (1) be a party to any merger, liquidation or consolidation; (2)
21
sell, transfer, convey, lease or otherwise dispose of all or substantially all of its assets or any portion of the Property (including but not limited to any fixtures or equipment now or hereafter attached thereto) except in the ordinary course of business and except for the Lease; (3) enter into any transaction outside the ordinary course of Developer's business; (4) assume, guarantee, endorse, or otherwise become liable in connection with the obligations of any other person or entity other than in connection with the Lender Financing (including but not limited to guarantees and indemnities provided in connection with the NMTC Loan, the Senior Loan and other financing needed to complete the Project); or (5) enter into any transaction that would cause a material and detrimental change to Developer's financial condition, provided that the City expressly consents to the Lender Financing;
(k) Developer has not incurred, and, prior to the issuance of a Certificate, shall not, without the prior written consent of the Commissioner of DPD, allow the existence of any liens against the Property (or improvements thereon) other than the Permitted Liens; or incur any indebtedness, secured or to be secured by the Property (or improvements thereon) or any fixtures now or hereafter attached thereto, except NMTC Loan, Lender Financing, and other financing disclosed in the Project Budget;
(I) Developer has not made or caused to be made, directly or indirectly, any payment, gratuity or offer of employment in connection with the Agreement or any contract paid from the City treasury or pursuant to City ordinance, for services to any City agency ("City Contract") as an inducement for the City to enter into the Agreement or any City Contract with Developer in violation of Chapter 2-156-120 of the Municipal Code;
(m) neither Developer nor any affiliate of Developer is listed on any of the following lists maintained by the Office of Foreign Assets Control of the U.S. Department of the Treasury, the Bureau of Industry and Security of the U.S. Department of Commerce or their successors, or on any other list of persons or entities with which the City may not do business under any applicable law, rule, regulation, order or judgment: the Specially Designated Nationals List, the Denied Persons List, the Unverified List, the Entity List and the Debarred List. For purposes of this subparagraph (m) only, the term "affiliate," when used to indicate a relationship with a specified person or entity, means a person or entity that, directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such specified person or entity, and a person or entity shall be deemed to be controlled by another person or entity, if controlled in any manner whatsoever that results in control in fact by that other person or entity (or that other person or entity and any persons or entities with whom that other person or entity is acting jointly or in concert), whether directly or indirectly and whether through share ownership, a trust, a contract or otherwise.
(n) Developer understands that (i) the City Funds are limited obligations of the City, payable solely from moneys on deposit in the TIF Fund; (ii) the City Funds do not constitute indebtedness of the City within the meaning of any constitutional or statutory provision or limitation; (iii) Developer will have no right to compel the exercise of any taxing power of the City for payment of the City Funds; and (iv) the City Funds do not and will not represent or constitute a general obligation or a pledge of the faith and credit of the City, the State of Illinois or any political subdivision thereof;
22
(o) Developer has sufficient knowledge and experience in financial and business matters, including municipal projects and revenues of the kind represented by the City Funds, and has been supplied with access to information to be able to evaluate the risks associated with the receipt of City Funds;
(p) Developer understands that there is no assurance as to the amount or timing of receipt of City Funds, and that the amounts of City Funds actually received by such party are likely to be substantially less than the maximum amounts set forth in Section 4.03(b);
(q) Developer understands it may not sell, assign, pledge or otherwise transfer its interest in this Agreement or City Funds in whole or in part except in accordance with the terms of Section 18.14 of this Agreement, and, to the fullest extent permitted by law, agrees to indemnify the City for any losses, claims, damages or expenses relating to or based upon any sale, assignment, pledge or transfer of City Funds in violation of this Agreement; and
(r) Developer acknowledges that with respect to City Funds, the City has no obligation to provide any continuing disclosure to the Electronic Municipal Market Access System maintained by the Municipal Securities Rulemaking Board, to any holder of a note relating to City Funds or any other person under Rule 15c2-12 of the Commission promulgated under the Securities Exchange Act of 1934 or otherwise, and shall have no liability with respect thereto.
Covenant to Redevelop. Upon DPD's approval of the Project Budget, the Scope Drawings and Plans and Specifications as provided in Sections 3.02 and 3.03 hereof; and Developer's receipt of all required building permits and governmental approvals, Developer shall redevelop the Property in accordance with this Agreement and all Exhibits attached hereto, the TIF Ordinances, the Scope Drawings, Plans and Specifications, Project Budget and all amendments thereto, and all federal, state and local laws, ordinances, rules, regulations, executive orders and codes applicable to the Project, the Property and/or Developer. The covenants set forth in this Section shall run with the land and be binding upon any transferee, but shall be deemed satisfied upon issuance by the City of a Certificate with respect thereto.
Redevelopment Plan. Developer represents that the Project is and shall be in compliance with all of the terms of the Redevelopment Plan, which is hereby incorporated by reference into this Agreement.
Use of Citv Funds. City Funds disbursed to Developer shall be used by Developer solely to pay for (or to reimburse Developer for its payment for) the TIF-Funded Improvements as provided in this Agreement.
Other Bonds. Developer shall, at the request of the City, agree to any reasonable amendments to this Agreement that are necessary or desirable in order for the City to issue (in its sole discretion) any bonds in connection with the Redevelopment Area, the proceeds of which may be used to reimburse the City for expenditures made in connection with, or provide a source of funds for the payment for, the TIF-Funded Improvements (the "Bonds"; provided, however, that any such amendments shall not have a material adverse effect on Developer, any Lender providing Lender Financing, or the Project. Developer shall, at Developer's expense, cooperate and provide reasonable assistance in connection with the marketing of any such Bonds, including
23
but not limited to providing written descriptions of the Project, making representations, providing information regarding its financial condition and assisting the City in preparing an offering statement with respect thereto.
Job Creation and Retention; Covenant to Remain in the City. Developer will make best efforts to retain not less than thirty full-time equivalent, permanent jobs at the Project following issuance of the Certificate, provided that Developer's failure to reach the afore-stated goals will not constitute an Event of Default under this Agreement. Developer hereby covenants and agrees to maintain its operations within the City of Chicago at the Property through the Term of the Agreement.
Employment Opportunitv; Progress Reports. Developer covenants and agrees to abide by, and contractually obligate and use reasonable efforts to cause the General Contractor and each subcontractor to abide by the terms set forth in Section 10 hereof. Developer shall deliver to the City written progress reports detailing compliance with the requirements of Sections 8.09. 10.02 and 10.03 of this Agreement. Such reports shall be delivered to the City when the Project is 33%, 66%, and 100% completed (based on the amount of expenditures incurred in relation to the Project Budget). If any such reports indicate a shortfall in compliance, Developer shall also deliver a plan to DPD which shall outline, to DPD's satisfaction, the manner in which Developer shall correct any shortfall.
Employment Profile. Developer shall submit, and contractually obligate and cause the General Contractor or any subcontractor to submit, to DPD, from time to time, statements of its employment profile upon DPD's request.
Prevailing Wage. Developer covenants and agrees to pay, and to contractually obligate and cause the General Contractor and each subcontractor to pay, the prevailing wage rate as ascertained by the Illinois Department of Labor (the "Department"), to all Project employees. All such contracts shall list the specified rates to be paid to all laborers, workers and mechanics for each craft or type of worker or mechanic employed pursuant to such contract. If the Department revises such prevailing wage rates, the revised rates shall apply to all such contracts. Upon the City's request, Developer shall provide the City with copies of all such contracts entered into by Developer or the General Contractor to evidence compliance with this Section 8.09.
Arms-Length Transactions. Unless DPD has given its prior written consent with respect thereto, no Affiliate of Developer may receive any portion of City Funds, directly or indirectly, in payment for work done, services provided or materials supplied in connection with any TIF-Funded Improvement. Developer shall provide information with respect to any entity to receive City Funds directly or indirectly (whether through payment to the Affiliate by Developer and reimbursement to Developer for such costs using City Funds, or otherwise), upon DPD's request, prior to any such disbursement.
Conflict of Interest. Pursuant to Section 5/11-74.4-4(n) of the Act, Developer represents, warrants and covenants that, to the best of its knowledge, no member, official, or employee of the City, or of any commission or committee exercising authority over the Project, the Redevelopment Area or the Redevelopment Plan, or any consultant hired by the City or
24
Developer with respect thereto, owns or controls, has owned or controlled or will own or control any interest, and no such person shall represent any person, as agent or otherwise, who owns or controls, has owned or controlled, or will own or control any interest, direct or indirect, in Developer's business, the Property or any other property in the Redevelopment Area.
Disclosure of Interest. Developer's counsel has no direct or indirect financial ownership interest in Developer, the Property or any other aspect of the Project.
Financial Statements. Developer shall obtain and provide to DPD Financial Statements for Developer's most recent three fiscal years and each year thereafter for the Term ofthe Agreement. In addition, Developer shall submit unaudited financial statements as soon as reasonably practical following the close of each fiscal year and for such other periods as DPD may request.
Insurance. Developer, at its own expense, shall comply with all provisions of Section 12 hereof.
Non-Governmental Charges, (a) Payment of Non-Governmental Charges. Except for the Permitted Liens, Developer agrees to pay or cause to be paid when due any Non-Governmental Charge assessed or imposed upon the Project, the Property or any fixtures that are or may become attached thereto, which creates, may create, or appears to create a lien upon all or any portion of the Property or Project; provided however, that if such Non-Governmental Charge may be paid in installments, Developer may pay the same together with any accrued interest thereon in installments as they become due and before any fine, penalty, interest, or cost may be added thereto for nonpayment. Developer shall furnish to DPD, within thirty (30) days of DPD's request, official receipts from the appropriate entity, or other proof satisfactory to DPD, evidencing payment of the Non-Governmental Charge in question.
(b) Right to Contest. Developer has the right, before any delinquency occurs:
to contest or object in good faith to the amount or validity of any Non-Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted, in such manner as shall stay the collection of the contested Non-Governmental Charge, prevent the imposition of a lien or remove such lien, or prevent the sale or forfeiture of the Property (so long as no such contest or objection shall be deemed or construed to relieve, modify or extend Developer's covenants to pay any such Non-Governmental Charge at the time and in the manner provided in this Section 8.15); or
at DPD's sole option, to furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property or any portion thereof or any fixtures that are or may be attached thereto, during the pendency of such contest, adequate to pay fully any such contested Non-Governmental Charge and all interest and penalties upon the adverse determination of such contest.
25
Developer's Liabilities. Developer shall not enter into any transaction that would materially and adversely affect its ability to perform its obligations hereunder or to repay any material liabilities or perform any material obligations of Developer to any other person or entity. Developer shall immediately notify DPD of any and all events or actions which may materially affect Developer's ability to carry on its business operations or perform its obligations under this Agreement or any other documents and agreements.
Compliance with Laws. To the best of Developer's knowledge, after diligent inquiry, the Property and the Project are and shall be in compliance with all applicable federal, state and local laws, statutes, ordinances, rules, regulations, executive orders and codes pertaining to or affecting the Project and the Property. Upon the City's request, Developer shall provide evidence satisfactory to the City of such compliance.
Recording and Filing. Developer shall cause this Agreement, certain exhibits (as specified by Corporation Counsel), all amendments and supplements hereto to be recorded and filed against the Property on the date hereof in the conveyance and real property records of the county in which the Project is located. This Agreement shall be recorded prior to any mortgage made in connection with Lender Financing. Developer shall pay all fees and charges incurred in connection with any such recording. Upon recording, Developer shall immediately transmit to the City an executed original of this Agreement showing the date and recording number of record.
8.19 Real Estate Provisions, (a) Governmental Charges.
Payment of Governmental Charges. Developer agrees to pay or cause to be paid when due all Governmental Charges (as defined below) which are assessed or imposed upon Developer, the Property or the Project, or become due and payable, and which create, may create, a lien upon Developer or all or any portion of the Property or the Project. "Governmental Charge" shall mean all federal, State, county, the City, or other governmental (or any instrumentality, division, agency, body, or department thereof) taxes, levies, assessments, charges, liens, claims or encumbrances relating to Developer, the Property or the Project including but not limited to real estate taxes.
Right to Contest. Developer has the right before any delinquency occurs to contest or object in good faith to the amount or validity of any Governmental Charge by appropriate legal proceedings properly and diligently instituted and prosecuted in such manner as shall stay the collection of the contested Governmental Charge and prevent the imposition of a lien or the sale or forfeiture of the Property. No such contest or objection shall be deemed or construed in any way as relieving, modifying or extending Developer's covenants to pay any such Governmental Charge at the time and in the manner provided in this Agreement unless Developer has given prior written notice to DPD of Developer's intent to contest or object to a Governmental Charge and, unless, at DPD's sole option,
26
Developer shall demonstrate to DPD's satisfaction that legal proceedings instituted by Developer contesting' or objecting to a Governmental Charge shall conclusively operate to prevent or remove a lien against, or the sale or forfeiture of, all or any part of the Property to satisfy such Governmental Charge prior to final determination of such proceedings; and/or
Developer shall furnish a good and sufficient bond or other security satisfactory to DPD in such form and amounts as DPD shall require, or a good and sufficient undertaking as may be required or permitted by law to accomplish a stay of any such sale or forfeiture of the Property during the pendency of such contest, adequate to pay fully any such contested Governmental Charge and all interest and penalties upon the adverse determination of such contest.
(b) Developer's Failure To Pay Or Discharge Lien. If Developer fails to pay any Governmental Charge or to obtain discharge of the same, Developer shall advise DPD thereof in writing, at which time DPD may, but shall not be obligated to, and without waiving or releasing any obligation or liability of Developer under this Agreement, in DPD's sole discretion, make such payment, or any part thereof, or obtain such discharge and take any other action with respect thereto which DPD deems advisable. All sums so paid by DPD, if any, and any expenses, if any, including reasonable attorneys' fees, court costs, expenses and other charges relating thereto, shall be promptly disbursed to DPD by Developer. Notwithstanding anything contained herein to the contrary, this paragraph shall not be construed to obligate the City to pay any such Governmental Charge. Additionally, if Developer fails to pay any Governmental Charge, the City, in its sole discretion, may require Developer to submit to the City audited Financial Statements at Developer's own expense.
8.20 [Intentionally omittedl
Annual Report(s). Beginning with the issuance of the Certificate and continuing throughout the Term of the Agreement, Developer shall submit to DPD. the Annual Compliance Report within 60 days after the end of the calendar year to which the Annual Compliance Report relates. Failure to submit the Annual Compliance Report within 60 days after calendar year end shall result in the assessment of liquidated damages equal to $10,000 for each such failure, provided that such payment shall be required no more often than once per calendar year.
Inspector General. It is the duty of Developer and the duty of any bidder, proposer, contractor, subcontractor, and every applicant for certification of eligibility for a City contract or program, and all of Developer's officers, directors, agents, partners, and employees and any such bidder, proposer, contractor, subcontractor or such applicant, to cooperate with the Inspector General in any investigation or hearing undertaken pursuant to Chapter 2-56 of the Municipal Code. Developer represents that it understands and will abide by all provisions of Chapter 2-56 of the Municipal Code and that it will inform subcontractors of this provision and require their compliance.
8.23 Sustainable Development. Within one year following the issuance of the
Certificate, Developer shall provide written evidence acceptable to the City that the Project
complies with the Chicago Sustainable Development Policy (as in effect at such time of the
27
completion ofthe Project). Failure to so comply with the Chicago Sustainable Development Policy shall be considered an Event of Default and result in a repayment of $250,000 of City Funds to the City in accordance with Section 15.02.
8.24. FOIA and Local Records Act Compliance.
FOIA. The Developer acknowledges that the City is subject to the Illinois Freedom of Information Act, 5 ILCS 140/1 et. seq., as amended ("FOIA"). The FOIA requires the City to produce records (very broadly defined in FOIA) in response to a FOIA request in a very short period of time, unless the records requested are exempt under the FOIA. If the Developer receives a request from the City to produce records within the scope of FOIA, then the Developer covenants to comply with such request within 48 hours of the date of such request. Failure by the Developer to timely comply with such request shall be an Event of Default.
Exempt Information. Documents that the Developer submits to the City under Section 8.21, (Annual Compliance Report) or otherwise during the Term of the Agreement that contain trade secrets and commercial or financial information may be exempt if disclosure would result in competitive harm. However, for documents submitted by the Developer to be treated as a trade secret or information that would cause competitive harm, FOIA requires that Developer mark any such documents as "proprietary, privileged or confidential." If the Developer marks a document as "proprietary, privileged and confidential", then DPD will evaluate whether such document may be withheld under the FOIA. DPD, in its discretion, will determine whether a document will be exempted from disclosure, and that determination is subject to review by the Illinois Attorney General's Office and/or the courts.
Local Records Act. The Developer acknowledges that the City is subject to the Local Records Act, 50 ILCS 205/1 et Seq., as amended (the "Local Records Act"). The Local Records Act provides that public records may only be disposed of as provided in the Local Records Act. If requested by the City, the Developer covenants to use its best efforts consistently applied to assist the City in its compliance with the Local Records Act.
8.25 Lease Representations. Warranties and Covenants. With respect to the Lease, each of Owner and Tenant represents, warrants and covenants as follows:
as of the date hereof, the Lease is valid and binding as to the Owner and Tenant, is iri full force and effect, and is either unmodified or modified only by approved Material Amendments and/or amendments that do not constitute Material Amendments;
as of the date hereof, each of the Owner and the Tenant has performed all of its current obligations under the Lease;
Throughout the Term of the Agreement, each of the Owner and Tenant: (i) shall deliver to DPD a copy of written notice of any change in circumstances of which such party has knowledge that makes the representations and warranties in this Section 8.25 inaccurate; and (ii) shall comply with its obligations under the Lease; and
28
(d) Throughout the Term of the Agreement, neither the Owner nor Tenant shall (i) execute or consent to a Material Amendment or (ii) sell, sublease, release, assign or otherwise transfer its interest in the Lease, except as contemplated by the Lease and as consistent with the Operating Covenant without the prior written consent of DPD, provided that no consent shall be needed for a termination of the Lease following a Permitted Transfer of the Property from Owner to Tenant after the end of the NMTC Compliance Period;
The covenants set forth in this Section 8.25 shall run with the land and the leasehold interest and be binding upon any transferee for the Term of the Agreement.
8.26 Landmark Designation.
Prior to issuance of the Certificate, the Developer shall deliver to DPD a Preliminary Summary of Information, in a form acceptable to DPD's Historic Preservation Division, for the purpose of the landmark designation of the Facility.
The Developer covenants and agrees that it will consent to the designation of the Facility as a City of Chicago Landmark after the issuance of the Certificate.
8.27 Survival of Covenants. All warranties, representations, covenants and agreements
of Developer contained in this Section 8 and elsewhere in this Agreement shall be true, accurate
and complete at the time of Developer's execution of this Agreement, and shall survive the
execution, delivery and acceptance hereof by the parties hereto and (except as provided in
Section 7 hereof upon the issuance of a Certificate) shall be in effect throughout the Term of the
Agreement.
SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF CITY
General Covenants. The City represents that it has the authority as a home rule unit of local government to execute and deliver this Agreement and to perform its obligations hereunder.
Survival of Covenants. All warranties, representations, and covenants of the City contained in this Section 9 or elsewhere in this Agreement shall be true, accurate, and complete at the time of the City's execution of this Agreement, and shall survive the execution, delivery and acceptance hereof by the parties hereto and be in effect throughout the Term of the Agreement.
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS
10.01 Employment Opportunity. Developer, on behalf of itself and its successors and assigns, hereby agrees, and shall contractually obligate its or their various contractors, subcontractors or any Affiliate of Developer operating on the Property (collectively, with Developer, the "Employers" and individually an "Employer") to agree, that for the Term of this Agreement with respect to Developer and during the period of any other party's provision of services in connection with the construction of the Project or occupation of the Property:
29
No Employer shall discriminate against any employee or applicant for employment based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income as defined in the City of Chicago Human Rights Ordinance, Chapter 2-160, Section 2-160-010 et seq., Municipal Code, except as otherwise provided by said ordinance and as amended from time to time (the "Human Rights Ordinance"). Each Employer shall take affirmative action to ensure that applicants are hired and employed without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income and are treated in a non-discriminatory manner with regard to all job-related matters, including without limitation: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Each Employer agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this nondiscrimination clause. In addition, the Employers, in all solicitations or advertisements for employees, shall state that all qualified applicants shall receive consideration for employment without discrimination based upon race, religion, color, sex, national origin or ancestry, age, handicap or disability, sexual orientation, military discharge status, marital status, parental status or source of income.
To the greatest extent feasible, each Employer is required to present opportunities for training and employment of low- and moderate-income residents of the City and preferably of the Redevelopment Area; and to provide that contracts for work in connection with the construction of the Project be awarded to business concerns that are located in, or owned in substantial part by persons residing in, the City and preferably in the Redevelopment Area.
Each Employer shall comply with all federal, state and local equal employment and affirmative action statutes, rules and regulations, including but not limited to the City's Human Rights Ordinance and the Illinois Human Rights Act, 775 ILCS 5/1-101 et seq. (1993), and any subsequent amendments and regulations promulgated thereto.
Each Employer, in order to demonstrate compliance with the terms of this Section, shall cooperate with and promptly and accurately respond to inquiries by the City, which has the responsibility to observe and report compliance with equal employment opportunity regulations of federal, state and municipal agencies.
Each Employer shall include the foregoing provisions of subparagraphs (a) through (d) in every contract entered into in connection with the Project, and shall require inclusion of these provisions in every subcontract entered into by any subcontractors, and every agreement with any Affiliate operating on the Property, so that each such provision shall be binding upon each contractor, subcontractor or Affiliate, as the case may be.
Failure to comply with the employment obligations described in this Section 10.01 shall be a basis for the City to pursue remedies under the provisions of Section 15.02 hereof.
10.02 Citv Resident Construction Worker Employment Requirement. Developer agrees for itself and its successors and assigns, and shall contractually obligate its General Contractor and shall cause the General Contractor to contractually obligate its subcontractors, as applicable,
30
to agree, that during the construction of the Project they shall comply with the minimum percentage of total worker hours performed by actual residents of the City as specified in Section 2-92-330 of the Municipal Code (at least 50 percent of the total worker hours worked by persons on the site of the Project shall be performed by actual residents of the City); provided, however, that in addition to complying with this percentage, Developer, its General Contractor and each subcontractor shall be required to make good faith efforts to utilize qualified residents of the City in both unskilled and skilled labor positions.
Developer may request a reduction or waiver of this minimum percentage level of Chicagoans as provided for in Section 2-92-330 of the Municipal Code in accordance with standards and procedures developed by the Chief Procurement Officer of the City.
"Actual residents of the City" shall mean persons domiciled within the City. The domicile is an individual's one and only true, fixed and permanent home and principal establishment.
Developer, the General Contractor and each subcontractor shall provide for the maintenance of adequate employee residency records to show that actual Chicago residents are employed on the Project. Each Employer shall maintain copies of personal documents supportive of every Chicago employee's actual record of residence.
Weekly certified payroll reports (U.S. Department of Labor Form WH-347 or equivalent) shall be submitted to the Commissioner of DPD in triplicate, which shall identify clearly the actual residence of every employee on each submitted certified payroll. The first time that an employee's name appears on a payroll, the date that the Employer hired the employee should be written in after the employee's name.
Developer, the General Contractor and each subcontractor shall provide full access to their employment records to the Chief Procurement Officer, the Commissioner of DPD, the Superintendent of the Chicago Police Department, the Inspector General or any duly authorized representative of any of them. Developer, the General Contractor and each subcontractor shall maintain all relevant personnel data and records for a period of at least three (3) years after final acceptance of the work constituting the Project.
At the direction of DPD, affidavits and other supporting documentation will be required of Developer, the General Contractor and each subcontractor to verify or clarify an employee's actual address when doubt or lack of clarity has arisen.
Good faith efforts on the part of Developer, the General Contractor and each subcontractor to provide utilization of actual Chicago residents (but not sufficient for the granting of a waiver request as provided for in the standards and procedures developed by the Chief Procurement Officer) shall not suffice to replace the actual, verified achievement of the requirements of this Section concerning the worker hours performed by actual Chicago residents.
When work at the Project is completed, in the event that the City has determined that Developer has failed to ensure the fulfillment of the requirement of this Section concerning the worker hours performed by actual Chicago residents or failed to report in the manner as indicated above, the City will thereby be damaged in the failure to provide the benefit of demonstrable
31
employment to Chicagoans to the degree stipulated in this Section. Therefore, in such a case of non-compliance, it is agreed that 1/20 of 1 percent (0.0005) ofthe aggregate hard construction costs set forth in the Project budget (the product of .0005 x such aggregate hard construction costs) (as the same shall be evidenced by approved contract value for the actual contracts) shall be surrendered by Developer to the City in payment for each percentage of shortfall toward the stipulated residency requirement. Failure to report the residency of employees entirely and correctly shall result in the surrender of the entire liquidated damages as if no Chicago residents were employed in either of the categories. The willful falsification of statements and the certification of payroll data may subject Developer, the General Contractor and/or the subcontractors to prosecution. Any retainage to cover contract performance that may become due to Developer pursuant to Section 2-92-250 of the Municipal Code may be withheld by the City pending the Chief Procurement Officer's determination as to whether Developer must surrender damages as provided in this paragraph.
Nothing herein provided shall be construed to be a limitation upon the ANotice of Requirements for Affirmative Action to Ensure Equal Employment Opportunity, Executive Order 11246 " and Standard Federal Equal Employment Opportunity, Executive Order 11246," or other affirmative action required for equal opportunity under the provisions of this Agreement or related documents.
Developer shall cause or require the provisions ofthis Section 10.02 to be included in the Construction Contract and all subcontracts related to the Construction Contract.
10.03. MBE/WBE Commitment. Developer agrees for itself and its successors and assigns, and, if necessary to meet the requirements set forth herein, shall contractually obligate the General Contractor to agree that during the Project:
Consistent with the findings which support, as applicable, (i) the Minority-Owned and Women-Owned Business Enterprise Procurement Program, Section 2-92-420 et seq., Municipal Code (the "Procurement Program"), and (ii) the Minority- and Women-Owned Business Enterprise Construction Program, Section 2-92-650 et seq., Municipal Code (the "Construction Program," and collectively with the Procurement Program, the "MBEAA/BE Program"), and in reliance upon the provisions of the MBEAA/BE Program to the extent contained in, and as qualified by, the provisions of this Section 10.03, during the course of the Project, at least the following percentages of the MBEAA/BE Budget (as set forth in Exhibit H-2 hereto) shall be expended for contract participation by MBEs and by WBEs:
At least 26 percent by MBEs.
At least six percent by WBEs.
For purposes of this Section 10.03 only, Developer (and any party to whom a contract is let by Developer in connection with the Project) shall be deemed a "contractor" and this Agreement (and any contract let by Developer in connection with the Project) shall be deemed a Acontract" or a "construction contract" as such terms are defined in Sections 2-92-420 and 2-92-670, Municipal Code, as applicable.
32
(c) Consistent with Sections 2-92-440 and 2-92-720, Municipal Code, Developer's
MBEAA/BE commitment may be achieved in part by Developer's status as an MBE or WBE (but
only to the extent of any actual work performed on the Project by Developer) or by a joint venture
with one or more MBEs or WBEs (but only to the extent of the lesser of (i) the MBE or WBE
participation in such joint venture or (ii) the amount of any actual work performed on the Project
by the MBE or WBE), by Developer utilizing a MBE or a WBE as the General Contractor (but only
to the extent of any actual work performed on the Project by the General Contractor), by
subcontracting or causing the General Contractor to subcontract a portion of the Project to one
or more MBEs or WBEs, or by the purchase of materials or services used in the Project from one
or more MBEs or WBEs, or by any combination of the foregoing. Those entities which constitute
both a MBE and a WBE shall not be credited more than once with regard to Developer's
MBEAA/BE commitment as described in this Section 10.03. In accordance with Section 2-92-730,
Municipal Code, Developer shall not substitute any MBE or WBE General Contractor or
subcontractor without the prior written approval of DPD.
Developer shall deliver quarterly reports to the City's monitoring staff during the Project describing its efforts to achieve compliance with this MBE/WBE commitment. Such reports shall include, inter alia, the name and business address of each MBE and WBE solicited by Developer or the General Contractor to work on the Project, and the responses received from such solicitation, the name and business address of each MBE or WBE actually involved in the Project, a description of the work performed or products or services supplied, the date and amount of such work, product or service, and such other information as may assist the City's monitoring staff in determining Developer's compliance with this MBE/WBE commitment. Developer shall maintain records of all relevant data with respect to the utilization of MBEs and WBEs in connection with the Project for at least five years after completion of the Project, and the City's monitoring staff shall have access to all such records maintained by Developer, on five Business Days' notice, to allow the City to review Developer's compliance with its commitment to MBE/WBE participation and the status of any MBE or WBE performing any portion ofthe Project.
Upon the disqualification of any MBE or WBE General Contractor or subcontractor, if such status was misrepresented by the disqualified party, Developer shall be obligated to discharge or cause to be discharged the disqualified General Contractor or subcontractor, and, if possible, identify and engage a qualified MBE or WBE as a replacement. For purposes of this subsection (e), the disqualification procedures are further described in Sections 2-92-540 and 2-92-730, Municipal Code, as applicable.
Any reduction or waiver of Developer's MBEAA/BE commitment as described in this Section 10.03 shall be undertaken in accordance with Sections 2-92-450 and 2-92-730, Municipal Code, as applicable.
Prior to the commencement of the Project, Developer shall be required to meet with the City's monitoring staff with regard to Developer's compliance with its obligations under this Section 10.03. The General Contractor and all major subcontractors shall be required to attend this pre-construction meeting. During said meeting, Developer shall demonstrate to the City's monitoring staff its plan to achieve its obligations under this Section 10.03, the sufficiency of which shall be approved by the City's monitoring staff. During the Project, Developer shall submit the documentation required by this Section 10.03 to the City's monitoring staff, including the following:
33
(i) subcontractor's activity report; (ii) contractor's certification concerning labor standards and prevailing wage requirements; (iii) contractor letter of understanding; (iv) monthly utilization report; (v) authorization for payroll agent; (vi) certified payroll; (vii) evidence that MBEAA/BE contractor associations have been informed of the Project via written notice and hearings; and (viii) evidence of compliance with job creation/job retention requirements. Failure to submit such documentation on a timely basis, or a determination by the City's monitoring staff, upon analysis of the documentation, that Developer is not complying with its obligations under this Section 10.03, shall, upon the delivery of written notice to Developer, be deemed an Event of Default. Upon the occurrence of any such Event of Default, in addition to any other remedies provided in this Agreement, the City may: (1) issue a written demand to Developer to halt the Project, (2) withhold any further payment of any City Funds to Developer or the General Contractor, or (3) seek any other remedies against Developer available at law or in equity.
SECTION 11. ENVIRONMENTAL MATTERS
11.01. Environmental Studies. The Developer provided the City with a Phase I ESA, dated September 28, 2022, and a Phase II ESA, dated November 8, 2022.
The Phase I ESA identified Recognized Environmental Conditions ("RECs") and the Developer performed the Phase II ESA to ascertain the presence of any environmental impacts that may be associated with the RECs. The Phase II ESA identified contamination above residential remediation objectives as determined by Title 35 of the Illinois Administrative Code ("IAC") Part 742. The Developer must obtain a new Phase I ESA, dated within 180 days prior to the Closing Date, and obtain a Phase II ESA to address any new RECs identified in the Phase I. The Developer shall enroll the Property in the lEPA's SRP in order to obtain a No Further Remediation Letter for the enrolled Property. The Developer acknowledges and agrees that it may not commence construction on the Property or commence any other activity on the Property that could interfere with the. prompt start and completion ofthe RAP until the IEPA issues a RAP Approval Letter for the Property.
The Developer covenants and agrees that upon, receipt of the RAP Approval Letter for the Property, the Developer shall promptly complete all Remediation Work necessary to obtain an NFR Letter for the Property, using all reasonable means. The City shall have the right to review in advance and approve all Environmental Documents and any changes thereto. Within 14 days (unless extended by the City), the Developer shall submit an estimate of the cost to perform the Remediation Work to the City. The Developer shall bear sole responsibility for all costs of the Remediation Work necessary to obtain the NFR Letter, and the costs of any other investigative and cleanup costs associated with the Property. The Developer shall promptly transmit to the City copies of all Environmental Documents prepared or received with respect to the Remediation Work, including, without limitation, any written communications delivered to or received from the IEPA or other regulatory agencies. The Developer acknowledges and agrees that the City will not permit occupancy until the IEPA has issued, the City has approved, and the Developer has recorded with the Cook County Recorder of Deeds a Final Comprehensive NFR Letter for the Property enrolled in the SRP. The City's approval of the NFR Letter as issued by the IEPA shall not be unreasonably withheld. If the Developer fails to obtain the Final NFR Letter within six (6) months of the submission of the Remedial Action Completion Report to the IEPA, unless the City agrees to
34
extend such time period, then the City shall have the right to issue a notice of default of this Agreement pursuant to Section 14 of this Agreement.
The Developer must abide by the terms and conditions of the NFR Letter and must inform any subsequent owner and tenants of the Property to abide by the terms of the NFR Letter.
Developer will conduct a Hazardous Building Material Survey of the Site prior to conducting any work that could constitute renovation, demolition, or abatement under the Environmental Laws ('abatement work") on or within an existing physical structure located on the Property. The Hazardous Building Material Survey shall include (but is not limited to) asbestos and lead-based paint surveys and testing and visually inspecting and, as necessary, testing the Property to determine the presence and location of polychlorinated-biphenyl (PCB)-containing equipment and materials (such as lighting ballasts, switchgears, transformers, and hydraulic fluids), mercury-containing equipment and materials (mercury lamps, thermostats, switches, thermometers, regulators, and gauges), radioactive material-containing equipment and/or waste, medical wastes (such as biological or infectious wastes, hazardous chemicals, and/or wastes), refrigerants such as chlorofluorocarbons (CFCs), large appliances or equipment, mold, or any other materials that may require special handling or disposal during or after abatement work. A report documenting the Hazardous Building Material Survey results and an abatement plan shall be submitted to the City for review prior to beginning any abatement work.
The Developer will incorporate the results of the Hazardous Building Material Survey into its Project documents and perform abatement work as part of the Project in accordance with all Environmental Laws. A report documenting the completion of the abatement work shall be submitted to and approved by the City prior to approval of the Property for occupancy. If abatement work activities are not deemed sufficient by the City, the Developer shall continue work at their own expense until approved.
Release and Indemnification. The Developer, on behalf of itself and its officers, directors, employees, successors, assigns and anyone claiming by, through or under them (collectively, the "Developer Parties"), hereby releases, relinquishes and forever discharges the City, its officers, agents and employees (collectively, the "Indemnified Parties"), from and against any and all Losses which the Developer ever had, now have, or hereafter may have, whether grounded in tort or contract or otherwise, in any and all courts or other forums, of whatever kind or nature, whether known or unknown, foreseen or unforeseen, now existing or occurring after the Closing Date, based upon, arising out of or in any way connected with, directly or indirectly (i) any environmental contamination, pollution or hazards associated with the Property or any improvements, facilities or operations located or formerly located thereon, including, without limitation, any release, emission, discharge, generation, transportation, treatment, storage or disposal of Hazardous Substances, or threatened release, emission or discharge of Hazardous Substances or Other Regulated Materials; (ii) the structural, physical or environmental condition of the Property, including, without limitation, the presence or suspected presence of Hazardous Substances in, on, under or about the Property or the migration of Hazardous Substances or Other Regulated Materials from or to other Property; (iii) any violation of, compliance with, enforcement of or liability under any Environmental Laws, including, without limitation, any governmental or regulatory body response costs, natural resource damages or Losses arising under CERCLA, 42 U.S.C. § 6901 et seq; and (iv) any investigation, cleanup, monitoring,
35
remedial, removal or restoration work required by any federal, state or local governmental agency or political subdivision or other third party in connection or associated with the Property or any improvements, facilities or operations located or formerly located thereon (collectively, "Released Claims"); provided, however, the foregoing release shall not apply to the extent such Losses are proximately caused by the gross negligence or willful misconduct of the City following the Closing Date. Furthermore, the Developer shall indemnify, defend (through an attorney reasonably acceptable to the City) and hold the Indemnified Parties harmless from and against any and all Losses which may be made or asserted by any third parties (including, without limitation, any of the Developer Parties) arising out of or in any way connected with, directly or indirectly, any of the Released Claims, except as provided in the immediately preceding sentence for the City's gross negligence or willful misconduct following the Closing Date. The Developer Parties waive their rights of contribution and subrogation against the Indemnified Parties.
Release Runs with the Property. The covenant of release in Section 11.02 above shall run with the Property and shall be binding upon all successors and assigns ofthe Developer with respect to the Property, including, without limitation, each and every person, firm, corporation, limited liability company, trust or other entity owning, leasing, occupying, using or possessing any portion of the Property under or through the Developer. The Developer acknowledges and agrees that the foregoing covenant of release constitutes a material inducement to the City to enter into this RDA, and that, but for such release, the City would not have agreed to provide financial assistance to the Developer. It is expressly agreed and understood by and between the Developer and the City that, should any future obligation of the Developer or Developer Parties arise or be alleged to arise in connection with any environmental, soil or other condition of the Property, the Developer and any of the Developer Parties shall not assert that those obligations must be satisfied in whole or in part by the City, because Section 11.02 contains a full, complete and final release of all such claims, except as provided in such section for the City's gross negligence or willful misconduct following the Closing Date.
Indemnity. Without limiting any other provisions hereof, Developer agrees to indemnify, defend and hold the City harmless from and against any and all losses, liabilities, damages, injuries, costs, expenses or claims of any kind whatsoever including, without limitation, any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any Environmental Laws incurred, suffered by or asserted against the City as a direct or indirect result of any of the following, regardless of whether or not caused by, or within the control of Developer: (i) the presence of any Hazardous Substances or Other Regulated Materials on or under, or the escape, seepage, leakage, spillage, emission, discharge or release of any Hazardous Substances or Other Regulated Materials from (A) all or any portion of the Property or (B) any other real property in which Developer, or any person directly or indirectly controlling, controlled by or under common control with Developer, holds any estate or interest whatsoever (including, without limitation, any property owned by a land trust in which the beneficial interest is owned, in whole or in part, by Developer), or (ii) any liens against the Property permitted or imposed by any Environmental Laws, or any actual or asserted liability or obligation of the City or Developer or any of its Affiliates under any Environmental Laws relating to the Property.
11.06 Survival. This Section 11 shall survive the Closing Date or any termination of this
Agreement (regardless ofthe reason for such termination).
36
SECTION 12. INSURANCE
Developer must provide and maintain, at Developer's own expense, or cause to be provided and maintained during the term ofthis Agreement, the insurance coverage and requirements specified below, insuring all operations related to the Agreement.
Prior to execution and delivery of this Agreement.
Workers Compensation and Employers Liability
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $100,000 each accident, illness or disease.
Commercial General Liability (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $1.000.000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations independent contractors, separation of insureds, defense, and contractual liability (with no limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
All Risk Property
All Risk Property Insurance at replacement value ofthe property to protect against loss of, damage to, or destruction ofthe building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.
Construction. Prior to the construction of any portion of the Project, Developer will cause its architects, contractors, subcontractors, project managers and other parties constructing the Project to procure and maintain the following kinds and amounts of insurance:
Workers Compensation and Employers Liability
Workers Compensation Insurance, as prescribed by applicable law covering all employees who are to provide work under this Agreement and Employers Liability coverage with limits of not less than $ 500.000 each accident, illness or disease.
Commercial General Liability (Primary and Umbrella)
Commercial General Liability Insurance or equivalent with limits of not less than $2,000,000 per occurrence for bodily injury, personal injury, and property damage liability. Coverages must include the following: All premises and operations, products/completed operations (for a minimum of two (2) years following project completion), explosion, collapse, underground, separation of insureds, defense, and contractual liability (with no
37
limitation endorsement). The City of Chicago is to be named as an additional insured on a primary, non-contributory basis for any liability arising directly or indirectly from the work.
Automobile Liability (Primary and Umbrella)
When any motor vehicles (owned, non-owned and hired) are used in connection with work to be performed, the Automobile Liability Insurance with limits of not less than $2,000,000 per occurrence for bodily injury and property damage. The City of Chicago is to be named as an additional insured on a primary, non-contributory basis.
Railroad Protective Liability
When any work is to be done adjacent to or on railroad or transit property, Developer must provide cause to be provided with respect to the operations that Contractors perform, Railroad Protective Liability Insurance in the name of railroad or transit entity. The policy must have limits of not less than $2,000,000 per occurrence and $6,000,000 in the aggregate for losses arising out of injuries to or death of all persons, and for damage to or destruction of property, including the loss of use thereof.
All Risk /Builders Risk
When Developer undertakes any construction, including improvements, betterments, and/or repairs, Developer must provide or cause to be provided All Risk Builders Risk Insurance at replacement cost for materials, supplies, equipment, machinery and fixtures that are or will be part ofthe project. The City of Chicago is to be named as an additional insured and loss payee/mortgagee if applicable.
Professional Liability
When any architects, engineers, construction managers or other professional consultants perform work in connection with this Agreement, Professional Liability Insurance covering acts, errors, or omissions must be maintained with limits of not less than $ 1.000,000. Coverage must include contractual liability. When policies are renewed or replaced, the policy retroactive date must coincide with, or precede, start of work on the Contract. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years.
Valuable Papers
When any plans, designs, drawings, specifications and documents are produced or used under this Agreement, Valuable Papers Insurance must be maintained in an amount to insure against any loss whatsoever, and must have limits sufficient to pay for the recreation and reconstruction of such records.
Contractors Pollution Liability
38
When any remediation work is performed which may cause a pollution exposure, Developer must cause remediation contractor to provide Contractor Pollution Liability covering bodily injury, property damage and other losses caused by pollution conditions that arise from the contract scope of work with limits of not less than $1,000,000 per occurrence. Coverage must include completed operations, contractual liability, defense, excavation, environmental cleanup, remediation and disposal. When policies are renewed or replaced, the policy retroactive date must coincide with or precede, start of work on the Agreement. A claims-made policy which is not renewed or replaced must have an extended reporting period of two (2) years. The City of Chicago is to be named as an additional insured.
(c) Post Construction:
(i) All Risk Property Insurance at replacement value of the property to protect against loss of, damage to, or destruction of the building/facility. The City is to be named as an additional insured and loss payee/mortgagee if applicable.
(d) Other Requirements:
Developer must furnish the City of Chicago, Department of Planning and Development, City Hall, Room 1000, 121 North LaSalle Street 60602, original Certificates of Insurance, or such similar evidence, to be in force on the date of this Agreement, and Renewal Certificates of Insurance, or such similar evidence, if the coverages have an expiration or renewal date occurring during the term of this Agreement. Developer must submit evidence of insurance on the City of Chicago Insurance Certificate Form (copy attached) or equivalent prior to closing. The receipt of any certificate does not constitute agreement by the City that the insurance requirements in the Agreement have been fully met or that the insurance policies indicated on the certificate are in compliance with all Agreement requirements. The failure of the City to obtain certificates or other insurance evidence from Developer is not a waiver by the City of any requirements for Developer to obtain and maintain the specified coverages. Developer shall advise all insurers of the Agreement provisions regarding insurance. Non-conforming insurance does not relieve Developer of the obligation to provide insurance as specified herein. Nonfulfillment of the insurance conditions may constitute a violation ofthe Agreement, and the City retains the right to stop work and/or terminate agreement until proper evidence of insurance is provided.
The insurance must provide for 60 days prior written notice to be given to the City in the event coverage is substantially changed, canceled, or non-renewed.
Any deductibles or self-insured retentions on referenced insurance coverages must be borne by Developer and Contractors.
Developer hereby waives and agrees to require their insurers to waive their rights of subrogation against the City of Chicago, its employees, elected officials, agents, or representatives.
39
The coverages and limits furnished by Developer in no way limit Developer's liabilities and responsibilities specified within the Agreement or by law.
Any insurance or self-insurance programs maintained by the City of Chicago do not contribute with insurance provided by Developer under the Agreement.
The required insurance to be carried is not limited by any limitations expressed in the indemnification language in this Agreement or any limitation placed on the indemnity in this Agreement given as a matter of law.
If Developer is a joint venture or limited liability company, the insurance policies must name the joint venture or limited liability company as a named insured.
Developer must require Contractor and subcontractors to provide the insurance required herein, or Developer may provide the coverages for Contractor and subcontractors. All Contractors and subcontractors are subject to the same insurance requirements of Developer unless otherwise specified in this Agreement.
If Developer, any Contractor or subcontractor desires additional coverages, the party desiring the additional coverages is responsible for the acquisition and cost.
The City of Chicago Risk Management Department maintains the right to modify, delete, alter or change these requirements.
SECTION 13. INDEMNIFICATION
13.01 General Indemnity. Developer agrees to indemnify, pay, defend and hold the City, and its elected and appointed officials, employees, agents and affiliates (individually an "Indemnitee," and collectively the "Indemnitees") harmless from and against, any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, claims, costs, expenses and disbursements of any kind or nature whatsoever (and including without limitation, the reasonable fees and disbursements of counsel for such Indemnitees in connection with any investigative, administrative or judicial proceeding commenced or threatened, whether or not such Indemnitees shall be designated a party thereto), that may be imposed on, suffered, incurred by or asserted against the Indemnitees in any manner relating or arising out of:
Developer's failure to comply with any of the terms, covenants and conditions contained within this Agreement or
Developer's or any contractor's failure to pay General Contractors, subcontractors or materialmen in connection with the TIF-Funded Improvements or any other Project improvement; or
the existence of any material misrepresentation or omission in this Agreement, any official statement, limited offering memorandum or private placement memorandum or the Redevelopment Plan or any other document related to this Agreement that is the result of information supplied or omitted by Developer or any Affiliate Developer or any
40
agents, employees, contractors or persons acting under the control or at the request of Developer or any Affiliate of Developer; or
(iv) Developer's failure to cure any misrepresentation in this Agreement or any other agreement relating hereto;
provided, however, that Developer shall have no obligation to an Indemnitee arising from the wanton or willful misconduct of that Indemnitee. To the extent that the preceding sentence may be unenforceable because it is violative of any law or public policy, Developer shall contribute the maximum portion that it is permitted to pay and satisfy under the applicable law, to the payment and satisfaction of all indemnified liabilities incurred by the Indemnitees or any of them. The provisions of the undertakings and indemnification set out in this Section 13.01 shall survive the termination of this Agreement.
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT
14.01 Books and Records. Developer shall keep and maintain separate, complete,
accurate and detailed books and records necessary to reflect and fully disclose the total actual
cost of the Project and the disposition of all funds from whatever source allocated thereto, and to
monitor the Project. All such books, records and other documents, including but not limited to
Developer's loan statements, if any, General Contractors' and contractors' sworn statements,
general contracts, subcontracts, purchase orders, waivers of lien, paid receipts and invoices, shall
be available at Developer's offices for inspection, copying, audit and examination by an authorized
representative of the City, at Developer's expense. Developer shall incorporate this right to
inspect, copy, audit and examine all books and records into all contracts entered into by Developer
with respect to the Project.
14.02 Inspection Rights. Upon three (3) business days' notice, any authorized
representative ofthe City has access to all portions ofthe Project and the Property during normal
business hours for the Term of the Agreement.
SECTION 15. DEFAULT AND REMEDIES
15.01 Events of Default. The occurrence of any one or more of the following events, subject to the provisions of Section 15.03, shall constitute an "Event of Default" by Developer hereunder:
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under this Agreement or any related agreement;
the failure of Developer to perform, keep or observe any of the covenants, conditions, promises, agreements or obligations of Developer under any other agreement with any person or entity if such failure may have a material adverse effect on Developer's business, property, assets, operations or condition, financial or otherwise;
41
the making or furnishing by Developer to the City of any representation, warranty, certificate, schedule, report or other communication within or in connection with this Agreement or any related agreement which is untrue or misleading in any material respect;
except as otherwise permitted hereunder, the creation (whether voluntary or involuntary) of, or any attempt to create, any lien or other encumbrance upon the Property, including any fixtures now or hereafter attached thereto, other than the Permitted Liens, or the making or any attempt to make any levy, seizure or attachment thereof;
the commencement of any proceedings in bankruptcy by or against Developer or for the liquidation or reorganization of Developer, or alleging that Developer is insolvent or unable to pay its debts as they mature, or for the readjustment or arrangement of Developer's debts, whether under the United States Bankruptcy Code or under any other state or federal law, now or hereafter existing for the relief of debtors, or the commencement of any analogous statutory or non-statutory proceedings involving Developer; provided, however, that if such commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such proceedings are not dismissed within sixty (60) days after the commencement of such proceedings;
the appointment of a receiver or trustee for Developer, for any substantial part of Developer's assets or the institution of any proceedings for the dissolution, or the full or partial liquidation, or the merger or consolidation, of Developer; provided, however, that if such appointment or commencement of proceedings is involuntary, such action shall not constitute an Event of Default unless such appointment is not revoked or such proceedings are not dismissed within sixty (60) days after the commencement thereof;
the entry of any judgment or order against Developer which remains unsatisfied or undischarged and in effect for sixty (60) days after such entry without a stay of enforcement or execution;
the occurrence of an event of default under the Lender Financing, which default is not cured within any applicable cure period, and with respect to which the applicable lender delivers written notice of its intent to foreclose its mortgage, unless such Lender gives written notice to the City that such lender (or its successors, assigns or designees) shall, upon taking possession of the Property, accept the obligations and liabilities of "Developer" under this Agreement as set forth in Section 16 below;
(i) the dissolution of Developer or the death of any natural person who owns a material
interest in Developer;
(j) the institution in any court of a criminal proceeding (other than a misdemeanor) against Developer or any natural person who owns a material interest in Developer, which is not dismissed within thirty (30) days, or the indictment of Developer or any natural person who owns a material interest in Developer, for any crime (other than a misdemeanor);
(k) prior to the issuance of the Certificate, the sale or transfer of a majority of the ownership interests of Developer without the prior written consent of the City;
42
(I) prior to the expiration of the Term of the Agreement, the occurrence of a Capital Event:
(m) The failure of Developer, or the failure by any party that is a Controlling Person (defined in Section 1-23-010 of the Municipal Code) with respect to Developer, to maintain eligibility to do business with the City in violation of Section 1-23-030 of the Municipal Code; such failure shall render this Agreement voidable or subject to termination, at the option of the Chief Procurement Officer;
(n) the assignment or other direct or indirect transfer by Owner or Tenant of the Lease without the prior written approval of the City, an Event of Default (as defined in the Lease) that is not cured within the cure period, if any, granted under the Lease, or the execution of a Material Amendment without the prior written approval of the City under Section 8.24; or
(o) the failure to obtain an NFR Letter as described in Section 11.
For purposes of Sections 15.01 (i) and 15.01(i) hereof, a person with a material interest in Developer shall be one owning in excess often (10%) of Developer's membership interests.
Remedies. Upon the occurrence of an Event of Default other than a Capital Event, the City may terminate this Agreement and any other agreements to which the City and Developer are or shall be parties, suspend disbursement of City Funds, place a lien on the Project in the amount of City Funds paid, and/or seek reimbursement of any City Funds paid. The City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to damages, injunctive relief or the specific performance of the agreements contained herein. Upon the occurrence of an Event of Default under Section 8.06, Developer shall be obligated to repay to the City all previously disbursed City Funds.
Upon the occurrence of an Event of Default because of failure to comply with Section 8.23. Sustainable Development, the City's sole remedy shall be the right to seek reimbursement of $250,000 in City Funds from Developer. Notwithstanding the foregoing, if the City Funds paid upon Certificate issuance were reduced by $250,000 due to anticipated failure to achieve LEED Certification as described in Section 4.03(b). then the City shall not have the right to seek reimbursement of an additional $250,000.
Upon the occurrence of a Capital Event, Developer shall pay and remit to the City an amount equal to the City Funds previously disbursed. In addition, the City may, in any court of competent jurisdiction by any action or proceeding at law or in equity, pursue and secure any available remedy, including but not limited to damages, injunctive relief or the specific performance of the agreements contained herein
Curative Period. In the event Developer shall fail to perform a monetary covenant which Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless Developer has failed to perform such monetary covenant within ten (10) days of its receipt of a written notice from the City specifying that it has failed to perform such monetary covenant.
43
In the event Developer shall fail to perform a non-monetary covenant which Developer is required to perform under this Agreement, notwithstanding any other provision of this Agreement to the contrary, an Event of Default shall not be deemed to have occurred unless Developer has failed to cure such default within thirty (30) days of its receipt of a written notice from the City specifying the nature of the default; provided, however, with respect to those non-monetary defaults which are not capable of being cured within such thirty (30) day period, Developer shall not be deemed to have committed an Event of Default under this Agreement if it has commenced to cure the alleged default within such thirty (30) day period and thereafter diligently and continuously prosecutes the cure of such default until the same has been cured; and provided, further, that there shall be no cure period under this Section 15.03 with respect to the occurrence of a Capital Event.
Notwithstanding anything to the contrary contained herein, in the event that an Event of Default occurs under this Agreement, and if, as a result thereof, the City intends to exercise any right or remedy available to it that could result in the termination of this Agreement or the cancellation, suspension, or reduction of any payment due from the City under this Agreement, the City shall send notice of such intended exercise to each of the lenders providing the Lender Financing, and each of the lenders providing the Lender Financing shall have the right (but not the obligation) to cure such an Event of Default under the following conditions:
if the Event of Default is a monetary default, any party entitled to cure such default may cure it within 30 days after the later of: (i) the expiration of the cure period, if any, granted to the Developer with respect to such monetary default; or (ii) receipt by the lenders of such notice from the City; and
if the Event of Default is of a non-monetary nature, any party entitled to cure such default shall have the right to cure it within 30 days after the later of: (i) the expiration of the cure period, if any, granted to the Developer with respect to such non-monetary default; or (ii) receipt of such notice from the City; provided, however, that if such non-monetary default is not reasonably capable of being cured by the lenders within such 30-day period, such period shall be extended for such reasonable period of time as may be necessary to cure such default, provided that the party seeking such cure must continue diligently to pursue such cure and, if possession of the Project is necessary to effect such cure, the party seeking such cure must have instituted appropriate legal proceedings to obtain possession to the extent such party has the right to do so
44
SECTION 16. MORTGAGING OF THE PROJECT
All mortgages or deeds of trust in place as of the date hereof with respect to the Property or any portion thereof are listed on Exhibit G hereto (including but not limited to mortgages made prior to or on the date hereof in connection with Lender Financing, including, but not limited to the NMTC Loan and the Senior Loan) and are referred to herein as the "Existing Mortgages." Any mortgage or deed of trust that Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof is referred to herein as a ANew Mortgage." Any New Mortgage that Developer may hereafter elect to execute and record or permit to be recorded against the Property or any portion thereof with the prior written consent of the City and any Existing Mortgage is referred to herein as a "Permitted Mortgage." It is hereby agreed by and between the City and Developer as follows:
(a) In the event that a mortgagee or any other party shall succeed to Developer's
interest in the Property or any portion thereof pursuant to the exercise of remedies under a New
Mortgage (other than a Permitted Mortgage), whether by foreclosure or deed in lieu of foreclosure,
and in conjunction therewith accepts an assignment of Developer's interest hereunder in
accordance with Section 18.15 hereof, the City may, but shall not be obligated to, attorn to and
recognize such party as the successor in interest to Developer for all purposes under this
Agreement and, unless so recognized by the City as the successor in interest, such party shall
be entitled to no rights or benefits under this Agreement, but such party shall be bound by those
provisions of this Agreement that are covenants expressly running with the land.
(b) In the event that any mortgagee or designee thereof or foreclosure purchaser shall
succeed to Developer's interest in the Property or any portion thereof or otherwise succeed to
Developer's interest in the collateral provided for such loan pursuant to the exercise of rights and
remedies under an Existing Mortgage or a Permitted Mortgage, whether by foreclosure or deed
in lieu of foreclosure, and in conjunction therewith accepts an assignment of Developer's interest
hereunder in accordance with Section 18.15 hereof, the City hereby agrees to attorn to and
recognize such party as the successor in interest to Developer for all purposes under this
Agreement so long as such party accepts all of the obligations and liabilities of "Developer";
provided, however, that, notwithstanding any other provision of this Agreement to the contrary, it
is understood and agreed that if such party accepts an assignment of Developer's interest under
this Agreement, such party has no liability under this Agreement for any Event of Default of
Developer which accrued prior to the time such party succeeded to the interest of Developer
under this Agreement, in which case Developer shall be solely responsible. However, if such
mortgagee under a Permitted Mortgage or an Existing Mortgage or designee thereof or
foreclosure purchaser does not expressly accept an assignment of Developer's interest
hereunder, such party shall be entitled to no rights and benefits under this Agreement, and such
party shall be bound only by those provisions of this Agreement, if any, which are covenants
expressly running with the land.
(c) Prior to the issuance by the City to Developer of a Certificate pursuant to Section
7 hereof, no New Mortgage shall be executed with respect to the Property or any portion thereof
without the prior written consent of the Commissioner of DPD.
45
SECTION 17. NOTICE
Unless otherwise specified, any notice, demand or request required hereunder shall be given in writing at the addresses set forth below, by any of the following means: (a) personal service; (b) telecopy or facsimile; (c) overnight courier, or (d) registered or certified mail, return receipt requested.
If to the City: City of Chicago Department of Planning and Development 121 North LaSalle Street, Room 1000 Chicago, Illinois 60602 Attention: Commissioner If to Developer: mHUB Support Corporation 965 W. Chicago Ave Chicago, Illinois 60642 Attention: Manas Mehandru And mHUB 965 W. Chicago Ave Chicago, Illinois 60642 Attention: Manas Mehandru
With Copies To: City of Chicago Department of Law 121 North LaSalle Street, Room 600 Chicago, Illinois 60602 Attention: Finance and Economic Development Division With Copies To: Applegate & Thorne-Thomse, P.C. 425 S. Financial Place, Suite 1900 Chicago, Illinois 60605 Attention: Eric Mittereder Email: emittereder@att-law.com
If to NMTC Lender:
If to Senior Lender:
46
Such addresses may be changed by notice to the other parties given in the same manner provided above. Any notice, demand, or request sent pursuant to either clause (a) or (b) hereof shall be deemed received upon such personal service or upon dispatch. Any notice, demand or request sent pursuant to clause (c) shall be deemed received on the day immediately following deposit with the overnight courier and any notices, demands or requests sent pursuant to subsection (d) shall be deemed received two (2) business days following deposit in the mail.
SECTION 18. MISCELLANEOUS
18.01 Amendment. This Agreement and the Exhibits attached hereto may not be
amended or modified without the prior written consent ofthe parties hereto; provided, however,
that the City, in its sole discretion, may amend, modify or supplement the Redevelopment Plan
without the consent of any party hereto. It is agreed that no material amendment or change to
this Agreement shall be made or be effective unless ratified or authorized by an ordinance duly
adopted by the City Council. The term "material" for the purpose of this Section 18.01 shall be
defined as any deviation from the terms of the Agreement which operates to cancel or otherwise
reduce any developmental, construction or job-creating obligations of Developer (including those
set forth in Sections 10.02 and 10.03 hereof) by more than five percent (5%) or materially changes
the Project site or character of the Project or any activities undertaken by Developer affecting the
Project site, the Project, or both, or increases any time agreed for performance by Developer by
more than ninety (90) days.
18.02 Entire Agreement. This Agreement (including each Exhibit attached hereto, which
is hereby incorporated herein by reference) constitutes the entire Agreement between the parties
hereto and it supersedes all prior agreements, negotiations and discussions between the parties
relative to the subject matter hereof.
Limitation of Liability. No member, official or employee of the City shall be personally liable to Developer or any successor in interest in the event of any default or breach by the City or for any amount which may become due to Developer from the City or any successor in interest or on any obligation under the terms of this Agreement.
Further Assurances. Developer agrees to take such actions, including the execution and delivery of such documents, instruments, petitions and certifications as may become necessary or appropriate to carry out the terms, provisions and intent of this Agreement.
Waiver. Waiver by the City or Developer with respect to any breach of this Agreement shall not be considered or treated as a waiver of the rights of the respective party with respect to any other default or with respect to any particular default, except to the extent specifically waived by the City or Developer in writing. No delay or omission on the part of a party in exercising any right shall operate as a waiver of such right or any other right unless pursuant to the specific terms hereof. A waiver by a party of a provision ofthis Agreement shall not prejudice or constitute a waiver of such party's right otherwise to demand strict compliance with that provision or any other provision of this Agreement. No prior waiver by a party, nor any course of
47
dealing between the parties hereto, shall constitute a waiver of any such parties' rights or of any obligations of any other party hereto as to any future transactions.
Remedies Cumulative. The remedies of a party hereunder are cumulative and the exercise of any one or more ofthe remedies provided for herein shall not be construed as a waiver of any other remedies of such party unless specifically so provided herein.
Disclaimer. Nothing contained in this Agreement nor any act of the City shall be deemed or construed by any of the parties, or by any third person, to create or imply any relationship of third-party beneficiary, principal or agent, limited or general partnership or joint venture, or to create or imply any association or relationship involving the City.
Counterparts. This Agreement may be executed in several counterparts, each of which shall be deemed an original and all of which shall constitute one and the same agreement.
Severability. If any provision in this Agreement, or any paragraph, sentence, clause, phrase, word or the application thereof, in any circumstance, is held invalid, this Agreement shall be construed as if such invalid part were never included herein and the remainder of this Agreement shall be and remain valid and enforceable to the fullest extent permitted by law.
Conflict. In the event of a conflict between any provisions of this Agreement and the provisions of the TIF Ordinances and/or the Bond Ordinance, if any, such ordinance(s) shall prevail and control.
18.11 Governing Law. This Agreement shall be governed by and construed in
accordance with the internal laws of the State of Illinois, without regard to its conflicts of law
principles.
Form of Documents. All documents required by this Agreement to be submitted, delivered or furnished to the City shall be in form and content satisfactory to the City.
Approval. Wherever this Agreement provides for the approval or consent of the City, DPD or the Commissioner, or any matter is to be to the City's, DPD's or the Commissioner's satisfaction, unless specifically stated to the contrary, such approval, consent or satisfaction shall be made, given or determined by the City, DPD or the Commissioner in writing and in the reasonable discretion thereof. The Commissioner or other person designated by the Mayor of the City shall act for the City or DPD in making all approvals, consents and determinations of satisfaction, granting the Certificate or otherwise administering this Agreement for the City.
Assignment. Developer may not sell, assign or otherwise transfer its interest in this Agreement in whole or in part without the written consent of the City. The City hereby consents to the execution and delivery of a Collateral Assignment in favor of the Bridge Lender, NMTC Lender or the Senior Lender. Any successor in interest to Developer under this Agreement shall certify in writing to the City its agreement to abide by all remaining executory terms of this Agreement, including but not limited to Sections 8.19 Real Estate Provisions and 8.26 (Survival of Covenants) hereof, for the Term of the Agreement. Developer consents to the City's sale, transfer, assignment or other disposal of this Agreement at any time in whole or in part.
48
Binding Effect. This Agreement shall be binding upon Developer, the City and their respective successors and permitted assigns (as provided herein) and shall inure to the benefit of Developer, the City and their respective successors and permitted assigns (as provided herein). Except as otherwise provided herein, this Agreement shall not run to the benefit of, or be enforceable by, any person or entity other than a party to this Agreement and its successors and permitted assigns. This Agreement should not be deemed to confer upon third parties any remedy, claim, right of reimbursement or other right.
Force Majeure. Neither the City nor Developer nor any successor in interest to either of them shall be considered in breach of or in default of its obligations under this Agreement in the event of any delay caused by damage or destruction by fire or other casualty, strike, shortage of material, unusually adverse weather conditions such as, by way of illustration and not limitation, severe rain storms or below freezing temperatures of abnormal degree or for an abnormal duration, tornadoes or cyclones; and other events or conditions beyond the reasonable control of the party affected which in fact interferes with the ability of such party to discharge its obligations hereunder. The individual or entity relying on this section with respect to any such delay shall, upon the occurrence ofthe event causing such delay, immediately give written notice to the other parties to this Agreement. The individual or entity relying on this section with respect to any such delay may rely on this section only to the extent of the actual number of days of delay effected by any such events described above.
Business Economic Support Act. Pursuant to the Business Economic Support Act (30 ILCS 760/1 et seg.). if Developer is required to provide notice under the WARN Act, Developer shall, in addition to the notice required under the WARN Act, provide at the same time a copy of the WARN Act notice to the Governor of the State, the Speaker and Minority Leader of the House of Representatives of the State, the President and minority Leader of the Senate of State, and the Mayor of each municipality where Developer has locations in the State. Failure by Developer to provide such notice as described above may result in the termination of all or a part of the payment or reimbursement obligations of the City set forth herein.
Venue and Consent to Jurisdiction. If there is a lawsuit under this Agreement, each party may hereto agrees to submit to the jurisdiction of the courts of Cook County, the State of Illinois and the United States District Court for the Northern District of Illinois.
Costs and Expenses. In addition to and not in limitation of the other provisions of this Agreement, Developer agrees to pay upon demand the City's out-of-pocket expenses, including attorney's fees, incurred in connection with the enforcement of the provisions of this Agreement. This includes, subject to any limits under applicable law, attorney's fees and legal expenses, whether or not there is a lawsuit, including attorney's fees for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals and any anticipated post-judgment collection services. Developer also will pay any court costs, in addition to all other sums provided by law.
Business Relationships. Developer acknowledges (A) receipt of a copy of Section 2-156-030 (b) ofthe Municipal Code, (B) that Developer has read such provision and understands that pursuant to such Section 2-156-030 (b), it is illegal for any elected official of the City, or any
49
person acting at the direction of such official, to contact, either orally or in writing, any other City official or employee with respect to any matter involving any person with whom the elected City official or employee has a business relationship that creates a "Financial Interest" (as defined in Section 2-156-010 of the Municipal Code)(a "Financial Interest"), or to participate in any discussion in any City Council committee hearing or in any City Council meeting or to vote on any matter involving any person with whom the elected City official or employee has a business relationship that creates a Financial Interest, or to participate in any discussion in any City Council committee hearing or in any City Council meeting or to vote on any matter involving the person with whom an elected official has a business relationship that creates a Financial Interest, and (C) that a violation of Section 2-156-030 (b) by an elected official, or any person acting at the direction of such official, with respect to any transaction contemplated by this Agreement shall be grounds for termination of this Agreement and the transactions contemplated hereby. Developer hereby represents and warrants that, to the best of its knowledge after due inquiry, no violation of Section 2-156-030 (b) has occurred with respect to this Agreement or. the transactions contemplated hereby.
[THE REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK.]
50
IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment Agreement to be executed on or as of the day and year first above written.
MHUB SUPPORT CORPORATION, an Illinois not-for-profit corporation
By: Its:
MHUB, an Illinois not-for-profit corporation
By: Its:
CITY OF CHICAGO, by and through its Department of Planning and Development
By:
Maurice Cox, Commissioner
51
STATE OF ILLINOIS ) COUNTY OF COOK )
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that , personally known to
me to be the of mHUB Support Corporation, an Illinois not-for-
profit corporation ("Owner"), and personally known to me to be the same person whose name is
subscribed to the foregoing instrument, appeared before me this day in person and acknowledged
that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to
him/her by the Board of Directors of Owner, as his/her free and voluntary act and as the free and
voluntary act of Owner, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this day of
Notary Public
My Commission Expires
(SEAL)
52
STATE OF ILLINOIS ) COUNTY OF COOK )
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that , personally known to
me to be the of mHUB, an Illinois not-for-profit corporation
("mHUB"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument, pursuant to the authority given to him/her by the Board of Directors of mHUB, as his/her free and voluntary act and as the free and voluntary act of mHUB, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this day of , .
Notary Public
My Commission Expires.
(SEAL)
53
STATE OF ILLINOIS ) COUNTY OF COOK )
I, , a notary public in and for the said County, in the State
aforesaid, DO HEREBY CERTIFY that Maurice Cox, personally known to me to be the Commissioner of the Department of Planning and Development of the City of Chicago (the "City"), and personally known to me to be the same person whose name is subscribed to the foregoing instrument, appeared before me this day in person and acknowledged that he/she signed, sealed, and delivered said instrument pursuant to the authority given to him/her by the City, as his/her free and voluntary act and as the free and voluntary act of the City, for the uses and purposes therein set forth.
GIVEN under my hand and official seal this th day of
Notary Public
My Commission Expires.
54
EXHIBIT A REDEVELOPMENT AREA [not attached for ordinance]
55
EXHIBIT B
PROPERTY
[Subject to Survey and Title Insurance]
/(r-^/a^A'eel(-
56
Legal Description:
PARCEL 1:
LOTS 1 TO 10, BOTH INCLUSIVE (EXCEPT THAT PART LYING EAST OF A LINE 50.00 FEET WEST OF AND PARALLEL TO THE EAST LINE OF SECTION 7) IN D. W. SUTHERLAND SUBDIVISION IN SECTION 7, TOWNSHIP 39 NORTH, RANGE 14, EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS. PARCEL IA:
THE EAST 1/2 OF THE VACATED NORTH/SOUTH VACATED ALLEY LYING WEST OF AND ADJOINING PARCEL 1 AFORESAID, IN COOK COUNTY, ILLINOIS. PARCEL 2:
LOTS 1 TO 6, BOTH INCLUSIVE, IN H.E. BARBOUR'S SUBDIVISION OF PART OF BLOCK 48 IN CANAL TRUSTEES' SUBDIVISION OF SECTION 7, TOWNSHIP 39 NORTH, RANGE 14, EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS. PARCEL 2A:
THE EAST/WEST 10-FOOT VACATED ALLEY LYING SOUTH OF AND ADJOINING THE SOUTH LINE OF LOTS 1, 2 AND 3 AND NORTH OF AND ADJOINING THE NORTH LINE OF LOTS 4, 5 AND 6 OF PARCEL 2 AFORESAID; ALSO
THE WEST 1/2 OF THE NORTH/SOUTH VACATED ALLEY LYING EAST OF AND ADJOINING THE EAST LINE OF LOT 1, THE EAST LINE OF LOT 1 PRODUCED SOUTH 10.00 FEET AND EAST OF AND ADJOINING THE EAST LINE OF LOT 6 OF PARCEL 2 AFORESAID, IN COOK COUNTY, ILLINOIS. PARCEL 3:
LOTS 1 TO 7, BOTH INCLUSIVE, ALL OF LOTS 26 TO 32, BOTH INCLUSIVE IN C.J. HULL'S SUBDIVISION OF PART OF BLOCK 48 IN CANAL TRUSTEES' SUBDIVISION OF SECTION 7, TOWNSHIP 39 NORTH, RANGE 14, EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILUNOIS. PARCEL3A:
THE EAST/WEST 16-FOOT VACATED ALLEY LYING SOUTH OF AND ADJOINING THE SOUTH LINE OF LOTS 1 TO 4, LOT 5 (EXCEPT THE WEST 16.00 FEET THEREOF) AND NORTH OF AND ADJOINING
THE NORTH LINE OF LOT 28 (EXCEPT THE WEST 16.00 FEET THEREOF) AND LOTS 29 TO 32 OF PARCEL 3 AFORESAID, IN COOK COUNTY, ILLINOIS. PARCEL3B:
THE EAST-WEST 16-FOOT VACATED ALLEY LYING SOUTH OF AND ADJOINING THE SOUTH LINE OF THE WEST 16.00 FEET OF LOT 5 AND LOTS 6 AND 7 AND NORTH OF AND ADJOINING THE NORTH LINE OF LOTS 26, 27 AND THE WEST 16.00 FEET OF LOT 28 OR PARCEL 3 AFORESAID, IN COOK COUNTY, ILLINOIS.
Property Address: 240 North Ashland Avenue, Chicago, IL PINs:
17-07-411-007-0000 17-07-411-008-0000 17-07-411-016-0000 17-07-411-024-0000 17-07-411-025-0000 17-07-411-026-0000 17-07-411-027-0000 17-07-411-028-0000
v.
EXHIBIT C TIF-FUNDED IMPROVEMENTS TIF- Eligible
Budget
Acquisition Costs $32,500,000
Hard Costs
Demolition $273,700
Asphalt $24,000
Environmental Remediation $175,000
Concrete $40,300
Masonry $207,500
Misc Metals $34,500
Rough Carpentry $178,500
Millwork $454,900
Fireproofing/ Firesafing $12,000
Roofing $35,000
Doors, Frames & Hardware $268,200
Glass & Glazing $609,500
Drywall $776,500
Ceramic Tile $58,500
Acoustical Ceilings $234,800
Wood Flooring $60,000
Carpet & Resilient $169,950
Special Floor Coatings $156,800
, Floor Prep Allowance $45,300
Painting & Wallcovering $165,000
Folding Partitions / Overhead Doors $123,900
Specialties $14,000
Appliances $0
Elevators $15,000
Fire Protection $192,300
Plumbing $239,000
HVAC $1,335,700
Electrical $2,722,200
Communications $201,500
Low Voltage Equipment $200,000
Security $0
Cleaning & Rubbish Removal $134,200
57
i
General Requirements $0
Final Cleaning Allowance $32,000
Scanning/BIM/VDC Coordination $25,000
Premium Time / Schedule Shift Beyond
6/1 $61,000
Furniture $0
Manufacturing/IT/AV Equipment $1,290,000
Other FF&E $0
Hard Cost Contingency $0
Total Hard Costs $10,676,350
Soft Costs/Fees
Architecture & Engineering &
Engineering Management $659,600
Survey/title/appraisal $0
Construction Insurance $0
TIF Consultant $0
Permits $70,000
TIF Bridge Loan Financing $0
Soft Cost Contingencies $0
Total Soft Costs $729,600
Total TIF Eligible $43,905,950
*Notwithstanding the total of TIF-Funded Improvements or the amount of TIF-eligible costs, the assistance to be provided by the City is limited to the amount described in Section 4.03 and shall not exceed the lesser of $17,550,000 or 37.5% of the Project Budget.
58
EXHIBIT E CONSTRUCTION CONTRACT [Not attached for ordinance]
59
EXHIBIT F [Intentionally omitted]
60
EXHIBIT G PERMITTED LIENS
1. Liens or encumbrances against the Property:
Those matters set forth as Schedule B title exceptions in the owner's title insurance policy issued by the Title Company as of the date hereof, but only so long as applicable title endorsements issued in conjunction therewith on the date hereof, if any, continue to remain in full force and effect.
Liens permitted pursuant to the Lease by Owner as landlord, and Tenant, as tenant, pursuant to which Tenant holds leasehold title to the Property.
Liens arising from refinancing of any of the foregoing.
[To be completed by Developer's counsel, subject to City approval.]
61
EXHIBIT H-1 PROJECT BUDGET See attached
62
Exhibit H-l
Acquisition Costs Hard Costs
Demolition Asphalt
Environmental Remediation
Concrete
Masonry
Misc Metals
Rough Carpentry
Millwork
Fireproofing / Firesafing Roofing
Doors, Frames & Hardware
Glass & Glazing
Dry wa 11
Ceramic Tile
Acoustical Ceilings
Wood Flooring
Carpet & Resilient
Special Floor Coatings
Floor Prep Allowance
Painting & Wallcovering
Folding Partitions / Overhead Doors
Specialties
Appliances
Elevators
Fire Protection
Plumbing
HVAC
Electrical
Communications
Low Voltage Equipment
Security
Cleaning & Rubbish Removal General Requirements Final Cleaning Allowance Scanning/BIM/VDC Coordination Premium Time / Schedule Shift Beyond 6/1 Furniture
Manufacturing/IT/AV Equipment Other FF&E
Hard Cost Conti ngency Total Hard Costs
Project Budget $32,500,000
$273,700 $24,000 $175,000 $40,300 $207,500 $34,S00 $178,500 $454,900 $12,000 $35,000 $268,200 $609,500 $776,500 $58,500 $234,800 $60,000 $169,950 $156,800 $45,300 $165,000 $123,900 $14,000 $29,000 $15,000 $192,300 $239,000 $1,335,700 $2,722,200 $201,500 $200,000 $90,400 $134,200 $20,200 $32,000 $25,000 $61,000 $800,000 $1,290,000 $100,000
$325,520
$11,930,870
Soft Costs/Fees
Architectures, Engineerings, Engineering Management
Survey/ti tl e/a ppra i s a I
Construction Insurance
TIF Consultant
Permits
TIF Bridge Loan Financing Soft Cost Contingencies Total Soft Costs
$659,600 $196,750 $315,600 $80,000 $70,000 $968,391 $80,000 $2,370,341
$46,801,211
63
EXHIBIT H-2 MBE/WBE BUDGET See attached.
64
Hard Costs
Demolition Asphalt
Environmental Remediation Concrete Masonry Misc Metals Rough Carpentry Mi 11 work
Fireproofing/ Firesafing Roofi ng
Doors, Frames & Hardware Glass & Glazing Drywa 11 Ceramic Tile Acoustical Ceilings Wood Flooring Carpet & Resilient Special Floor Coatings Floor Prep Allowance Pai nti ng & Wal Icoveri ng Folding Partitions / Overhead Doors Specialties Eleva tors Fire Protection Plumbing HVAC Electrical Communications Low Voltage Equi pment Security
Cleaning & Rubbish Removal General Requirements Final Cleaning Allowance Scanning/BIM/VDC Coordination Premium Time / Schedule Shift Beyo Manufacturing/IT/AV Equipment Total Hard Costs
Exhibit H-2 MBE/WBE Budget
$273,700 $24,000 $175,000 $40,300 $207,500 $34,500 $178,500 $454,900 $12,000 $35,000 $268,200 $609,500 $776,500 $58,500 $234,800 $60,000 $169,950 $156,800 $45,300 $165,000
$123,900 $14,000 $15,000 $192,300 $239,000 $1,335,700 $2,722,200 $201,500 $200,000 $90,400 $134,200 $20,200 $32,000 $25,000 $61,000 $1,290,000 $9,386,350
Soft Costs/Fees
Architecture & Engineering & Engine $659,600 Total Soft Costs $659,600
$11,335,950
Project MBE Total at 26% $2,947,347 Project WBE Total at 6% $680,157
65
EXHIBIT I APPROVED PRIOR EXPENDITURES [Not attached for ordinance]
66
EXHIBIT J OPINION OF DEVELOPER'S COUNSEL [To be retyped on Developer's Counsel's letterhead]
City of Chicago
121 North LaSalle Street
Chicago, IL 60602
ATTENTION: Corporation Counsel
Ladies and Gentlemen:
We have acted as counsel to mHUB Support Corporation, an Illinois not-for-profit corporation (the Owner"), and mHUB, an Illinois not-for-profit corporation (the "Tenant", and collectively with the Owner, the "Developer"), in connection with the purchase of certain land and the rehabilitation of certain facilities thereon located in the Kinzie Industrial Corridor Redevelopment Project Area (the "Project"). In that capacity, we have examined, among other things, the following agreements, instruments and documents of even date herewith, hereinafter referred to as the "Documents":
(a) mHUB Redevelopment Agreement (the "Agreement") of even date herewith, executed by Developer and the City of Chicago (the "City");
[(b) the Escrow Agreement of even date herewith executed by Developer and the City;]
[insert other documents including but not limited to documents related to purchase and financing of the Property and all lender financing related to the Project]; and
all other agreements, instruments and documents executed in connection with the foregoing.
In addition to the foregoing, we have examined
the original or certified, conformed or photostatic copies of Developer's (i) Articles of Incorporation, as amended to date, (ii) qualifications to do business and certificates of good standing in all states in which Developer is qualified to do business, (iii) By-Laws, as amended to date, and (iv) records of all corporate proceedings relating to the Project [revise if Developer is not a corporation]; and
such other documents, records and legal matters as we have deemed necessary or relevant for purposes of issuing the opinions hereinafter expressed.
67
In all such examinations, we have assumed the genuineness of all signatures (other than those of Developer), the authenticity of documents submitted to us as originals and conformity to the originals of all documents submitted to us as certified, conformed or photostatic copies.
Based on the foregoing, it is our opinion that:
Each of Owner and Tenant is a not-for-profit corporation duly organized, validly existing and in good standing under the laws of its state of incorporation, has full power and authority to own and lease its properties and to carry on its business as presently conducted, and is in good standing and duly qualified to do business as a foreign corporation under the laws of every state in which the conduct of its affairs or the ownership of its assets requires such qualification, except for those states in which its failure to qualify to do business would not have a material adverse effect on it or its business.
Developer has full right, power and authority to execute and deliver the Documents to which it is a party and to perform its obligations thereunder. Such execution, delivery and performance will not conflict with, or result in a breach of, Developer's respective Articles of Incorporation or By-Laws or result in a breach or other violation of any of the terms, conditions or provisions of any law or regulation, order, writ, injunction or decree of any court, government or regulatory authority, or, to the best of our knowledge after diligent inquiry, any of the terms, conditions or provisions of any agreement, instrument or document to which Developer is a party or by which Developer or its properties is bound. To the best of our knowledge after diligent inquiry, such execution, delivery and performance will not constitute grounds for acceleration of the maturity of any agreement, indenture, undertaking or other instrument to which Developer is a party or by which it or any of its property may be bound, or result in the creation or imposition of (or the obligation to create or impose) any lien, charge or encumbrance on, or security interest in, any of its property pursuant to the provisions of any of the foregoing, other than liens or security interests in favor of the lender providing Lender Financing (as defined in the Agreement).
The execution and delivery of each Document and the performance of the transactions contemplated thereby have been duly authorized and approved by all requisite action on the part of Developer.
Each of the Documents to which Developer is a party has been duly executed and delivered by a duly authorized officer of Developer, and each such Document constitutes the legal, valid and binding obligation of Developer, enforceable in accordance with its terms, except as limited by applicable bankruptcy, reorganization, insolvency or similar laws affecting the enforcement of creditors' rights generally.
Exhibit A attached hereto (a) identifies each class of capital stock of Developer, (b) sets forth the number of issued and authorized shares of each such class, and (c) identifies the record owners of shares of each class of capital stock of Developer and the number of shares held of record by each such holder. To the best of our knowledge after diligent inquiry, except as set forth on Exhibit A, there are no warrants, options, rights or commitments of purchase, conversion, call or exchange or other rights or restrictions with respect to any of the
68
capital stock of Developer. Each outstanding share of the capital stock of Developer is duly authorized, validly issued, fully paid and nonassessable.
To the best of our knowledge after diligent inquiry, no judgments are outstanding against Developer, nor is there now pending or threatened, any litigation, contested claim or governmental proceeding by or against Developer or affecting Developer or its property, or seeking to restrain or enjoin the performance by Developer of the Agreement or the transactions contemplated by the Agreement, or contesting the validity thereof. To the best of our knowledge after diligent inquiry, Developer is not in default with respect to any order, writ, injunction or decree of any court, government or regulatory authority or in default in any respect under any law, order, regulation or demand of any governmental agency or instrumentality, a default under which would have a material adverse effect on Developer or its business.
To the best of our knowledge after diligent inquiry, there is no default by Developer or any other party under any material contract, lease, agreement, instrument or commitment to which Developer is a party or by which the company or its properties is bound.
To the best of our knowledge after diligent inquiry, all of the assets of Developer are free and clear of mortgages, liens, pledges, security interests and encumbrances except for those specifically set forth in the Documents.
The execution, delivery and performance of the Documents by Developer have not and will not require the consent of any person or the giving of notice to, any exemption by, any registration, declaration or filing with or any taking of any other actions in respect of, any person, including without limitation any court, government or regulatory authority.
To the best of our knowledge after diligent inquiry, Developer owns or possesses or is licensed or otherwise has the right to use all licenses, permits and other governmental approvals and authorizations, operating authorities, certificates of public convenience, goods carriers permits, authorizations and other rights that are necessary for the operation of its business.
A federal or state court sitting in the State of Illinois and applying the choice of law provisions of the State of Illinois would enforce the choice of law contained in the Documents and apply the law of the State of Illinois to the transactions evidenced thereby.
We are attorneys admitted to practice in the State of Illinois and we express no opinion as to any laws other than federal laws of the United States of America and the laws of the State of Illinois.
[Note: include a reference to the laws of the state of incorporation/organization of Developer, if other than Illinois.]
This opinion is issued at Developer's request for the benefit of the City and its counsel, and may not be disclosed to or relied upon by any other person.
Very truly yours,
69
By:_ Name:
70
EXHIBIT K
PRELIMINARY TIF PROJECTION - REAL ESTATE TAXES [Not attached for ordinance]
71
EXHIBIT L
FORM OF PAYMENT AND PERFORMANCE BOND [Not attached for ordinance]
72
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
SECTION I - GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: mHUB Support Corporation
Check ONE of the following three boxes:
Indicate whether the Disclosing Party submitting this EDS is:
[X] the Applicant
OR
[ ] a legal entity currently holding, or anticipated to hold within six months after City action on
the contract, transaction or other undertaking to which this EDS pertains (referred to below as the
"Matter"), a direct or indirect interest in excess of 7.5% in the Applicant. State the Applicant's legal
name:
OR
3. [ ] a legal entity with a direct or indirect right of control of the Applicant (see Section 11(B)(1)) State the legal name of the entity in which the Disclosing Party holds a right of control:
d d riL r^- i t> 965 Chicago Ave
B. Business address of the Disclosing Party: _
Chicago, IL 60642
Telephone: 312-248-8704 Fax; Email: manas@mhubchicago.com
Name of contact person: Manas Mehandru
Federal Employer Identification No. (if you have one):
Brief description of the Matter to which this EDS pertains. (Include project number and location of property, if applicable):
Redevelopment Agreement for 240 N Ashland Ave, Chicago, IL
Which City agency or department is requesting this EDS? Department of Planning and Development
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
Specification # and Contract #
Ver.2018-1 Page lof 15
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
NATURE OF THE DISCLOSING PARTY
[ ] Limited liability company [ ] Limited liability partnership [ ] Joint venture [ x] Not-for-profit corporation (Is the not-for-profit corporation also a 501(c)(3))?
1. Indicate the nature of the Disclosing Party
Person [
Publicly registered business corporation [
Privately held business corporation [
Sole proprietorship [
General partnership (
Limited partnership
Trust
[x] Yes [ ] No
[ ] Other (please specify)
2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable:
Illinois
3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
[ x] Organized in Illinois
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1. List below the full names and titles, if applicable, of: (i) all executive officers and all directors of the entity; (ii) for not-for-profit corporations, all members, if any, which are legal entities (if there are no such members, write "no members which are legal entities"); (iii) for trusts, estates or other similar entities, the trustee, executor, administrator, or similarly situated party; (iv) for general or limited partnerships, limited liability companies, limited liability partnerships or joint ventures, each general partner, managing member, manager or any other person or legal entity that directly or indirectly controls the day-to-day management of the Applicant.
NOTE: Each legal entity listed below must submit an EDS on its own behalf.
Name Title
No members are legal entities
List of Officers and Directors Attached
2. Please provide the following information concerning each person or legal entity having a direct or indirect, current or prospective (i.e. within 6 months after City action) beneficial interest (including ownership) in excess of 7.5% of the Applicant. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture, interest of a member or manager in a
Page 2 of 15
Director Name Title
Haven Allen Chief Executive Officer, mHUB (President)
Manas Mehandru Chief Operating Officer, mHUB (Treasurer)
Melissa Lederer Chief Experience Officer, mHUB (Secretary)
Kevin Wilier Partner, Chicago Ventures
Meredith O'Connor International Director, Co-Chairman of Headquarters Practice Group, JLL
Victoria Lakes-Battle Executive Director - Chicago Region, IFF
Susan Kai Partner, Eversheds-Sutherland
limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None."
NOTE: Each legal entity listed below may be required to submit an EDS on its own behalf.
Name Business Address Percentage Interest in the Applicant
None
SECTION III - INCOME OR COMPENSATION TO, OR OWNERSHIP BY, CITY ELECTED OFFICIALS
Has the Disclosing Party provided any income or compensation to any City elected official during the
12-month period preceding the date of this EDS? [ ] Yes [x] No
Does the Disclosing Party reasonably expect to provide any income or compensation to any City
elected official during the 12-month period following the date of this EDS? [ ] Yes [ x] No
If "yes" to either ofthe above, please identify below the name(s) of such City elected official(s) and describe such income or compensation:
Does any City elected official or, to the best of the Disclosing Party's knowledge after reasonable
inquiry, any City elected official's spouse or domestic partner, have a financial interest (as defined in
Chapter 2-156 of the Municipal Code of Chicago ("MCC")) in the Disclosing Party?
[ ] Yes [x] No
If "yes," please identify below the name(s) of such City elected official(s) and/or spouse(s)/domestic partner(s) and describe the financial interest(s).
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist (as defined in MCC Chapter 2-156), accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature of the relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll. If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure.
Page 3 of 15
Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:
to be retained) lobbyist, etc.) "hourly rate" or "t.b.d." is
not an acceptable response.
(Add sheets if necessary)
[x] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under MCC Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
Has any person who directly or indirectly owns 10% or more of the Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
[ ] Yes [ ] No [x] No person directly or indirectly owns 10% or more of the Disclosing Party.
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
[ ] Yes [ ] No
FURTHER CERTIFICATIONS
[This paragraph 1 applies only if the Matter is a contract being handled by the City's Department of Procurement Services.] In the 5-year period preceding the date of this EDS, neither the Disclosing Party nor any Affiliated Entity [see definition in (5) below] has engaged, in connection with the performance of any public contract, the services of an integrity monitor, independent private sector inspector general, or integrity compliance consultant (i.e., an individual or entity with legal, auditing, investigative, or other similar skills, designated by a public agency to help the agency monitor the activity of specified agency vendors as well as help the vendors reform their business practices so they can be considered for agency contracts in the future, or continue with a contract in progress).
The Disclosing Party and its Affiliated Entities are not delinquent in the payment of any fine, fee, tax or other source of indebtedness owed to the City of Chicago, including, but not limited to, water and sewer charges, license fees, parking tickets, property taxes and sales taxes, nor is the Disclosing Party delinquent in the payment of any tax administered by the Illinois Department of Revenue.
Ver.2018-1 Page 4 of 15
The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section 11(B)(1) ofthis EDS:
are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
have not, during the 5 years before the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement; theft; forgery; bribery; falsification or destruction of records; making false statements; or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in subparagraph (b) above;
have not, during the 5 years before the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
have not, during the 5 years before the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The Disclosing Party understands and shall comply with the applicable requirements of MCC Chapters 2-56 (Inspector General) and 2-156 (Governmental Ethics).
Certifications (5), (6) and (7) concern:
the Disclosing Party;
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties");
any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity). Indicia of control include, without limitation: interlocking management or ownership; identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity. With respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity;
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
Page 5 of 15
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor, nor any Agents have, during the 5 years before the date of this EDS, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the 5 years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency ofthe federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity;
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise; or
made an admission of such conduct described in subparagraph (a) or (b) above that is a matter of record, but have not been prosecuted for such conduct; or
violated the provisions referenced in MCC Subsection 2-92-320(a)(4)(Contracts Requiring a Base Wage); (a)(5)(Debarment Regulations); or (a)(6)(Minimum Wage Ordinance).
Neither the Disclosing Party, nor any Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on a Sanctions List maintained by the United States Department of Commerce, State, or Treasury, or any successor federal agency.
[FOR APPLICANT ONLY] (i) Neither the Applicant nor any "controlling person" [see MCC Chapter 1-23, Article I for applicability and defined terms] of the Applicant is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any "sister agency"; and (ii) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If MCC Chapter 1-23, Article I applies to the Applicant, that Article's permanent compliance timeframe supersedes 5-year compliance timeframes in this Section V.
[FOR APPLICANT ONLY] The Applicant and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed as having an active exclusion by the U.S. EPA on the federal System for Award Management ("SAM").
10. [FOR APPLICANT ONLY] The Applicant will obtain from any contractors/subcontractors hired
or to be hired in connection with the Matter certifications equal in form and substance to those in
Certifications (2) and (9) above and will not, without the prior written consent of the City, use any such
Ver.2018-1 Page 6 of 15
contractor/subcontractor that does not provide such certifications or that the Applicant has reason to believe has not provided or cannot provide truthful certifications.
11. If the Disclosing Party is unable to certify to any of the above statements in this Part B (Further
Certifications), the Disclosing Party must explain below: none
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
12. To the best ofthe Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none"), none
13. To the best ofthe Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, ofthe City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $25 per recipient, or (iii) a political contribution otherwise duly reported as required by law (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name ofthe City recipient, none
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is [x] is not
a "financial institution" as defined in MCC Section 2-32-455(b).
If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in MCC Chapter 2-32. We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in MCC Chapter 2-32. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City."
Page 7 of 15
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in MCC Section 2-32-455(b)) is a predatory lender within the meaning of MCC Chapter 2-32, explain here (attach additional pages if necessary):
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
D. CERTIFICATION REGARDING FINANCIAL INTEREST IN CITY BUSINESS
Any words or terms defined in MCC Chapter 2-156 have the same meanings if used in this Part D.
In accordance with MCC Section 2-156-110: To the best of the Disclosing Party's knowledge after reasonable inquiry, does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[ ]Yes [x]No
NOTE: Ifyou checked "Yes" to Item D(l), proceed to Items D(2) and D(3). Ifyou checked "No" to Item D(l), skip Items D(2) and D(3) and proceed to Part E.
Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning ofthis Part D.
Does the Matter involve a City Property Sale?
[ ] Yes [^No
If you checked "Yes" to Item D(l), provide the names and business addresses of the City officials or employees having such financial interest and identify the nature of the financial interest:
Name Business Address Nature of Financial Interest
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
Page 8 of 15
E. CERTIFICATION REGARDING SLAVERY ERA BUSINESS
Please check either (1) or (2) below. If the Disclosing Party checks (2), the Disclosing Party must disclose below or in an attachment to this EDS all information required by (2). Failure to comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
_^ 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
2. The Disclosing Party verifies that, as a result of conducting the search in step (1) above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
NOTE: If the Matter is federally funded, complete this Section VI. If the Matter is not federally funded, proceed to Section VII. For purposes ofthis Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
A. CERTIFICATION REGARDING LOBBYING
1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995, as amended, who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary): None
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995, as amended, have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay
any person or entity listed in paragraph A(l) above for his or her lobbying activities or to pay any
person or entity to influence or attempt to influence an officer or employee of any agency, as defined
by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee
Ver.2018-1 Page 9 of 15
of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A(l) and A(2) above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) ofthe Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities," as that term is defined in the Lobbying Disclosure Act of 1995, as amended.
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A(l) through A(4) above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration of the Matter and must make such certifications promptly available to the City upon request.
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Party the Applicant?
[ x] Yes [ ] No
If "Yes," answer the three questions below:
Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[X]Yes [ ]No
Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ ] Yes [ ] No [x] Reports not required
Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes [x] No
If you checked "No" to question (1) or (2) above, please provide an explanation:
Page 10 of 15
- FURTHER ACKNOWLEDGMENTS AND CERTIFICATION
The Disclosing Party understands and agrees that:
The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter. The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based.
The City's Governmental Ethics Ordinance, MCC Chapter 2-156, imposes certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text ofthis ordinance and a training program is available on line at www.cityofchicago.org/Ethics , and may also be obtained from the City's Board of Ethics, 740 N. Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with this ordinance.
If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other City transactions. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided in, and appended to, this EDS may be made publicly available on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to MCC Chapter 1-23, Article I (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by MCC Chapter 1-23 and Section 2-154-020.
Page 11 of 15
CERTIFICATION
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS, and all applicable Appendices, on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS, and all applicable Appendices, are true, accurate and complete as ofthe date furnished to the City.
mHUB Support Corporation (Print or type exact legal name of Disclosing Party)
(Sign here) Manas Mehandru
(Print or type name of person signing) Treasurer
(Print or type title of person signing)
j i
Signed and sworn to before me on (date) } 2- f (y i 2 2.
al t 00 k County, / II)
V^^/Notary Public
Commission expires:
Page 12 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
FAMILIAL RELATIONSHIPS WITH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5%. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Under MCC Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B.I.a., if the Disclosing Party is a corporation; all partners ofthe Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members ofthe Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers ofthe Disclosing Party; and (3) any person having more than a 7.5% ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
[ ]Yes pCJNo
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title ofthe elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
Page 13 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX B
BUILDING CODE SCOFFLAW/PROBLEM LANDLORD CERTIFICATION
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5% (an "Owner"). It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Pursuant to MCC Section 2-154-010, is the Applicant or any Owner identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
[ ]Yes [X|No
If the Applicant is a legal entity publicly traded on any exchange, is any officer or director of the Applicant identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
[ ] Yes [ ] No [Xj The Applicant is not publicly traded on any exchange.
3. If yes to (1) or (2) above, please identify below the name of each person or legal entity identified as a building code scofflaw or problem landlord and the address of each building or buildings to which the pertinent code violations apply.
Page 14 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX C
PROHIBITION ON WAGE & SALARY HISTORY SCREENING - CERTIFICATION
This Appendix is to be completed only by an Applicant that is completing this EDS as a "contractor" as defined in MCC Section 2-92-385. That section, which should be consulted (www.amlegal.com' ), generally covers a party to any agreement pursuant to which they: (i) receive City of Chicago funds in consideration for services, work or goods provided (including for legal or other professional services), or (ii) pay the City money for a license, grant or concession allowing them to conduct a business on City premises.
On behalf of an Applicant that is a contractor pursuant to MCC Section 2-92-385,1 hereby certify that the Applicant is in compliance with MCC Section 2-92-385(b)(l) and (2), which prohibit: (i) screening job applicants based on their wage or salary history, or (ii) seeking job applicants1 wage or salary history from current or former employers. I also certify that the Applicant has adopted a policy that includes those prohibitions.
[ ] Yes
[ ]No
[Xj N/A - I am not an Applicant that is a "contractor" as defined in MCC Section 2-92-385. This certification shall serve as the affidavit required by MCC Section 2-92-385(c)(l). If you checked "no" to the above, please explain.
Page 15 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
SECTION I -- GENERAL INFORMATION
A. Legal name of the Disclosing Party submitting this EDS. Include d/b/a/ if applicable: mHUB
Check ONE of the following three boxes:
Indicate whether the Disclosing Party submitting this EDS is:
[X] the Applicant
OR
[ ] a legal entity currently holding, or anticipated to hold within six months after City action on
the contract, transaction or other undertaking to which this EDS pertains (referred to below as the
"Matter"), a direct or indirect interest in excess of 7.5% in the Applicant. State the Applicant's legal
name:
OR
3. [ ] a legal entity with a direct or indirect right of control ofthe Applicant (see Section 11(B)(1)) State the legal name ofthe entity in which the Disclosing Party holds a right of control:
B. Business address of the Disclosing Party: 965 Chicago Ave
Chicago, IL 60642
Telephone: 312-248-8704 Fax; Email; manas@mhubchicago.com
Name of contact person: Ma"as Mehandru
Federal Employer Identification No. (if you have one).
Brief descnption ofthe Matter to which this EDS pertains. (Include project number and location of property, if applicable):
Redevelopment Agreement for 240 N Ashland Ave, Chicago, IL
Which City agency or department is requesting this EDS? Department of Planning and Development
If the Matter is a contract being handled by the City's Department of Procurement Services, please complete the following:
Specification # and Contract #
Ver.2018-1 Pa°elofl5
SECTION II - DISCLOSURE OF OWNERSHIP INTERESTS
A. NATURE OF THE DISCLOSING PARTY
1. Indicate the nature of the Disclosing
[ ] Person
[ ] Publicly registered business corporation
[ ] Privately held business corporation
[ ] Sole proprietorship
[ ] General partnership
[ ] Limited partnership
[ ] Trust
[ ] Limited liability company
[ ] Limited liability partnership
[ ] Joint venture
[ x] Not-for-profit corporation
(Is the not-for-profit corporation also a 501(c)(3))?
[x] Yes [ ] No [ ] Other (please specify)
2. For legal entities, the state (or foreign country) of incorporation or organization, if applicable: Illinois
3. For legal entities not organized in the State of Illinois: Has the organization registered to do business in the State of Illinois as a foreign entity?
[ ] Yes [ ] No [x] Organized in Illinois
B. IF THE DISCLOSING PARTY IS A LEGAL ENTITY:
1. List below the full names and titles, if applicable, of: (i) all executive officers and all directors of the entity; (ii) for not-for-profit corporations, all members, if any, which are legal entities (if there are no such members, write "no members which are legal entities"): (iii) for trusts, estates or other similar entities, the trustee, executor, administrator, or similarly situated party; (iv) for general or limited partnerships, limited liability companies, limited liability partnerships or joint ventures, each general partner, managing member, manager or any other person or legal entity that directly or indirectly controls the day-to-day management of the Applicant.
NOTE: Each legal entity listed below must submit an EDS on its own behalf.
Name Title
No members are legal entities
See attached list
2. Please provide the following information concerning each person or legal entity having a direct or indirect, current or prospective (i.e. within 6 months after City action) beneficial interest (including ownership) in excess of 7.5% ofthe Applicant. Examples of such an interest include shares in a corporation, partnership interest in a partnership or joint venture, interest of a member or manager in a
Page 2 of 15
Name Company Title Officer
Erin Braddock Guthrie Microsoft Sr director, C+AI Strategy
Kevin Wilier Chicago Ventures Partner
Gani Nayak CGI EVP and CTO
Corey Ryan William Blairand Company Managing Director
Ushma Kriplani Argonne/DOE Industrail Decarbonization Lead
Miction Ellis CLOUT, LLC CEO
Bill Fienup mHUB VP of mHUB, ED of Al MedTech, VP of Innovation Services Vice President
Jeff Malehorn L3.0Ventures Founding Principal
Melissa Lederer mHUB CXO Secretary
Manas Mehandru mHUB coo Treasurer
Meredith O'Connor JLL International Director
Steve Kase ASK CEO Emeritus
Nicole Wolter HM Manufacturing President
Jian Cao Northwestern University Professor
Mark Karasek Grainger Engineering, UIUC Clinical Associate Professor
Don McNeill Spire Brand Ventures CEO
Robert M Weissbourd RW Ventures, LLC President
Jeff Margolis Innovation Strategies President
Karen Kerr Exposition Ventures General Partner
Edward A Coleman West Side Forward President and CEO
Nicole Stevenson Flex VP Strategy & Marketing
Steven Koch Bowline Group Managing Partner
Thomas Simeone Manor Tool and Mfg Co President
Zach Kaplan Inventables CEO
Jacob Babcock NuCurrent CEO
Haven Allen mHUB Chief Executive Officer and Managing Partner President
limited liability company, or interest of a beneficiary of a trust, estate or other similar entity. If none, state "None."
NOTE: Each legal entity listed below may be required to submit an EDS on its own behalf.
Name Business Address Percentage Interest in the Applicant
None
SECTION III - INCOME OR COMPENSATION TO, OR OWNERSHIP BY, CITY ELECTED OFFICIALS
Has the Disclosing Party provided any income or compensation to any City elected official during the
12-month period preceding the date ofthis EDS? [ ] Yes [x] No
Does the Disclosing Party reasonably expect to provide any income or compensation to any City
elected official during the 12-month period following the date ofthis EDS? [ ] Yes [x] No
If "yes" to either ofthe above, please identify below the name(s) of such City elected official(s) and describe such income or compensation:
Does any City elected official or, to the best of the Disclosing Party's knowledge after reasonable
inquiry, any City elected official's spouse or domestic partner, have a financial interest (as defined in
Chapter 2-156 of the Municipal Code of Chicago ("MCC")) in the Disclosing Party?
[ ] Yes [XJ No
If "yes," please identify below the name(s) of such City elected official(s) and/or spouse(s)/domestic partner(s) and describe the financial interest(s).
SECTION IV - DISCLOSURE OF SUBCONTRACTORS AND OTHER RETAINED PARTIES
The Disclosing Party must disclose the name and business address of each subcontractor, attorney, lobbyist (as defined in MCC Chapter 2-156), accountant, consultant and any other person or entity whom the Disclosing Party has retained or expects to retain in connection with the Matter, as well as the nature ofthe relationship, and the total amount of the fees paid or estimated to be paid. The Disclosing Party is not required to disclose employees who are paid solely through the Disclosing Party's regular payroll. If the Disclosing Party is uncertain whether a disclosure is required under this Section, the Disclosing Party must either ask the City whether disclosure is required or make the disclosure,
Page 3 of 15
Name (indicate whether Business Relationship to Disclosing Party Fees (indicate whether
retained or anticipated Address (subcontractor, attorney, paid or estimated.) NOTE:
to be retained) lobbyist, etc.) "hourly rate" or "t.b.d." is
not an acceptable response.
Neal & Leroy (retained); 20 S Clark St Suite 2050, Chicago IL, 60603, TIF Attorney $80,000 (Estimated)
Applegate & Thorne-Thomsen (retained), 425 S Financial Place, Suite 1900, Chicago IL, 60605; NMTC Attorney SI 10,000 (Estimated)
Baker Tilly Capital(retamed); 4807 Innovate Ln, Madison. Wl 53718; NMTC Consultant $350,000 (Estimated)
(Add Sheets if necessary) Chapman & Cutler (anticipated); 320 S Canal St, Chicago, IL 60606; Bond Counsel $100,000 (Estimate)
[ ] Check here if the Disclosing Party has not retained, nor expects to retain, any such persons or entities. SECTION V - CERTIFICATIONS
COURT-ORDERED CHILD SUPPORT COMPLIANCE
Under MCC Section 2-92-415, substantial owners of business entities that contract with the City must remain in compliance with their child support obligations throughout the contract's term.
Has any person who directly or indirectly owns 10% or more ofthe Disclosing Party been declared in arrearage on any child support obligations by any Illinois court of competent jurisdiction?
[ ] Yes [ ] No [x] No person directly or indirectly owns 10% or more of the Disclosing Party.
If "Yes," has the person entered into a court-approved agreement for payment of all support owed and is the person in compliance with that agreement?
[ ] Yes [ J No
FURTHER CERTIFICATIONS
[This paragraph 1 applies only if the Matter is a contract being handled by the City's Department of Procurement Services.] In the 5-year period preceding the date of this EDS, neither the Disclosing Party nor any Affiliated Entity [see definition in (5) below] has engaged, in connection with the performance.of any.-public contract, the services.of an integrity monitor,.independent.private sector . inspector general, or integrity compliance consultant (i.e., an individual or entity with legal, auditing, investigative, or other similar skills, designated by a public agency to help the agency monitor the activity of specified agency vendors as well as help the vendors reform their business practices so they can be considered for agency contracts in the future, or continue with a contract in progress).
The Disclosing Party and its Affiliated Entities are not delinquent in the payment of any. fine, fee, tax or other source of indebtedness owed to the City of Chicago, including, but not limited to, water and sewer charges, license fees, parking tickets, property taxes and sales taxes, nor is the Disclosing Party delinquent in the payment of any tax administered by the Illinois Department of Revenue.
Page 4 of 15
The Disclosing Party and, if the Disclosing Party is a legal entity, all of those persons or entities identified in Section 11(B)(1) of this EDS:
a are not presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from any transactions by any federal, state or local unit of government;
have not, during the 5 years before the date of this EDS, been convicted of a criminal offense, adjudged guilty, or had a civil judgment rendered against them in connection with: obtaining, attempting to obtain, or performing a public (federal, state or local) transaction or contract under a public transaction; a violation of federal or state antitrust statutes; fraud; embezzlement, theft; forgery; bribery; falsification or destruction of records, making false statements, or receiving stolen property;
are not presently indicted for, or criminally or civilly charged by, a governmental entity (federal, state or local) with committing any of the offenses set forth in subparagraph (b) above;
d have not, during the 5 years before the date of this EDS, had one or more public transactions (federal, state or local) terminated for cause or default; and
e have not, during the 5 years before the date of this EDS, been convicted, adjudged guilty, or found liable in a civil proceeding, or in any criminal or civil action, including actions concerning environmental violations, instituted by the City or by the federal government, any state, or any other unit of local government.
The Disclosing Party understands and shall comply with the applicable requirements of MCC Chapters 2-56 (Inspector General) and 2-156 (Governmental Ethics).
5. Certifications (5), (6) and (7) concern:
the Disclosing Party,
any "Contractor" (meaning any contractor or subcontractor used by the Disclosing Party in connection with the Matter, including but not limited to all persons or legal entities disclosed under Section IV, "Disclosure of Subcontractors and Other Retained Parties"),
• • any "Affiliated Entity" (meaning a person or entity that, directly or indirectly: controls the Disclosing Party, is controlled by the Disclosing Party, or is, with the Disclosing Party, under common control of another person or entity). Indicia of control include, without limitation: interlocking management or ownership, identity of interests among family members, shared facilities and equipment; common use of employees; or organization of a business entity following the ineligibility of a business entity to do business with federal or state or local government, including the City, using substantially the same management, ownership, or principals as the ineligible entity. With respect to Contractors, the term Affiliated Entity means a person or entity that directly or indirectly controls the Contractor, is controlled by it, or, with the Contractor, is under common control of another person or entity,
any responsible official of the Disclosing Party, any Contractor or any Affiliated Entity or any other official, agent or employee of the Disclosing Party, any Contractor or any Affiliated Entity, acting pursuant to the direction or authorization of a responsible official of the Disclosing Party, any Contractor or any Affiliated Entity (collectively "Agents").
Page 5 of 15
Neither the Disclosing Party, nor any Contractor, nor any Affiliated Entity of either the Disclosing Party or any Contractor, nor any Agents have, during the 5 years before the date of this EDS, or, with respect to a Contractor, an Affiliated Entity, or an Affiliated Entity of a Contractor during the 5 years before the date of such Contractor's or Affiliated Entity's contract or engagement in connection with the Matter:
bribed or attempted to bribe, or been convicted or adjudged guilty of bribery or attempting to bribe, a public officer or employee of the City, the State of Illinois, or any agency of the federal government or of any state or local government in the United States of America, in that officer's or employee's official capacity,
agreed or colluded with other bidders or prospective bidders, or been a party to any such agreement, or been convicted or adjudged guilty of agreement or collusion among bidders or prospective bidders, in restraint of freedom of competition by agreement to bid a fixed price or otherwise, or
made an admission of such conduct described in subparagraph (a) or (b) above that is a matter of record, but have not been prosecuted for such conduct; or
d violated the provisions referenced in MCC Subsection 2-92-320(a)(4)(Contracts Requiring a Base Wage); (a)(5)(Debarment Regulations); or (a)(6)(Minimum Wage Ordinance).
Neither the Disclosing Party, nor any Affiliated Entity or Contractor, or any of their employees, officials, agents or partners, is barred from contracting with any unit of state or local government as a result of engaging in or being convicted of (1) bid-rigging in violation of 720 ILCS 5/33E-3; (2) bid-rotating in violation of 720 ILCS 5/33E-4; or (3) any similar offense of any state or of the United States of America that contains the same elements as the offense of bid-rigging or bid-rotating.
Neither the Disclosing Party nor any Affiliated Entity is listed on a Sanctions List maintained by the United States Department of Commerce, State, or Treasury, or any successor federal agency
[FOR APPLICANT ONLY] (i) Neither the Applicant nor any "controlling person" [see MCC Chapter 1-23, Article I for applicability and defined terms] of the Applicant is currently indicted or charged with, or has admitted guilt of, or has ever been convicted of, or placed under supervision for, any criminal offense involving actual, attempted, or conspiracy to commit bribery, theft, fraud, forgery, perjury, dishonesty or deceit against an officer or employee of the City or any "sister agency", and (n) the Applicant understands and acknowledges that compliance with Article I is a continuing requirement for doing business with the City. NOTE: If MCC Chapter 1-23, Article I applies to the Applicant, that Article's permanent compliance timeframe supersedes 5-year compliance timeframes in this Section V.
[FOR APPLICANT ONLY] The Applicant and its Affiliated Entities will not use, nor permit their subcontractors to use, any facility listed as having an active exclusion by the U.S. EPA on the federal System for Award Management ("SAM")
[FOR APPLICANT ONLY] The Applicant will obtain from any contractors/subcontractors hired or to be hired in connection with the Matter certifications equal in form and substance to those in Certifications (2) and (9) above and will not, without the prior written consent of the City, use any such
Ver.2018-1 Page 6 of 15
contractor/subcontractor that does.not provide such certifications or that the Applicant has reason to believe has not provided or cannot provide truthful certifications.
11. Tf the Disclosing Party is unable to certify to any of the above statements in this Part B (Further Certifications), the Disclosing Party must explain below
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
12. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all current employees of the Disclosing Party who were, at any time during the 12-month period preceding the date of this EDS, an employee, or elected or appointed official, of the City of Chicago (if none, indicate with "N/A" or "none"), none
13. To the best of the Disclosing Party's knowledge after reasonable inquiry, the following is a complete list of all gifts that the Disclosing Party has given or caused to be given, at any time during the 12-month period preceding the execution date of this EDS, to an employee, or elected or appointed official, of the City of Chicago. For purposes of this statement, a "gift" does not include: (i) anything made generally available to City employees or to the general public, or (ii) food or drink provided in the course of official City business and having a retail value of less than $25 per recipient, or (iii) a political contribution otherwise duly reported as required by law (if none, indicate with "N/A" or "none"). As to any gift listed below, please also list the name of the City recipient, none
C. CERTIFICATION OF STATUS AS FINANCIAL INSTITUTION
The Disclosing Party certifies that the Disclosing Party (check one)
[ ] is [x] is not
a "financial institution" as defined in MCC Section 2-32-455(b).
If the Disclosing Party IS a financial institution, then the Disclosing Party pledges:
"We are not and will not become a predatory lender as defined in MCC Chapter 2-32 We further pledge that none of our affiliates is, and none of them will become, a predatory lender as defined in MCC Chapter 2-32. We understand that becoming a predatory lender or becoming an affiliate of a predatory lender may result in the loss of the privilege of doing business with the City ."
Page 7 of 15
If the Disclosing Party is unable to make this pledge because it or any of its affiliates (as defined in MCC Section 2-32-455(b)) is a predatory lender within the meaning of MCC Chapter 2-32, explain here (attach additional pages if necessary):
If the letters "NA," the word "None," or no response appears on the lines above, it will be conclusively presumed that the Disclosing Party certified to the above statements.
D. CERTIFICATION REGARDING FINANCIAL INTEREST IN CITY BUSINESS
Any words or terms defined in MCC Chapter 2-156 have the same meanings if used in this Part D.
In accordance with MCC Section 2-156-110: To the best of the Disclosing Party's knowledge after reasonable inquiry, does any official or employee of the City have a financial interest in his or her own name or in the name of any other person or entity in the Matter?
[ ] Yes [x] No
NOTE: Ifyou checked "Yes" to Item D(l), proceed to Items D(2) and D(3). Ifyou checked "No" to Item D(l), skip Items D(2) and D(3) and proceed to Part E.
Unless sold pursuant to a process of competitive bidding, or otherwise permitted, no City elected official or employee shall have a financial interest in his or her own name or in the name of any other person or entity in the purchase of any property that (i) belongs to the City, or (ii) is sold for taxes or assessments, or (iii) is sold by virtue of legal process at the suit of the City (collectively, "City Property Sale"). Compensation for property taken pursuant to the City's eminent domain power does not constitute a financial interest within the meaning of this Part D.
Does the Matter involve a City Property Sale?
[ ] Yes [ ] No
Ifyou checked "Yes" to Item D(l), provide the names and business addresses of the City officials or employees having such financial interest and identify the nature of the financial interest
Name Business Address Nature of Financial Interest
4. The Disclosing Party further certifies that no prohibited financial interest in the Matter will be acquired by any City official or employee.
Page 8 of 15
E CERTIFICATION REGARDING SLAVERY ERA BUSINESS
Please check either (1) or (2) below. If the Disclosing Party checks (2), the Disclosing Party must disclose below or in an attachment to this EDS all information required by (2). Failure to comply with these disclosure requirements may make any contract entered into with the City in connection with the Matter voidable by the City.
_^ 1. The Disclosing Party verifies that the Disclosing Party has searched any and all records of
the Disclosing Party and any and all predecessor entities regarding records of investments or profits from slavery or slaveholder insurance policies during the slavery era (including insurance policies issued to slaveholders that provided coverage for damage to or injury or death of their slaves), and the Disclosing Party has found no such records.
2. The Disclosing Party verifies that, as a result of conducting the search in step (1) above, the
Disclosing Party has found records of investments or profits from slavery or slaveholder insurance policies. The Disclosing Party verifies that the following constitutes full disclosure of all such records, including the names of any and all slaves or slaveholders described in those records:
SECTION VI -- CERTIFICATIONS FOR FEDERALLY FUNDED MATTERS
NOTE If the Matter is federally funded, complete this Section VI If the Matter is not federally funded, proceed to Section VII. For purposes of this Section VI, tax credits allocated by the City and proceeds of debt obligations of the City are not federal funding.
A. CERTIFICATION REGARDING LOBBYING
1. List below the names of all persons or entities registered under the federal Lobbying Disclosure Act of 1995, as amended, who have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter: (Add sheets if necessary): None
(If no explanation appears or begins on the lines above, or if the letters "NA" or if the word "None" appear, it will be conclusively presumed that the Disclosing Party means that NO persons or entities registered under the Lobbying Disclosure Act of 1995, as amended, have made lobbying contacts on behalf of the Disclosing Party with respect to the Matter.)
2. The Disclosing Party has not spent and will not expend any federally appropriated funds to pay any person or entity listed in paragraph A(l) above for his or her lobbying activities or to pay any person or entity to influence or attempt to influence an officer or employee of any agency, as defined by applicable federal law, a member of Congress, an officer or employee of Congress, or an employee Ver 2018-1 Page9oflS
of a member of Congress, in connection with the award of any federally funded contract, making any federally funded grant or loan, entering into any cooperative agreement, or to extend, continue, renew, amend, or modify any federally funded contract, grant, loan, or cooperative agreement.
The Disclosing Party will submit an updated certification at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the statements and information set forth in paragraphs A(l) and A(2) above.
The Disclosing Party certifies that either: (i) it is not an organization described in section 501(c)(4) of the Internal Revenue Code of 1986; or (ii) it is an organization described in section 501(c)(4) of the Internal Revenue Code of 1986 but has not engaged and will not engage in "Lobbying Activities," as that term is defined in the Lobbying Disclosure Act of 1995, as amended.
If the Disclosing Party is the Applicant, the Disclosing Party must obtain certifications equal in form and substance to paragraphs A(l) through A(4) above from all subcontractors before it awards any subcontract and the Disclosing Party must maintain all such subcontractors' certifications for the duration ofthe Matter and must make such certifications promptly available to the City upon request.
B. CERTIFICATION REGARDING EQUAL EMPLOYMENT OPPORTUNITY
If the Matter is federally funded, federal regulations require the Applicant and all proposed subcontractors to submit the following information with their bids or in writing at the outset of negotiations.
Is the Disclosing Parry the Applicant? [x]Yes [JNo
If "Yes," answer the three questions below:
Have you developed and do you have on file affirmative action programs pursuant to applicable federal regulations? (See 41 CFR Part 60-2.)
[XJ Yes [ ] No
Have you filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance Programs, or the Equal Employment Opportunity Commission all reports due under the applicable filing requirements?
[ J Yes [ ] No p] Reports not required
Have you participated in any previous contracts or subcontracts subject to the equal opportunity clause?
[ ] Yes [XJ No
If you checked "No" to question (1) or (2) above, please provide an explanation:
Page 10 of 15
SECTION VII -- FURTHER ACKNOWLEDGMENTS AND CERTIFICATION
The Disclosing Party understands and agrees that:
A. The certifications, disclosures, and acknowledgments contained in this EDS will become part of any contract or other agreement between the Applicant and the City in connection with the Matter, whether procurement, City assistance, or other City action, and are material inducements to the City's execution of any contract or taking other action with respect to the Matter The Disclosing Party understands that it must comply with all statutes, ordinances, and regulations on which this EDS is based
B The City's Governmental Ethics Ordinance, MCC Chapter 2-156, imposes certain duties and obligations on persons or entities seeking City contracts, work, business, or transactions. The full text ofthis ordinance and a training program is available on line at www.citvofchicago.org/Ethics , and may also be obtained from the City's Board of Ethics, 740 N. Sedgwick St., Suite 500, Chicago, IL 60610, (312) 744-9660. The Disclosing Party must comply fully with this ordinance.
If the City determines that any information provided in this EDS is false, incomplete or inaccurate, any contract or other agreement in connection with which it is submitted may be rescinded or be void or voidable, and the City may pursue any remedies under the contract or agreement (if not rescinded or void), at law, or in equity, including terminating the Disclosing Party's participation in the Matter and/or declining to allow the Disclosing Party to participate in other City transactions. Remedies at law for a false statement of material fact may include incarceration and an award to the City of treble damages.
It is the City's policy to make this document available to the public on its Internet site and/or upon request. Some or all of the information provided in, and appended to, this EDS may be made publicly available on the Internet, in response to a Freedom of Information Act request, or otherwise. By completing and signing this EDS, the Disclosing Party waives and releases any possible rights or claims which it may have against the City in connection with the public release of information contained in this EDS and also authorizes the City to verify the accuracy of any information submitted in this EDS.
The information provided in this EDS must be kept current. In the event of changes, the Disclosing Party must supplement this EDS up to the time the City takes action on the Matter. If the Matter is a contract being handled by the City's Department of Procurement Services, the Disclosing Party must update this EDS as the contract requires. NOTE: With respect to Matters subject to MCC Chapter 1-23, Article I (imposing PERMANENT INELIGIBILITY for certain specified offenses), the information provided herein regarding eligibility must be kept current for a longer period, as required by MCC Chapter 1-23 and Section 2-154-020.
Page 11 of 15
CERTIFICATION
Under penalty of perjury, the person signing below: (1) warrants that he/she is authorized to execute this EDS, and all applicable Appendices, on behalf of the Disclosing Party, and (2) warrants that all certifications and statements contained in this EDS, and all applicable Appendices, are true, accurate and complete as of the date furnished to the City.
mHUB
(Print or type exact legal name of Disclosing Party)
(Sign here)-Manas Mehandru
(Print or type name of person signing)
Chief Operating Officer, Treasurer (Print or type title of person signing)
.^Xj-. fc
Notary Public}
OFFICIAL SEAL
CHELSEA ELIZABETH BIGGS NOTARY PUBLIC. STATE OF ILLINOIS MY COMMISSION EXPIRES Mtf 1/2026
Page 12ofl5
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX A
FAMILIAL RELATIONSHIPS WTTH ELECTED CITY OFFICIALS AND DEPARTMENT HEADS
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5%. It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Under MCC Section 2-154-015, the Disclosing Party must disclose whether such Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently has a "familial relationship" with any elected city official or department head. A "familial relationship" exists if, as of the date this EDS is signed, the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof is related to the mayor, any alderman, the city clerk, the city treasurer or any city department head as spouse or domestic partner or as any of the following, whether by blood or adoption: parent, child, brother or sister, aunt or uncle, niece or nephew, grandparent, grandchild, father-in-law, mother-in-law, son-in-law, daughter-in-law, stepfather or stepmother, stepson or stepdaughter, stepbrother or stepsister or half-brother or half-sister.
"Applicable Party" means (1) all executive officers of the Disclosing Party listed in Section II.B. 1 .a., if the Disclosing Party is a corporation, all partners of the Disclosing Party, if the Disclosing Party is a general partnership; all general partners and limited partners of the Disclosing Party, if the Disclosing Party is a limited partnership; all managers, managing members and members of the Disclosing Party, if the Disclosing Party is a limited liability company; (2) all principal officers of the Disclosing Party; and (3) any person having more than a 7.5% ownership interest in the Disclosing Party. "Principal officers" means the president, chief operating officer, executive director, chief financial officer, treasurer or secretary of a legal entity or any person exercising similar authority.
Does the Disclosing Party or any "Applicable Party" or any Spouse or Domestic Partner thereof currently have a "familial relationship" with an elected city official or department head?
[ ] Yes [ *\ No
If yes, please identify below (1) the name and title of such person, (2) the name of the legal entity to which such person is connected; (3) the name and title of the elected city official or department head to whom such person has a familial relationship, and (4) the precise nature of such familial relationship.
Page 13 of 15
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX B
BUILDING CODE SCOFFLAW/PROBLEM LANDLORD CERTIFICATION
This Appendix is to be completed only by (a) the Applicant, and (b) any legal entity which has a direct ownership interest in the Applicant exceeding 7.5% (an "Owner"). It is not to be completed by any legal entity which has only an indirect ownership interest in the Applicant.
Pursuant to MCC Section 2-154-010, is the Applicant or any Owner identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
•[ ] Yes No
If the Applicant is a legal entity publicly traded on any exchange, is any officer or director of the Applicant identified as a building code scofflaw or problem landlord pursuant to MCC Section 2-92-416?
[ ] Yes [ ] No [X] The Applicant is not publicly traded on any exchange.
If yes to (1) or (2) above, please identify below the name of each person or legal entity identified as a building code scofflaw or problem landlord and the address of each building or buildings to which the pertinent code violations apply.
i
Page 14ofl5
CITY OF CHICAGO ECONOMIC DISCLOSURE STATEMENT AND AFFIDAVIT
APPENDIX C
PROHIBITION ON WAGE & SALARY HISTORY SCREENING - CERTIFICATTON
This Appendix is to be completed only by an Applicant that is completing this EDS as a "contractor" as defined in MCC Section 2-92-385. That section, which should be consulted (www.amleaal com), generally covers a party to any agreement pursuant to which they: (i) receive City of Chicago funds in consideration for services, work or goods provided (including for legal or other professional services), or (u) pay the City money for a license, grant or concession allowing them to conduct a business on City premises.
On behalf of an Applicant that is a contractor pursuant to MCC Section 2-92-385,1 hereby certify that the Applicant is in compliance with MCC Section 2-92-385(b)(1) and (2), which prohibit: (i) screening job applicants based on their wage or salary history, or (ii) seeking job applicants' wage or salary-history from current or former employers. T also certify that the Applicant has adopted a policy that includes those prohibitions.
[ 1 Yes [ JNo
[X] N/A - 1 am not an Applicant that is a "contractor" as defined in MCC Section 2-92-385.
This certification shall serve as the affidavit required by MCC Section 2-92-385(c)( l).
If you checked "no" to the above, please explain.
Page 15 of 15